Villa renovation contract model

Contracts or agreements generally differ only in name and title. As long as it does not violate laws and moral habits, the parties can arbitrarily agree on the name, content and form of the contract or agreement, which are all valid. The following is a sample of villa renovation contract that I compiled for you. Welcome to reading.

Villa renovation contract model 1

Customer (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After friendly negotiation, Party A decided to entrust Party B to lay floor tiles and wall tiles, and signed this agreement for mutual compliance.

I. Project Location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Two. Formal structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Three. Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1, four rooms (two bedrooms, two living rooms) are paved with 80_80 tiles, and the corner lines are laid, requiring leveling; A kitchen, a bathroom wall 25_40 porcelain to the top, leaving ceiling space, grinding angle, 30_30 tiles on the ground, required to be flat; The floors of the two balconies are paved with 30_30 tiles, which are required to be flat.

2. If no details are involved, Party A shall propose a plan and discuss it.

4. Contracting method: Party A must ensure the materials needed during the decoration period (Party B informs Party A in advance) and the lunch supply during the construction period according to Party B's requirements, and Party B shall be responsible for the construction.

Verb (abbreviation of verb) quality standard: the construction quality meets the safety requirements, and the decoration quality is not lower than the decoration standard of the same construction type, which is recognized by both parties. After the project is completed and accepted, if there are quality problems in Party B's construction within 3 months, Party B shall be responsible for rework and maintenance for free.

Engineering cost of intransitive verbs: materials are provided by Party A, and Party A pays Party B the labor cost of decoration.

Seven. Payment method: in order to ensure the project quality, the deposit is RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. After the project is completed, Party A shall pay Party B the labor cost within three days if it meets the above construction project and design requirements upon acceptance.

Eight. This agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into effect as of the date of signature by both parties.

Party A (signature): Party B (seal): Party A (signature): Party B (seal): Party A (seal): Party B (seal)

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Villa renovation contract Mode 2

Employer (hereinafter referred to as Party A):

Contractor (hereinafter referred to as Party B):

Party A subcontracted the renovation project of the large supermarket of Hajian Building on Tianshan North Road in Hami City to Party B. In order to protect the legitimate rights and interests of both parties, according to the Contract Law of People's Republic of China (PRC) and the Trial Measures for Renovation Management, both parties reached the following terms through consultation on the principle of equality and mutual benefit for their common compliance.

I. Overview and requirements

1. Decoration construction site: Sun International Investment Promotion of Hajian Building, Tianshan North Road, Hami City

2. Decoration construction content: ground foundation engineering, ceiling, wall decoration, column wrapping, wooden hanger, cabinet combination and decoration.

3. Contracting method: contracting for work and materials.

4. Price settlement: according to the quota of architectural decoration and installation project in Hami area of Xinjiang in 20 years and the corresponding project cost information documents; After the changed construction content is approved by both parties, the changed part of the project payment will be settled according to the facts.

Two. Requirements of Party A:

1, the decoration requirements are subject to the design of the corresponding supermarket stores, and must pass the corresponding acceptance;

2. The decoration renderings shall prevail;

3. The materials must use the material report provided by Party A;

4, according to the decoration time stipulated in the contract completed and passed the acceptance;

Three. Material supply agreement:

1. Materials provided by Party B: See the quotation of main materials in the annex for details.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used.

Four. Agreement on project quality and acceptance:

1, this project implements the local standards and quality evaluation acceptance criteria formulated by the municipal construction administrative department, such as Dbj08-62-97 Technical Specification for Building Decoration Engineering, DB3 1/T30- 1999 Acceptance Criteria for Decoration.

2. The design scheme of this project is provided by Party A. ..

3. In case of quality accident due to Party B, the cost of rework shall be borne by Party B, and the construction period shall remain unchanged.

4. During the construction process, Party A shall contact Party B in advance when proposing design modification opinions and adding or subtracting engineering projects. The construction of this project can only be carried out after signing the project change order, thus affecting the completion date agreed by both parties. If Party A agrees with the workers to change the construction content privately, all consequences shall be borne by Party A, and if losses are caused to Party B, Party A shall compensate.

