Five separate building agreements in 2022

Agreement refers to a contractual document with economic or other relations concluded by a country, a political party, an enterprise, a group or an individual after reaching an agreement on a certain issue through negotiation or consultation. Next, I'll sort out the individual building agreement for everyone in 2022. I hope you like it!

2022 individual housing agreement 1

Both parties to the contract: the seller (Party A): (hereinafter referred to as Party A) ID number:

(Property owner) ID number (Property owner) ID number (Property owner) ID number (Property owner)

The above-mentioned personnel are the * * * property owners of the house mentioned in this contract.

Buyer (Party B): (hereinafter referred to as Party B)

ID number:

In accordance with the Economic Contract Law of the People's Republic of China, the Law of People's Republic of China (PRC) Municipality on Urban Real Estate Management and other relevant laws and regulations, Party A and Party B, on the principles of voluntariness, equality, equal compensation, honesty and credibility, have reached an agreement on the purchase of real estate by Party B from Party A through full consultation, and both parties shall abide by it.

Article 1: Statement of Party A's property rights: Party A is a demolished resident of Zhaojiatiaowei Village, Houhu Township, Jiang 'an District, Wuhan City. According to the National Demolition Law, Party A signed the House Demolition Compensation and Resettlement Agreement with Wuhan Fu Hong Demolition Co., Ltd. in June 2008. According to the agreement, Party A legally obtained the area of the "Apple City" residential project in Houhu No.1 Road, Jiang 'an District, Wuhan. 16m2, of which 90-135m2 * * sets of ordinary houses. The community is currently in the stage of infrastructure construction. The house is developed and operated by Wuhan Shenghua Industrial Co., Ltd., and the property ownership certificate is applied by Party A to Wuhan real estate ownership registration authority through Wuhan Shenghua Industrial Co., Ltd.

Article 2. Basic information of the house: The house under this contract is located in the "Apple City" community in Houhu Township, Jiang 'an District, Wuhan, which is located on the east side of Jinqiao Avenue, the south side of Jiang 'an District Court, the west side of Houhu No.2 Road and the north side of the railway line. The house is an ordinary residential house, and the delivery time of the house is subject to the government reconstruction time, with a construction area of about 90 square meters.

The specific building number, unit number, floor number and room number shall be selected according to the demolition and resettlement agreement number after being informed by the developer. Party B has fully understood all the houses owned by Party A and is willing to buy the house.

Article 3. Statement of Party A on the right to buy and sell: Party A guarantees that the house conforms to the relevant laws, regulations, policies and provisions of the state and Wuhan Municipality on property rights transactions, and the property rights of the house sold are truly owned by Party A, and there is no fictitious property rights or the sale of the house beyond the building area. Party A voluntarily sells the house to Party B, which is a true expression of Party A's intention. Party A shall bear the legal and economic responsibilities caused by violating the relevant policies and regulations of the state and Wuhan. ..

Article 4. Party A shall take full responsibility for the ownership of the house, and ensure that there is no property right dispute or mortgage debt. Before this transaction, all economic disputes such as ownership of property rights and mortgage of property rights shall be settled by Party A.. If there are any matters not mentioned above, all responsibilities shall be borne by Party A..

Article 5. When signing the first-hand house contract with the developer, Party A shall ensure that the property right of the house sold is directly renamed to Party B.. If Party A fails to sign a first-hand house contract with the developer for various reasons, it will be renamed as Party B's property directly, and the subsequent taxes and fees for the transfer of second-hand houses by both parties shall be borne by Party A except the land transfer fee payable according to the national regulations.

Article 6. The transaction price of the above real estate is RMB four thousand Wu Bai Yuan only (4,500m2) per square building area, and the total transaction price of the house is about RMB four hundred thousand Yuan only. The actual transaction price is the building area of the real estate license multiplied by 4500 yuan. The actual construction area shall be subject to the measured area of the real estate registration agency. If there is any difference between the actual area and the measured area:

If the actual area is insufficient, it shall be returned according to the difference area, and the part exceeding the square meter shall be paid separately by Party B in advance. The transaction price of 4500 yuan is a fixed price. No matter how the housing market price fluctuates in the future, both parties shall not go back on their word because of the rise and fall of housing prices, otherwise it will be regarded as a breach of contract and should bear the liability for breach of contract.

