Model contract for construction projects in 2022

1.2022 construction project contract template

Party A: (hereinafter referred to as Party A) Party B: Yang (hereinafter referred to as Party B)

Party A and Party B have reached an agreement on the project construction through consultation in accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Regulations on Quality and Safety Management of Construction Projects and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith:

I. Overview of the Project:

(1) Project Name: Pengshan Village Building Restoration Project

(2) Project Location: Pengshan Village, Chengdong New District, Yangxin County

(3) Project scale: about 40,000 square meters.

(4) Project content: Pengshan Village building restoration project designed by Architectural Design Institute, and the construction content included in the construction drawing.

Second, the scope and methods of contracting:

(1) The building under construction is designed as a multi-storey and small high-rise group project. Multi-floors shall be contracted according to the floor area of 800 yuan/㎡, and small and high floors shall be contracted according to 1 160/㎡. The roads around each building are about 3 meters wide, including main roads, greening, lighting, hardening and security doors, elevators and residential walls, property, etc.

(2) The project scope contracted by Party B includes: artificial materials, aluminum alloy windows and ordinary indoor doors. Interior wall paint, cement floor, simple water and electricity installation, kitchen suggested cooktop, ceramic tile, simple toilet, simple ceramic tile on wall and floor, and electricity in each room is connected and plugged in, including fire-fighting facilities, red sand paint or paint sprayed on the exterior wall, stair cement treads, ordinary handrails, imitation porcelain paint on the wall and induction lamp facilities.

3. When signing this contract, Party B shall pay RMB 4 million as the project reputation fund. After the completion of the engineering foundation, Party A will return 2 million yuan to Party B. When the fourth floor is capped, Party A will pay the remaining 2 million yuan to Party B as a credit fund. If it is not returned within the time limit, it will be paid to Party B at 3% interest.

Four. Quality requirements: the project is guaranteed to be qualified. If Party B does a good job, Party A will reward Party B according to national standards.

5. Time limit: When Party B breaks ground to deliver the first batch of 30,000 square meters, the time limit shall not exceed 380 days. In case of exceeding or delaying, Party A and Party B shall increase or decrease 1 1,000 yuan/day.

Safety requirements of intransitive verbs: During normal construction, Party B must purchase accident group insurance for construction workers to ensure personal safety and zero accidents. In case of personal injury accident, all responsibilities shall be borne by Party B, and Party A shall not be held responsible.

Seven. Payment terms:

(1) When Party B's main body is capped and multi-layer main body is capped, Party A shall pay Party B 3 million yuan for the project.

(2) After the project is completely completed, Party A shall pay Party B an advance payment of 70% of the total cost. After the project is completed and accepted, Party A shall pay Party B an advance payment of 25% of the total price within three months, and the remaining 5% shall be paid to Party B in full one year without any quality accident.

Eight. Party A's responsibilities:

(1) Party A is responsible for handling the relevant engineering procedures to ensure the smooth progress of Party B's construction. If the procedures cannot be put in place halfway due to Party A's reasons, which affects the project shutdown, all losses will be borne by Party A, and Party A will also bear the loss of 200 yuan per person per day caused by the shutdown.

(2) Party A is responsible for coordinating local and social relations. In case of stoppage due to disputes over neighboring relations during construction, Party A shall bear the losses of Party B per person per day in 200 yuan.

(3) Party A guarantees to pay the project payment according to the contract. If the payment cannot be made according to the contract, Party B has the right to refuse to deliver part of the house to Party A, and Party A shall bear 3% interest compensation every month.

(4) Party A shall prepay all the steel and double admixture of Party B in this project at the market price until the completion acceptance and settlement deduction.

Nine. Party B's responsibilities:

1. Party B shall carry out the construction with good quality and quantity according to the drawings. In case of rework or unqualified construction quality, Party A has the right to order Party B to rework, and Party B shall be responsible for the losses caused thereby.

2. Party B must obey the reasonable arrangement of Party A's full-time supervisors, and it is strictly forbidden for unqualified building materials to enter the site. Once found, the supervisor of Party A has the right to order Party B to replace the qualified materials.

3. During the construction period, Party B shall conduct civilized construction, and it is forbidden to use the old, the weak, the sick and the disabled and child labor. The project organization on the construction site must be orderly, and Party A has the right to supervise Party B's behavior.

Ten, ancillary works and other supporting projects with the same price, Party B has the priority to contract, the two sides signed a separate contract agreement.

XI。 Matters not covered in this contract shall be settled by both parties through consultation at the construction site.

