Pure contracting project contract

In today's society, people pay more and more attention to contracts, and the status of contracts cannot be ignored. Signing a contract can make both parties promise and perform cooperation in a standardized way. I believe many friends are very upset about the contract to be signed. The following is a sample of pure contracting project contracts (8 selected) compiled by me for your reference only. Let's have a look.

Pure contracted project 1 Contract: _ _ (hereinafter referred to as Party A)

Contractor: _ _ _ (hereinafter referred to as Party B)

In accordance with the Economic Contract Law of the People's Republic of China, the Urban Planning Law of People's Republic of China (PRC) and relevant regulations, both parties reach an agreement through consultation and sign this contract for mutual compliance.

I. The construction area of this project is _ _ ㎡.

Second, before the project starts, Party A must make a good job of leveling the construction site and provide a full set of construction drawings.

Three, according to the national time limit for a project quota and use needs, the total project duration is agreed to be _ _ _ days (calendar _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ ..

Four. Before construction, Party B must be qualified by the leading group before construction.

5. Party B must carry out the construction in strict accordance with the drawings. Before construction, Party A shall conduct design disclosure or joint examination. If Party B finds design errors and unreasonable places in the construction process, it shall notify Party A in advance, and Party A will contact the design and issue a change notice.

6. All building materials provided by Party A must be qualified, otherwise Party B has the right to refuse to use them. The main building materials must also have quality certificates, and all materials must be transported to the construction site. The materials purchased by Party B must also meet the quality standards specified in this article. In case of quality accidents during construction, Party B shall report to Party A in time and take remedial measures, or invite the design and leading group to study and deal with them.

Seven, this project from the date of completion by Party B in accordance with the provisions of the project guarantee.

Eight, project payment details:

1. The contractor's total salary is based on RMB yuan, the bottom RMB yuan, the second RMB yuan, the third RMB yuan, the top RMB yuan after completion, the cash RMB yuan after painting is qualified, and the remaining RMB yuan as the deposit.

2. In case of quality accident during construction, Party B shall bear the responsibility.

9. Party B is solely responsible for the safety production during the project construction, and Party A will not bear the economic and legal responsibilities for any safety accidents, but Party A must take out construction insurance for Party B, and Party B shall be responsible for all accidents in its own construction.

X this contract is made in duplicate, one for each party and the leading group.

XI。 Once this contract is signed by both parties, both parties shall abide by it and neither party shall violate it. In case of contract disputes, both parties shall settle them through consultation. If negotiation fails, it may apply to the contract arbitration organ for arbitration or bring a lawsuit to the people's court.

12. For matters not covered, Party A and Party B may settle them through consultation or sign supplementary terms.

Party A (signature): _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Phone number: _ _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ Phone number

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Contract II of Pure Contracting Project: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

Party A builds its own house and contracts it to Party B. Through negotiation, both parties hereby agree on the following terms:

1. Project overview: The basement, the first floor and the mezzanine of this project are all frame structures.

The second, third and fourth floors are brick-concrete structures;

2. Party A will contract out the main part to Party B, and the civil part: excluding steel workers, the main part and underground area exceed 0. 72 yuan/m2;

3. Settlement method: after the completion of the main project, the settlement will be based on the actual output, and the selected part will be calculated according to the actual area.

4. Payment method: one payment on the first floor, and one-time payment within ten days after the completion of the project.

5. At the request of Party A, Party B shall construct according to the drawings, and the quality shall be made according to Party A's requirements. ..

Safety construction of intransitive verbs: Party B shall always carry out safety construction and inspection, and Party A shall not bear any responsibility for accidents (except for major problems).

Seven. Matters not covered in this agreement shall be negotiated by both parties.

Eight. This agreement is made in duplicate, and both parties shall abide by it.

IX. This Agreement shall come into force as of the date of signature, and shall be automatically terminated after the subject completes the payment.

Party A (signature): _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Phone number: _ _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ Phone number

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Third Contract of Pure Contracting Project: _ _ _ _ _ _ _ _ _ _ _ _

Contractor: _ _ _ _ _ _ _ _ _ _ _ _

In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reached an agreement on project contracting and signed this contract.

I. Article 1: Overview of the Project

The contracted project of lakeside slope protection project is contracted to Party B, and the construction is contracted with materials. The total length of lakeside slope protection is calculated in meters.

