How to write a simple decoration agreement (5 articles)

# Letter # Introduction With the development of economy, more and more people buy houses. After buying a new house, it is essential to decorate the house. We can protect our rights and interests through the decoration agreement. The following is how to write a simple decoration agreement for everyone, for reference only, welcome to read.

1. How to write a simple decoration agreement?

Entrusting party (Party A): _ _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (Party B): _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, this contract (including its annexes and all supplementary contracts) is hereby signed for * * * to abide by.

Rule number one,? Project overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ Room specifications

3. Construction content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _.

5. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Rule number two , project price

The project price (amount in words) is _ _ _ _ _ _ _ _ _ _ _ _ _.

Rule three. , quality requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. Regarding the acceptance standard of this project, both parties agree to refer to Zhejiang local standard "Acceptance Standard for Residential Decoration".

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

Article 4? , payment method

1. Once the contract is signed, Party A shall pay 100% of the engineering materials and _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The remaining _ _ _ _ _ _% shall be settled by Party A after the project is completed and accepted. (Note: Construction labor costs include labor costs) Party A pays off the project price, and Party B issues a unified invoice to hand over the warranty card of the decoration project to Party A. If Party A fails to pay the price due, it is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing the construction change form and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in this contract, Party A shall pay _ _ _ _% of the unpaid project price to Party B for each day overdue.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 5? responsibility for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay _ _ _% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 6? Alteration and termination of the contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 7? The contract comes into effect.

1. This contract shall be sealed by both parties and come into force after being signed.

2. This contract shall take effect on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (Owner): _ _ _ _ _ _ _ _ _ _ Party B (Commitment): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. How to write a simple decoration agreement?

Entrusting party (Party A): _ _ _ _ _ _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _ _ _ _ _ _

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * to abide by.

Rule number one. Project overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Room specification: room type: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. Construction content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

4. Entrustment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 2, the project price

The project price (in words) is _ _ _ _ _ _ _ _ Yuan (in words).

1, material _ _ _ _ _ _ _ yuan;

2, labor costs _ _ _ _ _ _ _ yuan;

3. The design fee is _ _ _ _ _ _ yuan;

4, the construction freight _ _ _ _ _ _ yuan;

5. The handling fee is _ _ _ _ _ _ _ yuan;

6. The management fee is _ _ _ _ _ _ yuan;

7. Other expenses (please specify the contents) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 3, Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.

3. In the process of construction, if Party A has special construction projects or special quality requirements, both parties shall sign a supplementary contract for the increased cost.

4. Party A shall be responsible for the quality of all materials and equipment purchased by it; Party B shall be responsible for the quality of the project.

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4. Material supply

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall be prohibited from being used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B _ _ _ _ _ of the total amount of materials supplied by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5. terms of payment

1, once the contract is signed, Party A shall pay RMB _ _ _ _ _ _ _ _ _ ten thousand Yuan. When the construction period is over half (_ _ _ _ _ _), Party A shall pay 40% of the second project price, and the remaining 65,438+00% shall be paid to Party A for settlement after the project is completed and accepted. (Note: Construction costs include labor costs). Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall issue a construction change form and notify the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in this contract, Party A shall pay 1% of the unpaid project price to Party B for each day overdue.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 6, the construction period

1. If the completion is delayed due to Party B, Party A shall be paid a penalty of RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. During the construction, due to the quality problems of the project, both parties disagree, resulting in the suspension of work, failure to act as punishment for delaying the work or the construction period. Both parties should take the initiative to ask the relevant departments to mediate or the arbitration department to coordinate and deal with the dispute as soon as possible, so as to continue the construction.

4. If rework is required due to Party A's reasons or the construction period is delayed due to Party A's change of construction contents, a visa is required, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7, project acceptance

1, project quality acceptance, except for concealed works, which need to be accepted by sections, Party B shall organize Party A to conduct completion acceptance after all projects are completed. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.

Article 8. any other business

1, Party A's responsibility.