5, project acceptance. The acceptance of the project shall be subject to the acceptance of Party A and the corresponding competent department.

Verb (abbreviation of verb) Agreement on project price and settlement:

The total contract amount is RMB 3,500,000.00 Yuan, in words. Pay in three installments.

Down payment: Party A shall pay Party B 60% of the total contract amount within seven working days after signing the contract.

Party A as the start-up advance payment.

Second payment: 90% of the total contract amount will be paid in half the construction period.

Third payment: After the completion acceptance is qualified and both parties have no objection to settlement book, the balance shall be paid within 14 working days.

Liability for breach of contract of intransitive verbs:

1. The construction period will be postponed if the construction starts to be delayed or stops halfway due to Party A's reasons.

2. If the completion of the project is delayed due to Party B's reasons, Party B shall pay liquidated damages to Party A for each day overdue \u 65438+ 0 _% of the payment made by Party A..

3. If the construction is not carried out according to the quality of Party A, all losses shall be borne by Party B, and 20% of the corresponding processing fee shall be paid to Party A as penalty. Party A has the right not to pay the subsequent project funds.

4. If Party B breaches the contract halfway, it shall return the advance payment to Party A and compensate 20% of the corresponding liquidated damages.

Seven. Dispute handling method:

1. In case of any dispute over the quality of the project, according to the text of this contract, both parties may consult and mediate with the Decoration Committee of the Building Decoration Association, or submit the dispute to the district/county construction administrative department or consumer association.

2. If the parties are unwilling to settle the dispute through negotiation or mediation, or if negotiation or mediation fails, they may apply to the Municipal Arbitration Commission for arbitration or bring a lawsuit to the people's court according to this contract.

Eight. Modification and dissolution of the contract:

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay liquidated damages at _ 10 _% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in writing. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Nine. Other agreements:

In order to ensure the smooth performance of the contract, Party B needs to pay 70,000 yuan to Party A as a performance bond, and Party A will return it to Party B after the contract is dissolved or terminated.

X this contract is made in quadruplicate, two for each party, with the same legal effect.

XI。 The annexes to this contract are an integral part of this contract.

Party A (signature): Party B (signature):

Legal Representative: Authorized Agent:

Address: Address:

Tel: Tel:

Post: post:

Date of signature: year month day.

Signing place:

Villa renovation contract Mode 3

Party A:

Party B:

Party A entrusts Party B to undertake the scheme design and construction drawing design of the decoration project. This contract is signed by both parties through consultation.

1. This contract is signed on the basis of the following documents:

1. 1, People's Republic of China (PRC) Contract Law and Regulations on Construction Engineering Survey and Design Contracts;

1.2, national and local laws and regulations on engineering survey and design management;

1.3, construction project approval document;

1.4, details of this project.

2. Contents and requirements of services provided by Party B:

2. 1. Complete the scheme design and construction drawing design of decoration works such as commercial and residential lobby, commercial and residential meeting (fourth floor), building demonstration unit, sales delivery standard, public waiting space, awning, public passage and fire escape;

2.2. Complete the design supporting services for the construction site of the decoration project in 2. 1;

2.3, project product consultation and consulting work, and other related work;

2.4. Party B shall, according to the electronic documents of architectural and structural drawings provided by Party A, complete the original drawings, computer renderings and explanatory materials of the decoration engineering design scheme in 2. 1, deepen and improve relevant schemes, and complete design services such as construction drawing design, material template selection and provision, and cost budget.

2.5 For each design, Party B shall provide more than two design schemes for Party A's reference.

2.6, design requirements:

2.6. Layout plan and renderings of the commercial and residential lobby of Building1,with map specifications as specifications;

2.6.2 Layout and renderings of commercial and residential clubs, with specifications as specifications;

2.6.3 Color plans and renderings of standard apartment buildings with different styles in the northern half of the standard floor. The style and performance shall be determined by the designer of Party B, the unilateral cost shall be controlled within RMB, and the plate specifications shall be specifications; The southern part of the standard layer demonstrates the color layout and renderings of different unit combinations, and the plate specifications are specifications;

2.6.4 renderings of public waiting spaces, public passages and fire exits, with specifications as specifications;

2.6.5 renderings of the entrance lobby and skirt building shopping mall on the first floor, with specifications as specifications.

2.6.6 Combined version of the above scheme.

2.7 After the scheme is confirmed by Party A, Party B shall submit a full set of construction drawings 10 within 5 working days. ..

3. Party B's remuneration and payment method:

3. 1. When Party B completes the services described in Article 2 of this contract, Party A shall pay Party B RMB.

3.2 After Party B submits the construction drawing to Party A, Party A shall pay Party B 60% of the total contract amount (i.e. RMB); After all services agreed in this contract are completed, Party A shall pay Party B 40% of the total contract price (i.e. RMB).

4. Party A's responsibilities

4. 1. Party A shall submit materials and documents to Party B within the specified time according to the contents of this contract, and shall be responsible for their completeness and correctness. If Party A submits the above materials and documents within 3 days beyond the specified time limit, Party B shall postpone the delivery of the design documents at the same time according to the provisions of this contract; When the specified time limit exceeds 3 days, Party A and Party B shall renegotiate the delivery time of the design documents.

4.2. Sign and confirm the approved design scheme, construction drawings, technical data and material samples.

4.3. If Party A changes the entrusted design project, scale and conditions, or Party B needs to rework due to errors in the submitted data or major modifications in the provided data, both parties shall sign a supplementary contract (or make another contract) through consultation, and re-define the relevant terms. Party A shall pay Party B the rework fee according to the workload consumed by Party B, and the calculation and cost standard of the consumed workload shall be determined by both parties through consultation.

4.4, responsible for the organization of the scheme and construction drawing came.

5. Party B's responsibilities

5. 1. Submit the design documents to Party A according to the content, time and number specified in this contract.

5.2. Provide relevant services in time.

5.3. Party B must design according to the design task book approved by Party A or the design documents of the previous stage approved by Party A, as well as the relevant design technical and economic agreement documents, and strictly implement the national design standards, technical specifications and regulations, and submit the design documents that meet the quality. Be responsible for modifying or supplementing omissions or errors in design documents, and assume relevant responsibilities.

5.4. Party B is responsible for making necessary modifications within the scope of the original task book or design entrustment, which will not affect the design period.

5.5. Party B's design shall meet the use requirements of Party A, and submit the budget document according to the construction drawing.

5.6. Party B shall provide the whole construction coordination service for the decoration project of Jinsheng Mansion, and make technical design disclosure to the constructors before construction, participate in the blue prints.the design, solve related design problems during construction, be responsible for design changes, and participate in the acceptance of concealed works and completion acceptance.

5.7. Party B shall make suggestions on interior decoration articles, materials and color samples that Party A needs to purchase, and assist Party A in purchasing furniture, lighting, curtains, decorations, plants, etc. , and guide the layout of furniture.

5.8. Participate in the bidding meeting for decoration materials and decoration projects held by Party A, and give corresponding answers to the questions raised by bidders.

5.9. Party B shall not disseminate or transfer the technical and economic data and design drawings of various stages submitted by Party A to a third party. In case of the above situation, Party A has the right to claim compensation.

6. Liability for breach of contract

6. 1. Party A shall pay the design fee to Party B according to the amount and time specified in this contract. If the overdue period exceeds 10 days, Party B has the right to suspend the next stage of work and notify Party A in writing.

6.2 During the performance of the contract, if Party B fails to start the design work and Party A requests to terminate or terminate the contract, the deposit paid by Party A will not be refunded; If the design work has started, Party A shall calculate the design fee according to the actual workload completed by Party B and pay it to Party B..

6.3. If the delivery time of design documents stipulated in this contract is delayed due to Party B's own reasons, 5 ‰ of the total contract price shall be reduced for each day of delay; If the overdue period exceeds 10 days, Party A has the right to unilaterally terminate the contract and demand Party B to return the money paid by Party A.. ..

6.4. Where the engineering quality accident losses are caused by Party B's design mistakes, Party B shall, in addition to taking remedial measures, waive the design fee for the lost part and pay compensation to Party A according to the actual loss degree.

6.5 After this contract comes into effect, if the contract is terminated or dissolved due to Party B's reasons, Party B shall refund the paid amount to Party A and compensate Party A for RMB 50,000.

6.6. Party A has the right to claim compensation from Party B for the technical and economic data, design drawings and documents at any stage that Party B has diffused or transferred to a third party without Party A's consent.

7. Others

7. 1. During the performance of this contract, if Party A is dissatisfied with Party B's design and Party B's creative design is not adopted in the final construction, Party B shall fully refund the design fee paid by Party A. In this case, Party A shall not disclose Party B's design data and documents to others.

7.2. If the contract cannot be performed due to force majeure, both parties shall settle it through negotiation in time.

7.3. The ownership and copyright of the finished product or design draft confirmed in this contract belongs to Party A. In case of any dispute with a third party due to Party B's infringement, Party B shall bear all economic and legal responsibilities.

7.4 Any dispute arising from the performance of this decoration engineering design contract shall be settled by both parties through negotiation in time. If negotiation fails, either party has the right to bring a lawsuit to the people's court where the project is located.

7.5 For matters not covered in this contract, both parties may sign a supplementary agreement as an annex, which has the same effect as this contract.

7.6. This contract shall come into effect as of the date of signature and seal by both parties.

7.7 This contract is made in sextuplicate, four for Party A and two for Party B, each with the same legal effect.

Party A: _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _

Date of signature: _ _ _ _ _ _ _ _ _ _ _ _

Signing place: _ _ _ _ _ _ _ _ _ _ _

Villa renovation contract Mode 4

Party A:

Party B:

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Regulations on Quality Management of Construction Projects and other relevant regulations, in order to clarify the responsibilities and rights of Party A and Party B, ensure the safe, civilized and smooth construction of the project, and in combination with the specific conditions of this project, and in order to clarify the responsibilities of both parties, this contract is hereby signed on the principle of equality and unity.

1. Project name: interior decoration project of Xiaojihan coal mine building.

2. Project location: Xiaojihan Coal Mine.

Third, contracting light industry: calcium silicate board ceiling, aluminum veneer ceiling, etc.

IV. Contract Price:

1, dressing room, bathroom ceiling:

Calcium silicate board ceiling, aluminum veneer ceiling (including flat ceiling, irregular ceiling and aluminum grid square pipe ceiling), labor cost: 25 yuan /M2, calculated according to the floor area.

2. Corridor ceiling: aluminum veneer ceiling, blockboard as lamp trough, and blockboard with calcium silicate board. Labor cost: 30 yuan /M2 is calculated according to the occupied area.

3. If every room has windows, calcium silicate board will be added at the bottom of the joinery board, and the labor cost will be 25 yuan /M2, calculated according to the developed area.

5. Party A is responsible for providing building materials and providing power supply. Among other things, all other machinery and tools are provided by Party B. ..

Six, the time limit for a project requirements:

1, construction period: 201April 310—2065438+May 25, 2003.

2. According to Party A's general, monthly and daily construction schedule and the construction tasks assigned by the constructor, Party B shall complete it within the time limit specified in the list. If Party B fails to complete the project on schedule, Party A shall have the right to punish Party B accordingly, with a fine of 500- 1000 yuan for each day of delay.

Seven, quality standards and acceptance requirements:

1. During the construction of this project, Party B shall strictly implement the current national standards and the quality acceptance evaluation standards of this project in the region. After the completion of each construction site or working procedure, Party B shall report to Party A for re-inspection and acceptance, and conduct actual measurement according to the national standard (GB 50300-2001+0) for quality inspection and evaluation standards of this project.

2. According to the Regulations on the Management of Construction Projects, Party B shall be responsible for the quality of the projects contracted by Party A, and Party B must carefully organize the construction according to the technical and quality disclosure of the design institute, Party A, the supervisor and relevant departments. If there is any problem, Party A must obey Party A's rectification opinions and make rectification within a time limit. If Party A fails to make rectification within the time limit, Party A has the right to impose a fine on Party B. Due to Party B's poor construction quality and repeated reminders, Party A has the right to terminate the contract, and Party B shall bear the consequences caused this time.

3. Party B has the obligation to protect all completed projects and finished products on site. If there is any damage, Party B shall repair it to its original state at its own expense.

