Car repair shop paint contract

Auto Repair Shop Paint Contract 1 Party A:

Party B:

Based on the principle of mutual benefit, honesty and trustworthiness, Party A and Party B have reached the following agreement through friendly negotiation:

I. Product quality

1. The paint surface of the whole vehicle is glossy, free from any defects, paint hanging and paint leakage, so as to ensure that the paint of the whole vehicle has no obvious quality problems within one year.

2. Party B's paint and accessories must meet the national industry quality standards;

3. Before the construction, Party B shall provide the process flow standard, and the construction can only be started after it is approved by Party A;

4, paint color, according to the color approved by Party A, shall not be changed.

Two. Responsibilities undertaken by Party A

1. Provide Party B with workplace, painting room, drying room and trolley that can meet the production tasks.

2. Water and electricity facilities and expenses.

3. Party A provides accommodation for Party B's personnel, and Party B's personnel bring their own luggage.

4. Provide Party B with the production task schedule for the next month every month.

5. In the first three months, Party A shall guarantee that the monthly output of Party B shall not be less than 65,438+000 units, and the shortfall shall be settled at 65,438+000 units/month.

Three. Responsibilities undertaken by Party B

1. If the product quality fails to meet the requirements, it shall bear all corresponding economic losses;

2. Ensure the production schedule and deliver the car in time according to the requirements of Party A (Party A and Party B shall negotiate the emergency order, and Party B shall try to complete it within the specified time without delay).

3, civilized construction production, keep the workshop clean and tidy, the workplace clean and hygienic, Party A will check the fine according to the relevant rules and regulations, and deduct it from the project payment.

4. All employees of Party B shall strengthen organization and management, abide by laws and regulations, and carry them out.

Implement Party A's relevant rules and regulations, adhere to safety in production, and compensate Party A's equipment and facilities for damages according to the price in case of industrial accidents or illegal acts in the factory.

5. If Party A causes paint damage to the whole vehicle or repairs the vehicle, both parties shall negotiate pricing.

IV. See the attached table for accounting standards. (The contract price of coatings varies with the price of raw materials and market conditions).

Verb (abbreviation of verb) settlement method

1. Party B shall go through the settlement formalities with Party A's finance on the basis of Party A's receipt before 30th of each month, issue bills, and settle the payment before 10 of the following month.

2. The price of a single unit (including sealant application) 1 190 yuan per unit;

The monthly output reaches 300 sets/month, 1080 yuan/set;

The monthly output reaches 500 units/month, 960 yuan/unit.

Liability for breach of contract of intransitive verbs

1. During the term of the agreement, neither party may terminate the agreement halfway. In case of breach of contract, the breaching party must bear corresponding responsibilities.

2. Either party may terminate this Agreement and bear corresponding economic responsibilities if it commits any of the following acts.

A. Party B's car paint has serious batch quality problems.

Party B's failure to complete Party A's production tasks has caused great economic losses to Party A. ..

C. Party A seriously delays Party B's payment.

Seven. For matters not covered, both parties shall negotiate and sign a supplementary agreement.

8. In case of any dispute between the two parties, both parties may bring a lawsuit to the court through friendly negotiation.

Nine. This agreement shall be valid from the date of the month to the date of the month.

X one month before the expiration of the agreement, both parties shall discuss the annual cooperation agreement in advance. If Party B is not prepared to cooperate, it shall notify the other party two months in advance, otherwise Party B shall bear all the economic losses caused to Party A from this. ..

Eleven, after the termination of the contract, pay off all the money within six months.

12. This agreement is made in duplicate, one for each party, and shall come into force after being sealed and signed.

Party A: Shan Hao Yu Vehicle Co., Ltd. Party B:

Representative signature (seal): Representative signature (seal):

Date:

Car repair shop paint contract II (hereinafter referred to as Party A) ID number:

(hereinafter referred to as Party B) ID number:

In accordance with the provisions of "People's Republic of China (PRC) Contract Law" and "Regulations on Construction and Installation Engineering Contracts", and in combination with the situation of this project, this contract is concluded by both parties through consultation:

Article 1 General situation of the project

1, project name:

