Engineering agreement

Collection of seven practical engineering protocol templates

In the rapidly developing society, more and more places need to use agreements, which has played a positive role in the performance of bilateral affairs. There are many precautions in the agreement. Are you sure you can write? The following are seven engineering agreements that I have compiled. Welcome to read the collection.

Project Agreement 1 Employer: (hereinafter referred to as Party A) Contractor: (hereinafter referred to as Party B)

According to the Construction Law of People's Republic of China (PRC), Regulations on Quality Management of Construction Projects and Measures for Quality Warranty of Building Construction Projects, Party A and Party B sign the quality warranty of the project through consultation.

A, after the completion of the project review system

1. After the project completed by Party B has passed the completion acceptance of relevant departments, during the quality warranty period, Party B shall take the initiative to pay a return visit to Party A or the project property management company entrusted by Party A to find out what quality defects exist in the project undertaken by Party B, so that both parties can sum up their experiences and solve them in future project construction.

2. The return visit time is once a month after the quality warranty period begins, until the quality warranty period expires.

3. The object of the return visit is Party A or the project property management company entrusted by Party A. ..

Second, the project quality warranty scope and content

1. During the quality warranty period, Party B shall undertake the quality warranty responsibility of all projects within the scope of the construction contract stipulated in the construction contract in accordance with the management provisions of relevant laws, regulations and rules and the agreement of both parties.

2. All the quality problems or other defects in various parts of the project caused by Party B, as well as the owner's related losses caused by Party B's maintenance, are within the warranty responsibility of Party B, not the responsibility of Party A. ..

Third, the quality warranty period

The warranty period is one year, and the actual warranty period is calculated from the date when the project is actually completed, accepted and delivered.

Four. Quality warranty: the quality warranty of this project is calculated as% of the total settlement price of this project.

5. Return of quality warranty money: After the warranty period expires and Party B normally performs its obligations during the warranty period, Party A will return it without interest within 7 working days.

Six, quality warranty responsibility

1. During the warranty period, Party B shall repair and replace the quality problems caused by Party B for free; In case of failure or equipment damage caused by Party A's improper use or maintenance, Party B shall be responsible for paid maintenance (materials only).

Fee, no service fee).

2. The replacement parts within the warranty period must be new parts produced by the original manufacturer. The replaced parts belong to the property of Party B, and the replaced parts become the property of Party A. ..

3. During the warranty period, under normal circumstances, Party B shall send someone to repair the accident within 48 hours after receiving the accident notice from Party A. In case of emergency repair, Party B shall immediately arrive at the scene of the accident for repair after receiving the accident notice.

4. In case of the following situations, Party A may entrust others to repair, and all expenses incurred (including but not limited to labor costs, material costs, liquidated damages and other losses caused to Party A) shall be directly deducted from the quality warranty fund by Party A, and the insufficient part shall be made up by Party B within 5 days, and the original quality warranty fund shall be made up:

(1) Party B fails to send personnel for maintenance as required by Party A or fails to do so within a reasonable period of time;

(2) After two repairs, Party B still fails to repair the same part.

5. If the equipment and materials are replaced during the warranty period, the warranty period of the replaced equipment and materials shall be recalculated from the date of replacement.

6. During the warranty period, any safety accidents caused by Party B's quality problems shall be borne by Party B. ..

7. If all losses are caused by Party B's delay and prevarication, or economic losses and legal liabilities are caused to Party A (or the property management company in charge of the project), and the total amount of relevant quality deposit is not enough to pay, Party A (or the property management company in charge of the project) has the right to recover from Party B until bringing a lawsuit to the people's court.

8. After each maintenance, Party B is responsible for cleaning up the construction site and obtaining the acceptance signatures of the owner and Party A (or property management company).

9. The above warranty return visit record and whether Party B performs the warranty responsibility shall be subject to the signatures of the owner and Party A (or the property management company). Without the signature of the owner and Party A (or property management company), Party A will refuse to pay the due warranty money.

As an annex to the construction contract, the quality warranty of this project has the same legal effect as the construction contract and expires.