(1) The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make on-site disclosure to Party B. ..

(2) Secondary decoration project, in which all or part of the house is vacated and obstacles affecting the construction are removed. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

(3) If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood.

2. Party B's responsibilities.

(1) should take the initiative to show business license, membership card or construction qualification; The handling salesman must have a certificate of entrustment from the legal representative.

(2) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.

(3) Be responsible for the safety, fire prevention, related certificates and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

(4) Strictly perform the contract and implement the credit period. If the completion is delayed, such as divestiture, slowdown or excuses to induce Party A to advance funds, it will be treated as breach of contract after investigation.

(5) Take the warranty responsibility within the scope of decoration construction. The warranty period is 12 months, counting from the date when the project is completed and accepted by Party A. ..

Article 9. Dispute mediation

In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.

Article 10 Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at _ _ _ of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 11 Entry into force of contract

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. The supplementary contract has the same legal effect as this contract.

3. This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy.

Party A: _ _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. How to write a simple decoration agreement?

Entrusting party (Party A): _ _ _ _ _ _ _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _ _ _ _ _ _

According to relevant regulations, Party A and Party B, through equal and friendly negotiation, decided to entrust Party B to lay floor tiles and wall tiles, and signed this agreement for both parties to abide by.

I. Project site

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Room.

Second, the formal structure

_ _ _ floor, _ _ _ room _ _ _ _ hall _ _ _ _ kitchen _ _ bathroom.

Third, the project

1, four rooms (_ _ _ _ _ _ bedroom, _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. If no details are involved, Party A shall propose a plan and discuss it.

Fourth, the way of contracting.

Party A must, according to Party B's requirements, ensure the materials needed during the renovation period (Party B shall notify Party A in advance) and the lunch supply during the construction period, and Party B shall be responsible for the construction.

Verb (abbreviation of verb) quality standard

The construction quality shall meet the safety requirements, and the decoration quality shall not be lower than the decoration standard of the same building type, which shall be approved by both parties. After the project is completed and accepted, if there are quality problems in Party B's construction within 3 months, Party B shall be responsible for rework and maintenance for free.

Six, the project cost

The materials shall be provided by Party A, and Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Seven. terms of payment

In order to ensure the quality of the project, the deposit of _ _ _ _ _ _ _ _ _ Yuan is temporarily withheld, and the deposit will be returned to Party B in full from _ _ _ _ _ _ _. After the project is completed, Party A shall pay Party B the labor cost within three days if it meets the above construction project and design requirements upon acceptance.

Eight. This agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into effect as of the date of signature by both parties.

Party A: _ _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. How to write a simple decoration agreement?

Owner (Party A): _ _ _ _ _ _ Tel: _ _ _ _ _ _ _

Contractor (Party B): _ _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In the spirit of friendly cooperation, Party A and Party B sign the following contract on the basis of equality and fairness in accordance with the Contract Law and other relevant laws of the state.

I. Project Overview and Price

Project address: _ _ _ _ _ _ Building area: _ _ _ _ _ usable area: _ _ _ _ _ _ _

This project is a clean packaging decoration project, which is contracted by Party B and the decoration materials are provided by Party A. ..

The total labor cost for clearing the package is RMB _ _ _ _ _ _ _, in words: _ _ _ _ _ _

Among them, the plumber is a member of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Second, the mode of payment.

1. After the completion acceptance, Party A shall pay the labor fee in one lump sum, totaling _ _ _ _ _ _ _ _.

2. Deduct RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Third, the construction cycle

1. The construction period is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. If the construction period is delayed due to Party A's factors and Party B's factors, Party A may deduct Party B's labor cost of _ _ _ _ _ _ _ _ yuan per day.

3. Before construction, Party B shall organize relevant construction personnel to know the engineering drawings and plans in detail, and formulate scientific and efficient construction organization plans and quality accident emergency plans.