2. Project location:

3. Contract scope: interior wall painting construction.

4. Contract method: 1, light industry contract; 2. Contracting projects and materials.

5. Project price: RMB.

6. Project duration: The project duration is.

Article 2 Obligations of Party A

Provide Party B with the construction requirements or practices confirmed by 1 and 1 days before the start of construction, and make disclosure to Party B;

2. Send Party A's representative to the construction site to be responsible for the performance of the contract, supervise and inspect the quality and progress of the project, and handle the acceptance and other matters;

3. Coordinate related matters on the construction site.

Article 3 Obligations of Party B

1. Participate in the on-site disclosure of construction requirements or work instructions organized by Party A, draw up construction plans and progress plans, and submit them to Party A for approval;

2. The construction team leader is the representative of Party B at the construction site, responsible for the contract performance and the safety supervision and inspection of the project quality and progress.

Check; Organize the construction according to the requirements, complete the task with good quality and quantity according to the construction period, and solve all matters that Party B is responsible for;

3. During the project construction, Party B shall abide by the relevant regulations of Party A, and shall have the obligation and responsibility to safeguard Party A's reputation and interests, and shall not do anything detrimental to Party A;

Article 4 Project Quality and Acceptance

1, project quality: just like the comparison between Tiexikang and Lishe.

Article 5 Payment Terms

Pay 30% of the total project cost every day from the commencement diary. After completion, only RMB will be used as the maintenance fund (overdue) and must be paid within days.

Article 6 Dispute settlement

Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, it shall be arbitrated by the Arbitration Commission or awarded by the people's court.

Article 7 This contract shall come into effect as of the date of signature and seal by both parties, and each party shall hold one copy.

Party A: (Seal) Party B (Seal) Tel:

Car Repair Shop Paint Contract 3 Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

In order to successfully complete the construction task of this project, ensure the high-quality project, create a safe and civilized double-standard chemical field and give full play to the enthusiasm of the construction team, the project department implements the internal contract responsibility system. Upon Party B's request for Party A's consent, Party B will contract the decoration works (painting and white cement decoration works) of this project. In order to clarify the responsibilities of both parties, the following contract is signed through consultation, and both parties must strictly abide by it.

I. Project Location and Name:

A bid section of Meilanyuan Community on Danghu Road.

Second, the project content and scope:

Engineering (materials shall be borne by Party B).

Third, the settlement method:

According to actual area: white cement ceiling, white cement wall, whitewashed wall and whitewashed wall.

Fourth, the quality requirements:

(1) Party A requires that this project must achieve high quality.

(2) Party B promises to ensure the high-quality project of this project (subject to quality supervision and evaluation) and operate according to the requirements of Party A's quality commitment letter.

Five, the time limit for a project requirements:

Party B must complete the production schedule plan formulated by Party A on time.

Payment method of intransitive verbs:

According to the progress of the project, pay 50% of the project cost every month, and pay the total amount after the project is completed. After the completion acceptance, the countersigner will sign the remaining amount.

Seven. Responsibilities of both parties:

(I) Party A's responsibilities

1. Party A is responsible for technical disclosure, supervision and inspection of Party B's quality, safety and civilized construction, recheck various specifications, sizes and quantities, and put forward rectification opinions.

2. Party A is responsible for conducting safety education and safety knowledge examination for Party B. ..

3. After the materials enter the site, Party B must be responsible for unloading and stacking them neatly.

4. Party A shall be responsible for the temporary accommodation and meals of Party B's personnel (the meals shall be borne by Party B).

5. Party A is responsible for registering the temporary population of Party B's personnel and assisting Party B to handle the necessary documents (the expenses shall be borne by Party B).

6. In case of any of the following circumstances, Party A shall have the right to terminate the contract or withdraw, and Party B shall compensate Party A for the corresponding economic losses.

If the quality fails to meet the quality standards, it will be fined 10% of the project cost;

B. Due to the responsibility of Party B, the construction period is delayed and a fine of RMB/day is imposed;

C. If a major safety accident occurs in Party B's illegal operation, the expenses shall be borne by Party B, and a fine of xx yuan shall be imposed;

D. Economic losses caused by accidents and fights due to violation of public security management shall be compensated by Party B, with a fine of 1 1,000 yuan/time.

7. Party A shall provide internal scaffolding and iodine tungsten lamp, and Party B shall be responsible for other tools.

(II) Party B's responsibilities

1. Party B must carry out the construction according to the construction drawing (minutes of joint hearing and change contact list), operate according to the specifications, and actively accept the quality supervision and management of the quality supervision department, the owner, the supervisor and Party A. ..

2. Party B must carefully organize the construction according to the standards of high-quality projects. Before starting construction, Party B must prepare a reasonable construction plan and designate a special person to be responsible for the quality. If quality problems are found, they should be rectified in time.

3. Party B must form a construction team with excellent quality and instill quality awareness into every member of the team. In case of the following quality problems, Party A will impose a fine, which will be deducted from the project payment of the month.

4. Party B must complete the schedule arranged by Party A, and shall not delay the construction period, and shall be equipped with labor according to Party A's requirements, and shall not stop work without reason. Stop work without reason, and fine 500 yuan every time.

5. Party B must strictly implement the safety rules and regulations formulated by Party A, attend the safety education and related meetings organized by Party A, take part in the safety knowledge examination, conduct safety education and safety disclosure to the team members every day, urge the team members to use safety labor protection articles, conduct safety activities once a week, keep a safety diary and resolutely put an end to casualties. In case of industrial accidents due to Party B, all losses and expenses shall be borne by Party B, Party A shall be responsible for Party A's reasons, and other teams and individuals shall bear all expenses.

6. Party B shall actively cooperate with Party A to create a "double-bid" site, reasonably pile up materials, put an end to the phenomenon of "disorder and dirt" on the site, do a good job in cleaning up the leftovers, and shall not scatter them anywhere, clean up the site after work, and shall not refuse to clean up the leftovers for any reason. Party A will be fined 200 yuan/time for urging for many times.

7. The person in charge or contractor of Party B must personally command at the construction site 90% of the time, otherwise the project progress payment will be withheld or stopped.

8. Party B is responsible for the safety management of Party B's personnel at the construction site. No picking fights, fighting, gambling or bringing children and construction-related personnel into the construction site. It is forbidden for men and women to live together in the dormitory. If the above things are found, a fine will be imposed according to the Regulations on Punishment of Dormitory Management, and it will be severely sent to the local public security organ for handling (Party A will not arrange girls' dormitories and couples' rooms).

9. Party B must be familiar with the operation procedures of various machines in this type of work, connect the electricity safely and take protective measures according to the standards. Illegal operation is strictly prohibited. Each machine must designate a special person to be responsible for fire prevention and extinguishing. If illegal operation is found, the fine will be 30- 100 yuan/time.

10, Party B must save raw materials, make full use of floor ash and other raw materials, and shall not waste them. The collected materials and tools shall be properly kept and returned in time, and all lost materials shall be compensated by Party B according to the price.

Eight, reward and punishment standards

1. This contract includes a quality award.

2. The standard of liquidated damages in this contract has been stipulated in the above detailed rules.

Nine. Other explanations

1. All fines will be deducted from Party B's monthly salary. After Party A verbally puts forward the contents of the fine, it will issue a fine, which is valid without the signature of the monitor.

2. For matters not covered in this contract, both parties shall sign a supplementary agreement through consultation.

3. This contract is made in quadruplicate, one for Party A and one for Party B, which shall come into effect after being signed by both parties and become invalid after the project is completed.

Party A:

Party B:

On behalf of:

Date:

Car Repair Shop Paint Contract 4 Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

ID number:

Home address:

Contact telephone number:

Through friendly negotiation between Party A and Party B, in accordance with the provisions of the Contract Law of People's Republic of China (PRC), the two parties have reached the following labor contract agreement on Party B's contracting of painting and painting projects of Party A's after-sales department on the principle of fairness and voluntariness, in order to clarify the rights and obligations of both parties.

I. The term of this contract starts from _ _ _ _ _ _ _ _ _ _ _ _ _.

Two. Rights and obligations of Party A and Party B

1. Rights of both parties

(1) Rights of Party A

(1) Party A has the right to conduct various administrative management on Party B, such as hygiene, safety, use of raw materials and smoking. Such as hygiene, safety, use of raw materials and smoking. , Party A has the right to deal with it according to the relevant system of the company; Smoking is prohibited in the workshop to avoid fire. If Party A suffers losses due to smoking and other reasons, Party B shall bear all the losses.

② Before Party A and Party B sign this contract, Party A has informed Party B of the nature of this post, and Party B clearly understands the professional nature of this post, and voluntarily accepts the painting work of Party A's after-sales department; Party A has nothing to do with this.

(3) Party A has the right to require Party B to operate according to the painting process, wear corresponding labor protection tools at work, and prohibit illegal operation. If Party B fails to operate illegally according to the company's requirements, it will cause losses to Party A.. Have the right to claim compensation from Party B. ..

(4) Party A gives Party B monthly or temporary production tasks, and Party B shall complete the production tasks with good quality and quantity on time according to Party A's requirements. Party A has the right to impose economic penalties on Party B's late delivery, and every day of delay will affect the delivery schedule, deducting Party B 100 yuan, and all expenses arising from Party A's late delivery shall be borne by Party B. ..

(2) Party A's obligations

(1) During the contract period of Party B, Party A shall provide Party B with corresponding protective tools according to the post requirements. If Party A fails to provide protective tools in time as required, Party B has the right to request Party A to provide them in writing; If Party A fails to provide protective tools in time after receiving the written notice from 1, this contract may be terminated.

(2) Party A shall provide Party B with equipment, tools, raw materials and venues required for production free of charge.

(3) Party A shall pay the contract fee in full to Party B on _ _ every month according to the company's financial system, and the payment time shall be postponed in case of weekend and other reasons.

2. Rights and obligations of Party B

(1) Rights of Party B

(1) During the validity period of the contract, Party B has the right to request Party A to provide corresponding protective equipment for this position. If Party A fails to provide protective tools in time as required, Party B has the right to request Party A to provide them in writing; If Party A fails to provide protective tools in time after receiving the written notice from 1, this contract may be terminated.

② Within the validity period of the contract, Party B has the right to ask Party A to equip it with equipment, tools, raw materials, venues, etc. For free production. If the construction period is delayed due to Party A's reasons, Party B will not bear any responsibility.

(3) Party B has the right to require Party A to pay the contract fees in full and on time.

④ During the contract period, the equipment provided and added by Party B shall be owned by Party B personally.

(2) Obligations of Party B

(1) Party B shall abide by Party A's administrative rules and regulations, and some rules and regulations, such as attendance, can be handled flexibly according to Party A's work needs.

(2) Party B shall operate according to Party A's painting process, and wear corresponding labor protection tools when working, and it is forbidden to operate illegally. If Party B violates the company's requirements and causes losses to Party A, Party A has the right to demand compensation from Party B..

(3) Party B shall complete the production tasks with good quality and quantity on time as required by Party A, and Party A has the right to impose economic penalties on Party B for delayed delivery. For every day of delay, Party B will be deducted 65,438+000 yuan, and all expenses arising from Party A's delay in delivery will be borne by Party B. ..

(4) Party B has the obligation to take good care of the equipment and tools provided by Party A, and arrange, rectify, clean, sweep, cultivate, preserve and secure the office environment according to the "7S requirements"; If the tools are damaged or lost due to failure to fulfill the custody obligation, Party A has the right to claim compensation.

⑤ After this contract comes into effect, Party B shall not subcontract any more; If Party B needs to send employees when he does not come to work in the company, Party B shall provide employee information to Party A for filing, and ensure the personal safety of employees, the property safety of Party A's company and the product quality.

III. Contract Fees and Payment Methods

(1) contract cost

Through friendly negotiation between both parties, Party A pays Party B the contract fee of RMB _ _ _ _ _ _ _ yuan every month. (In words:)

(2) Payment method

Party A shall pay Party B's expenses by bank transfer every month, and provide the bank account number to Party A for filing before the transfer.

Fourth, others.

1. When the contract expires, both parties shall notify the other party one month in advance whether to renew or terminate the contract.

2. Matters not covered in this contract shall be handled in accordance with relevant laws.

3. This contract is made in duplicate, one for each party, and it will come into effect after being signed and sealed by both parties.

Verb (abbreviation for verb) method of dispute settlement

1. In case of any dispute, both parties shall settle it through friendly negotiation.

2. If negotiation fails, Party A and Party B have the right to file an arbitration with the Labor Arbitration Committee where Party A is located, or directly file a lawsuit with the competent court where Party A is located.

