Five General Rules of renovation contract for Individual Housing

When decorating, we must first determine a project, customize one or several suitable schemes, and choose the grade that we can bear, high-grade, middle-grade or low-grade. The following is a list of individual houses of renovation contract General Motors that I have compiled for you. Welcome to reading.

Individual House renovation contract GM 1

_ _ _ _ _ _ _ (hereinafter referred to as Party A)

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ refers to any one of _ _ _ _ _ _ _ _ _

This agreement is reached by both parties through consultation, and both parties shall abide by it. By mutual consent, this agreement was drafted by _ _.

I. Project:

1, three rooms (two rooms and one living room, hereinafter referred to as three rooms) shall be marked with corner lines, including heating and pipes (the living room shall be symmetrical), and plaster lines shall be marked around the roof to cover the doors and windows of the three rooms; The living room and bedroom are covered with laminated wood floors; Remove the original paint from all rooms, putty from the living room and bedroom, and paint with Nippon paint twice.

2. Put a crossbar at the doors and windows of the balcony, and make a shelf on it according to Party A's requirements (drawings); On the east side of the balcony, a multi-purpose cabinet (shoes below and bookcases above) and a hanging cabinet on the west side are used to cover the balcony, lay tiles and hang PVC boards.

3, bathroom, bathroom, kitchen tiles to the top, PVC board hanging on the roof; The kitchen floor was tiled and a stove was built.

4. The power supply circuit of the room should be properly adjusted according to the requirements of Party A, and there is a multi-purpose cabinet behind the living room door (shoes are placed below and clothes are hung on it).

5. If no details are involved, Party A shall put forward a plan and discuss it.

2. Signing method: renovation contract sample of individual housing. Party A must guarantee the materials needed during the renovation according to Party B's requirements (Party B shall notify Party A in advance), and Party B shall be responsible for the construction.

Third, the quality standard:

The construction quality shall meet the safety requirements, and the decoration quality shall not be lower than the decoration standard of the same building type, which shall be approved by both parties.

Fourth, the construction period:

From August 20, 2000 to August 0, 2000 10/0, 50 yuan will be fined every day if it cannot be completed on time.

Five, the project cost:

Materials are provided by Party A, and Party A only pays Party B five thousand six hundred yuan for decoration labor.

Terms of payment for intransitive verbs:

After the completion of the project, if Party A meets the above-mentioned construction projects and design requirements after acceptance, the decoration labor cost shall be paid in one lump sum within three days.

Seven, other issues:

The specific requirements of the renovation project shall be put forward by Party A and implemented by Party B. Matters not covered in this agreement shall be settled by both parties through consultation. This agreement shall come into effect as of the date of signature by both parties.

Eight. This agreement is made in duplicate, each party holds one copy, which has the same effect.

Party A: Party B:

Signature (seal): Signature (seal):

Year, month, sun, moon, sun.

Renovation contract general rules for individual houses II

Client (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After friendly negotiation between Party A and Party B, Party A decided to entrust Party B to decorate the house and signed this agreement for both parties to abide by.

1. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Decoration time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. Project:

(1) _ _ _ _ _ _ (_ _ _ _ bedroom, _ _ _ _ _ living room); _ _ _ _ _ _ _ _ kitchens, _ _ _ _ _ bathrooms and _ _ _ _ _ balconies, with a total construction area of _ _ _ _ _ square meters. All walls of all rooms should be painted _ _ _ _ _ _ _ times according to the specification requirements (putty should be painted _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(2) Where the details are not involved, Party A shall put forward the scheme and discuss it.

4. Contracting method: Party B must ensure the necessary auxiliary materials (sand, cement, etc.). ) During the renovation, according to the requirements of the renovation budget, be responsible for the construction.

5. Quality standard: the construction quality meets the safety requirements, and the decoration quality is not lower than the decoration standard of the same construction type, which is recognized by both parties. Within _ _ _ _ _ months after the project completion acceptance, Party B shall be responsible for free rework and maintenance due to the quality problems of Party B's construction.

6. Project cost: The total decoration amount is RMB _ _ _ _ _ _ _. Materials and decoration expenses shall be provided by Party B first, and Party A shall pay according to the total decoration amount after acceptance.