4. Party B shall issue a water and electricity construction drawing and a woodworking construction drawing, which shall be signed and approved by Party A before construction.

Fourth, the removal of materials and garbage

1. Party B shall provide Party A with a list of materials to be purchased seven days in advance, and Party A shall timely purchase materials for use by the construction team two days in advance, and both parties shall bear their respective responsibilities for the construction delay and economic losses caused thereby.

2. Without the consent of Party A, Party B shall not purchase materials by itself. If it has been purchased, Party A unconditionally refuses to use and pay for the materials.

3. Party B shall check the quality of the building materials purchased by Party A, and raise quality problems with Party A in time. Party B knows that there are quality problems in the building materials purchased by Party A but fails to inform Party A, and the relevant losses caused thereby shall be borne by Party B. ..

4. Party B shall assist Party A to receive the goods and check the accuracy of the quantity and accessories. Party B shall properly keep the materials and prohibit other personnel from entering the site. Party B shall protect the finished products after construction.

5. Without Party A's permission, Party B is forbidden to take any building materials out of the house. If such a phenomenon is found, twice the material price will be deducted from the labor cost.

6. Party A's materials are delivered to the downstairs where the project is located, and any construction personnel of Party B shall carry them unconditionally. Daily garbage should be cleaned up on the same day and in fashion bags, and removed by Party B to the garbage dump designated by the property. After the project is completed, Party B is responsible for removing the construction waste.

Verb (abbreviation of verb) construction site management

1. Party B shall show Party A the original identity cards of all construction workers and provide copies of them.

2. On-site construction personnel are strictly forbidden to spend the night, cook and other behaviors unrelated to decoration. Party B's documents for temporary residence and work in this city are complete, and the relevant losses caused by incomplete documents shall be borne by Party B. Party A shall assist Party B in handling community access documents and pay relevant fees.

3. Party B designates _ _ _ _ _ as the person in charge of the construction site and _ _ _ _ as the alternate person in charge. Without the consent of Party A, Party B shall not change the construction personnel at will, and there must be more than 2 construction personnel on site every day. Without the consent of Party A, Party B shall not stop work or go slow under any circumstances.

4. During the construction period, Party B shall accompany Party A to select materials at any time according to Party A's requirements. ..

5. Party B shall bring its own tools needed for construction, and ensure the safety and good usability of the tools, and the maintenance expenses of the tools shall be borne by Party B..

6. Open flame is strictly prohibited on site; Smoking is prohibited on site; Paint materials must be placed separately from other materials.

Maintenance of intransitive verbs

Party B shall repair the quality problems caused by Party B's construction free of charge within two years. For general maintenance, Party B shall carry out maintenance within 24 hours after Party A notifies Party B, and for special cases (water and electricity problems), Party B must arrive and carry out maintenance within 8 hours. If Party B fails to complete the maintenance in time as stipulated in the contract, Party A can arrange other construction teams to carry out the maintenance work, and the labor costs incurred will be deducted from the warranty fund.

Seven. Annex to the contract

The annex to the contract includes: the construction project and quotation list signed and approved by both parties; Material procurement list issued by Party B; Party B shall issue the construction drawings of waterways, circuits and furniture that come into effect with the signature of Party A; Project process acceptance list signed by Party A; Copy of ID cards of Party B's responsible person and construction personnel.

Eight. dispute over a contract

This contract is made in duplicate, one for each party. In case of any dispute, both parties shall negotiate first. If negotiation fails, they can bring a lawsuit to the court.

Nine. Other instructions and requirements

1. Party B must strictly guarantee the construction quality and technology, and carry out the construction in strict accordance with the process acceptance sheet of the project. If quality problems are found in the acceptance process, the construction contractor shall immediately correct them, and the owner has the right to refuse to pay labor costs before the rectification requirements of the owner are met. Party B shall bear all losses caused thereby.