Two. Article 2: Construction Scheme

1, slope protection

(1) The basement is meters wide and meters thick, and it is gradually closed to the height of meters from bottom to top. Cold-drawn brick belts are needed for the stressed parts, and the external walls should be polished (cement numbers 42 and 5, and the bricks should be blue bricks or red bricks with good quality).

(2) Demolition of three houses next to the toilet for access.

(3) After completion, the fence is about10m.

(4) The gap between the wall and the bank shall be tamped with soil, and a proper amount of leaking pipes shall be added to the wall.

Three. Article 3: Term of Contract

1. The construction period is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. In case of force majeure during construction, or Party A requests Party B to stop work, the construction period will be postponed accordingly.

Four. Article 4: Price and Payment Method

1, and the total contract price of the project is _ _ _ _ _ _ _ yuan.

2. The above-mentioned total contract price is lump sum price, including all work contents, labor and materials contracting and all other expenses (including house demolition and fence) of this contract, and Party A does not need to pay any more expenses to Party B. ..

3. Payment method: RMB will be paid after the completion acceptance, and the rest will be paid after one year (counting from the date of acceptance) except for 5% of the total amount.

Verb (abbreviation of verb) Article 5: Obligations of Party A.

1. Allocate project funds to Party B according to the contract.

2. Assist in coordinating matters such as temporary water and electricity use on the construction site.

Article 6 of intransitive verb: Party B's obligations

1. The contractor is responsible for supervising and inspecting the quality, progress and safety of the project, handling daily related matters and ensuring the safety and stability of the project construction.

2. The contractor must complete the contracted project and shall not subcontract it to others.

Seven. Article 7: Construction Safety

The contractor shall abide by the relevant provisions of the project construction safety production management, organize the construction in strict accordance with the safety standards, and take necessary safety protection measures to eliminate the hidden dangers of accidents.

Party B shall bear all responsibilities and expenses caused by accidents in the construction process.

Eight. Article 8: Acceptance

The project completion acceptance shall be based on the construction scheme and quality acceptance standard. If the acceptance is unqualified, Party B shall be responsible for rework for free.

Nine. Article 9: Liability for breach of contract

1. Party A shall pay the project payment in time as agreed in this contract. In case of overdue, Party A shall pay liquidated damages to Party B (the interest shall be calculated according to the bank loan interest rate of the payable amount for the same period).

2. If Party B fails to complete the project on schedule due to reasons other than Party A's or force majeure, Party B shall pay liquidated damages of 1% of the total project amount to Party A for each day overdue; If the overdue period exceeds ten days, Party A has the right to unilaterally terminate the contract.

X article 10: others

This contract was signed by both parties on.

Employer (Party A) (Seal) _ _ _ _ _ _ _ _ _ _ _ _

Authorized agent (signature or seal): _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _

Contractor (signature or seal): _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A: (hereinafter referred to as Party A) _ _ _ _ _ _

Party B: (hereinafter referred to as Party B) _ _ _ _ _ _ _

Party A contracted 750㎡ interior decoration on the second floor of Building B in Phoenix to Party B. In order to clarify their respective responsibilities, both parties reached the following terms through negotiation.

Article 1 Project name:

Article 2 Project Location:

Article 3 Project Content: Interior Decoration of Early Education Center (see internal list for details)

Article 4 Contracting methods: contracting labor, materials and everything.

Article 5 Project cost: Budget price: six hundred and seventy-eight thousand four hundred and fifty-six Yuan only (678,456.0 Yuan). After verification by both parties, the final total project price is six hundred and twenty thousand yuan only (620,000.0 yuan only). If the drawings remain unchanged or Party A does not increase the total project price of other projects, it will remain unchanged.

Article 6 Contract term: Commencement date 1 year, April 20XX, and completion date, June 20, 20XX, with 80 working days. Both parties shall confirm whether the construction can be carried out every day. If there are other objective factors affecting the progress of the project, the construction period can be postponed accordingly.

