How to write the demonstration contract of epoxy floor paint construction?

How to write a contract, let's take a look:

The main contents of the contract include: 1, and the names and residences of the employer and the contractor should be clearly written; 2. Write clearly the contents of the contracted project; 3. Write down the time limit and specific requirements for performing the contract; 4. Write down the price amount and payment method; 5, write clearly the liability for breach of contract, etc.

Epoxy floor paint 1 construction contract template

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), Regulations on Construction and Installation Engineering Contracts, and in combination with the relevant provisions of this contract, in order to clarify the rights and economic responsibilities of both parties in the construction process, both parties agree to sign this contract through consultation and fully perform it.

Article 1 General situation of the project

1, project name: _ _ basement epoxy floor construction project.

2. Project location: _ _ _ _

3. Painting color: subject to the on-site samples.

4. Project area: 3350_

5. Building type: epoxy flat-coated floor

6. Construction technology: ① base surface grinding and dust removal; (2) ground contact agent; ③ Scraping the bottom of epoxy resin mixed quartz sand; ④ Polishing and dust removal; (5) epoxy resin mixed putty powder batch coating; ⑥ epoxy resin mixed putty powder batch coating; ⑦ batch scraping; Roll up the last coat today.

7. Contracting method: Party B undertakes the general contract of this project by contracting the project, materials, construction period, quality, safe and civilized construction and taxes.

8. Contract unit price: epoxy floor 40 yuan/_, epoxy logo 8 yuan /m, epoxy arrow 30 yuan/piece.

9. Total cost: The total contract price is tentatively set at 150600.00 (in words: one hundred and fifty thousand six hundred yuan only).

Details are as follows:

Flat coating of epoxy floor: 3350_40 yuan /_= 134000 yuan (this part of the total price is lump sum price, which will not be adjusted during settlement). The parking space line and roadway line are tentatively set at 20_ m _8 yuan /m= 16000 yuan (this part is settled according to the facts). There are 20 epoxy arrows tentatively _30 yuan =600 yuan (this part is settled in real terms).

Article 2 Project duration

This project must be completed on February 3, 20001day.

Article 3 Responsibilities of both parties

I. Responsibility of Party A

1. When signing the contract, Party A shall provide Party B with the construction drawings or the designated paint general plan;

2. Before construction, ensure the power supply of the construction site;

3. Before starting work, ensure that the painting area is dry and free of water or dust impurities;

4. No cross construction will be arranged during the construction;

5, the construction site need related engineering personnel to coordinate and arrange;

6. Party A shall provide storage areas for Party B's materials, equipment and tools, and do a good job in the closed management of the site. Irrelevant personnel are prohibited from entering and leaving, which affects the construction quality. If the above requirements are not met, Party A shall be responsible for the consequences.

Two. Party B's responsibilities:

1. The project shall not be subcontracted to a third party;

2. Carry out construction according to the construction technology agreed in the contract to ensure that the construction materials are qualified;

3. Ensure the quality of painting project: the painted surface has uniform color, no cracks, no delamination and no background color;

4, must be civilized and safe construction, strictly abide by the rules and regulations of Party A, and accept the supervision and correct guidance of Party A's project supervision;

5. All economic losses caused to Party A due to Party B's mismanagement (such as theft and damage) shall be borne by Party B..

6, do a good job in the maintenance of unfinished projects and the corresponding finished product protection;

7. Party B shall provide Party A with samples of materials, which shall be approved by Party A, so as to ensure that the materials and processes of Party B are consistent with the samples provided during construction.

8. Do a good job of warranty.

Article 4 Settlement and payment of project funds

1, after the completion of the sixth working procedure, Party A shall pay 70% of the total project cost to Party B;

2. Within one week after the project completion acceptance, Party A shall complete the audit within five working days and pay 97% of the settlement amount, and the remaining 3% shall be paid within one week after the expiration of the one-year warranty period (excluding interest).

4. It is forbidden to withdraw cash for this project, and Party B must provide the construction safety tax invoice with the corresponding approved amount.

Article 5 Liability for breach of contract

1. The warranty period of this project is 12 months (calculated from the date of completion acceptance). During the warranty period, if there is a quality accident due to Party B's materials or construction technology, Party B shall unconditionally guarantee it within the agreed time after receiving the notice from Party A; If any quality accident is caused by improper use of Party A or other reasons, Party B shall repair it at its own expense. ..