Article 7 Time and method of payment: Party B shall pay the deposit (deposit)100000 yuan to Party A on March 20th, and Party A shall issue a receipt to Party B on the day of payment, indicating the payment amount and purpose. The second house payment is RMB two hundred and fifty thousand Yuan only, and the third house payment is RMB fifty thousand Yuan only, which shall be paid to Party A within five days after Party A transfers (renames) all the houses mentioned in this contract to the buyer's name, and within three days after Party A completes all the formalities of the houses mentioned in this contract and gives the house keys to the buyer. Party A and Party B agree to pay by installments in cash or by bank transfer. Every time Party B makes payment, Party A will issue a receipt to Party B, indicating the payment amount and purpose. If Party B fails to make payment according to the terms of this contract, Party B shall pay interest to Party A at the annual rate of 12% according to the time when the payment amount is delayed.

Article 8. The house selection priority agreement stipulates that after receiving the notice from the developer, Party A shall inform Party B in time to ensure that Party B receives the house selection information in the first time (15 minutes) and that Party A will give priority to Party B's house selection in the renovation of the same type of house.

Article 9. Delivery of the house: Party A shall, within 2 days after receiving the notice that the developer has received the house keys and attached relevant documents, deliver all the procedures related to house demolition and resettlement and the documents and documents related to the house to Party B, and deliver all the keys of the house to Party B to complete all the handover procedures of the house.

Article 10 Liability for overdue transfer (renaming): If Party A fails to transfer (rename) the property right of the house to Party B within the time limit stipulated in this contract, it shall be deemed that Party A has breached the contract, and Party B has the right to claim liquidated damages from Party A according to the paid house price, and pay 20% of the paid house price to Party B as liquidated damages. If this contract continues to be performed, Party A shall bear all taxes and fees for the transfer of the second-hand house.

Article 11 Party A's liability for breach of contract for overdue delivery: If Party A fails to deliver the house to Party B within the time limit stipulated in this contract, Party B has the right to claim liquidated damages from Party A according to the paid house price. Liquidated damages Pay liquidated damages to Party B according to 30% of the house price paid by Party B, and continue to perform the contract. If the delay exceeds 15 days, Party A shall be deemed to have failed to perform the contract, and Party B shall have the right to hold Party A liable for breach of contract according to the following three provisions.

1. Party A shall pay Party B 30% of the accumulated payment, continue to perform the contract and deliver the house within 5 days from the actual delivery date agreed in Article 6 of this contract.

2. Upon termination of this contract, Party A shall pay Party B all the accumulated house payment, and pay Party B the interest at the annual rate of 12% according to the actual payment time of the house payment.

3. If Party A intentionally conceals the original owner, location and quality problems of the house, which affects Party B's residence and use, Party B has the right to request to return the house, and all losses shall be borne by Party A. ..

Article 12 Agreement on the registration and transfer of property rights: For other formalities such as property right certificate and land certificate that need to be handled in the future, Party A and Party B have reached the following agreement through consultation.

1. Party A shall bear all the taxes and fees required for handling the formalities of ownership certificate and land use right certificate of the house in the name of Party B.. Party A shall hand over the title certificate to Party B within five days after receiving the title certificate.

2. Since the date of signing this contract, Party B actually takes over the relevant formalities of the house, and Party A shall assist the developer to go through the ownership registration formalities with the real estate property registration authority according to the stipulations of this contract, and shall not refuse or obstruct in any way. If Party B fails to obtain the property right certificate within the time limit stipulated by the state due to Party A, Party B has the right to return the house, and Party A shall return all the house payment paid by Party B to Party B within 5 days from the date when Party B requests to return the house. And pay interest to Party B according to the benchmark interest rate of bank loans stipulated by the state multiplied by 3 times, and calculate compensation according to 30% of the paid amount to compensate Party B's losses.

Article 13 The subject of this contract

1. Party A is * * *, and the entrusted agent is Party A's representative .. Party A and Party A's representative guarantee that the house will be recognized by the owner of the house when signing this contract.

2. Party B is and the representative is.

Article 14: This contract shall be notarized by the State Notary Office; However, this contract does not need any legal notarization and has the same legal effect. This contract shall come into effect as of the date of signature by both parties (date of 20). The words filled in the blank of this contract have the same legal effect as the printed words.

Article 15. This contract shall come into effect after being signed by Party A, Party B and witnesses. This contract is made in triplicate. The property owner of Party A and the entrusted agent of Party A each hold one copy, Party B holds one copy, and the witness (middleman) holds one copy for future reference.