Article 7 Payment method: Party A shall pay 20% of the total price, about RMB one hundred and twenty-four thousand Yuan only (65,438+024,000 Yuan only) within 65,438+00 days after Party B's personnel enter the site for construction; When more than 40% of the total engineering quantity is completed, Party A shall pay 30% of the second total price, which is about RMB one hundred and eighty-six thousand Yuan only (65,438+086,000 Yuan only); When more than 90% of the total engineering quantity is completed, Party A shall pay 30% of the total price, namely RMB one hundred and eighty-six thousand Yuan only (65,438+086,000 Yuan only). Party A shall pay the remaining amount within 20 working days after the completion and acceptance of all projects.

Article 8 Design change: If it is necessary to change the drawings and projects during the construction, both parties shall reach an agreement through consultation, and Party A shall bear the increased cost of the change.

Article 9 Project quality: Party B must strictly follow the drawings, strive for perfection, strive for excellent projects, and do not cut corners and shoddy products, which will affect the project quality.

Article 10 Responsibilities of Party A and Party B:

Party A's responsibilities:

(1) Party A shall provide power facilities at the construction site free of charge.

(2) Party A shall pay the project payment on time and shall not delay the payment, so as not to delay the construction period.

Responsibility of Party B: Party B must complete the project on time within the specified time, and Party B shall be responsible for the safety accidents caused by improper construction operation.

Article 11 Liability for breach of contract: Party A fails to pay the decoration payment on time, and is fined 1 000 yuan, and delays the construction period, and is fined 1 000 yuan.

Article 12 Contract disputes: Matters not covered in the above terms shall be settled by both parties through consultation. In case of dispute, it shall be decided by the local people's courts of both parties.

Article 13 This contract is made in duplicate, with each party holding one copy, and shall come into effect after being signed by both parties.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contract 5 of pure contracting project (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After friendly negotiation, Party A decided to entrust Party B with the decoration. In order to protect the legitimate rights and interests of both parties, combined with the specific conditions of this project, the two parties reached the following agreement for common compliance.

1, project overview

(1) Decoration construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(2) Decoration construction content: See the attachment for details.

(3) Contracting method: quantity contracting.

(4) Construction period: starting from: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. Overdue completion, according to the daily compensation of RMB yuan.

2, the project price and settlement agreement

(1) Total project price: _ _ _ _ _ _ _ Yuan, in words (RMB): _ _ _ _ _ _ _ _ _ _ _ _ _.

(2) The payment method of project funds is as follows:

1) When the budget design is approved for the first time, 30% of the total project cost will be paid, totaling _ _ _ _ _ _ _ _ yuan.

2) Pay 70% of the total project cost on the day of the second completion acceptance, totaling RMB _ _ _ _ _ _.

3) The project quality warranty period is 1 year. The warranty period is calculated from the date of signing the completion acceptance.

3. Material supply and decoration process agreement

(1) If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If there are quality problems or specification differences in the materials and equipment provided by Party B, resulting in engineering losses, Party B shall bear the responsibilities.

(2) During the construction, Party A shall contact Party B in advance when proposing design modification opinions and adding or subtracting engineering projects. The construction of this project can only be carried out with the consent of both parties, thus affecting the completion date, and both parties agree.

(3) In the process of construction, Party B shall take necessary safety protection and fire control measures to ensure the safety of operators and nearby residents, and prevent accidents such as pipeline blockage, water leakage, power failure and destruction of articles. In case of the above situation, it shall be the responsibility of Party A, and Party A shall be responsible for and compensate; Where Party B is responsible, Party B shall be responsible for repair and compensation.

(4) Party B shall participate in the on-site disclosure of the construction drawings or work instructions organized by Party A, organize the construction as required, complete the construction tasks with good quality and quantity on schedule, and solve all matters for which Party B is responsible, and Party B shall recognize its actions. Without the consent of Party A and the approval of the local housing management or property management department, the original building load-bearing structure, various equipment and pipelines shall not be dismantled and modified at will.

4. Dispute handling methods

Any dispute arising from the execution of the contract between the two parties shall be settled through friendly negotiation. If negotiation fails, a lawsuit may be brought to the people's court.

After this contract is signed by both parties, both parties must strictly abide by it.

Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Contract 6 of pure contracting project (hereinafter referred to as Party A):

Contractor (hereinafter referred to as Party B):

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, Party A has contracted _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

I. Projects

1, project name:

2. Project location:

3. Project content:

4. Form of contract:

5. Project duration:

The total duration of this contract is _ _ _ _ _ _ _ _ _ (calendar days), and the commencement date is _ _ _ _ _ _ _ _ _ _.