2. Party B must complete the project on June 65438+February 365438 +0, 20_ _. Except for the extension of the construction period agreed by Party A in writing, if Party B fails to start or complete the construction period (sub-construction period) as scheduled or fails to perform any obligations in time, it shall bear a penalty of RMB 1000 per day for each overdue day. If any item is overdue for 5 days, Party A has the right to terminate the contract, and Party B shall pay 20% of the total contract amount to Party A as liquidated damages, and all losses caused to Party A therefrom (including but not limited to liquidated damages and compensation payable by Party A to the third party) shall be borne by Party B. ..

Article 6 Completion acceptance and acceptance criteria

1. After the completion of the project, Party A shall take the contract and relevant national construction specifications as the acceptance criteria. After the acceptance, both parties shall fill in the Completion Acceptance Form of Epoxy Floor Project and sign it into effect.

2. The main basis for acceptance: acceptance shall be carried out according to the construction process of this contract.

Article 7 Ways to settle contract disputes:

In case of any dispute between Party A and Party B during the performance of this Contract, both parties can settle it through negotiation or coordination; If negotiation or coordination fails, it may apply to the arbitration organ where Party B is located or bring a lawsuit to the people's court.

Article 8 This contract is made in quadruplicate, two for each party, and shall come into effect as of the date of signature and seal by both parties.

Article 9 Matters not covered in this contract shall be settled by both parties through negotiation in good faith.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model construction contract of epoxy floor paint II

Party A:

Party B:

In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws, following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on matters related to this floor project and signed this contract.

Article 1 General situation of the project

1. 1 project name:

1.2 Project location:

1.3 project area: about m (the settlement is subject to the measured data).

Article 2 Term of Contract

2. 1 Party B's entry date is 20 _ _-20 _ _ _

2.2 In any of the following circumstances, the contract term will be automatically extended:

2.2. 1 Party A fails to hand over the site of the area to be built to Party B one day before entering the site as stipulated in the contract, or personnel and articles not serving the project enter or are stored in the area to be built;

2.2.2 The power supply and water supply facilities provided by Party A are not connected, which affects the normal work of Party B;

2.2.3 Due to the change of the project itself or the whole project, the changed content directly affects the process specification, content and workload of the project;

2.2.4 The contract is affected by weather (such as temperature, which cannot meet the engineering requirements) or force majeure (such as typhoon, rainstorm, flood, fire, earthquake, war, riot, etc.). );

2.2.5 Other emergencies (such as power failure, water seepage or leakage in the working face, lax closure of the construction site, etc.). ) affect the work progress;

2.2.6 Party A fails to make payment as stipulated in the contract;

2.2.7 Other circumstances that affect the execution of contract terms occur.

Article 3 Contract Price

Remarks: This price does not include any tax invoices, and 6% tax will be added if invoices are required.

4.2 When the project is completed, it shall be settled according to the actual construction area and quantity. 4.3 If new projects are added or processes are changed during the construction with the consent of both parties, the contract unit price and construction period will be adjusted accordingly.

Article 4 Cooperation between the two parties

4. 1 Party A, as the site representative of this project, and Party B, as the site representative of this project, coordinate and solve various problems on behalf of both parties.

4.2 Party A shall make the site have working conditions, and the working area must be cleaned up one day before Party B enters the site to ensure that the project can be carried out as scheduled.

4.3 Party A shall provide standard concrete base, the quality of which shall meet the national standards or Party B's requirements (see Party B's technical scheme and materials for details). If the concrete has been cured by abrasion resistance, Party A shall notify it in writing. If the foundation is cured by water, it may react with the hardener. Otherwise, Party B will not be responsible for all problems arising therefrom. If there are serious quality problems in the newly-built or existing concrete foundation provided by Party A, which can affect the construction quality of Party B, both parties shall sign a memorandum on foundation treatment after site reconnaissance, and make settlement according to the measured area immediately after completion.

4.4 Party A shall provide ready-made 220V or 380V electrical contacts and lighting equipment free of charge, and the supply must meet the needs of normal engineering.

4.5 Party A shall coordinate with the site to ensure that there is no intersection with other projects, and the main passages are unblocked, so as to meet the needs of the operation and transportation of this project, and restrict other non-service personnel from entering the site to trample on the floor or affect the operation.

4.6 Party A shall be responsible for handling the construction permit and other documents, approvals or temporary application approval procedures required for operation.