Article 16 Settlement of disputes in this contract: Both parties sign this contract on the principle of friendly negotiation, fairness and reasonableness. After the signing of this contract, both parties shall strictly abide by it and shall not go back on our word for any reason. Disputes arising from the performance of this contract can be settled by both parties through consultation. If negotiation fails, both parties agree to settle the dispute as follows.

1, submitted to the Arbitration Commission for arbitration.

Either party may bring a lawsuit to the people's court with jurisdiction.

Article 17. Matters not covered in this contract can be agreed by both parties separately, and its supplementary agreement shall be settled by Party A, Party B and Witness through consultation, which has the same legal effect as this contract.

Seller (Party A): ID number:

(Owner) ID number

(Owner) ID number

address

Telephone Date: Period: Year Month Day

Buyer (Party B): ID number:

address

Telephone Date: Year Month Day

Witness (middleman): ID number Date: MM DD YY.

2022 Individual Building Agreement II

Party A: ID number:

Party B: ID number:

Party A purchased _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Due to lack of funds, Party A and Party B agreed to jointly build a seven-and-a-half-story residential building through friendly negotiation. Details of the agreement are as follows:

1. Party A is responsible for the supply of the above-mentioned land, and Party B contributes RMB 880,000.00 Yuan to allocate a set of 20 1 five-bedroom, two-hall, one bathroom and three bathrooms in Block A of Welsh Complex, with a construction area of about 200m2 and a construction area of RMB 4,400.00 Yuan. (Area is subject to the measurement of building area)

2. For the real estate jointly built by Party B, Party A shall assist Party B to handle the real estate license uniformly, and the expenses shall be paid by floor. Party B owns the real estate ownership of the house. The right to use the house is 70 years.

Three. Architectural planning and design scheme: After communicating with the Planning Bureau, Party A preliminarily confirms that the land plot ratio is ≤2.0, the building density is ≤25%, the greening rate is ≥35%, and the commercial-residential ratio is ≤0. 15. Therefore, the architectural plan is to build a three-storey 5m-deep pavement along the 55m north-south sea road (the upper two floors are cantilevered 1.5 m), covering an area of 275m2 and 935m2. Three villas with one staircase, two households, six floors and a half plus a row will be built in the north-south direction, and the technical floor at the bottom is 2.2m overhead, with a construction area of 480m2. The east and west parts above the first floor are cantilevered 1.5 m, with an average construction area of 584m2 and an area of 480m2. * * * Eighteen households with 3801㎡ (584 _ 6+5842 = 3801). After the acceptance of Simon, 18 garages with a depth of 6m and a width of 4m were built along the east-west direction, with a total area of 576m2.

Four, building and decoration requirements:

1. The building is a frame-shear structure (Party A shall be responsible for the fine for the overbuilding part).

2. Decoration: The exterior wall is made of bluestone, high-grade exterior paint and other stones, and the house is delivered as a rough house. Exterior wall window adopts electrophoretic aluminum alloy window, and entrance door adopts fireproof steel door. The water and electricity facilities shall be reserved by Party A, and the expenses for urban land acquisition and road construction shall be borne by Party A. Party A must ensure the construction quality, and if there are any problems, Party A shall be responsible. (According to the original layout, the expenses for Party B's second decoration and change shall be borne by Party B)

5. Payment method: down payment, 200,000 yuan after the agreement comes into effect; For the second payment, the land certificate shall be handled in the name of Party A's company, with a payment of 300,000 yuan; The third payment, after the construction permit is completed, 350,000 construction expenses will be paid within seven days; Fourth payment, delivery date of house acceptance, final payment and related purchase tax. If Party B fails to pay the money to Party A on time, it will be regarded as an automatic waiver of property rights, and the receipt of Party B's cooperative housing construction will be invalid, and the lawyer's witness fee will be borne by Party B. ..

6. Both parties shall enjoy the right to public access facilities of the building, and shall abide by national laws, regulations and social ethics, maintain public access facilities, and pay management fees for public access facilities (security guard's salary, public electricity fee, security office and other related residents * * * are calculated according to the housing area). When public facilities need maintenance, they shall be paid according to the proportion of the property area occupied by both parties.

Seven, after the delivery of real estate, if it needs to be modified, in order not to affect the overall structure as the principle, otherwise all economic losses will be borne by the damaged party.

Eight. Liability for breach of contract: this agreement shall come into effect after being signed by both parties and witnessed by the witness department. If either party breaches the contract and causes losses to the other party, the breaching party shall pay corresponding economic compensation.

Nine. Any dispute arising from this cooperation agreement shall be settled through negotiation between both parties. If negotiation fails, it can be submitted to Shenzhen Arbitration Commission for arbitration.

X. If the house is damaged due to force majeure or other factors, both parties shall compensate, and the compensation amount shall be divided according to the proportion of the construction area, and the related expenses shall also be paid according to this proportion.

XI。 Party A will not charge any other management fees and other miscellaneous fees in the future.

12. This agreement is made in triplicate, one for each party and one for the witness department, with the same legal effect.

Party A:

Party B:

20__ _ _ _ _ _ _ _

Agreement on Personal Buildings in 2022 3

Party A:

Party B:

Because my building has been uninhabited for a long time and has been in disrepair for a long time, the house is being renovated and redone. Based on the principles of fairness, honesty and credibility, Party A and Party B have reached an agreement on the renovation and reconstruction of the house through consultation and signed this agreement:

First, the scope and form of project contracting

This project is contracted to Party B in the form of contract work and materials. Scope of contract: original roof leveling, floor upgrading, renovation of internal and external walls, etc.

Second, the quality requirements

In strict accordance with the drawings and Party A's requirements, the construction quality meets Party A's requirements.

Third, the term of the contract.

The total construction period of this project is _ days, and the commencement date shall be subject to Party A's notice. ..

Fourth, the price and project payment

1, RMB per square meter for single-storey upgrading, renovation of internal and external walls, and actual construction area for upgrading.

2. Pay cash in one lump sum after acceptance.

V. Courtesy, Safety and Fire Protection Agreement

1. During the construction period, politeness, safety, fire control, hygiene and environment shall be strictly implemented in accordance with the requirements of the village.

2. Party A shall be responsible for the neighborhood relations during the renovation.

3. During the construction period, Party B shall be responsible for all safety accidents.

This agreement is made in duplicate, one for each party. Matters not covered in this agreement shall come into effect after signing and become invalid after settlement.

Party A: Party B:

Date: Date:

Agreement on Personal Buildings in 2022 4

Before signing the contract, the fundraiser (Party B) should read the agreement materials carefully. If you have any objection to the terms of the agreement and professional terms, you can consult the relevant competent authorities.

The parties and the parties hereto:

Party A (Second Engineering Office ...):

Party B (employee participating in fund-raising for building):

According to relevant laws and regulations, Notice on Further Strengthening and Standardizing the Management of Building by Raising Funds, Implementation Plan of Building by Raising Funds for Employees, Supplementary Notes on Building by Raising Funds for Employees and other related policies, Party A and Party B have reached the following agreement on the basis of equality and voluntariness:

1. Entrusted by the management office, Party A decided to build houses by raising funds to build workers' houses in a centralized and unified way. Party B agrees to understand the Administrative Office's Implementation Plan for Building Houses by Raising Funds for Employees and Supplementary Instructions for Building Houses by Raising Funds for Employees, and voluntarily decides to participate in building houses by raising funds.

2. The housing where Party B participates in fund-raising cooperation is policy housing. According to the requirements of the "Reply on Raising Funds for Cooperative Housing Construction and Resettlement of Workers in New District", that is, "Raising funds for housing construction is included in the local affordable housing supply plan and enjoys various preferential policies for affordable housing construction, and property rights relations and listing transactions are implemented in accordance with the relevant provisions of affordable housing."

Three. The total construction area of the fund-raising house purchased by Party B is square meters (subject to the final measured area), and the apartment type is: room, hall and bathroom.

Four. The construction area control standard of the house purchased by Party B is within 90 square meters for ordinary employees, with intermediate title 100 square meters, deputy senior title 1 15 square meters, and ordinary title 1230 yuan, with a floating area of 65,430 square meters (up to 45 square meters at all levels). Before the house is delivered for use, the house payment shall be settled according to the measured area, floor coefficient and floating area of the unit with surveying and mapping qualifications, and the refund shall be made more and the subsidy shall be made less.

According to the progress of the construction project, Party B will pay in three installments. 30% of the total house price (that is, 30% of the specified grade area control standard _ _1230m2+floating area _ _1450m2 _ _) shall be paid in advance by each household before _ _ _, and 50% shall be paid after the main project is completed.