6. Project price:

7. Payment method:

Second, the construction period is postponed.

1, due to force majeure factors such as typhoon, rainstorm and hurricane;

2. The construction period is delayed due to force majeure.

3. If the construction period is delayed due to Party B's reasons, it shall not be required to extend the construction period.

Three. Supply and procurement of building materials and equipment

1. Engineering materials and equipment shall be purchased by Party B. ..

2. The materials and equipment purchased by Party B must be accompanied by product certificate and test report before they can be used in the project. If Party A thinks that the materials provided by Party B need to be reinspected, Party B shall provide the reinspect report as required. Only after re-inspection can it meet the quality requirements be used in the project; If the reinspection does not meet the quality requirements, it shall be returned, and the reinspection fee and return loss shall be borne by Party B. ..

IV. Construction and design changes

1. The design drawings, descriptions and relevant technical data signed by Party A shall be taken as the effective basis for construction, and Party B shall not modify them without authorization.

2. In order not to affect the construction progress, Party B shall first implement the changes proposed by Party A due to the use of functions, and conduct on-site visa in time.

3. The increase or decrease of design changes shall be subject to the visa form of Party A's representative, and the increase or decrease of project funds shall be confirmed by both parties through consultation.

Verb (abbreviation of verb) project acceptance

1. If the project has concealed conditions, Party B shall conduct self-inspection first and notify Party A in writing 48 hours before concealed acceptance. After the acceptance is qualified, the contractor can continue the construction under cover only after the acceptance record is signed by the site representative of Party A.. If the acceptance is unqualified, Party B shall submit it to Party A for re-acceptance after rectification.

2. The project meets the requirements of completion acceptance. Party B shall provide Party A with complete completion data and completion acceptance report (including completion drawing, concealed works visa, site visa and warranty, etc.). ) according to the relevant provisions of the national project completion acceptance. If it passes the acceptance, both parties shall hand it over; If the acceptance is unqualified, Party B shall rework it in time, and the expenses shall be borne by Party B. If the rework causes delay in the construction period, Party B shall bear the corresponding liabilities for breach of contract.

Six, safety construction

Party B shall abide by the management regulations on safety production in engineering construction, organize construction in strict accordance with safety standards, and take necessary safety protection measures to eliminate hidden dangers of accidents. The responsibility for accidents caused by Party B's ineffective safety measures and the expenses arising therefrom shall be borne by Party B. ..

Seven. quality assurance

1. The warranty period of this project is _ _ _ _ years, counting from the date when the project is completed and accepted.

2. During the free warranty period, Party B shall ensure smooth communication so that Party A can get in touch with Party B at any time. After receiving the maintenance notice from Party A, Party B shall arrive at the site within _ _ _ _ hours and handle it in time. If Party B changes the warranty personnel or contact telephone number, it shall notify Party A in time. If Party B delays shirking due to poor communication or deliberate non-answer, Party A will regard Party B as violating the warranty responsibility and have the right to solve it by itself, and Party B will bear all the expenses and add 10% service fee.

3. The quality of this project must reach the standard of _ _ _ _ _ _ _ _.

Eight. responsibility for breach of contract

1. Party B shall not modify the drawings without authorization. If the drawings need to be modified, it must be decided through consultation with Party A..

2. Party A shall not delay the payment of project funds. If Party B can't work on time due to Party A's default in project payment, Party A shall bear the losses by itself.

3. Any breach of this contract by Party A and Party B shall be a breach of contract and shall be liable to the observant party for breach of contract.

Nine. Dispute mediation

In case of any dispute arising from the performance of this contract, both parties shall settle it through consultation. If negotiation fails, both parties shall choose one of the following methods:

(1) Apply for arbitration to the arbitration institution where the project is located;

(2) Bring a lawsuit to a court with jurisdiction.

X. supplementary provisions

1. This contract shall come into effect after being signed and sealed by both parties, and shall automatically become invalid after the contract is fulfilled.