12. This contract has the same legal effect. In case of unilateral breach of contract, the breaching party shall bear the penalty of 10% of the total house price to compensate the observant party.

Thirteen. This contract is made in quadruplicate, with Party A and Party B holding two copies respectively. The signature and seal will take effect and both parties will abide by it.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2.2022 construction project contract template

Owner: (Party A) Contractor: (Party B)

On the basis of equality, voluntariness and consensus, and on the principle of independent operation and self-financing, Party A and Party B have reached the following agreement on the basis of recognizing and implementing the terms of this contract and combining the specific conditions of this project:

I. Project name:

Second, the scope of contracting:

Three. Quality: Carry out the construction according to the drawing project agreed by both parties, and Party B shall complete the construction according to the requirements agreed by both parties through consultation.

Fourth, the construction period: days.

Verb (abbreviation of verb) Project cost and payment method:

1. Project cost: yuan/ton, * * * ton, * * * yuan.

2. Payment method: one-time payment after completion.

Duties and obligations of Party A and Party B:

1. If Party A fails to pay according to the contract, Party B has the right to stop the construction, and Party A shall compensate all economic losses caused by Party B's delay in work.

2. Before Party B's construction, Party A must ensure that water, electricity and roads are connected during Party B's construction, and water and electricity must arrive at the construction site.

3. During the construction period, Party B shall bear the industrial accidents at the site.

4. All losses caused to Party A due to Party B's failure to construct according to the design requirements and quality problems shall be borne by Party B. ..

5. During the construction period, due to individual weather and conditions, the construction period can be postponed. If the project cannot be completed according to the contract due to Party B's reasons, Party A has the right to fine Party B at 2% of the total project cost.

7. Any dispute between Party A and Party B shall be settled through negotiation. If negotiation fails, it shall be decided by Shouguang Municipal People's Court.

Eight. Matters not covered in this contract shall be settled by both parties through consultation.

Nine. This contract is made in duplicate, one for each party. This contract shall come into effect as of the date of signature and seal by both parties.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3.2022 Model construction contract

Employer: (hereinafter referred to as Party A) Contractor: (hereinafter referred to as Party B)

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B agree to sign this contract through consultation for mutual compliance. The specific terms are as follows:

First, the installation content

1, project name:

2. Project location:

3. Scope of contract:

1) Construction drawing and system diagram of fire protection system provided by Party A..

2) The scope specified in the design change

3) Scope specified in the technical verification table

4. Contracting method: auxiliary materials are included in the contracting method (general construction contract). For water system, Party A only provides pipelines, equipment, valves, clamps, malleable cast iron, flange screws, pipeline paint, section steel and casing; For the alarm system, Party A only provides conduits, cables, boxes, screws and alarm equipment. Other materials shall be provided by Party B, and the materials provided shall meet the specifications and design requirements.

Second, the construction period

1) According to the general contract of this project, the total construction period of Party B is calendar days, the commencement date is subject to Party A's notice of entry, and the completion date is that Party B shall complete the debugging and operation of the whole system within 10 days.

2) If the construction period is delayed due to irresistible reasons or Party A's reasons within the specified construction period, the construction period shall be postponed, and Party A shall verify and sign a written record. ..

3) A fine of 1 ,000 yuan will be imposed for each day of delay in the construction period, and Party A's temporary work-grabbing requirements will be regarded as the construction period, and the construction period will be rewarded in advance 1 ,000 yuan.

4) If the construction period cannot be completed after taking measures, the third paragraph of Article 8 shall apply and a fine of 5% of the contract amount shall be imposed.

Third, the project quality requirements:

1) Organize construction in strict accordance with relevant construction acceptance specifications. In case of major quality accidents, Party A has the right to impose a fine of 5% of the contract amount and terminate the contract unconditionally, and all losses caused thereby shall be borne by Party B..

2) If the general quality problems are not rectified after being pointed out by Party A, 500 yuan will be fined. If the general quality problems are not rectified after punishment, Party A has the right to terminate the contract unconditionally.

3) Encourage reasonable suggestions. After the proposal is adopted, it will generate benefits, and 40% of the cash that creates benefits will be rewarded on the spot.

Fourth, the project price:

Total project price: RMB (in figures ￥).

In which: ① automatic fire alarm system: RMB yuan;

② Automatic sprinkler system: RMB yuan;

③ Fire hydrant system: RMB;

Verb (abbreviation of verb) settlement method

1) Settlement of progress payment: the settlement basis of water spraying and fire hydrant system is pipeline extension meter, and the settlement basis of fire alarm system is alarm point.

