Construction contract of construction project

Model construction contract of building engineering (8 general rules)

With the establishment of people's legal consciousness, more and more scenes and occasions need to use contracts, and the signing of contracts is the best specification for the rights and obligations of both parties. Then do you know the format of the contract? The following is a template of construction contract (generally 8 copies) carefully arranged by me for reference only. Welcome to read it.

Construction Contract of Construction Project 1 Employer (full name):

Contractor (full name):

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this building project and conclude this contract.

I. Overview of the Project

Project name:

Project location:

Project content:

Project approval number:

Second, the scope of project contracting

Scope of contract: all the labor, materials, equipment, construction machinery and services required for the construction and completion of civil works, installation works and embedded works, except the subcontracted works agreed by the Employer in the construction drawing (some materials and steel structures are provided by the Employer).

Third, the term of the contract.

Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (The actual commencement date is subject to the commencement order issued by the Employer and the Supervisor);

Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total calendar days of contract term: _ _ _ days.

Fourth, quality standards.

Engineering quality standard: qualified (in which the main body is high-quality structure)

Verb (abbreviation of verb) contract price

Amount (in words): _ _ _ _ _ _; The budget price is about _ _ _ _ ten thousand yuan.

Composition of intransitive verb contract documents

This contract document includes:

1, as agreed in this contract;

2. Drawings;

The written agreement or document on project negotiation and change between both parties shall be regarded as an integral part of this contract.

Seven. Breach of Contract, Claims and Disputes

1. The Employer and the Contractor shall abide by the above agreement. If one party violates the agreement and causes economic losses to the other party, it shall pay corresponding compensation.

2. Any dispute arising from the performance of this contract shall be settled by both parties through negotiation or a third party shall be invited for mediation. If negotiation or mediation fails, both parties agree to apply to the _ _ _ _ _ _ _ _ _ Arbitration Commission for arbitration.

Eight, the contractor promises to the employer to carry out construction and completion in accordance with the contract, and undertake the project quality warranty responsibility within the quality warranty period.

Nine. Engineering settlement

1. within _ _ days after the project completion acceptance report is approved by the employer, the contractor shall submit the completion settlement report and complete settlement data to the employer, and both parties shall adjust the project completion settlement according to the contract price agreed in the agreement and the contract price agreed in the special terms and conditions.

2, the general formula of the project price completion settlement is:

Project payment for completion settlement = budget (or budgetary estimate) or contract price+adjustment amount of budget or contract price under construction-prepaid settled project price-quality guarantee fund.

3, the developer and the contractor agreed in the construction project contract quality deposit, the developer set aside from the project payment payable, to ensure the contractor's funds for defect maintenance of the construction project during the defect liability period, and the quality deposit is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. : _ _ _ _ _ _ _ _ _ _ Yuan (RMB).

X. effective date of the contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1. Place of conclusion of the contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. This contract shall come into effect after being signed and sealed by both parties. This contract will be automatically terminated after the provisions of the terms of the project quality warranty signed by both parties are met and there is no dispute.

Employer:

Legal representative:

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor:

Legal representative:

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A's construction contract II:

Party B:

In order to cooperate hand in hand, promote development, satisfy interests and clarify responsibilities, Party A and Party B, based on the principle of good faith and mutual benefit, hereby sign this contract for both parties to abide by:

Article 1: Project name _ _ _ _ (refers to the project name between subcontracted parts)

Article 2: Project location.

Article 3: Project scope.

Article 4: The quality standard _ _ _ _ _ can be listed according to detailed construction drawings, construction instructions and technical specifications for construction acceptance of installation works).

Article 5: Contractor _ _ _ _ _ _ _ _ (If the contract is contracted or awarded according to the budget, the subcontractor shall specify the material variety, specification, quantity, delivery time and technical requirements in the attached table).

Article 6: Total Project Price

The total price of this project is RMB _ _ _ _ _.

Article 7: Project Package Price

The total price of this project is RMB _ _ _ _ (the total cost of this project minus the total value of materials provided by the Employer and the General Contractor).

Article 8: Payment method: _ _ _ _ _ _.