7. This agreement is in the form of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A: _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Signature (seal): _ _ _ _ _ _ _ _ Signature (seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Renovation contract General Rules for Individual Houses III

Employer (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ ID card: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ ID card: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Through various investigations, it is determined that _ _ _ _ _ _ _ Co., Ltd. is the contractor of this project to undertake the material procurement and decoration engineering construction of this project. Combined with the specific conditions of this project and relevant national laws and regulations, based on the principles of fairness, openness and justice, and through repeated consultations between Party A and Party B, in order to clarify the responsibilities of both parties, * * * hereby signs the following contract to complete the construction task:

1, project overview

(1) Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(2) Project content: responsible for the material procurement and decoration engineering construction of this project.

(3) The construction period is _ _ _ _ _ _ _ days (starting from _ _ _ _ _ _)

(4) Construction cooperation: During the project construction, Party A shall provide Party B with water, electricity, equipment storage room and staff dormitory free of charge, and Party A shall be responsible for it.

2, the project cost

This project is general contracting and general contracting construction, and the total contract price is _ _ _ _ _ _ _ ten thousand yuan. The increased expenses outside the scope of the contract shall be settled according to the actual situation.

3. Maintenance service

(1) The main equipment is guaranteed for three years due to its own quality problems. If the equipment can not be used normally due to man-made damage and other reasons, the maintenance fee will be charged appropriately, and all the equipment will be maintained for life.

(2) Party B shall implement a 24-hour quick response system for after-sales service, and arrive at the site within 24 hours after receiving the system failure call from Party A.. If it cannot be repaired within 2 hours after arriving at the site, Party B will provide similar products to Party A for free.

4. Payment and settlement methods

(1) Within 3 days after the signing of the contract, Party A shall pay _ _ _ _ _% of the total contract price of the project to Party B;

(2) Party A shall pay _ _ _ _ _ _% of the total contract price to Party B after entering the site for construction;

(3) Party A shall pay _ _ _ _ _% of the total contract price to Party B within 1 week after the acceptance of the project;

(4) After one year of use, if there is no quality problem, Party A will pay the balance to Party B within 10 days;

(5) All funds are interest-free.

5. Liability for breach of contract

(1) Party B guarantees to complete the project on schedule. If the construction period is delayed due to Party A's reasons, the construction period will be postponed. Otherwise, Party B shall pay Party A a fine of 0. 1% for each day of delay. If the project payment cannot be paid to Party B on time due to Party A's reasons, Party A shall pay 0.1%of the overdue project payment to Party B for each day of delay;

(2) If the project quality does not meet the standard requirements agreed by both parties, or the contract cannot be performed due to Party B's responsibility, Party B shall compensate all the losses; If the contract cannot be performed due to Party A's reasons, Party A shall compensate all losses.

6, safety responsibility

Party B shall ensure the safety of on-site construction, strictly abide by the current national safety regulations, formulate detailed rules for the implementation of safe and civilized construction, and designate special personnel to strengthen management. During the construction period, Party B shall bear all the responsibilities for the safety accidents caused by Party B, and the responsible party shall be responsible for the safety accidents caused by cross operation.

Step 7 accept

After the project is completed, after Party B submits a written acceptance application to Party A, Party A shall organize relevant personnel to accept the project within one week. If the project cannot be accepted on schedule due to Party A's reasons, Party B shall be informed in writing to change the acceptance date. If Party A fails to organize the acceptance within one week after the change, it shall be deemed as qualified. Party A will no longer organize acceptance.

8. Others

(1) The equipment configuration list is an annex to this contract. (See equipment configuration list for details)

(2) This contract shall come into effect as of the date of signing, and shall become invalid after the agreed work content is completed.

(3) This contract is made in quadruplicate, with Party A and Party B holding two copies respectively, and each contract has the same legal effect.

(4) Matters not covered in this contract shall be settled by both parties through consultation.

Party A (official seal): _ _ _ _ _ _ _ _ _ _ Party B (official seal): _ _ _ _ _ _ _ _ _ _.