2) The final settlement is based on the alarm point and the spray point, namely, the alarm element/point and the spray element/point, 280 yuan for new fire hydrant and 200 yuan for fire hydrant.

3) Engineering design changes shall be settled on the basis of visa, and the price reduction shall be no less than 5 points, and the increased labor costs shall be settled according to the facts.

4) After Party B enters the site, Party A shall pay 50% of the completed works as the progress payment for each layer (pipeline pressure test). After the trial operation of the project, Party A shall pay Party B 70% of the provisional total amount of the project, and 95% of the total settlement price of the project after the government and users accept and hand over the construction fee. 5% as the project quality deposit, paid one year later.

Six: Warranty

Implement the State Council No.279th Order "Regulations on Quality Management of Construction Projects".

The warranty period is one year, counting from the date of acceptance. The construction team shall be solely responsible for the maintenance during the warranty period, and the expenses shall be borne by Party B. ..

Seven. Responsibility of both parties

(1) Party A's responsibilities:

1) Provide construction drawings and relevant technical data, and make technical disclosure for construction.

2) Organize materials to enter the site in time.

3) Provide Party B with suitable working conditions.

4) Pay in time according to Party B's project progress, and organize acceptance in time after Party B's construction is completed.

(II) Party B's responsibilities:

1) Organize the construction in strict accordance with the construction drawings, national technical specifications and construction procedures, and Party B shall not change the original design without Party A's notice of design change. Participate in construction coordination meetings and technical seminars as required by Party A. ..

2) Be responsible for coordination with the supervisor, complete the original records, concealed works records, technical data and as-built drawings in construction in time, and put them into a book and submit them to Party A. ..

3) Be responsible for the finished product protection of the completed project, bear the loss expenses before delivery, and accept Party A's request to take special protection measures for the completed project.

4) Party B's personnel stationed at the site shall remain stable. If the transfer is required, Party A's consent shall be obtained in advance. Party A will be fined 1 ,000 yuan each time if he leaves his job without consent or in disguised form.

5) Conduct civilized construction. If there is any behavior that damages Party A's corporate image and causes adverse effects, Party B will be fined 65,438 yuan+0,000-5,000 yuan depending on the seriousness of the case.

6) Dress for safe construction. Those who don't wear work clothes will be fined 20 yuan each time, and those who don't wear safety helmet will be fined 100 yuan each time. 500 yuan will be fined for not wearing a seat belt when working high above the ground.

7) Party B must purchase accident insurance for all construction personnel. In case of a safety accident, all economic responsibilities shall be borne by Party B, and Party A will deduct 5% of the total contract amount as liquidated damages. If the circumstances are serious, Party B shall resign unconditionally.

8) Be responsible for the on-site storage of the materials provided by Party A. In case of loss or theft, Party B shall make full compensation.

9) The material loss of Party B in the construction process shall not be greater than the fixed material loss coefficient, otherwise the difference shall be borne by Party B..

10) Party B shall not deduct the project payment or default on the wages of workers. If the worker finds Party A or the construction party due to salary problems, 5% of the total contract amount shall be deducted as liquidated damages.

Eight. Other matters:

1) Both parties must strictly abide by the terms of the contract. In case of unilateral breach of contract, the breaching party shall bear the responsibility for economic losses.

2) Party B shall keep the communication unblocked. If Party B fails to contact due to downtime, shutdown, number change, etc., it will be fined 50 yuan for the first time and 100 yuan for each subsequent time.

3) If Party B fails to complete the construction task according to Party A's schedule or quality requirements, Party A has the right to handle it in the following ways.

① Unconditional replacement of site management personnel;

(2) Unconditional economic punishment;

(3) unconditionally accept the face assignment of the project department;

(4) Dissolve the contract between both parties and leave unconditionally.

4) This contract is made in duplicate, with each party holding one copy.

5) Matters not covered in this contract shall be settled by both parties through negotiation.

Party A: Party B:

Representative: representative:

Address: Address:

Tel: Tel:

Date: Year Month Day Date: Year Month Day

4.2022 Construction Project Contract Template

Party A: Party B:

According to People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Construction Law and other relevant laws, regulations and rules. Based on the principles of equality, voluntariness, fairness, honesty and credit, both parties have reached an agreement on this project and will abide by it together.

I. Overview of the Project

1, Project Name: Safety Maintenance Project of Flood Control Material Warehouse of Jiangsu Flood Control and Drought Relief Center.