If Party B fails to pay the money within the agreed time, it will be deemed as a waiver of the qualification of fund-raising housing construction. Party A will take back the fund-raising house selected by Party B and return the prepaid house payment paid by Party B without interest.

Six, after the completion of the project, by the staff housing construction management leading group put forward housing allocation scheme, solicit opinions from the staff and workers, reported to the prefectural and administrative office for approval before implementation.

7. Party A shall deliver the house that has passed the acceptance of the construction quality supervision department to Party B before1_ _ _ _. The warranty responsibility, duration and scope of the house shall be implemented in accordance with the relevant provisions of the state.

Eight, in the process of building construction, Party B can understand and supervise the construction process and building quality through the office of the leading group for staff housing construction management.

Nine. Party B shall not damage the main structure and public facilities of the house when decorating the house, and Party B shall bear all responsibilities and corresponding compensation for all economic losses and related responsibilities caused by Party B's decoration.

10. All the fund-raising houses built are subject to property management, and Party B must obey the relevant regulations and requirements of property management after moving in.

XI。 Matters not covered in this agreement shall be handled in accordance with the relevant policies of the government to raise funds to build houses.

Twelve. This agreement shall come into force after being signed and sealed by both parties. This agreement is made in triplicate, with Party A and Party B holding one copy respectively, and employees participating in fund-raising housing construction holding one copy respectively.

Party A (seal): Party B (signature)

Authorized Agent (signature): ID number:

Year, month, sun, moon, sun.

Agreement on personal buildings in 2022 5

Party A (Employer):

Party B (contractor):

In order to complete the construction project safely and timely, avoid and reduce contradictions and problems in the construction process as much as possible, and clarify the rights and obligations of both parties, Party A and Party B have reached the following agreement on the principle of fairness and reciprocity:

1. Party B must carry out the construction in strict accordance with the drawings or requirements provided by Party A, and the parapet and water and electricity shall be installed within the contracted scope. In case of any objection, both parties shall negotiate.

2. Party A has the right to supervise the construction process and quality of Party B to ensure the project quality.

Three. Contract method: contractor does not include materials, building materials are supplied to the site by Party A, and Party B provides its own construction tools.

4. The contract price (unit price) is RMB per square meter, totaling RMB.

5. Payment method: layered payment. Party A shall pay 90% of the house price of each floor to Party B on the day of capping, and the rest shall be paid in one lump sum after the whole house is completed.

Six, stair double calculation, 1 m2.

Seven. Party A is responsible for coordinating the water and electricity connection required for the project construction.

8. Party A must take good care of the templates and tools that Party B brings to the construction site. If losses are caused, Party A must compensate according to the price.

Nine. Party A is responsible for handling the contradictions and disputes in the construction process to ensure the normal construction of Party B. If the construction period is delayed, Party A shall compensate Party B for the lost time, and then both parties shall negotiate to extend the construction period.

X. When Party B has serious quality problems and technical problems in the construction process and does not obey the supervision and adjustment of Party A, Party A has the right to order Party B to stop work, and the losses caused thereby shall be borne by Party B. ..

XI。 In the process of construction, Party B shall ensure the safety of construction and prohibit all illegal operations. Party B shall be responsible for all safety accidents during the construction, and Party A shall not bear any responsibility.

12. Party A shall be solely responsible for the safety accidents caused by Party A in the construction process, and Party B shall not bear any legal responsibilities.

Thirteen. Liability for breach of contract: once this agreement is signed, both parties must strictly implement it and shall not breach it, otherwise the breaching party shall bear all losses caused thereby.

14. This agreement is made in duplicate, one for each party, and shall come into effect immediately after being signed. Matters not covered shall be negotiated by both parties.

Fifteen:

Sixteen:

Party A (seal):

Party B (seal):

date month year

Five Articles Related to Personal Building Agreement in 2022:

★ Individual construction contract template

★ 20 simple and standardized individual housing sales agreement contracts in 2022

★ 6 sets of standard self-built house contract templates

★ Article 5 of renovation contract Clause for individual houses in 2022.

★ 6 concise versions of individual housing sales contract model

★ 6 Model contract for the sale of rural self-built houses

★ Five sales contracts for private small property houses.

★ Self-built house purchase contract in 2022

★ Five simple single project contracting agreements

★ Written contract for land contracting and circulation in 2022 (select 5 articles)