4.7 Party A shall ensure that during the operation and maintenance period, there is no water leakage and water seepage on the site, and the doors and windows are complete to block the outdoor wind and rain, and Party B shall designate a special person to supervise.

4.8 During the initial maintenance period after Party B completes the operation, Party A has the obligation to assist Party B to protect the site and prohibit other personnel from entering the operation area; Only after the curing period is over can heavy objects be moved in. If you need to move in advance, you should wear soft slippers with soft soles, and do a good job in paving and protecting the floor on the premise that it will not damage the floor.

4.9 If the ground is seriously damaged during use, Party A shall bear the maintenance expenses. ..

4. 10 The original construction joints and expansion joints are not treated.

4. 1 1 Party B shall organize management operations, keep the site clean and tidy, and clean up the site after the project is completed.

4. 12 If it is necessary to adjust the process or contract period due to the change of field operation conditions or other reasons, Party B shall notify Party A in writing.

4. 13 Party B shall complete the project and submit it for acceptance according to the acceptance criteria and time limit agreed by both parties.

4. 14 After the completion of the project, Party B shall unconditionally guarantee the quality problems caused by Party B within the specified warranty period after receiving the notice.

4. 15 Party B has the obligation to provide Party A with the floor maintenance and precautions.

4. 16 If both parties fail to fulfill the above obligations and cause losses to the other party, the responsible party shall compensate the other party for related losses and lost time.

Article 5 Project acceptance

5. 1 Within three working days after the completion of the project, Party A shall organize relevant personnel to accept and confirm the actual workload; In case of special circumstances, if Party A needs to postpone the acceptance, it shall notify Party B in writing, and the delay shall not exceed fifteen days after Party B agrees. Party A shall do a good job in site protection during this period.

5.3 As a single professional project, this project only carries out single acceptance, which has nothing to do with other projects of Party A, and does not bind the whole project or other projects for acceptance and settlement.

5.4 In any of the following circumstances, it shall be deemed that the acceptance of this project has been actually completed and confirmed as qualified by Party A:

5.4. 1 Party A operates other processes on the basis of Party B's operation of the material layer;

5.4.2 Party A fails to make acceptance within the specified time;

5.4.3 Party B's work area has been put into use.

Article 6 Quality Assurance

6. 1 The warranty period provided by Party B is twelve months from the date of project completion.

6.2 Warranty scope: the unqualified products caused by the quality problems of the epoxy floor paint itself.

6.3 During the warranty period, Party B shall provide free maintenance for those who meet the warranty scope; If it does not meet the warranty scope, Party B will charge the maintenance fee.

6.4 After the warranty period, Party B shall provide high-quality follow-up services and charge maintenance fees.

6.5 The quality problems caused by the following circumstances are not covered by the warranty, and Party A cannot affect the payment to Party B:

6.5. 1 When the previous working procedure does not fully meet the requirements, Party A requires Party B to work on site or cross-construct, which will affect the quality;

6.5.2 Party A requires Party B to rush the work during the construction process or there are other cross-constructions at the site, which will affect the project quality;

6.5.3 After completion, the ground is artificially damaged and Party A is overloaded;

Article 7 Payment Terms

7. 1 After the contract comes into effect, Party A shall pay-%of the total contract price for material preparation.

7.2 Party A shall pay 60% of the total contract price within the same day after Party B's materials and personnel enter the site.

7.3 When the construction progress is over half, Party A shall pay 20% of the total contract price.

7.4 After the construction is completed, the balance shall be settled according to the total price of the actual settlement area.

7.5 Party A will pay Party B cash.

Article 8 Breach of Contract and Disputes

8. 1 If either party unilaterally or partially terminates the contract, it shall bear the liability for breach of contract and pay 30% of the liquidated damages to the other party.

8.2 If Party B delays the delivery period of the project without reason, Party B shall pay Party A a penalty of 3‰ of the contract amount for each day of delay. 8.3 If Party A fails to pay the contract amount according to the schedule stipulated in the contract, Party B has the right to stop the construction, and the losses caused thereby shall be borne by Party A (calculated by the number of people stationed at the site, the standard is 300 yuan per person per day). For each day of delay, Party A shall pay 3‰ of the payable amount to Party B as liquidated damages, and the contract term shall be postponed accordingly.

8.4 If Party A fails to pay, accept or pay on time within the time limit stipulated in the contract, it shall pay liquidated damages and late fees to Party B. ..