Article 9: Construction Period

According to the project scope in Article 3 of this contract, the project will start on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 10: The _ _ _ _ _ project within the scope of this project started on _ _ _ _ _. _ _ _ _ _ Article 11: Contact system and cooperation measures of both parties _ _ _ _ _.

Article 11: This contract is made in duplicate, each party holds one copy.

Party A:

Party B:

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contract 3 of Party A's construction project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _

In order to implement the large and medium-sized reservoir fund project in xx county in 20xx and solve the drinking water problem of xx people, the project is now contracted out to Party B for implementation. In order to ensure that the project can complete the construction task on time with good quality and quantity, the following contract is signed by both parties through consultation: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1. Project _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ 20xx large and medium-sized reservoir fund project.

Second, the construction content and scale

1, content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. Scale: _ _ _ _ _ _ _ _ _ According to the design drawings and budget.

Third, the project cost

The total investment of the total project cost is about 340,000 yuan, and the project cost shall be subject to the audit and settlement of the actual acceptance quantities.

Four. Mode of contracting: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

The responsibility of party a and party b with intransitive verbs

Party A: _ _ _ _ _ _ _ _ _ _ _ _ to provide the construction design drawings on time. During the construction period, Party A will send supervisors to the site for technical guidance and quality supervision from time to time.

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Work, strictly control the quality, and accept the quality inspection and supervision of Party A during the construction period.

All expenses for rework caused by unqualified project quality shall be borne by Party B. ..

Seven. Do a good job in production safety: _ _ _ _ _ _ _ _ _ _ _ _ _ Party B shall pay attention to safety during construction, and any accident of Party B's personnel during construction has nothing to do with Party A, and Party B shall be responsible for it.

Eight. Payment method of this project is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Set aside 5% as the project quality deposit. If there is no quality problem in the project after one year, the deposit will be refunded in full.

Nine, this contract shall come into effect as of the date of signature and seal by both legal persons, and will be automatically terminated after the project is completed and accepted and the deposit is returned clearly.

X this contract is made in quadruplicate, two for party a, one for party b and one for the finance bureau.

Party A: _ _ _ _ _ _ _ _ _ _ _

Legal Representative: _ _ _ _ _ _ _ _ _ _ _

Project leader: _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _

Legal Representative: _ _ _ _ _ _ _ _ _ _ _

Project leader: _ _ _ _ _ _ _ _ _ _ _ _

Date of signature: _ _ _ _ _ _ _ _ _ _ _ _ _

Construction Contract of Building Project 4 Party A (Head of Household):

Address:

Party B (contractor):

Address:

Party A entrusts Party B to build a private residence, and through friendly negotiation, both parties reach the following agreement.

First, the way of contracting:

The contractor does not contract materials.

Second, the contract price:

Calculated in RMB per square meter, the contract price includes workers' meals and cigarettes.

Iii. Terms of payment:

Party A shall pay RMB yuan in advance when the project starts, RMB yuan in advance when the structure ends (capped), and the balance shall be settled before the Spring Festival next year.

Fourth, the time limit for a project:

The commencement date is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Verb (short for verb) quality:

Party B should pay attention to quality in the construction. If there are quality problems in the construction, Party B shall immediately rectify them. If Party A insists on not rectifying, Party A has the right to refuse to pay the project payment.

Six, safety management:

During the construction period, Party B shall strengthen safety management to ensure the safety of construction personnel. If management is neglected, all expenses and responsibilities of personal injury accidents shall be borne by Party B, which has nothing to do with Party A. ..

Seven. Responsibilities and obligations of both parties:

Party A:

① Party A shall ensure that the timely arrival of building materials will not affect the use of Party B. ..

Party B:

(1) responsible for the construction of vertical transportation equipment, mixing machinery, trolleys, steel cutting tools, mud buckets, etc.

(2) Party B shall inform Party A of the arrival time of building materials in advance, otherwise Party A will not be responsible.

(3) Scope of contract: construction according to drawings and construction instructions. Civil wooden formwork, roof wooden foundation, water and electricity installation shall be separately contracted by Party A..

8. This contract is made in triplicate, which shall come into effect after being signed by both parties, and shall become invalid after the project payment is settled.