2. Project location: Flood Control and Drought Relief Emergency Center.

Second, the time limit for a project:

1. Commencement and completion date: August 29 -20, 20001October 27 (subject to the commencement report).

2. The total duration of the contract is 60 working days. In case of irresistible special weather such as continuous rainstorm, the construction period can be postponed accordingly after being signed by Party A and the supervisor.

Three, the quality standard adopts the following contents:

Meet the national quality acceptance standards;

Four. Contract price

The settlement of the project price in this contract adopts the following methods:

1. The fixed unit price is RMB/m2 (the workload is settled in real terms).

Verb (abbreviation of verb) payment terms

1, the project payment will be paid to 90% of the approved price after review, and the retention money of the quality guarantee fund 10% will be paid one year later.

Six, materials and equipment supply:

VII. Quality and Acceptance

1. The quality of the project must meet the standards specified in Article 4 of this Agreement and be implemented according to the current national acceptance specifications. The quality guarantee period is years. If the project involves the main structure, it will be guaranteed for life.

2. Without the consent of Party A, all Party B's personnel entering the site shall not be replaced at will. If it is really necessary to change, an application shall be made to Party A in writing three days in advance, otherwise, if Party B arbitrarily changes 30% of the staff, Party A has the right to terminate the contract and Party B will leave unconditionally.

3, project quality acceptance must be carried out according to the specification, all engineering data must be synchronized with the engineering construction, for the relevant departments and personnel to consult, unqualified data timely correction.

5, subdivisional work acceptance, and concealed engineering acceptance, must be signed by Party A and supervision before the construction of next working procedure.

6. Party A shall complete the acceptance within hours after receiving Party B's inspection report and issue a written acceptance opinion. Usually, Party A conducts spot checks regularly or irregularly, and when quality problems are found, it issues written rectification opinions within a time limit, and Party B must rectify within a time limit according to Party A's requirements. If quality problems are found many times, or still fail to meet the requirements after two rectifications, Party A has the right to pay liquidated damages as appropriate, and if the circumstances are serious, Party A shall be ordered to withdraw from the market, and all losses shall be borne by Party B. ..

7. After completion, Party B shall notify Party A in writing for acceptance, and Party B shall provide the as-built drawings and all as-built materials that meet the requirements of the specifications in duplicate within one day after completion.

8. Other agreements: The construction shall be carried out according to the drawings to meet the requirements of Party A, and it is forbidden to spill or dump it anywhere.

Eight, construction organization and time limit for a project

1. Party B shall submit a written construction organization plan to Party A within three days after receiving Party A's formal construction drawings, and Party B shall go through relevant formalities such as the commencement report, and Party A shall examine and approve Party B's construction organization plan and arrange technical disclosure of the drawings.

2. Party B must organize the construction according to the contract period and the approved schedule, and accept the supervision and inspection of the project progress by Party A and the supervisor. When the actual progress of the project is not in conformity with the plan, Party A and the supervisor have the right to order improvement within a time limit, and Party B shall put forward rectification measures according to the requirements of Party A and the supervisor, and report them to Party A and the supervisor for approval before implementation. During this period, Party B shall pay overtime. When the monthly progress is obviously behind schedule, Party A has the right to suspend the payment of project funds. If Party B obviously can't complete the project according to the agreed time limit, Party A has the right to change the construction team, and Party B shall unconditionally evacuate the site within 10 days after receiving the evacuation notice from Party A, and all personnel and equipment shall be evacuated, and the project payment shall be paid according to% of the actually completed project amount, otherwise, Party A will not pay any money, and shall bear a penalty of 2‰ of the total project amount for each day of delay, and compensate other losses in full.

4. Agreement on water, electricity, accommodation, tools and other facilities during the construction period: Party B shall solve it by itself.

Nine, safety and civilized construction and management

1. Party B shall strictly implement relevant safety operation management regulations.

2. Persons without ID cards, bad records, physical disabilities and child labor shall not be employed. Otherwise, the consequences are at your own risk.

3, special projects need to hold a license issued by the labor department, show certificates.

4. Party B shall handle industrial accidents or other internal disputes during the construction period and bear all economic responsibilities.

5. All mechanical equipment should meet the needs of engineering construction, and special equipment should have safety inspection certificate.

6. Party B shall conduct standardized management on the construction site according to the regulations of the relevant departments of the local government, and all penalties and losses caused by inadequate standardized management shall be borne by Party B. ..

