5 copies of written contract model for maintenance project

Model written contract for maintenance works 1

Party A (hereinafter referred to as Party A): _ _ _ _ _ _

Party B (hereinaft

5 copies of written contract model for maintenance project

Model written contract for maintenance works 1

Party A (hereinafter referred to as Party A): _ _ _ _ _ _

Party B (hereinafter referred to as Party B): _ _ _ _ _ _ _

Because Party A needs to carry out routine sporadic maintenance work. Party B is required to do sporadic maintenance work. The maintenance work is contracted by Party B and all materials are provided by Party B. The following agreement is reached through consultation between both parties:

I. Project Content: Project Requirements:

1. The normal school order shall not be affected during office hours. At the same time, safety precautions should be taken, and other facilities should not be affected during construction. In case of damage, Party B shall be responsible for compensation and repair;

2. In the work, the construction must be carried out in accordance with relevant specifications, and the laws and regulations of Party A must be observed;

3. Party B must strictly take corresponding technical measures in the construction process;

4. Party B must be serious and responsible in the construction process, and cannot endanger the original facilities. In case of any damage, all responsibilities shall be borne by Party B, and Party A reserves the right to further investigate the legal responsibilities of Party B;

5. When working high above the ground, Party B shall independently do safety precautions and personal safety work. All safety responsibilities shall be borne by Party B, and Party A is not responsible.

Second, the project cost:

The actual settlement fee is (in figures: _ _ _ _ _ _) (see the acceptance certificate for specific fees).

Three. Payment terms:

Payment shall be made within one month after project acceptance.

Four, shelf life:

One year from the date of completion acceptance. (This maintenance project was completely completed on February 20th, 2007/KLOC-0, and passed the acceptance. )

5. Party B shall, according to the relevant national and local codes and regulations, do a good job in the safety precautions for on-site construction and strictly abide by the safety operation procedures. All kinds of accidents in the construction process shall be borne by Party B, and Party A shall not be held responsible. All construction tools shall be provided by Party B. ..

6. This contract is made in duplicate, one for each party, and shall come into effect after being signed and sealed by both parties.

Party A (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model written contract for maintenance works II

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

In order to clarify the responsibility, complete the construction task of _ _ _ _ _ _ _ _

1. Project name: maintenance project on the second floor of warehouse group.

2. Contract price: RMB three hundred and forty-one thousand four hundred and fifteen yuan and forty-nine cents (￥34 1, 4 15.49 yuan).

Third, the contracting method: all-inclusive.

Four. Engineering quality: qualified

Verb (abbreviation of verb) project settlement method: Party B prepays the expenses required for the project. After the project is completed and accepted, the project funds will be handed over for payment. If any items are added or changed, they shall be paid together with the original cost.

6. Project duration: 90 days. If natural factors such as wind, rain, freezing and high temperature affect the construction progress, the construction period will be postponed according to the actual number of days.

7. Party B shall ensure the safe construction without affecting the production, and all accidents shall be borne by Party B. ..

8. Party A shall send personnel to supervise the quality and progress of the project, and Party B shall carry out the construction in strict accordance with the construction requirements to ensure the quality of the project. If Party B fails to carry out the construction according to the regulations, Party A has the right to put forward rectification measures, otherwise, Party A has the right to refuse to pay.

Nine, other matters not covered, the two sides can negotiate to solve. If negotiation fails, a lawsuit shall be brought to Bengbu People's Court according to law.

X this contract is made in quadruplicate, with party a and party b holding two copies respectively, and shall come into effect after being signed and sealed.

Party A (signature or seal):

Party B (signature or seal):

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model written contract for maintenance works 3

Owner (Party A): Contractor of Anhui Medical University (Party B):

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, and in combination with the specific conditions of this project, both parties reach the following agreement.

Article 1 General situation of the project

1. 1 project name:

1.2 Project location: Anhui Medical University

1.3 Contracting method: Party B will contract the work and materials.

1.4 construction period: this project will be completed before the contract signing date.

1.5 engineering quality: qualified.

1.6 Contract price (RMB): in words (RMB)

Article 2 Work of Party A

2. 1 Make on-site disclosure to Party B three days before commencement. Provide Party B with water, electricity, gas, communication and other equipment required for construction, and explain the matters needing attention in use.

2.2 Party B is appointed as the on-site representative of Party A to be responsible for the performance of the contract. Supervise and inspect the quality and progress of the project, and handle matters such as acceptance, change and registration. Where an economic visa is involved, the examination and approval procedures shall be handled in accordance with the relevant provisions of Anhui Medical University.

2.3 If it is determined that it is necessary to dismantle the original building structure or equipment pipeline, it is responsible for handling the corresponding examination and approval procedures with relevant departments.