Party A (official seal): _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Construction Contract 5 Party A:

Party B:

Through negotiation between Party A and Party B, Party A delivered the brick-concrete structure house to Party B for construction. In order to ensure that this project can be completed on time in accordance with the provisions of the People's Republic of China (PRC) Contract Law, the following agreement is hereby signed:

I. Project name:

Brick-concrete constructional column has two floors (with a total area of about square meters), one floor is 4 meters high, and the second floor is 3 or 8 meters high. The height of the anchor ring beam is 40 cm. Except that the patio is concrete, all the others should be tiled. The wall is required to be flat, and two layers of toughened powder are scraped on the inner wall. One side of the external wall is tiled, and the back is plastered with cement mortar.

Second, the nature of the contract:

The labor contract does not contain materials, and the labor price per square meter is calculated according to the actual projected area of the main building (RMB: RMB/square meter).

Three. Scope of contract:

Party B is responsible for the construction of all main and auxiliary projects of this project, including ground anchor ring beam, septic tank, interior decoration (tile laying, bathroom, stairs, toughened powder, etc. ) and fences, so as to achieve smooth and beautiful.

Four. Rights and obligations of both parties:

This project shall be constructed according to the construction scheme negotiated by both parties. During the construction, materials shall not be wasted to Party A and shall be used reasonably. If it is necessary to change, it can only be changed after Party A agrees.

1. Party A must ensure smooth water, electricity and roads for Party B, and provide necessary building materials before construction;

2. The mixer, vibrator, formwork, top lining and construction tools required for construction shall be provided by Party B;

3, each layer of water, pouring column must use mixer and vibrator vibration, pouring column must use plug-in vibrator vibration;

4. The building lines of the whole house should be straight, the walls should be flat and smooth, and the corner lines and flatness of ceramic tiles should meet the requirements of building quality;

5. Party B shall strictly abide by Party A's requirements and carry out the construction in accordance with the current management standards related to design and construction specifications promulgated by the state. In order to ensure the quality of the project, if it is found that the quality fails to meet the requirements of Party A, Party A has the right to order Party B to stop work or rework, and if it fails to make corrections within the time limit, Party A has the right to unilaterally terminate the contract and refuse to pay the project payment.

6. The accommodation and meals of Party B and temporary workers shall be provided by Party B, and Party A shall not provide any fees.

7. In the process of construction, safety first, idle personnel are not allowed to enter the construction site. Party B must carry out the construction in accordance with the national regulations on production safety, and all the responsibilities for all kinds of accidents during the construction shall be borne by Party B. ..

10. Party B must notify Party A in advance of the building materials it needs, and Party B shall not stop work privately under any excuse.

1 1. Party A is responsible for transporting the materials to the construction site, and Party B will solve other problems by itself.

12. Both parties have the right to make suggestions and demands, and are obliged to accept the reasonable suggestions of the other party. If it is difficult to reach an agreement on the requirements, it shall be handled according to the opinions of Party A..

13. The losses caused by force majeure shall be borne by both parties.

Five, construction and engineering quality requirements:

Construction shall be carried out in accordance with national civil building standards and drawings. If it is not clear, both parties must meet the quality inspection requirements through consultation.

1, indoor floor tiles, bathroom sanitary tiles, and other walls are scraped white with toughened powder, which is smooth and beautiful. If the construction workers who laid the floor tiles and brushed the toughened powder are not in the same group, the construction workers must clean up the indoor residue after the completion of the single construction.

2, stair step tile, vertical tile, the area is calculated according to the projection area, not according to the slope. The gable and interior wall thickness on the right side of the wall is 18 cm, and the wall thickness of bathroom and kitchen door is 12 cm. After drying, scrape two layers of toughened powder.

3. Party B shall not waste materials at will during the construction period. In principle, the mortar must be used up on the same day, and the mortar number must meet the requirements of building standards.

4. After the construction personnel enter the construction site, they must strictly manage the construction to ensure the construction safety. Casualties (including third-party casualties) caused in the construction process shall be borne by Party B, and Party A shall not be held responsible.