4. In the self-contracted subdivisional work, there is an obligation to protect the finished product. During the warranty period, if the ceiling is uneven or falls off, Party B shall repair it for free.

5, the overall quality of construction must meet the quality requirements between examples.

6. If the project constructed by Party B fails to meet the above quality standards, safe production and civilized construction, and the construction progress is seriously lagging behind, Party A will impose a fine on Party B. ..

Eight. Payment terms:

Party B shall pay the living expenses during the construction period, 55% after the completion of the construction and 100% after the completion acceptance.

Nine, health:

1, do a good job in the construction site after work every day, clean the environment inside and outside the dormitory, and ensure that the construction site is civilized and tidy, and the living quarters are clean and hygienic.

2. Clean up the garbage after construction.

X. Man-made safety accidents during the construction period shall be borne by Party B. 1 1. Fighting and collective disturbances are strictly prohibited. If it happens, Party A will fine Party B 200-500 yuan each time.

12. This contract is made in duplicate, with each party holding one copy, and shall come into effect after being signed by both parties. After the expiration of the warranty period, the warranty terms will automatically expire.

Party A: Party B:

Authorized Agent: Authorized Agent:

Date: Year Month Day

Villa renovation contract model 5

Party A: _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _

Party A, store operator, _ _ _ _ _ _ _ _ _ _ _ _ _ store operator.

Article 1: Decorate the website

Store _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 2: Decoration period

The renovation period starts from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 3: Decoration deposit

Before entering the site for renovation, Party B shall pay the renovation mortgage of RMB to the commercial building management office. After the renovation is completed, the renovation mortgage will be returned to Party B without interest after one month.

Article 4: Decoration specifications

1. Party A has the right to review the store decoration plan proposed by Party B, and Party B can only carry out the decoration after obtaining the written consent of Party A. ..

2. Party B's decoration plan must specify the location, scope, content and other detailed information.

3. All expenses such as water, electricity and garbage removal during the renovation period shall be borne by Party B. ..

4. If Party B causes damage to the commercial house and other people's facilities and equipment during the renovation, Party B shall bear all responsibilities and all maintenance expenses.

5. All decoration and renovation works of Party B must be completed within the time limit specified by Party A, otherwise, the liquidated damages will be _ _ _ _ _ _ _ _ _ _ _.

6. If Party B needs to decorate the store (including installing fixtures in the site), it shall obtain the written consent of Party A in advance. Without written consent, Party B shall be responsible for restoring the original state and compensate for the losses caused to the Commodity House.

7. If Party B needs to transform the electric power system of the store or add lighting facilities, it must be reported to the commercial building management office for review. After a written reply, the construction shall be carried out in strict accordance with the _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ In case of unauthorized construction, Party B will be fined _ _ _ _ _ _ _ _ _.

8. Party B's decoration and renovation of the store shall not adversely affect the safety of the main structure of the building, the use safety of pipelines such as fire fighting, circuits and air conditioning, and the overall beauty, and shall not affect the operation of Party A or a third party, otherwise Party B shall immediately correct it and compensate for the losses caused to Party A and the third party.

9. The garbage and waste generated by Party B's decoration must be cleaned up in time to avoid affecting the beauty of the overall environment in the commercial building, otherwise a fine of RMB will be imposed.

10. Party B shall not drill holes in the walls and floors of the store, or directly install decorations or metal pendants on the walls. In case of violation, a fine of _ _ _ _ _ _ will be imposed.

1 1. The materials used in Party B's decoration project must meet the national requirements for fire prevention and environmental protection.

Article 5: Others

This contract shall come into effect as of the date of signature and seal by both parties. This contract is made in duplicate, one for each party.

Party A: _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Villa renovation contract model related articles:

★ How to write the decoration design contract agreement?

★ Model villa agreement

★ Five renovation contract samples of urban houses.

★ Decoration engineering contractor contract template

★ Bao Qing worker renovation contract

★ 5 pieces of practical villa sales contract model

★ 202 1 standard design contract template

★ Make clear the packaging of renovation contract samples.

★ Five lease contracts for villa houses.

★ renovation contract