(There is no text on this page)

(Party A): (Party B)

Legal representative or entrusted agent (signature): Legal representative or entrusted agent (signature):

Tel: Tel:

Handler (signature): Handler (signature):

Contract signing time:

Date, year and month

Article 2 of the Project Agreement Owner:

Contractor:

In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this building project and conclude this contract.

I. Overview of the Project

Project name:

Project address:

Project content:

Second, the project contract period

Start date:

Date of completion:

Third, the quality standard

Four. Contract price

Total project cost (amount):

Verb (abbreviation of verb) payment terms

1. After Party B enters the site, Party A shall pay xx% of the project cost to Party B, xx% in the interim and xx% after completion, and Party A shall withhold 5% of the project cost as a deposit, which shall be paid by xxxx.

2. Party B must pay 20% of the project cost to Party A as the project transfer fee.

Six, the construction requirements

Clean up all the rubbish in the original site, transport it out, fill up the site, and fill in 30 cm of black soil to keep it flat with the outdoor parking lot pavement.

Seven. Rights and obligations of both parties:

1. Party B shall not default on the wages of construction workers during the construction process, which has nothing to do with Party A's economic disputes and other disputes, and Party A shall not assume any responsibilities. Party B shall be responsible for all accidents and disability incidents during the construction, and Party A shall not bear any responsibility.

2. Fighting, drunkenness and theft are strictly prohibited in Party B's construction site. In case of such situation, Party B shall hand it over to the public security organ for handling and compensate all losses.

3. Party B must carry out the construction according to the contract requirements and ensure the construction quality and requirements. If Party A suffers from waste and loss of building materials, Party B will take double indemnity.

4. If Party B fails to carry out the construction according to the contract requirements, Party A has the right to refuse to pay the balance and clean up Party B, and the losses shall be borne by Party B. ..

Eight. If this contract is inconsistent with the original contract, the requirements of the original contract shall prevail.

Nine. This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature by both parties.

Party A:

Party B:

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In order to strengthen project management and ensure project quality and time limit, (Party A) entrusts project completion and defect maintenance to (Party B). Through negotiation, both parties have reached the following agreement:

Name and content of the first project:

(1) Project name:

(2) Project scope:

Party B's self-transcendence of this project is invalid, and Party B shall bear corresponding legal and economic responsibilities. Party B shall not subcontract this project or associate with others. Do not buy deposit, deposit, etc. On your own. This project shall not be used to mortgage or guarantee others.

Article 2 Construction period

The contract period of this project shall not exceed the period stipulated in the contract signed between Party A and the owner. If it is necessary to postpone or postpone, the owner's visa must be obtained, otherwise it will be regarded as a breach of contract. And shall be liable for the losses and breach of contract caused by the construction period.

Article 3 Project cost

The project cost is only RMB (? ), except for design changes, the total cost will not be modified.

Article 4 Distribution of benefits

(1) Party A shall withdraw the management fee at 5% of the total project price of Party B, and Party B shall pay the management fee in one lump sum before. The tax shall be paid by Party B. ..

(2) After the contract is signed, Party B shall set up a bidding project management department according to the contract. Party A helps Party B to handle the performance guarantee and advance payment guarantee. The bank guarantee mortgage shall be raised by Party B first, and the insufficient part shall be paid by Party A. After the advance payment of the project is in place, Party B will make up the mortgage paid by Party A. ..

(3) Party A is responsible for engraving the official seal, financial seal and project manager seal of the project department. Party B shall not engrave any seal in the name of Party A, and Party A shall assist Party B to establish a special account for the project as required by the owner. The official seal and project manager seal of the project department shall be kept by Party B, and the financial seal shall be managed by Party A, and sealed by Party A when necessary. During the construction of the project, all rights and obligations, creditor's rights and debts brought about by the management of the official seal of the project department and the project manager's seal shall be borne by Party B. After the project is handed over, Party B shall return the above seals to Party A. ..

Article 5 Financial management

(1) Party B shall conduct independent accounting at its own risk, be responsible for its own profits and losses, and bear legal and economic responsibilities.

(2) The materials preparation payment, progress payment and other payments paid by the owner according to the project contract shall be remitted to the account provided by Party A by transfer. In order to ensure the payment of funds, Party A shall deduct the management fee paid by Party B and other taxes and fees stipulated by the government according to the proportion of economic responsibility contracting, and return the balance to Party B according to the schedule, and Party A shall not default on the after-tax balance of Party B without reason. ..

(3) The quality guarantee system is implemented in this project, and the responsibility period is two years. The retention of the deposit shall be handled in accordance with the provisions of the owner. During the warranty period of defects liability, all quality problems caused by Party B's construction shall be repaired by Party B. If Party B fails to repair the engineering defects as scheduled or is unable to repair them, Party A has the right to organize another team to repair them, and the expenses incurred will be deducted from Party B's defect deposit. Upon the expiration of the defect liability period and acceptance, the remaining deposit will be refunded.

(4) Party B must use the bank account provided by Party A, and shall not make cash settlement with the owner or withdraw the project payment from the owner without authorization.

(5) All creditor's rights and debts of this project shall be handled and borne by Party B, and the ownership of all kinds of fixed assets such as construction machinery and equipment purchased and owned by Party B shall be owned by Party B. ..

Article 6 Project quality standard: according to the requirements of the contract signed between the owner and Party A. ..

Article 7 Project management

(1) Party A manages and supervises Party B's business operation, contract performance, quality and safety, and has the right to handle Party B's illegal and breach of contract business activities.

(2) Party B must carry out the construction in strict accordance with the technical specifications, construction drawings and design change documents. During the construction period (including the warranty period of the contract), if there are any disputes over the project quality, Party B shall bear the economic and legal responsibilities, and all expenses arising therefrom shall be borne by Party B. If Party B's actions cause economic losses to Party A, Party B must compensate Party A for all economic losses.

(3) Party B shall abide by the contract and guarantee the construction period according to the requirements of the agreement. If Party B fails to complete the contracted project construction tasks with good quality and quantity according to the agreed time limit and stage plan targets due to reasons such as slow mobilization, poor organization and improper utilization of time limit, Party B will breach the contract and will be fined RMB 10000 yuan as the liquidated damages for the delay of time limit for each day. Failure to organize personnel and equipment to enter the site in time according to the progress of the project may lead to serious delay in the construction period or the progress of the project and affect the overall project plan. Party A has the right to take back part or all of the unfinished works without obtaining Party B's consent, and may terminate the execution of this agreement when necessary, and arrange another construction team, and all economic losses caused thereby shall be borne by Party B. Party B shall not bear any responsibility for the delay in the construction period not caused by Party B..

(4) Before the completed project and related facilities are delivered to the Owner, Party B shall be responsible for protecting them. If there is any damage, Party B shall repair it at its own expense.

Article 8 Material management

The materials required for the project contracted by Party B shall be purchased by Party B itself, and the quality standards of the materials must meet the requirements of the Owner.

Article 9 Safety in production

(1) During the construction of the project, it is necessary to strengthen safety education and establish and improve various safety rules and regulations. In case of casualty accidents and various disputes, Party B shall bear economic and legal responsibilities, and all expenses arising therefrom shall be borne by Party B. ..

(2) When an accident occurs, Party B shall not conceal, falsely report or deliberately delay the reporting period, and shall not destroy the scene of the accident or hinder the normal investigation. In the accident investigation, Party B shall truthfully provide information, materials and evidence related to the accident, otherwise, it shall be handled according to the regulations.

Article 10 Completion acceptance and delivery.

(1) When the project is completed, Party B shall prepare a complete set of technical data (the expenses shall be borne by Party B) in accordance with the Measures for Acceptance of Highway Project Completion of the Ministry of Communications and the Owner's regulations on project acceptance, and submit it to the Owner for acceptance, and handle the project completion acceptance form and submit it to Party A for filing.

Article 11 Others

(1) matters concerning construction electricity and temporary land use shall be settled by Party B itself, and the expenses shall be borne by Party B.. ..

(2) All expenses arising from the construction of traffic access roads, renovation of existing traffic facilities, maintenance of existing rural traffic roads and environmental pollution shall be borne by Party B, and Party A may provide assistance when necessary. However, Party A will not bear any expenses in the process of assistance.

(3) Matters not covered in this contract shall be executed according to the contract signed by the owner and Liaoning Wuzhou Highway Engineering Co., Ltd. ..

(4) Two originals of this Agreement, one for each party; Four copies, two for each party.

(5) This agreement shall come into effect immediately after being signed by both parties, and shall become invalid immediately after the expiration of the project defect liability and acceptance, and all the money is settled.

Party A:

Legal representative:

Handler:

Date:

Party B:

Legal representative:

Handler:

Date:

Article 4 Project Agreement between Party A and Party B

Through negotiation between Party A and Party B, it is agreed that Party B will cooperate with Party A in the construction of the landscape project contracted by Party A, and the construction time and project content will be arranged and specified by Party A ... The following agreement is specifically reached:

1. Drawings, site positioning, lofting, elevation and site command provided by Party A; Provide all materials used.

2. Party B is responsible for personnel organization and project construction. Organize construction according to the requirements of Party A's construction personnel.

Three. Cooperation between two parties and engineering quality.

1. Party B actively cooperates to complete the project according to the schedule and deadline specified by Party A; The relationship with the owner, supervisor and the third party shall be handled by Party A. ..

2. Party B shall arrange enough personnel to carry out the construction according to the schedule requirements of Party A, and Party A shall actively cooperate with the material supply and the work that Party A should do. If Party B is dismissed because of Party A's problems, Party A shall pay the workers' wages.

3. All quality problems caused by Party B shall be borne by Party B; If rework is caused by quality or other reasons of Party A, Party B shall pay again.

4. Party A is responsible for the commanding personnel at the project site and related tests, data and archiving.

4. Payment method: (Labor fee does not include tax)

1. According to the Budget Quota for Construction Projects in Zhejiang Province (20xx version), the class III fee+information price+government guidance price of each project x 1.8 coefficient = actual cost.

2. According to the construction progress, Party B shall report to Party A's constructor in writing once every 65,438+00 days the quantities completed in this period; Report the monthly engineering quantity to Party A on 25th of each month, and Party A shall report it within 5-5 days after receiving the monthly report.

Pay 75% of Party B's monthly project cost within 10 days; Pay the remaining amount after the project is accepted.

Verb (short for verb) security:

1. All personnel of Party B must abide by the safety operation regulations when entering the construction site. Electricians and welders must hold relevant certificates.

2. All personnel of Party B shall submit a copy of their ID cards to Party A for filing.

3. Party A shall provide Party B with personal insurance for construction personnel.

6. In case of any dispute during the execution of this contract, Party A and Party B shall settle it through friendly negotiation; If negotiation fails, it can be submitted to Ningbo arbitration institution until the court decides.

Seven. This agreement shall come into force after being signed and sealed by the representatives of both parties; In quadruplicate, each party holds two copies, and both parties shall abide by it.

Eight. This agreement shall be automatically dissolved after the completion of the project.

Party A: Party B:

ID number: ID number:

Telephone number:

Year, month, sun, moon, sun.

Article 5 of the Project Agreement Party A:

ID number:

Address:

Telephone:

Party B:

ID number:

Address:

Telephone:

Party C:

ID number:

Address:

Telephone:

Fang Ding:

ID number:

Address:

Telephone:

Party A, Party B, Party C and Party D, on the premise of not violating the current national laws and regulations, have reached the following agreement through friendly negotiation based on the principles of fairness, simplification, trust, equal cooperation and mutual benefit.

Article 1 The purpose of the partnership:

On the premise of legality and rationality, carry out project construction to maximize the profit of the project.

Article 2 Cooperation projects and scope:

Contract _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 3 Term of Partnership

The partnership term is _ _ _ months, counting from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 4 Amount and mode of capital contribution

All parties contribute in cash, and each party contributes RMB _ _ _ _ _ _ _ _ _ _.

Article 5 surplus distribution and debt commitment

1. Remaining distribution: all parties contract this project in the form of labor and materials, and deduct various expenses (engineering agency fee, construction company affiliated fee, tax, construction team labor fee, construction machinery rental fee, project department management personnel salary, construction water and electricity fee, office building rental fee, temporary facilities fee, safety maintenance facility fee, pre-settlement fee, entertainment fee and various expenses of this project recognized by all parties).

2. Debt commitment: In line with the principle of * * * taking risks, if there is a loss in the cost project or relevant punishment in the middle of construction, all partners will be repaid by the profits of the partnership. If the partnership profits are insufficient to pay off, the liability shall be borne by the security deposit, each of which is _ _ _ _ _ _ _.

Article 6 Rights of Parties

1. The authority of Party A is:

(1) Liu wai started a business, entered into a contract and was responsible for the overall work of the project;

(2) managing cooperative enterprises;

(3) signature of all expenses;

(4) Paying partnership debts; Divide the profits of the partnership.

2. Rights of Party B:

(1) project construction schedule management;

(2) Listen to the report of the person in charge on the business;

(3) Examining the account books and operation of the partnership;

(4)*** Decision on handling major cooperation issues

3. Rights of Party C and Party D:

(1) Import and export of various materials;

(2) Listen to the report of the person in charge on the business;

(3) Examining the account books and operation of the partnership;

(4) Decision on handling major cooperation issues.

Acts prohibited by Article 7

1. Without the consent of the three parties, it is forbidden for any party to conduct business activities in the name of cooperation; If the profits from its operation belong to a partnership, it shall compensate for the losses according to the actual losses.

2. It is forbidden for any party to cooperate with others at the same project site.

3. It is forbidden to join other partnerships.

4. It is forbidden to quit when the partnership is unfavorable.

5. If both partners violate the above terms, they shall compensate the actual losses of the partnership enterprise according to _ _ _ _ _.

Article 8 Termination of the partnership and matters after termination

1. The cooperation may be terminated for one of the following reasons:

(1) The partnership term expires;

(2) The parties agree to terminate the partnership;

(3) cooperation is completed or cannot be completed;

(4) The contractual joint venture is revoked in violation of laws;

(5) The court decides to dissolve according to the request of the parties.

2. Matters after the termination of cooperation:

(1) immediately nominate liquidators and invite intermediaries (or notaries) to participate in liquidation;

(2) The surplus after liquidation shall be distributed in proportion to the remaining property;

(3) If there is any loss after liquidation, no matter how much the partners contribute, the partnership property shall be paid off first, and the outstanding part of the partnership property shall be borne by the upfront funds.

Solution to Article 9 Amendment

Disputes between partners shall be settled through consultation on the principle of being conducive to cooperation and development. If negotiation fails, you can resort to the local people's court.

Article 10 This Agreement shall come into force as of the date of signing the contract with _ _ _ _ _.

Article 11 If there are any matters not covered in this contract, Party A and Party B shall jointly negotiate, supplement or modify them. The supplementary and revised contents have the same effect as this contract.

Article 12 The original of this contract is in duplicate, with each party holding one copy.

Signature of Party A:

Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Signature of Party B:

Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Signature of Party C:

Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Signature of Party D:

Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 6 of the Project Agreement Party A:

Party B:

In order to ensure the safety of construction and effectively protect the life and health of construction personnel, Party A and Party B hereby sign a safety agreement. (As an annex to the contract, this agreement has the same legal effect as the main contract) Both parties shall strictly abide by it.

1. All construction workers who enter Party B's site must receive safety education and hold a work permit before they can take up their posts, otherwise they may not take up their posts.

Second, Party B's construction personnel must abide by all safety production rules and regulations on site and obey the management of site safety management personnel.

Three, the high work safety precautions:

(1) Before aerial work, it is necessary to check whether the scaffold is firm, and the scaffold board shall be laid in not less than three pieces side by side;

(2) Safety helmet and safety belt must be worn for aerial work;

(3) It is forbidden to wear slippers, high heels and other hard-soled shoes when working high above the ground;

(4) It is forbidden to carry out aerial work according to the doctor's advice after drinking alcohol, taking narcotic drugs and taking hallucinogenic drugs;

(5) It is forbidden to play, frolic and chat on the scaffold;

(6) Wind, rain and fire prevention measures should be taken in the material stacking area of the construction site.

Four, safe electricity matters needing attention:

(1) It is strictly forbidden to connect electricity without permission on the construction site, and the special person shall be responsible for the overlapping electricity.

(2) The wires and patch panels used in the construction should be checked frequently, especially at the joints, to see if they are exposed to prevent leakage.

(3) The construction of electric tools shall be operated by skilled workers, and the use of unlicensed personnel shall be eliminated.

5. The person in charge of Party B's construction must check the safety protection status of the employees on duty every day, and make safety inspection records carefully.

Six, Party B's construction team in the field construction should be strictly in accordance with the requirements and specifications of the construction unit and supervision department. Party A has the right to punish Party B for damaging the property and using the materials on site according to the consequences. Except for force majeure and Party A's exemption, Party B shall be responsible for all industrial accidents that occur in violation of this contract and the safety production agreement;

7. Articles 5 and 6 above belong to Party B's personal construction behavior and shall be managed by Party B;

Eight, scaffolding outside the site belongs to Party A's construction facilities. After plastering the bottom ash, some wall columns are removed, and the safety level of scaffolding can not meet the construction requirements. If Party B installs it, it must check and reinforce it by itself.

9. Construction personnel shall strictly abide by the above requirements and specifications in the current construction. If the operation is illegal, they will be punished by 50-20xx yuan. If the second punishment is still illegal, Party A has the right to terminate the performance of the contract, and all civil consequences arising therefrom shall be borne by Party B. ..

10. Casualties caused by Party B in the construction process shall be borne by Party B itself, and have nothing to do with Party A..

Eleven, the above agreement shall come into force as of the date of signing, and shall be abolished after the completion of the project.

Party A (signature): Party B (signature)

Year after year, month after month, year after year.

Article 7 of the Project Agreement: Principal (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Trustee (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _

Party A hereby entrusts Party B to handle the project settlement cost business, and both parties agree to abide by the following terms through consultation. First, the name and purpose of the entrusted fee settlement project

______________________________________________________________。 Second, the time to entrust the settlement of costs

Third, the way to settle the entrusted expenses

______________________________________________________________。 Four. Responsibility of both parties

(1) Party A shall provide true and accurate information to Party B;

(2) Party B has the responsibility to complete the expense settlement on time and with good quality according to the contents and requirements entrusted by Party A; (3) Party B is obliged to keep confidential the information, documents and contents of the settlement report provided by Party A. V. Liability for breach of contract of both parties.

(1) If Party A refuses or fails to pay the business expenses to Party B on time, Party B has the right to stop working or not to provide the settlement report to Party A;

(2) Party A may change or delete the signed agreement without consulting Party B, and may not claim the money paid to Party B;

(3) If Party A fails to provide true and legal information to Party B in time, Party A shall be responsible for the adverse consequences arising therefrom, and Party B shall not bear the responsibility, and pay Party B a penalty of 25% of the total income of the agreement;

(4) With the active cooperation of Party A, if Party B fails to complete the settlement on schedule, or changes or deletes the agreement signed by Party B without consulting with Party A, it will be regarded as a breach of contract, and the liquidated damages will be 25% of the total amount of the agreement. Six, charging standards and settlement methods

(1) charging standard: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(II) Settlement method: According to the charging standard, Party A shall pay Party B an audit fee of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. any other business

(1) This agreement shall come into effect after being signed by both parties and stamped with the official seal or special seal of the unit; (2) The original of this Agreement is in triplicate, with the same legal effect;

(III) If Party A and Party B or any party cannot perform this Agreement due to relevant national policy adjustment, legal revision and other force majeure events, the remaining issues shall be settled by both parties through consultation.

Party A (official seal): _ _ _ _ _ _ _ Legal representative (signature): _ _ _ _ _ Contact: _ _ _ _ _ _ _ _ _ _ _ Address: _ _ _ _ _ _ _ _. Official seal of Party B: _ _ _ _ _ _ _ _ _ _ Legal representative (signature): _ _ _ _ _ _ Contact: _ _ _ _ _ _ _ _ _ _ _ Address: _ _ _ _ _ _ _ _ _ _.