8.5 Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, both parties may apply to the Arbitration Commission for arbitration or bring a lawsuit to the people's court.

Article 9 Effectiveness and Termination of the Contract

9. 1 This contract shall come into effect as of the date of signature and seal by both parties.

9.2 The Contract shall be terminated after the acceptance and settlement by both parties (except the warranty clauses).

Article 10 Supplementary Provisions

10. 1 Matters not covered herein shall be implemented in accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, or shall be settled by both parties through consultation.

10.2 This contract is made in duplicate, with each party holding one copy, which has the same legal effect.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model essay 3 on construction contract of epoxy floor paint

Party A: Tel:

Party B: Tel:

According to the principles and relevant provisions of the Contract Law of People's Republic of China (PRC), Party A entrusts Party B to be responsible for the supply and construction of epoxy floor through friendly negotiation, and reaches the following agreement:

Article 1: Construction area and contract price: area:, the unit price is RMB/m2 (the final settlement area is calculated according to the actual area), and the total price is:

Article 2: Material: epoxy mortar floor.

Article 3: Engineering Quality Standards

Through research by both parties, the quality of this project is achieved: the materials laid by Party B are non-delaminating, sand-free, uniform in color and basically flat, but the quality problems such as ground cracks caused by concrete platform have nothing to do with Party B. It is suggested that the concrete grade should not be lower than C25, and the ground should be smooth and shiny. In case of outdoor construction, Party A shall take protective measures. If the construction is carried out indoors and the protective measures are not perfect, that is, it may be attacked by rain in rainy days, and the construction must be stopped.

Article 4: Construction and Acceptance

Party A must inform Party B of the commencement date.

Start date days.

Party A shall accept the ground laid by Party B within 3 days after the completion of the project construction. If the project fails to be accepted within 3 days, or the ground laid by Party B (including the ground used by a third party) is put into use without acceptance, it is deemed that the material laying has passed the acceptance. Party A shall make payment according to the provisions of this contract.

Article 5: Method of Payment

After signing this contract, Party A shall pay RMB to Party B..

Article 6: Final principle

1. This contract is made in duplicate, one for Party A and one for Party B, all of which have legal effect. If one party breaches the contract, it shall compensate the other party for all the losses. Any dispute arising from the interpretation or performance of this contract shall be settled through negotiation first. If negotiation fails, you can bring a lawsuit to the local court.

2. This contract shall take effect from the date of signature or seal until all the money is paid.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model essay 4 on construction contract of epoxy floor paint

Party A:

Party B:

In accordance with the Contract Law of People's Republic of China (PRC) and relevant regulations, in order to clarify the rights, obligations and responsibilities of Party A and Party B in the construction process, this contract is hereby signed by both parties through consultation for mutual compliance.

Article 1: Project Overview

1. 1. Project location:

1.2. Construction technology: epoxy floor (see the process description provided by Party B for details).

1.3. Color: color

1.4. Project area: _.

1.5 project unit price:/_.

The total project cost of 1.6 is about RMB. Capitalized:

Note: The final settlement amount shall be based on the actual construction area, and the crural line (RMB per meter) and the stay line (RMB per meter) shall be calculated according to the length.

Article 2: Construction Period

2. 1. The total construction period of this project is days.

2.2. The commencement date of this project is 20__ to 20__ _ _.

2.3. In case of the following circumstances, the construction period shall be postponed accordingly.

A. If the ground is wet due to weather or other factors, Party A confirms that it agrees to postpone.

B due to party a's reasons, the construction site cannot be cleaned as scheduled.

C. Due to continuous water and power cuts for more than 8 hours, normal construction cannot be carried out.

D. Failure to pay the advance payment as stipulated in the contract will affect the progress of the project.

Article 3: Responsibilities of both parties

1. Party A's responsibilities

A. Party A shall provide Party B with water, electricity and accommodation for construction personnel free of charge.

B. Before construction, the ground should be laid to ensure that the construction ground is dry, flat and free of oil pollution.

C. During the construction of Party B, Party A shall not arrange other projects to cross-construct (except those that do not affect Party B's construction).

D. If the actual ground construction color is slightly different from the color sample, the actual color shall prevail. However, if the color deviation seriously affects the overall effect of the project, Party B shall undertake the repair responsibility at the request of Party A. ..

2. Party B's responsibilities

A. Party B shall carry out the construction according to the process requirements agreed by both parties.

B. After the construction is completed, the coating surface shall be smooth, without delamination and with outstanding background color.

C. During the warranty period, if there is any problem with the project quality, Party B shall guarantee to give a written reply within 24 hours and complete the repair within 3 working days, so as to meet Party A's technical standards and reasonable requirements. ..

Article 4: Payment and settlement of project funds

1. After the contract is signed, Party A shall pay Party B% of the total project price, namely RMB. After the construction personnel and materials enter the site, Party A shall pay Party B% of the total project cost, totaling RMB. Party A will pay Party B% of the total project cost, that is, the RMB contract, before the primer painting is completed and the topcoat painting is completed.

2. After the project is completed, Party A will pay Party B% of the total project cost, namely RMB.

3. The settlement method can be cash, wire transfer or transfer check.

Article 5: Liability for breach of contract

5. 1. The warranty period of the project is one year. During the warranty period, Party B shall be responsible for free maintenance of quality problems caused by Party B, but Party A shall be responsible for quality problems caused by man-made and mechanical reasons. If maintenance is required after the warranty period expires, Party B shall charge a reasonable fee.

5.2. If Party A fails to pay the advance payment as stipulated in the contract, Party B will charge a late fee of% of the payable amount every day. If the overdue period exceeds 10 day, Party B has the right to terminate the contract, and Party A shall bear the penalty of% of the total project amount, namely RMB.

5.3 If Party B fails to complete the project on time according to the contract period, Party A will charge a late fee of% of the paid amount every day. If the overdue period exceeds ten days, Party A has the right to terminate the contract, and Party B shall bear the penalty of% of the total project amount, namely RMB.

5.4 Within three days after the completion of Party B's construction, Party A shall make timely acceptance. If it is deemed unqualified by Party A (referring to obvious color difference, delamination, exposed bottom and delamination), Party B shall repair or redo it within the grace period given by Party A at that time, and bear its own expenses.

Article 6: This contract shall have legal effect from the date of signing and shall become invalid after the warranty period expires.

Article 7: Matters not covered in this contract shall be settled by both parties through consultation. If negotiation fails, a lawsuit can be brought to the court where Party A is located.

Article 8: This contract is made in duplicate, each party holds one copy, which has the same legal effect.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model Article 5 of the Construction Contract for Epoxy Floor Paint

Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

Through friendly negotiation, Party A and Party B reached the following agreement on the floor paint construction in the workshop:

I. Contents of Project Construction

1, the workshop floor is painted with green and medium gray epoxy floor paint; Project area: _, unit price of construction contract materials: RMB/_.

Two. Party B's construction technology, steps and technical requirements

(1), construction technology

Pretreatment of cement floor surface-coating epoxy primer-scraping epoxy mortar putty-after 8 hours of self-drying, polishing, repairing and partially scraping the second layer of epoxy mortar putty-after 8 hours of self-drying, polishing, repairing and filling-cleaning, vacuumizing and coating the first oxygen topcoat-after 8 hours of self-drying, coating the second oxygen topcoat.

(2) Construction steps and technical requirements:

1, ground pretreatment before construction. For uneven ground, cement or epoxy mortar should be used for repair and leveling to ensure that the construction ground is flat, clean, dry and free from stains.

2. Epoxy penetration primer construction: mix the epoxy primers in proportion, stir them with a blender for 5 minutes, and then evenly brush them with a roller as required. The thickness of the coating is 15 μm, so as to achieve the best adhesion to the ground and play a role in sealing micropores.

3. Construction of epoxy mortar layer: After the primer is dried for about 2 hours, mix the epoxy mortar evenly according to the construction ratio, stir it with a blender for 5 minutes, scrape the material with a human knife to smooth the surface, and finish the construction of the intermediate coating in two times according to this construction requirement, and polish it flat, and the coating thickness reaches120m, thus completing the base construction.

4. Epoxy floor topcoat construction: After the intermediate coat is dried for 8 hours, mix the epoxy topcoat evenly according to the construction proportion, stir it with a blender for 5 minutes, and brush it with a roller (twice). Impurities found in the coating process should be removed immediately. The hardening time of the topcoat is about 24 hours, and the total thickness of the coating reaches 250 microns, that is, the topcoat coating construction is completed.

5. Maintenance period of the project: After the ground construction is completed, it will take 7 days to be put into use (people can walk here in 3 days).

Three. Party B's Service and Quality Commitment

Party B's commitment to product and construction quality shall meet the contract requirements.

1. Before construction: communicate with Party A's on-site technicians, introduce the product performance and supporting construction scheme in detail, and provide reference for customers to choose the best product and process construction, so as to achieve the best ideal effect of epoxy paint coating process and complete the construction within the scheduled time according to Party A's requirements.

2. After the project is completed and delivered for use, according to the service life of the selected products, if peeling or shedding is found, Party B shall make economic compensation to Party A according to the contract or relevant national quality regulations.

3. The color shall be prepared according to the sample color standard provided by Party A. After the project is delivered for use, Party B shall be responsible for timely repair in case of delamination and falling off during use within ten years.

Our company organizes production in strict accordance with national standards and enterprise standards. Each batch of products has qualified inspection reports and samples. Carry out the construction according to the painting process and safety requirements, and complete the construction within two weeks under normal rain or shine.

Fourth, safety and anti-corrosion measures

On the premise of safety first and quality first, our company has taken the following safety measures:

1, before the start of construction, safety technical personnel to the construction site for safety supervision and safety technical guidance.

2, the construction site staff must wear work clothes, masks and safety gloves.

3. Before each mount guard operation, the safety administrator shall supervise the safety protection of the construction personnel, and put forward and require the safety matters that should be paid attention to in the construction.

4. Party A is responsible for providing Party B with construction water and electricity, and Party B shall pay attention to the safety of electricity and water use.

5. Party B shall take full responsibility for all safety responsibilities arising in the construction process.

Verb (abbreviation of verb) Time limit for a project: All construction projects including floor cleaning shall be completed within 25 days from the date of signing the contract (the time limit for the project shall be postponed due to Party A's reasons).

Six, project cost, unit price and area:

1, total construction area: _

2. Unit price of contract and materials (project invoice has been issued): RMB/m2.

3. Total project cost: RMB.

Seven. Payment terms:

After the project is completed, Party A shall pay the total project price to Party B within 3 days, which will be deducted as the project quality deposit. After one year, the project has no engineering quality problems, and the deducted balance will be paid in one lump sum.

This contract is made in duplicate, one for each party, with the same legal effect.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model essay 6 on construction contract of epoxy floor paint

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), Regulations on Construction and Installation Engineering Contracts, and in combination with the relevant provisions of this contract, in order to clarify the rights and economic responsibilities of both parties in the construction process, both parties agree to sign this contract through consultation and fully perform it.

Article 1 General situation of the project

I. Project name:

Second, the project site selection:

Third, the coating color:

IV. Project Area:

Verb (abbreviation of verb) Building type: epoxy flat floor

Intransitive verb contracting method: acceptance of materials and packaging.

Seven. Contract unit price: RMB/m2

Eight. Total cost (tentative): (Note: The actual cost of this project is settled according to the actual construction area. )

Article 2 Project duration

The total duration of this project contract is days, and the actual commencement date shall be notified to Party B three days in advance by Party A;

Article 3 Responsibilities of both parties

I. Responsibility of Party A

1. When signing the contract, Party A shall provide Party B with the construction drawings or the designated paint general plan; Ensure that the power supply is connected to the construction site before construction, and bear the water and electricity costs; Before starting work, ensure that the painting area is dry and free of water or dust impurities; No cross construction will be arranged during the construction period; The construction site shall be coordinated and arranged by relevant engineering personnel; Party A shall provide the storage area for Party B's materials, equipment and tools, and do a good job in the closed management of the site, and prohibit irrelevant personnel from entering and leaving, which will affect the construction quality. If the above requirements are not met, Party A shall be responsible for the consequences.

2. Assist the completed but not yet accepted projects. It shall not be used before acceptance, otherwise it shall be deemed as qualified. Pay the project payment to Party B according to the agreed payment terms;

3 within three working days after the completion of the project, organize the relevant units to accept, and those who fail to accept within the time limit shall be regarded as qualified.

Two. Party B's responsibilities:

1, according to the design drawings, and ensure that the construction materials are qualified; Ensure the quality of painting project: the painted surface has uniform color, no cracks, no delamination and no background color; Must be civilized and safe construction, strictly abide by Party A's rules and regulations, accept the supervision and correct guidance of Party A's project supervisor;

2. All economic losses caused to Party A due to Party B's mismanagement (such as theft and damage) shall be borne by Party B.. Do a good job in the maintenance of unaccepted completed projects and the protection of corresponding finished products; Do a good job of warranty.

Article 4 the project payment settlement and