Legal representative (signature): _ _ _ _ _ _ _ _ _ _ Legal representative (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Renovation contract general rules for individual houses 4

Employer (full name): Yang Yingping

The contractor (full name) Qiannan No.2 Construction and Installation Engineering Co., Ltd., in accordance with the provisions of the People's Republic of China (PRC) Contract Law and in combination with the specific conditions of this project, on the principles of voluntariness, equality, honesty and credit, has reached the following terms and conditions through consultation, which shall be abided by both parties.

Article 1 General situation of the project

1. 1 Project name: Staff Welfare Office of duyun city Finance Bureau.

1.2 project location: former shabaobao finance office.

1.3 project and contract scope: see the project budget for details.

1.4 construction date: February 25, 20 16 to July 25, 20 16, with a construction period of ***5 months.

65,438+0.5 Total project amount: The total contract price for labor and materials is RMB 450,000.00 Yuan only.

Article 2 Agreement on Payment Method of Project Payment 2. 1 Within 7 days after the signing of this contract, Party A shall pay 35% of the total project cost to Party B in one lump sum, and the balance of the renovation project shall be paid to Party B within 7 natural days after Party A deducts 14000.00 yuan from the date when both parties pass the acceptance.

2.2 If the project budget expenses are changed due to the change or increase of the project (content), Party A shall sign the project change order, and the increased expenses shall be taken as an annex to the final accounts after signing.

2.3 After the completion of the project, if the final payment of the project is not paid in time according to the payment method agreed above, Party B has the right to charge Party A demurrage fee according to the standard of 1% of the unpaid final payment of the project for each day of delay until Party A pays it off.

2.4 The project funds payable by Party A shall not be delivered to non-signatory or non-signatory customers. Otherwise, all consequences arising therefrom shall be borne by Party A. ..

Article 3 Time limit for a project agreement

3. 1 During the construction process, Party A requests to modify the larger design scheme and postpone the construction period;

3.2 During the construction process, after the concealed works are completed, if Party A fails to conduct the concealed works acceptance in time and requests the reinspection for some reason after receiving the notice of project acceptance, the construction period will be postponed.

3.3 If the construction period is delayed due to reasons other than Party A's, the construction period will not be postponed.

3.4 If the contract time limit is delayed due to the non-extension of the time limit, Party B shall pay the delay fee to Party A according to the daily 500 yuan standard.

Article 4 Project (Content) Change Agreement

4. 1 After the signing of this construction contract, before the formal construction, if Party A requests to delete part of the project (content), Party A and Party B shall sign a confirmation form for the change of the project (content);

Article 5 Agreement on Project Quality and Acceptance

5. 1 party b shall purchase building materials according to the material quality standards listed in the project budget attached to this contract; Party A can decide the colors and patterns of decorative boards and other materials; Check and accept the materials purchased by Party B according to the listed standards.

5.2 Party B shall carry out the construction in accordance with the construction technology and contents specified in the "Project Budget" attached to this contract.

5.3 Party A and Party B shall conduct the construction quality acceptance according to the national engineering quality acceptance standard.

5.4 Acceptance of completed project: After the project is completed, Party B will issue a project acceptance notice to inform Party A to accept the completed project; Party A shall cooperate with Party B for completion acceptance within 3 days after receiving the notice of project acceptance. After the completion acceptance, Party A and Party B shall sign the project completion acceptance form and handle the project handover procedures.

Article 6 Project Settlement Agreement

6. 1 After the project is completed, Party B shall deliver the project settlement form to Party A within 2 calendar days after both parties complete the handover procedures, and Party A shall pay off all the payables within 7 working days after the project acceptance.

6.2 After the project is delivered for use after completion and acceptance, Party B shall issue a project quality guarantee.

Article 7 Service Agreement

7. 1 After the project is completed and settled, Party A shall take the warranty certificate issued by Party B as the warranty certificate.

7.2 Warranty service time and warranty refund agreement: within 365 natural days from the date of project completion acceptance and delivery, that is, one year. During the warranty period, Party B shall timely perform the warranty obligations within two days after receiving the warranty notice from Party A, and guarantee the emergency warranty items within one hour after receiving the warranty notice, otherwise, Party B shall bear all the direct and indirect losses caused to Party A. Within three days after the expiration of the warranty period, when Party B performs the warranty obligations as agreed, Party A will refund the warranty money without interest.