Article 3 Party B's responsibilities:

3. 1 Project quality: Party B shall strengthen the quality control measures and management during the construction to ensure that the project quality reaches the qualified level.

3.2 Labor Safety: Party B shall strengthen the labor management and education of the personnel on the construction site, pay attention to labor safety, do a good job in fire prevention, theft prevention and electric shock prevention on the construction site, and shall not arbitrarily destroy the safety enclosure facilities on the construction site. In case of industrial accidents or accidents, Party B shall be responsible. At the same time, Party B's construction personnel must obey and abide by the relevant regulations and rules and regulations of Party A's management.

3.3 Civilized construction: Material stacking and site construction shall be subject to Party A's management, so as to ensure that the materials are stacked in a neat and standardized manner and cleared after work; Keep the construction site clean and unobstructed. Fighting is strictly prohibited on the construction site, and drinking is strictly prohibited before going to work. Those who violate the responsibility will be severely punished, and the fine will be deducted directly from the project payment.

3.4 Protection of finished products: Party B shall strengthen the protection of finished products, not only to prevent the finished products from being damaged by others, but also to prevent them from being damaged by others. Party B shall be responsible for the finished products belonging to Party B; If Party B destroys other people's finished products, the losses shall be borne by Party B, and the loss expenses shall be deducted from the project payment.

3.5 Responsible for protecting the surrounding buildings and decoration, equipment and pipelines, green space, etc. Avoid damage, otherwise you should bear the corresponding expenses.

3.6 Cooperate with relevant departments to do a good job in on-site security, fire fighting, garbage disposal and removal, and bear the expenses.

3.7 All accidents during the construction period, such as insurance and casualties, shall be borne by Party B, and all expenses incurred shall be paid by Party B. ..

3.6 Party B is appointed as the on-site representative of Party B to be responsible for the performance of the contract. Organize the construction according to the requirements, ensure the quality and quantity, complete the construction tasks on schedule, and solve all matters that Party B is responsible for.

Article 4 Time limit for a project agreement

4. 1 When Party A requests to complete the construction period stipulated in the contract in advance, it shall obtain Party B's consent and pay Party B the expenses for the measures taken to speed up the work progress.

4.2 Due to Party A's failure to complete the work as agreed, the construction period will be postponed.

Article 5 Engineering Quality and Acceptance Criteria

5. 1 The acceptance criteria for quality evaluation are the construction drawings, practices, design changes, Code for Construction and Acceptance of Building Decoration Engineering (JGJ73-9 1), Acceptance Criteria for Quality Inspection and Evaluation of Building Installation Engineering, etc.

5.2 The quality of this project conforms to the national quality evaluation standard.

5.3 Party A and Party B shall handle the acceptance formalities of concealed works and intermediate works in time. If Party A fails to participate in the acceptance of concealed works and intermediate works on time, Party B may accept it by itself, and Party A will approve it. If Party A requests reinspection, Party B shall reinspect as required. If the reinspection is qualified, the expenses shall be borne by Party A, which will cause the shutdown and postpone the construction period; If the reinspection is unqualified, the expenses for reinspection and rework shall be borne by Party B, but the construction period shall be postponed accordingly.

5.4 In case of quality accident due to Party B, the rework cost shall be borne by Party B, and the construction period shall not be postponed.

5.5 After the completion of the project, Party B shall notify Party A for acceptance, and Party A will set another acceptance date after receiving the acceptance notice from Party B. However, Party A shall acknowledge the completion date and bear Party B's storage expenses and related expenses.

Article 6 Settlement of project funds

6. 1 Both parties agree that the second option is adopted for the contract price;

(1) Fixed price.

(2) Bid price (including bid risk)+economic visa. The changed part shall be settled according to the actual engineering quantity. Where an economic visa is involved, the examination and approval procedures shall be handled in accordance with the relevant provisions of Anhui Medical University.

(3) the price is adjustable; Calculate the cost according to the relevant national engineering valuation regulations, and make adjustments and final settlement according to the relevant regulations.

6.2 Quota is adopted for project settlement: 20- year national unified construction project foundation quota Anhui comprehensive evaluation table Hefei comprehensive price list (2nd edition), 1999 Anhui decoration project comprehensive evaluation table Hefei price list, and national unified installation project budget quota 20-Anhui pricing table. The material price adopts the market price information of Hefei construction project in the current year and the current month.

6.3 Charge standard: Charge according to four categories.

Article 7 Quality Assurance Period

The warranty period of this project is 1 year. During the warranty period, if the project is loose or falls off due to subjective and objective factors such as natural forces, Party B shall be present for free maintenance within 2 days.

Article 8 Payment Terms

8. 1 After the project is accepted, 70% of the contract price shall be paid to the winning bidder;

8..2 Pay 95% of the final settlement price after being audited by the Audit Department of Anhui Medical University and issuing a settlement report, and return the performance bond (interest-free).

8.2 5% of the settlement price is reserved as the project quality deposit. When there is no quality problem after the warranty period expires, the tenderer will refund the project quality deposit (interest-free).

Article 9 Material Supply Agreement

9. 1 The materials purchased by Party B shall be qualified products that meet the requirements of this project and relevant national standards.

9.2 If the materials purchased by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

Article 10 Safety Production and Fire Prevention Agreement

10. 1 The construction drawings or descriptions provided by Party A shall comply with the Fire Protection Regulations of People's Republic of China (PRC) and relevant fire protection design specifications.

10.2 during the construction period, party b shall strictly abide by the technical regulations for safety of construction and installation projects, the safety operation regulations for construction and installation workers, the regulations on fire control in People's Republic of China (PRC) and other relevant laws and regulations. In the process of construction and production, if Party B violates relevant safety operation regulations and fire regulations, resulting in safety or fire accidents, Party B shall bear all economic losses.

Article 11 Liability for breach of contract

1 1. 1 If the completion is overdue due to Party B's reasons, Party B shall pay 5% of the liquidated damages to Party A for each day overdue.

1 1.2 Party B shall properly protect the equipment provided by Party A and the furniture, furnishings and engineering products stacked on site. If losses are caused, Party B shall compensate the price.

1 1.3 Party A agrees to dismantle and change the original building structure or equipment pipeline without going through any formalities, and the losses or accidents (including fines) arising therefrom shall be borne by Party A. ..

1 1.4 Without the consent of Party A, Party B shall be responsible for the losses or accidents (including fines) caused by dismantling or modifying the original building structure or equipment pipeline.

1 1.5 If Party A uses it in advance or without authorization without going through the acceptance formalities, Party A shall be responsible for the losses caused.

1 1.6 If one party cannot continue to perform the contract due to reasons, it shall notify the other party to handle the contract termination agreement, and the responsible party shall compensate the other party for the economic losses caused thereby.

Article 12 dispute or dispute settlement

12. 1 In case of any dispute during the performance of this contract, both parties can settle it through consultation or ask the relevant departments for mediation without affecting the progress of the project.

12.2 settlement of contract disputes: disputes arising during the performance of this contract shall be settled by both parties through consultation; It can also be mediated by the local administrative department for industry and commerce; If negotiation or mediation fails, it shall be settled in the following (2) way.

(1) submitted to Hefei Economic Arbitration Commission for arbitration;

(2) Bring a lawsuit to the people's court where the construction project is located according to law.

Article 13 Other agreements

13. 1 In this construction, Party B should always pay attention to construction safety and try to avoid making a lot of noise on campus, so as not to affect students' normal study and personal safety.

13.2 party b shall carry out the construction in strict accordance with the procedures, and the construction of the next working procedure can only be carried out after each working procedure is accepted by party a, so as to ensure the engineering quality.

13.3 during the construction, if there is any change in this project, Party A shall notify Party B in time and apply for an economic visa.

13.4 if the completed quantities are reworked due to Party A's failure to notify in time, Party A shall bear the economic losses of Party B. ..

Article 14 Other matters not covered shall be settled by both parties through consultation in accordance with the principles of equality, voluntariness, fairness and good faith.

Article 15 The tender documents are an integral part of this contract, and matters not covered in this contract shall be subject to the tender documents of this project.

Article 16 This Agreement is made in sextuplicate, four for Party A and two for Party B. ..

Employer: Anhui Medical University (seal) Contractor: (seal)

Legal representative:

Authorized Agent: Authorized Agent:

Tel: Tel:

Bank of deposit: Bank of deposit:

Account number: Account number:

Date, month, 20

Model written contract for maintenance works 4

Party A:-(hereinafter referred to as Party A)

Legal representative:

Party B: Shangjiahe Village Committee (hereinafter referred to as Party B)

Legal representative:

Since June this year, continuous rainfall has caused the road in Tongcun Village of Shangjiahe Village to collapse and be interrupted in many places. The ferry has been in disrepair for a long time, and there is no place to stop and turn around in the village. In order to ensure the smooth relocation of Shangjiahe Village in June+10 this year, Party A and Party B reached the following agreement through consultation.

I. Quantity and content

1. Party B is responsible for maintaining five collapsed roads in the village.

2. Party B is responsible for building three stops in the village that can stop and turn around.

3. Party B is responsible for maintaining the ferry in the village to ensure the safe transition of people and vehicles.

Second, the engineering quality and requirements

1. Party B shall be responsible for the maintenance of roads in the village, clearing roadside landslides, improving side ditches and filling roads.

2. Party B is responsible for building three parking lots with an area of 40 square meters and simply hardening them.

Third, the project cost

All mechanical, labor and material expenses incurred by Party B in the construction are one-time expenses, totaling RMB 70,000.00.

Four. mode of payment

After Party B's construction is completed, Party A and Party B will organize acceptance. After the project is qualified, Party B will pay the project cost of 40,000 yuan in one lump sum.

Verb (abbreviation for verb) safety responsibility

Party B shall pay attention to construction safety, and Party A shall not bear any responsibility for all casualties during construction.

VI. Project Duration

-MM DD YY to MM DD YY, * * *-DD YY.

Seven. Legal liability

This agreement is made in duplicate, one for each party, with the same legal effect, and both parties must abide by it. Matters not covered in this agreement must be settled by both parties through consultation.

Party A: (signature and seal)

Party B: (signature and seal)

Legal representative:

Legal representative:

Year-month-day

Model written contract for maintenance works 5

Party A:

Party B:

The old office building has seriously affected the development of all work. In order to create a good office environment, strengthen efficiency construction and further improve office efficiency, Party A decided to repair the office building of the police station. Now, according to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and the Regulations on Quality Management of Construction Projects, and in combination with the specific conditions of this project, the following construction contract is concluded on a voluntary basis, so that * * * can abide by it together and define the responsibilities.

I. Project Location: Police Station

Second, the project content and cost

1. Office building maintenance works of police station: office building painting and painting, office aluminum alloy doors and windows installation, roof waterproofing treatment, aluminum alloy doors installation, etc.

2. Payment and settlement of project price

This project is a general contracting agreement with a total contract amount of 26,000 yuan (twenty-six thousand yuan only). Party B is responsible for solving the shortage, and the payment method adopts the progress reimbursement system. Party B submits the accounts with the tax bill, and then Party A pays.

Third, the way of contracting: contracting for labor and materials

Four. Duration: from (20-) to (20-), with * * * as the calendar days. In case of force majeure, it can be postponed after confirmation by both parties.

Five, the engineering quality requirements

1. Party B must carry out the construction in strict accordance with the promised quality standards, and immediately rectify the nonconformities to ensure the project quality.

2. Before the construction, Party B shall provide Party A with a letter of commitment for construction materials, and Party B's construction materials must be constructed according to the promised standards.

The intransitive verb Party A's work

1. Provide construction conditions for the construction site in time, and coordinate Party B's mobilization, construction water and electricity consumption.

2, appoint someone to be responsible for the supervision, command and coordination of the construction site.

Seven. Party B's work

1. Before construction, Party B shall provide Party A with the construction progress plan, which shall be strictly implemented after being confirmed by Party A. ..

2. Make clear that the project leader is responsible for the on-site construction, carry out the construction in strict accordance with the specifications, and complete all the contents of the project. Party B shall try its best to overcome the difficulties encountered in site construction to ensure the timely completion.

3. All safety responsibilities in the construction process have nothing to do with Party A, and Party B is responsible.

Eight. In the process of construction, if Party A changes the original design or Party B puts forward reasonable suggestions and is approved by Party A, the expenses and construction period arising therefrom will be increased or decreased according to the facts after both parties agree.

Nine. responsibility for breach of contract

1. If Party B fails to operate according to regulations during the construction period, Party A may request rectification.

2. Party A shall not default on Party B's project payment without reason.

X this agreement is made in triplicate, one for each party and one for file.

XI。 Matters not covered in this contract shall be settled by both parties through consultation. Any dispute between Party A and Party B during the performance of this contract can be settled through negotiation; If no agreement can be reached through negotiation, it can be settled through litigation. During the negotiation or litigation, some clauses that are not involved in the dispute shall continue to be performed.

12. This contract shall come into effect as of the date of signature by both parties. After the project is completed and accepted and the project payment is paid, the effectiveness of the contract will naturally terminate.

Party A (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Five articles related to the written contract model of maintenance engineering;

★ 5 copies of written contract model for highway maintenance.

★ 5 simple maintenance contract format templates

★ Five latest 202 1 maintenance contracts

★ 3 copies of model maintenance contract.

★ Five written contract templates for water pipe maintenance.

★ Model maintenance project construction contract

★ 5 maintenance contract models are the latest.

★ 5 samples of daily maintenance contract.

★ 5 copies of maintenance service contract text.

★ Five formal contract formats for equipment maintenance.