2. This contract is in duplicate, with each party holding one copy.

3. Matters not covered in this contract shall be settled by both parties through consultation.

Party A (signature and seal):

On behalf of:

Authorized representative (signature):

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (signature and seal):

On behalf of:

Authorized representative (signature):

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Pure contracting project contract 7 Party A: _ _ _ _ _ _ _

Party B: _ _ _ _ _ _

Through negotiation between both parties, the new hydropower project of Building 8- 14, Phase I and Phase II of Yiliang Century Liangcheng is contracted out to Party B for installation in the form of single package, as follows:

1. Install all joints of brick wall and all secondary conduits on brick wall, and the labor cost for installation and piping is RMB.

2, play all trough and sink, with each _ _ _ yuan labor cost calculation.

3. The labor cost for installing the strong and weak current boxes and pipes shall be calculated at RMB _ _ _ _ _ _ _ _ _ _

4. The above dimensions are subject to the horizontal line.

1. Jintong socket is 65 points below the horizontal line 1 meter.

Second, the switch is at 45 o'clock on the horizontal line.

Three, lighting control box to the horizontal line 55 points.

Fourth, the weak box is 45 points below the horizontal line.

5. If the above installation fails to meet the size requirements and goes out of the wall, Party B shall bear all the responsibilities due to reasons such as inadequate secondary piping and pipeline blockage. If the project quality is not up to standard or the wasted materials are compensated.

6. Tools shall be brought by Party B. ..

7. During the installation period, only the living expenses will be about 1000 yuan. After the installation is completed, Party B shall pay 70% of the labor cost after the supervision and acceptance, and all labor costs shall be paid within 60 days after the completion of the project.

8. Party B shall be responsible for safety. Party A does not undertake any safety responsibilities. Do not drink, fight, make trouble when entering the construction site, and do not take things home from the construction site. Party B shall be responsible for any of the above safety accidents.

9. In case of shutdown or waiting for work due to shortage of personnel and technicians, Party A has the right to take back the project without paying all the expenses.

10. This contract is made in duplicate, with each party holding one copy. The contract held by both parties has the same legal effect, and it will take effect from the date of signing by both parties, and will automatically become invalid after all the project funds are paid.

Party A (official seal): _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Pure contracting project contract 8: _ _ _ _ _ _ _ _ _ _ _

Contractor: _ _ _ _ _ _ _ _ _ _ _

In order to ensure the construction quality of _ _ _ _ _ _ _ _ _ _ _

1. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Construction area (project form) _ _ _ _ _ _ _

3. Construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4, time limit for a project:

(1) Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;

(2) Completion: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(3) The total duration of the contract is * * * days.

5. Form of contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Engineering quality standard: _ _ _ _ _ _ _ _ _ _ _ _ _

7. Project price: * * RMB _ _ _ _ _ _.

8. Payment method: pay _ _ _ _% of the contract amount after the contract comes into effect, totaling _ _ _ _ _ _ _ _ _ _; After the project completion acceptance, pay _ _ _ _% of the project price, totaling _ _ _ _ _ yuan; The quality assurance fee is RMB yuan, which will be paid after the expiration of the quality assurance period.

9. Warranty period: _ _ _ years.

10, responsibilities and obligations of both parties

(1) Responsibilities and obligations of the employer.

1) Provide the contractor with good construction site, roads, water and electricity supply and meet the starting conditions. Solve the adjacent relations and disputes that need to be solved by the employer in the construction;

2) Supervise and manage the project quality and material quality in the construction process, and supervise the project progress;

3) Provide the contractor with construction drawings, coordinate points and elevation points;

4) Allocate funds to the contractor on time, and conduct acceptance and settlement;

(2) The responsibilities and obligations of the contractor.

1) Carry out the construction according to the owner's requirements and drawings;

2) Complete the construction task as scheduled;

3) Accept the owner's technical guidance and quality standard requirements;

4) Responsible for the protection of materials and equipment provided by the Owner;

5) Educate the construction personnel to take good care of Party A's materials and not to steal or damage them;

6) Take responsibility and expenses for all safety accidents in the construction process;

1 1, others

(1) This contract shall come into effect after being signed and sealed by both parties, and shall be valid until the warranty period expires.

(2) Matters not covered in this contract can be settled by both parties through negotiation and a written supplementary agreement can be signed. The supplementary agreement has the same legal effect as this contract. If negotiation fails, it shall be submitted to the people's court of Cao County, Shandong Province for litigation.

(3) The annex to the contract is an integral part of the terms of this contract. This contract and its annexes are made in duplicate, one for each party, with the same effect.

Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.