7.3 Warranty content and scope:

7.4. 1 For the construction project undertaken by Party B in the form of contract, Party B shall carry out full free warranty for quality problems caused by improper material quality and construction technology; And bear all losses of Party A. ..

7.4.2 If Party B's construction project exceeds the warranty period, Party A will enjoy the priority of paid maintenance, and the charging contents include: material cost and labor cost.

Article 8 Other agreements

8. 1 This contract shall come into force after being signed by both parties. Before the formal performance of the terms of this contract, either party shall unilaterally terminate this contract and compensate the other party at 20% of the total contract budget.

8.2 During the construction period, Party A shall bear the costs of water, electricity and gas consumed by Party B in the construction site.

8.3 During the construction period and before the completion acceptance and delivery, Party B shall take full responsibility for all safety and personal injury, and Party A shall not bear any responsibility.

8.4 After the construction, Party B shall clean up the construction site.

8.5 Due to force majeure events that have a certain impact on the performance of the contract, Party A and Party B shall, according to different degrees, negotiate to terminate the contract, partially perform the contract and postpone the performance of the contract.

Article 9. Dispute settlement agreement

1. Any dispute concerning the validity, performance, breach and dissolution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, a lawsuit shall be brought to the People's Court of duyun city where this contract is performed.

Article 10 Supplementary Provisions

10. 1 This contract shall come into effect as of the date of signature and seal by both parties, in quadruplicate, with each party holding two copies, with the same legal effect, and both parties shall abide by it.

10.2 Matters not covered in this contract shall be settled by both parties through negotiation.

Party A: Party B:

Representative: representative:

Date of signing: Date of signing:

Signing place: Signing place:

Personal house renovation contract GM 5

Customer (Party A):

Organizer (Party B):

Project: According to People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Consumer Rights Protection Law, People's Republic of China (PRC) Price Law, Trial Measures of the Ministry of Construction for the Decoration Management of Family Rooms and other relevant laws and regulations, Party A and Party B decided to entrust Party B to decorate the room through friendly negotiation. In order to ensure the smooth progress of the project, this contract (including its annexes and all supplementary contracts) is hereby signed for * * *.

Article 1: Project Overview

1. The house decorated by Party A is legally inhabited.

Party B is an enterprise approved and registered by the administrative department for industry and commerce of this Municipality, and holds the qualification certificate of construction enterprise issued by the Municipal Construction Committee.

2. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Project address

3. Room Specification: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Room Specification: _ _ _ _ _ _ _ _ _ _ _ _ Room Specification

(1) room with an area of _ _ _ _ _ _ _ square meters;

(2) _ _ _ _ Hall, which is _ _ _ _ _ _ _ square meters;

(3) _ _ _ _ _ kitchen, with _ _ _ _ _ _ square meters as one meter;

(4) _ _ _ _ _ bathroom, with _ _ _ _ _ _ square meters as one meter;

5] _ _ _ _ _ balcony, which is _ _ _ _ _ _ square meters;

[6] _ _ _ _ _ _ corridor, with meter as _ _ _ _ _ square meters;

(7) Other (please specify the location) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. Project content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

5. Entrustment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

7. Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total days of the project: _ _ _ _ _ _ _ _

Article 2: Project Price

The project price (in words) is RMB. For details, please refer to Annex (II) Budget Table of Home Decoration Engineering Materials.

1. The material payment is RMB _ _ _ _ _ _;

2. Labor cost _ _ _ _ _ _ _ yuan;

3. The design fee is _ _ _ _ _ yuan;

4. The construction clearance fee is _ _ _ _ _ _ _ yuan;

5. The handling fee is _ _ _ _ _ yuan;

6. Management fee _ _ _ _ _ _ yuan;

7. Tax (3.41%) _ _ _ _ _ _ yuan;

8. Other expenses (please specify the contents) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties. See Annex (III) List of Final Accounts of Home Decoration Engineering Materials for details.

2. Regarding the acceptance standard of this project, both parties agree to refer to the local municipal standard DB3 1/T30- 1999 Acceptance Standard for Residential Decoration.

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

4. Quality supervision department: Home Decoration Professional Committee of City Interior Decoration Industry Association.

5. Party A shall be responsible for the quality of all materials and equipment purchased by it; Party B shall be responsible for the quality of the project.

6. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. For details, please refer to Annex (II) Budget Table of Home Decoration Engineering Materials. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

Article 5: Method of Payment

1. After the contract is signed, Party A shall pay 100% of the project cost and 50% of the project cost; When the progress of the construction period is over half (year, month and day), Party A will pay 40% of the project payment for the second time. The remaining 10% shall be paid to Party A after the project is completed and accepted. (Note: Construction costs include labor costs)

The payment proportion shall be determined according to the payment method table:

Payment Application Payment Time Payment Percentage Amount: Yuan

The content of the process is to sign a design contract with a budget of 1000 yuan.

Deducted when the payment is approved on the date of signing the intention.

Date of contract signing

100% is used for materials.

The construction cost is 50%

total

The construction period is over half.

During the construction period, the construction cost is 40%.

Date, year and month

Completion acceptance 10%

Add 100% of the engineering change signed by the project.

This form should be settled when the formalities are completed.

Party A shall pay off the project price, as shown in Annex VII of the Contract, and Party B shall issue a unified invoice, hand it over to Party A and issue a decoration project warranty card, as shown in Annex VIII of the Contract, Home Decoration Project Quality Warranty Card.

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there are any additions, deletions or changes in the project construction, please refer to Annex V of this contract, Change Form of Home Decoration Project. Both parties sign a supplementary contract, and Party B is responsible for issuing a construction change order and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in the contract, Party A shall pay 1% of the unpaid project price to Party B for each day overdue.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party B shall pay Party A 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid 1% of the labor cost in the decoration project price as lost time.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. During the construction, the shutdown caused by engineering quality problems and disagreement between the two parties shall not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.

4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7: Project Acceptance

1. See Annex (VI) Home Decoration Engineering Quality Acceptance Form for the project quality acceptance. Party B shall organize Party A to carry out the completion acceptance after the project is completed, except that the concealed works need to be accepted by sections. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.

Article 8: Other matters

1. Party A

1. The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided; otherwise, Party A shall provide the house plan and water, electricity and gas circuit diagram and make on-site disclosure to Party B. ..

2. The second decoration project, all or part of the empty house, remove obstacles that affect the construction. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

3. If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood.

2. Party B

1. Take the initiative to show business license, membership card or construction qualification; If it is a subordinate branch, it must also have a certificate issued by the superior company; The handling salesman must have a certificate of entrustment from the legal representative.

2. Assign (name) as the on-site representative of Party B, be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.

3. Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

4. Strictly perform the contract and implement the credit period. If the completion is delayed, such as material stripping, slowdown or an excuse to induce Party A to pay in advance, it will be regarded as a breach of contract after investigation.

5. Be responsible for the warranty within the scope of decoration construction. The warranty period is 12 months, counting from the date when the project is completed and accepted by Party A. ..

Article 9: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 10: dispute settlement

1. In case of any dispute during the performance of this contract, both parties shall settle it through negotiation without affecting the project progress. Or bring this contract and the unified invoice issued by Party B to complain to the Home Decoration Professional Committee of the Interior Decoration Industry Association of the city and demand settlement.

2. The parties are unwilling to settle the dispute through negotiation or mediation, or if negotiation or mediation fails, they may apply to the Arbitration Commission for arbitration according to this contract; -the people's court brought a lawsuit.

Article 11: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 12: Contract comes into effect

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. The supplementary contract has the same legal effect as this contract.

3. This contract (including its annexes and supplementary contracts) is made in duplicate, one for each party and the witness department.

Party A (Owner): (Signature) Party B: (Signature)

Address of domicile: address of enterprise:

Postal code:

Work Unit: Legal Representative:

Relevant clauses of individual housing GM 5 in renovation contract:

★ Article 5 of renovation contract Clause for Personal Residence in 2022.

★ All-inclusive house decoration contract (5 general terms)

★ Five model contracts for all-inclusive house decoration.

★ 5 simple houses renovation contract

★ Formal lease contract model (5 pieces)

★ 202 1 Five model contracts for house decoration project

★ 4 copies of renovation contract model for individual farmhouses.

★ Standard Edition of renovation contract Model of House

★ House renovation contract Simple Edition Agreement

★ Five general templates for private construction contracts