5. For the construction quality of the main body and ancillary works of the whole house, Party A invites the engineering quality supervision and management department to conduct quality acceptance with Party B * *. If the parts that need to be reworked fail to meet the acceptance criteria, Party B shall undertake all materials.

Six, the time limit for a project requirements:

Party B must carry out the pouring according to the time determined by Party A, and the construction date is from _ _ _ _ _ _ _ _.

7. Party B shall pay 4,000 yuan after the completion of each floor, and then pay according to the progress of the project.

After the project is completed and accepted, the remaining labor price shall be paid.

Eight. Liability for breach of contract:

1. The warranty period of the new building is two years. In case of any of the following circumstances, Party A shall not refuse to maintain under any excuse, and Party B shall be responsible for the warranty and maintenance materials.

(1) There are cracks on the board surface and the wall (except for the small cracks on the board surface within 2mm); (2) The house collapses and the roof falls off;

③ Other losses caused by unqualified building quality.

2. Both parties must strictly and conscientiously perform the contract, otherwise Party A and Party B have the right to unilaterally terminate the contract, and all losses caused by breach of contract shall be borne by the breaching party.

9. If there are any outstanding matters, Party A and Party B shall settle them through consultation. This contract is made in duplicate, one for each party. Neither party may make any changes to the contract (except with the consent of the other party). This contract shall come into effect as of the date of signing, and shall be automatically terminated after the completion and acceptance of all projects.

Party A (handprint signature): _ _ _ _ _ _

Party B (handprint signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A's Construction Contract 6: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC) and the Construction Law of People's Republic of China (PRC), combined with the relevant regulations and the specific conditions of this project, and on the basis of both parties' voluntary and complete understanding of the terms of this contract, this contract is signed through consultation.

I. Project Name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Two. Project location: _ _ _ _ _ _ _ _ _ _ _.

3. Project content: workshop, road, pipe network and water well.

Fourth, the way of project contracting: the contractor does not include materials.

5. Bricklayer's package price: RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

The road is _ _ _ _ yuan per square meter;

The pipe network is _ _ _ _ yuan per meter;

_ _ _ _ _ Yuan/round well;

Each square well is _ _ _ _ _ yuan.

Engineering materials of intransitive verbs: The materials used by Party A are commercial mixed roads, and the floor materials of the workshop are commercial mixed, and Party A is responsible for grinding the floor.

7. Payment method: Pay according to the progress of the project, and pay in one lump sum after the project is completed.

Eight. Commencement date: _ _ _ _ _ _ _ _ _ _ Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A: _ _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 7 of the construction contract for building projects: (the Employer) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: (Contractor) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, in order to clarify the rights, obligations and responsibilities of both parties in the project contracting and ensure the comprehensive completion of the project tasks, Party A and Party B sign this contract on the principle of voluntariness, equality and mutual benefit through consultation.

Article 1 General situation of the project

(1) Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(2) Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(3) Project scope: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(IV) Total project cost: Both parties determine that this project is a double contract (including frame, internal and external powder, doors and windows, water and electricity installation). The comprehensive unit price is 500 yuan per square meter, and the quantities are settled by the actual recipient. The total project cost is tentatively set at RMB _ _ _ _ _ _ _.

Article 2 Project duration

According to the negotiation between both parties, the construction period is from May 20th to June 5th, 20xx. Party B must complete the construction within the time limit agreed by both parties. If it is overdue, all consequences shall be borne by Party B.. If the work is postponed due to bad weather or natural disasters, the construction period will be postponed.

Article 3 Project Quality

Party B shall carry out the construction according to Party A's requirements to ensure the project quality.

Article 4 Settlement of project price

(1) The settlement of all engineering expenses in this contract shall be handled as follows:

The quantities in this contract are tentative quantities, which shall be taken as the basis for final settlement after mutual consent. According to the actual visa settlement.

(two) the way of project price settlement and disbursement; After the completion of the second floor, 80% of the second floor's quantities will be paid, and after the completion of the third floor, 100% of the third floor's quantities will be paid, and the final payment will be paid after all projects are completed and accepted by Party A. ..

Article 5 responsibilities of both parties

(I) Party A's responsibilities

1. Party A is responsible for coordinating the neighborhood relations at the construction site to ensure the smooth entry and exit of building materials and equipment.

2. Party A shall provide the water and electricity interfaces required by Party B for construction.

3. After the completion of the project, Party A shall organize special personnel to conduct acceptance within _ _ _ _ _.

(II) Party B's responsibilities

1. Party B shall work out the construction plan according to Party A's requirements and carry out the construction after Party A's consent.

2. Party B shall organize the construction in strict accordance with the construction plan agreed by both parties.

3. Party B shall formulate safety measures and strengthen the safety education for on-site construction personnel. Any accident shall be borne by Party B. ..

4. Party B shall reasonably organize the construction and deployment of mechanical vehicles to ensure that the project is completed on schedule.

5. Party B shall obey the unified command of Party A's on-site representative.

Article 6 Contract disputes

All disputes arising from the performance of this contract shall be settled by both parties through consultation or mediation. If negotiation or mediation fails, please choose one of the following two ways (if arbitration is selected, please indicate the specific arbitration commission).

1. Submit to _ _ _ _ _ _ _ _ _ Arbitration Commission ()

2, according to the law to the people's court ()

Article 7 Supplementary Provisions

(1) This contract shall come into effect after being signed by both parties, and shall be invalid after completion.

(II) If there are any matters not covered in this contract, both parties may negotiate additional terms according to the specific conditions for both parties to abide by.

(III) Party A and Party B shall hold one copy of the original contract, and the copy shall be filed with the relevant departments for visa in accordance with relevant laws and regulations.

Article 8 Additional clauses

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A's Construction Contract 8: _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _

According to relevant laws and regulations, Party A and Party B reached an agreement on the construction of private houses on the principles of equality, voluntariness, fairness and mutual benefit through consultation. In order to regulate the civil behavior of both parties in the construction of private houses, the terms of this contract are formulated, and both parties are expected to strictly implement them and abide by them together.

1. Overview of construction project: the commencement date is the second half of _ _ _ _ _.

This project is a brick-concrete structure. _ _ _ _ _ North of Yingbin Street, west of _ _ _ _ and east of _ _ _ _ _, there are two-story facade houses, and even the basement is a three-story building. The area is about 300 square meters, subject to the actual construction area.

2. Contract price: This project is contracted by Party A and Party B, and the contract price is the total price. The contract price per square meter is 1955 yuan, and the total contract price is subject to the actual area.

1. contracting method: the project is contracted without contracted materials. Materials such as steel, cement, sand and gravel used by Party A for building the house shall be provided by Party A, and construction tools such as mixers, cranes, vibrating equipment, formwork, jacking wood, scaffolding wood, shovels and trolleys used by Party B shall be borne by Party B.. ..

2. Project content: from the foundation plastering to the continuous completion of the main frame structure, indoor and outdoor plastering, the building height and front style required by Party A, to the capping. There is also the installation of circuits and water.

3. Project quality: Construction shall be carried out according to regulations. Quality requirements include straight walls, full bricks, vertical beams and columns, horizontal corners of the house, and bending of steel bars at both ends.

Three. Responsibilities of both parties:

1. Before the construction of this project, Party A must ensure that the power supply, water supply, access roads and building areas are unblocked, so as not to affect the construction. Disputes with neighboring neighbors on land boundaries, buildings, lines, etc. To be settled by Party A. ..

2. The project must be constructed according to the requirements of Party A, and Party B shall not change the construction method at will. If design problems are found in the construction process and need to be changed, both parties shall reach an agreement through consultation.

3. In the process of construction, Party B must ensure safe production and construction, and have sufficient safety guarantee mechanisms and measures. Party A shall not take full responsibility for any safety accident caused by Party B's carelessness.

Four. The settlement payment method is cash payment. Party A will pay part of the salary to Party B according to the progress of the project. After the completion of the project, if there are no major quality problems, Party A will pay the balance in one lump sum.

Verb (abbreviation of verb) Matters not covered in this contract shall be settled by both parties through consultation.

6. This contract is made in duplicate, with each party holding one copy.

Party A: _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Party B.

Date: _ _ _ _ _ _ _ _ Date: _ _ _ _ _ _ _ _ _ Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

;