Party A (signature of representative): Party B (signature):

(official seal) (official seal)

Date of signing:

Car repair shop painting contract 5 Party A: hereinafter referred to as Party A.

Party B: hereinafter referred to as Party B.

In accordance with relevant laws and regulations and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the contracting of architectural painting project and signed this contract for mutual compliance.

Article 1: scope and content of contracting methods

1. Contract method: labor cost, quality, construction period, raw materials, civilized construction on site.

2. Scope and content of the contract: painting of internal and external walls. Paint team work from polishing project to completion acceptance.

Article 2: Construction Period

1. Party B completed the first phase on.

; The second phase was completed on.

2. Party B must unconditionally complete the progress plan formulated by Party A on time, and timely implement the weekly plan and monthly plan adjusted by Party A according to the actual situation.

Article 3: Contract Unit Price and Payment Method

1. Contract unit price: RMB/m2.

2. Payment method: After Party B enters the site for construction, when half of the total project amount is completed, Party A shall pay% of the total project amount to Party B, and Party A shall pay% of the total project amount to Party B, and the rest shall be paid in one lump sum after on-site acceptance, and the warranty money shall be kept at%, which shall be paid in one year.

3. The project quality must meet the acceptance requirements of Party A's enterprise standards. Party B shall bear all expenses such as rework and quantity.

4. Calculation method: After the project is completed, Party A and Party B will calculate the same approved area according to the actual construction area of Party B..

This contract is made in duplicate, one for each party. Matters not covered shall be settled by both parties through consultation.

Party A (signature):

Party B (signature):

Date of contract signing:

Employer (Party A) of Paint Contract 6 of Auto Repair Shop: _ _ _ _ _ _ _ _ _ _ _

Contractor (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B, following the principles of equality, voluntariness and fairness, have reached the following contract terms on the labor cost of exterior wall coating construction of this project, which both parties shall abide by.

Article 1 General situation of the project

(1) Project name:

(2) Project location:

(3) Project content: All external wall putty and paint are roller coated.

(4) Settlement method: calculated according to the actual painting area.

(5) Contracting method: contracting for work and materials.

Article 2 Quality standards

Meet the national quality acceptance standards and meet the quality requirements of the engineering department and site supervision personnel.

Article 3 The contract budget quantities and the contract budget amount:

The budgeted quantities and amounts of this contract are calculated according to the drawings and related materials provided by the Owner, and the project area is calculated according to the actual quantities of the painting area:

Project Unit Price _ _ _ _ Yuan /m2 Total Quantity _ _ _ _ _ m2 Contract Budget Amount _ _ _ _

Article 4 Construction Conditions

The employer has the obligation to provide the contractor with the construction site, water and electricity free of charge, and provide

If the Employer fails to provide the above-mentioned construction conditions in time for the accommodation of construction personnel and the use of some construction equipment, causing losses to the Contractor and delays in the construction period, the Employer shall be responsible. Before painting construction, the contractor shall conduct disclosure inspection and acceptance on the previous working procedure. For the unqualified working procedure, the contractor may refuse to carry out the construction of the next working procedure.

Article 5 Construction personnel:

The contractor shall organize a professional painting construction team, the number of which shall meet the requirements of the project progress, ensure the project quality, obey the management of the owner unit, supervision unit and Party A, and accept the supervision of its construction quality and safety.

Article 6 Project acceptance:

After the completion of the project, Party A applies to the Engineering Department for inspection, and the Engineering Department is responsible for organizing relevant personnel to conduct inspection.

Article 7 Engineering Changes

In case of engineering change, the Employer shall issue a written notice of engineering change, and the resulting engineering change shall be calculated according to the actual engineering quantity. The employer must sign the engineering change settlement form for each engineering change as the settlement basis within three days after the engineering change notice is issued, and the construction period will be postponed accordingly.

Article 8 project settlement

The engineering quantity is calculated according to the actual engineering quantity, and accumulated settlement will be made within half a year after the project acceptance.

Article 9 This contract is made in duplicate, one for each party, and will automatically terminate upon completion.

Employer:

Contractor:

Signature time: