Contract management test center: the work of all parties in the construction preparation stage.

Supervision engineer construction project contract management test center: the work of all parties in the construction preparation stage

1. Employer's obligations

(1) Provide the construction site

① Construction site

The Employer shall complete the requisition, resettlement and demolition of the construction site in time, and provide the construction site to the Contractor according to the sunny and peaceful scope agreed in the special contract terms. The construction site includes permanent engineering land and temporary construction land. The handover of the construction site can be completed at one time or in several times, with the principle of not affecting the commencement of the unit project.

② Information about underground pipelines and underground facilities.

The Employer shall provide the Contractor with relevant information such as underground pipelines and underground facilities within the scope of the construction site in a timely manner according to the special terms and conditions. Underground pipelines include water supply, drainage, power supply, gas supply, heat supply, communication, radio and television and underground hydrogeological data. The Employer shall guarantee the truthfulness, accuracy and completeness of the information, but shall not be responsible for the consequences of the judgment and inference errors made by the Contractor accordingly.

③ Right of way outside the site

The Employer shall, according to the construction needs of the contract project, be responsible for obtaining the right of passage of special and temporary roads to and from the construction site, and the right to build off-site facilities for the project construction, and bear the relevant expenses.

(2) Assist the contractor to obtain the construction permit

(3) Organize design disclosure

The Employer shall, according to the contract schedule, organize the design unit to disclose the construction drawings and design documents provided to the contractor and supervisor, so that the contractor can formulate the construction plan and prepare the construction organization design.

(4) Commencement time

Considering the differences of different industries and projects, standard construction contract projects can be agreed in the contract agreement or special terms according to the actual situation.

2. Contractor's obligations

(1) field survey

After signing the contract agreement, the contractor shall investigate the construction site and surrounding environment, check the relevant information provided by the employer, and further collect local information related to the completion of the contract work, such as geology, hydrology, meteorological conditions, traffic conditions, customs and habits, so as to prepare the construction organization design and special construction plan.

When the actual situation found in the site reconnaissance is significantly different from the information provided by the Employer, the supervisor shall be informed in time, and the supervisor shall make corresponding instructions or explanations to clarify the contract responsibilities.

(2) Prepare the construction implementation plan

In the construction organization design, special construction schemes should be prepared for the construction of deep foundation pit engineering, underground excavation engineering, tall formwork engineering, aerial work engineering, deep water engineering and large-scale blasting engineering. For the special construction of the first three dangerous sub-projects, the safety and reliability of the scheme need to be demonstrated by more than 5 experts.

(3) Traffic roads and temporary works on the construction site

(4) Construction control network

(5) Apply for commencement.

The contractor shall submit the project commencement report to the supervisor after the preparatory work before construction meets the commencement conditions. The commencement application form shall specify the implementation of construction organization measures such as construction roads, temporary facilities, materials and equipment, and construction personnel, as well as the project schedule required for normal construction according to the contract schedule.

3. Responsibilities of the supervisor

(1) Review the contractor's implementation plan

(1) Contents of review

The supervisor carefully examines the construction organization design, quality management system and environmental protection measures submitted by the contractor, and approves or requires the contractor to modify the parts that do not meet the contract requirements.

② Review the progress plan.

The supervisor's review of the progress plan in the contractor's construction organization design should not only see whether the time schedule in the construction stage meets the contract requirements, but also evaluate whether the proposed construction organization and technical measures can ensure the realization of the plan. After review, the supervisor shall give a reply or propose amendments within the time limit agreed in the special terms and conditions, otherwise, the schedule will be deemed to have been approved. The construction progress plan approved by the supervisor is called? Contract schedule? .

In order to facilitate the project schedule management, the supervisor may require the contractor to prepare and submit a phased and itemized schedule on the basis of the contract schedule, especially the detailed construction plan of the unit project or divisional project on the key line of the contract schedule.

③ Contract progress plan

The contract progress plan is the basis for controlling the progress of the contract project, which is binding on the contractor, the employer and the supervisor, and not only requires the contractor to construct as planned; Employer's material supply, drawing distribution, etc. Shall not cause construction delay; Supervision should coordinate management according to the plan. Another important function of the contract schedule is the main basis for judging whether to extend the contract period to the contractor after the construction progress is disturbed by reasons other than the contractor's responsibility.

(2) Notice of business commencement

(a) the conditions for issuing the notice of commencement

When the employer's pre-commencement work has been completed and the agreed commencement date is approaching, the supervisor shall be entrusted to issue a commencement notice to the contractor according to the special terms and conditions. If the agreed commencement date has passed, but the employer's obligation to cooperate with the commencement has not been completed (such as on-site handover delay), due to the supervisor's failure to issue the commencement notice on time, the contract period will be extended and the contractor will be compensated for the corresponding losses.

If the cooperation work of the Employer before commencement has been completed and the agreed commencement date has passed, but the contractor's preparation for commencement does not meet the commencement conditions, the supervisor shall still issue commencement instructions on time, and the contract period will not be postponed.

② Notice of commencement

After obtaining the consent of the employer, the supervisor shall issue a commencement notice to the contractor 7 days before the commencement date, and the contract period shall be calculated from the commencement date specified in the commencement notice.