7. Party B shall give priority to the payment of wages to the construction personnel, and shall not default, and properly handle labor disputes and related issues, so as not to affect the construction and cause any adverse impact to Party A, otherwise Party A shall.

Have the right to take measures such as canceling the contract, ordering to leave, demanding compensation for losses, and demanding payment of liquidated damages.

X. Party A's responsibilities

1. Provide drawings and information as agreed, and make technical disclosure of drawings.

2. Pay the project payment to Party B as agreed. If Party A fails to cash in time due to financial difficulties, it shall negotiate with Party B and bear part of the bank loan interest payable to Party B according to different situations.

4. Perform other obligations agreed in this agreement and be responsible for

XI。 Party B's responsibilities

1. Complete the construction task with good quality and quantity as agreed, and meet the construction period and quality requirements.

2. Party B must obey Party A's on-site management, abide by laws and administrative regulations, abide by various rules and regulations, and safeguard Party A's reputation. If Party A is found to intentionally damage its reputation, seriously violate discipline or violate the contents of the agreement, Party A has the right to impose economic penalties until the contract is terminated.

3, should pay attention to protect the ecological environment, pay attention to the construction safety, do not cut down trees and damage other facilities, pay attention to forest fire prevention.

4. Party B shall not stop working or work passively for any reason, or take improper measures such as noise and threats, otherwise, Party A has the right to order him to leave, and all consequences shall be borne by Party B. ..

5. In case of quality problems during the warranty period, Party B shall enter the site for maintenance within days after receiving Party A's phone call or written notice, and complete the maintenance within days, otherwise the maintenance cost will be deducted from the warranty fund.

6. Party B shall, in accordance with relevant regulations, take the initiative to make a quality follow-up visit to the project.

Twelve. responsibility for breach of contract

1. Both parties shall strictly abide by the agreement. If there is any violation, it shall be liable for breach of contract according to the relevant provisions of this agreement.

2. If the construction period is delayed, Party B shall bear the liquidated damages according to the total contract price or pay the liquidated damages to Party A at a daily rate of 1 0,000 yuan.

3. In case of quality problems and violation of other agreements in this Agreement, Party B shall compensate all economic losses caused to Party A, and Party A may require Party B to bear the liquidated damages of 1%- 10% of the total contract price according to specific conditions.

Thirteen. supplementary terms

1. This agreement shall come into effect after being signed and sealed by both parties.

2. Once this agreement is signed, both parties shall strictly abide by it. Any dispute arising from the execution of this agreement shall be settled by both parties through consultation. If negotiation fails, the people's court of the place where the agreement is signed shall make a ruling.

3. This agreement is made in quadruplicate, two for each party, with the same legal effect.

4. Matters not covered in this contract or disputes arising from the execution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, it shall be settled by the people's court where the maintenance project is located.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5.2022 Model construction contract

Now _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A) has contracted the white concrete pavement project in the factory to _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B), and this contract is hereby signed to clarify the rights and obligations of both parties. The terms of the contract are as follows: 1. The project is located in _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Second, the total engineering quantity is _ _ _ _ _ _ _ _ _ _ square meters.

Third, the project contracting form is general contracting.

Four, the project cost per square meter is _ _ _ _ _ _ _ yuan, and the total project cost is determined according to the measured area at the end of construction.

V. _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Six, the project from _ _ _ _ _ _ _ _

Seven. Payment method: after Party B's personnel, machinery and materials enter the site, Party A will pay _ _ _ _ _ of the total project price; When Party B completes half of the total project price, Party A shall allocate _ _ _ _ _ _ of the total project price; The remaining _ _ _ _ _ _ _ project payment shall be paid to Party B in one lump sum after Party B's completion and acceptance.

Eight, the concrete used in the project is labeled as _ _ _ _ _ _ _, and the materials used must conform to the specification requirements, among which the cement used in the project must be _ _ _ _ _ ordinary portland cement exempted from inspection by the state.

9. When entering the construction site, Party B shall abide by the company's factory rules and regulations, take good care of the company's property and conduct civilized construction. If the company's property is damaged, Party B shall pay compensation according to the price.

X. When entering the construction site, Party B shall pay attention to safety construction, implement safety construction regulations and eliminate unsafe hidden dangers. In case of any safety accident during construction, Party B shall be responsible for it, which has nothing to do with Party A.. ..

XI。 Matters not covered in this contract shall be implemented in accordance with the Building Law of People's Republic of China (PRC) and Code for Quality Acceptance of Highway Engineering.

This contract is made in triplicate and shall come into effect as of the date of signature.

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _