Simple contract for office maintenance

Simple contract model of office maintenance (6 general articles)

With the deepening of people's understanding of the law, contracts have helped us more and more. The purpose of signing a contract is to protect the interests of both parties and avoid unnecessary disputes. What kind of contract have you seen? The following is a simple office maintenance contract template (generally 6) compiled by me, which is for reference only and I hope it will help you.

Simple Office Maintenance Contract 1 Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

I. Overview of the Project

1, project name:

2. Project location:

3. Contract duration: commencement date, completion date, completion date and completion date, including legal holidays, waiting time for cross-construction and cooperative construction. If the weather or other factors affect the construction, Party B may extend the construction period appropriately after Party A confirms and agrees.

Second, the engineering service form

Contract work, contract materials, contract term and contract quality.

Third, the total project price

It is tentatively set at RMB 10000 yuan (subject to the maintenance list confirmed by both parties).

Fourth, the settlement method

Pay off all the project funds after the project is completed and accepted.

Verb (short for verb) guarantee

1. After Party B's maintenance project is completed, Party B shall undertake the warranty responsibility for all projects. The warranty period is years, counting from the date when the project is completed, accepted and delivered to Party A. ..

2. During the warranty period, Party B shall pay a regular return visit to the construction project, make a record of the return visit, and solve the quality problems with hidden dangers in time. Party B now keeps the written address and telephone number of the person in charge of warranty so as to inform Party B to carry out maintenance.

Liability for breach of contract of intransitive verbs

65438+

2. If Party B stops work for more than two days (including two days) without Party A's permission, Party A has the right to terminate the contract, and Party B shall leave unconditionally within two days. After Party B leaves, both parties shall settle accounts.

3. If Party B violates any other obligations under this contract and is notified by Party A to make corrections within a time limit, Party A has the right to terminate this contract, and Party B shall bear all losses caused thereby.

4. Party A or the owner has the right to claim compensation from Party B within two years from the date of knowing the quality problems caused by Party B's intentional or negligent failure to meet the technical specifications and environmental protection requirements or inconsistent with the contract, regardless of whether the project has passed the acceptance, delivery and exceeded the warranty period.

5. Without the written consent of Party A, Party B shall not transfer the rights and obligations under this contract to others, otherwise, Party A has the right to terminate this contract.

6. Before the engineering quality problems of the parts repaired by Party B are solved, Party A has the right to refuse to pay any money.

7. If the contract is terminated due to Party B's reasons, Party B shall bear the penalty of 65,438+00% of the provisional contract price. If the liquidated damages are insufficient to make up for the losses of Party A (including the compensation and liquidated damages paid by Party A to the third party), Party B shall also compensate the losses of Party A.. ..

Seven, safety construction

Party B shall take strict construction safety measures in accordance with relevant regulations, and bear the responsibility for accidents caused by its own ineffective safety measures and the expenses and consequences arising therefrom. Party B shall be responsible for the personal safety of its construction personnel. Party B shall purchase personal accident insurance and all insurance related to the project construction for the construction personnel. In case of safety accidents or other accidents during construction, Party B shall bear the responsibilities.

Eight, the construction responsibility

1. Party A shall provide Party B with water, electricity and other conveniences during the construction period, and be responsible for coordinating with residents and subordinate departments. Party B shall carry out the construction according to the requirements of construction technology.

2. During the construction period, Party B shall protect the square brick footpath, flowers and trees of the unit from damage.

3. Before the project is completed and accepted, Party B shall be responsible for protecting all the facilities, finished products and semi-finished products on site and bear the expenses.

4. During the maintenance period, Party B must concentrate the garbage in the place designated by Party A every day, keep the construction site clean and remove it within the time required by Party A, otherwise Party A has the right to entrust others to clean it up, and the expenses incurred shall be deducted from the project payment payable by Party A to Party B. ..

5. Accept the quality inspection, inspection and supervision of Party A's representative and its appointed personnel at any time during the construction process, provide convenient conditions for inspection, inspection and supervision, rework and modify according to the requirements of Party A's representative and its appointed personnel, and bear the cost of rework and modification caused by its own reasons.

6. The maintenance works agreed in this contract must be completed by Party B. Without Party A's consent, Party B shall not subcontract or hand over the works to any other third party, otherwise, Party A has the right to terminate this contract.

Nine. others

1. This contract is made in sextuplicate, with Party A holding four copies and Party B holding two copies. This contract shall come into effect as of the date of signature and seal by both parties.

2. Matters not covered in this contract or disputes arising from the execution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, it shall be settled by the people's court where the maintenance project is located.

Party A (signature): Party B (signature):

Year, month, sun, moon, sun.

Simple office maintenance contract 2 Party A:

Party B:

Party A and Party B negotiate that Party B will decorate the office for Party A, as follows:

First, the content of the decoration:

1. Party B is responsible for the cement, sand, latex paint and labor costs for the whole office wall treatment.

2. Leveling all reinforced floors that should be laid. All materials and labor costs shall be borne by Party B. ..

3. The transformation of circuits and signal lines requires that every room and hall have corresponding telephone lines and computer signal lines. The lobby room needs a telephone and at least six computer signal lines.

4. Party B shall be fully responsible for the design and manufacture of ceiling and image wall.

5. Interior design of bedroom and decoration of partition wall.

6. The screens, desktops and chairs used in the office shall be subdued by Party B according to Party A's requirements. The style and color are decided by Party A. ..

Second, the mode of payment.

Pay after signing the contract? Rmb, to be paid after interior decoration? Yuan RMB. Finally, the balance will be paid in one lump sum after the production of office equipment is completed.

Party A: Party B:

date month year

Simple Office Maintenance Contract 3 Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reach an agreement on the construction of this decoration project and conclude this contract.

I. Project Overview and Contracting Method

1, project name:

2. Project location:

3. Project contracting method: contracting for work and materials.

4. Project Overview: Construction Area

Second, the engineering decoration content

Decorative works such as partition wall, wall latex paint, electrical transformation, glass installation and indoor door replacement have been added to the office.

Third, the project cost

The quantities of this project settlement shall be confirmed according to the site list; The amount is settled in real value.

Fourth, the term of the contract.

Project commencement date: year month day.

Project completion date: year month day.

Verb (abbreviation of verb) quality requirements

Reach the national current "building decoration engineering construction acceptance standard" qualified standard. After the completion of the project, if there is any quality problem (not the responsibility of Party A), Party B will guarantee it for two years free of charge.

Terms of payment for intransitive verbs

After the project is completed and accepted, Party A shall pay Party B the full amount of the total project cost.

Seven. any other business

5. Other matters not covered shall be settled by both parties through consultation.

6. This contract is made in quadruplicate and shall come into effect after being signed and sealed by both parties.

Name of Party A: Name of Party B.

(Seal) (Seal)

Authorized Agent: Authorized Agent:

Date of signature: year month day.

Simple Office Maintenance Contract 4 Employer: (Party A)

Contractor: (Party B)

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this construction project and conclude this contract.

Article 1: Project Overview

1, project name: office decoration.

2. Project location:

3. Project scope: interior decoration (see budget list)

4. Project contracting mode: This project adopts integrated contracting mode (see attached table).

5. Project cost

(1) The total cost of the project budget is RMB, in words: ten thousand yuan only.

⑵ Calculation basis of total cost of this project

A, according to the engineering design and construction drawings and design changes, on-site visa.

B. During the construction period, Party A and Party B shall confirm the cost of changes or additional measures caused by construction obstacles.

C. New engineering expenses required by Party A and Party B in the construction process.

Article 2: Construction Period

1. Upon confirmation by both parties, the contract duration of this project is 180 days (calendar), and the specific development time shall be subject to the commencement report signed by both parties.

2. The planned commencement date of this project is YY, and the planned completion date is YY.

3, this project in the construction process, in case of the following circumstances, can postpone the time limit for a project.

(1) The normal construction cannot be carried out due to force majeure;

(2) Continuous construction is affected due to Party A's reasons (including the lack of project payment).

(3) Due to design change or design uncertainty.

(4) because the relevant property rights or administrative examination and approval procedures have not been completed.

(5) Within one month, due to power failure, water and gas cut-off at the construction site (not due to Party B's reasons), the cumulative work stoppage exceeds 8 hours;

(6) The construction is affected because Party A fails to provide support in time or the supporting unit does not cooperate.

Article 3: Construction preparation and responsibilities of both parties

1, Party A's responsibility

(1) Before the commencement of construction, Party A shall coordinate all aspects and complete the mobilization procedures, and Party A shall undertake the mobilization procedures.

(2) Organize design disclosure and the blue prints.the design work.

(3) Being entrusted as the representative of Party A to supervise the quality and progress of the project and handle the daily affairs of the project on behalf of Party A. ..

(4) Before commencement 1 day, Party A shall vacate the decoration site for the commencement of the project.

(5) Supply materials and equipment provided by Party A; Implement the construction funds, declare and pay the project advance payment on schedule, handle the on-site visa and complete the acceptance.

2. Party B's responsibilities

(1) Provide complete construction drawings and construction technical data.

(2) Organize relevant personnel to be familiar with the construction drawings and design data, prepare the construction drawing budget and construction organization plan, and formulate the overall construction plan.

(3) Prepare for construction and organize mobilization, procurement, supply and management of personnel, materials and facilities.

(4) Carry out the construction in strict accordance with the construction drawings and instructions, ensure the quality of the project, complete the delivery on schedule according to the time stipulated in the contract, and undertake the relevant provisions of the maintenance agreement agreed by both parties. Man-made damage shall be repaired by the responsible party at its own expense.

(5) Being entrusted as the representative of Party B, contacting the representative of Party A on behalf of Party B. ..

Article 4: Project Price and Payment

1. The contract budget of this project is based on the workload of the construction drawing and the construction scheme.

2. The related expenses such as management cooperation fee and decoration deposit charged by the property shall be paid by Party A. ..

3. The total contract price of this project is RMB:

4. Pay by installments according to the progress of the project.

5. The time and corresponding amount of installment payment are:

(1) 10% of the contract price when signing the contract, RMB:? Jacky.

(2) yuan. Payment for engineering changes shall be confirmed by both parties, and the construction of additional projects can only be carried out after payment.

Article 5: Construction Quality and Design Changes

1. Adhere to the construction according to the drawings, and neither party may arbitrarily change the design. Losses caused to Party B due to the following circumstances shall be borne by the responsible party.

(1) If the design is found to be wrong or seriously unreasonable, after Party B notifies Party A, Party A shall negotiate with the design unit within three days, issue a design modification document, and start work only after both parties sign an agreement.

(2) When the design change exceeds the original design standard or scale, Party A must re-submit it for approval according to the examination and approval procedures, and construction can only start after both parties sign an agreement.

(3) Due to insufficient investment of Party A, the project progress payment cannot be allocated in time, which leads to the project shutdown or delay. Both parties agree to put the project in progress in place safely, and Party A shall bear the economic losses of Party B. ..

2. If Party B encounters important and complicated concealed works, it can notify Party A for acceptance. If Party A can't attend on time, Party B can accept it by itself, and Party A will acknowledge it.

Article 6: Acceptance and Settlement of Project Completion

1. Party B shall notify Party A of acceptance in writing or orally before the completion of the project.

2. Party A shall organize the acceptance after receiving the acceptance notice, and issue the project acceptance certificate after passing the acceptance.

3. If Party A uses the project before acceptance, it shall be deemed that Party A has confirmed that the project is qualified. If quality problems are found after use, Party A shall bear the responsibility.

4. After the project is completed, Party B will provide free maintenance service for one year, but it does not include the damage caused by human factors.

Article 7: Safe production and civilized construction of the project

1. Party A shall make safety disclosure for the project undertaken by Party B, make clear the safety requirements, and conduct supervision and inspection. Both parties shall negotiate related safety production responsibilities and public security fire control matters according to regulations.

2. Party B must conscientiously implement the rules and regulations of safe production and civilized construction, do a good job in safety production and civilized construction education, strictly abide by the safety operation rules and civilized construction requirements, and strictly implement the public security fire control regulations.

3. In the process of project construction, if Party B's personnel suffer from work-related injuries and acute diseases, Party A has the obligation to provide convenience and assist in rescue, and the responsibility and expenses shall be borne by the responsible party.

Article 8: Engineering Punishment and Arbitration

1. If the construction period is delayed by one day according to the contract of this project, it will be punished according to two thousandths of the total project cost, and the construction period punishment will be settled at one time after the completion of this project. If one party breaches the contract, the breaching party shall bear the penalty of 30% of the contract price.

2. If Party A delays the settlement and payment, it shall be implemented according to the current relevant national regulations.

3. In case of any contract dispute during the execution of this contract, both parties shall settle it through negotiation in time. If the coordination fails, either party shall apply to the superior competent department or the construction competent department for mediation. If mediation fails, it may be submitted to the Arbitration Commission where the project is located for arbitration or bring a lawsuit to the people's court where the project is located.

Article 9: Supplementary provisions

1. For matters not covered in this contract, both parties shall negotiate supplementary terms in time, which have the same legal effect as this contract.

2. This contract is made in duplicate, with each party holding one copy.

3. This contract shall come into effect after being signed and sealed by both parties. The warranty period expires after the project is completed, accepted and delivered, and the project price will be automatically terminated after settlement.

4. Effective annexes to this contract.

(1) Party B shall provide the plane drawings;

(2) Project budget;

(3) Supplementary clauses;

(4) Others

Party A (seal): Party B (seal):

Agent:

Date:

Simple Office Maintenance Contract 5 Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party A)

In accordance with the relevant provisions of the Contract Law of People's Republic of China (PRC) and following the principles of voluntariness, equality, fairness and good faith, both parties reached an agreement on building the roof of the office building of Dafeng Township Animal Husbandry and Veterinary Station and concluded this contract.

1. Project content: Party B is responsible for the construction of color steel roof tiles.

Second, the project quality and acceptance criteria: after the completion of the construction, it is guaranteed to resist the six-level gale and not leak rain. The color steel plate is 4 mm thick. If it collapses or is damaged within two years, Party B shall carry out on-site maintenance within 24 hours after the collapse or damage occurs, and the required expenses shall be borne by Party B. ..

Three. Project valuation: The color steel tile of this project is priced according to the panel, with unit price of 80 yuan /m2, construction area of m2, and total price? Yuan.

Fourth, the construction period is days

Verb (abbreviation for verb) The responsibility of both parties.

The responsibility of intransitive verb Party A:

1. Party A shall provide electricity for construction and convenient construction conditions.

2. Be responsible for allocating project funds to Party B. ..

Party B's responsibilities

1, in strict accordance with the construction requirements.

2, strict operating procedures, not forced, illegal construction, strictly put an end to fire safety accidents. Otherwise, Party B shall bear all responsibilities arising therefrom.

3. Before the completion of the project is handed over to Party A, Party B shall ensure that Party A will not bear any responsibilities arising from casualties or property losses, and Party A will not bear any litigation, accusation, claim liability and possible expenses belonging to Party B and its construction personnel. 7. Payment method: After the construction of this project is completed, Party A will provide effective tax invoices according to the construction area and quality of colored steel tiles completed by Party B, and settle the project payment in one lump sum after acceptance. ..

Eight. This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature.

Party A: Party B:

Year, month, sun, moon, sun.

Simple office maintenance contract 6 Party A:

Party B:

Due to the need of work, our office needs to renovate some floors and refresh the walls. Now our bureau has decided to entrust Yang Heping (hereinafter referred to as Party B) to undertake the work of this project, and now we have signed a cooperation agreement on the quality and construction safety of this project as follows:

1: Through negotiation between Party A and Party B, it is determined that this project will be contracted out to Party B for construction in the form of contracting, and all expenses (creditor's rights, debts, etc.). ) the expenses will be borne by Party B. ..

2. Party B shall use the materials according to the construction requirements, and be responsible for cleaning up the garbage generated by the construction and transporting it abroad. Party A does not conduct cost accounting alone, and provides free warranty for any quality problems of construction projects within one year. After the completion of the project, both parties shall conduct acceptance and settlement of the construction project according to the final statement of the project.

Three. Party B shall carry out the construction in strict accordance with the operating procedures to ensure the quality of the project. During the construction period, the workers they employ must be required to pay attention to the safety of water and electricity use to prevent accidents.

Four. During the construction period, Party B shall strictly control safety to ensure the life and property safety of third parties and constructors. If losses are caused to all parties, Party A shall not be liable for compensation. All legal liabilities and relevant compensation obligations shall be borne by Party B. ..

V: Party B shall start the construction from the date of signing this agreement and ensure the completion within 30 days. In case of special weather, which affects the construction progress, it may be appropriately postponed with the consent of Party A. ..

Six: After Party B's construction is completed and accepted by Party A, Party B will issue a tax invoice and account number, and Party A will be responsible for transfer payment.

The above terms and conditions shall come into effect after being confirmed and signed by both parties.

Signature and seal of Party A:

Signature and seal of Party B:

Date:

;