2. For the materials that the owner entrusts the construction contractor to purchase, the manufacturer, brand, specification and unit price of the construction contractor must be approved by the owner before purchasing and transporting them to the construction site, and there should be a valid invoice, otherwise the owner has the right to refuse the acceptance and put forward the return, rework and compensation for losses.

3. Ensure that the original decoration design ideas are reflected, and the decoration scheme shall not be changed without Party A's consent.

4. When the equipment and materials purchased by the owner and installed by the manufacturer, supplier and seller are installed at the door, the construction contractor shall actively do relevant auxiliary cooperation work (including helping the purchased materials and equipment to be transported to the site).

5. Renovation requirements beyond the contract: _ _ _ _ _ _ _ _ _ _.

6. After the hydropower construction is completed, Party B must provide the hydropower completion drawing to Party A for filing.

7. Construction personnel should be civilized and take good care of the original indoor facilities; If the wall is no longer painted or pasted with wallpaper, the plate shall not be placed against the wall; Heavy objects or boards with nails are not allowed to drag on the floor; It is not allowed to work on furniture surfaces, doors, drawers and basins. Don't let cement, sand, cardboard and other building materials or garbage fill toilets or sewers. All items owned by the owner shall not be disposed of without permission. The owner has the right to request the replacement of construction personnel who violate the requirements, and the person in charge of Party B's site will unconditionally implement it immediately.

8. The contractor shall strengthen the safety education on fire prevention and theft prevention for the on-site construction personnel, and the construction personnel shall not violate the law and discipline at the construction site. If you have any problems, you will be at your own risk.

9. Home decoration should comply with the Code for Construction and Acceptance of Decoration Engineering and the current relevant standards, norms and procedures.

10. Party B shall be fully responsible for the quality of waterproof works. In case of any loss caused by water leakage, Party B shall bear all responsibilities and compensate all direct and indirect losses.

1 1. If Party A's electrical appliances and furniture are damaged due to the quality problems of Party B's circuit engineering, Party B shall compensate all direct and indirect losses.

12. Party A reserves the right of final interpretation of this contract.

Representative of Party A: _ _ _ _ _ Representative of Party B: _ _ _ _ _ _

Signature: _ _ _ _ _ _ Signature: _ _ _ _ _ _ _

Tel: _ _ _ _ _ Tel: _ _ _ _ _ _

Date of signing: _ _ _ Date of signing: _ _ _

5. How to write a simple decoration agreement?

Entrusting party (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Trustee (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the relevant regulations of the state and local governments, this contract is signed and abided by by both parties through consultation.

Rule number one. Project overview

1, project address _ _ _ _ _ _ _.

2, room specifications _ _ _ _ _ _ room _ _ hall.

3. The construction area is _ _ _ _ _ _ _ _ _ _

4. Construction content (attached with construction sheet or construction drawing).

5. Entrustment method _ _ _ _ _ _ _.

6. Commencement Date _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

7. Completion date _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

8. The total project price is RMB _ _ _ _ _ (with project budget). In which: the material payment is RMB yuan; Labor costs _ _ _ _ yuan; Other expenses _ _ _ _ yuan.

Article 2, Quality Requirements

1. Varieties, specifications and names of materials used (attached list).

2. Process standard Both parties agree to refer to the Quality Standard for Home Decoration Engineering formulated by China National Light Industry Federation.

3, the construction quality inspection and supervision department _ _ _ _ _ _ _.

4. If there are special quality requirements in the construction process, both parties shall reach an agreement and sign a supplementary contract.

5. The quality warranty period is _ _ _ years after the project acceptance, and the warranty expenses shall be borne by the responsible party.

Article 3. Pay the price

1. After the contract is signed, the contractor shall pay% of the contract price in advance, and the balance shall be paid within one week after the completion acceptance. If the payment is delayed, _ _ _% of the amount owed shall be paid for each day of delay.

2. The contractor's payment method is _ _ _ _ _ _.

3. If there is any increase or decrease in the construction process, both parties shall sign supplementary terms for increase or decrease in the price.

Article 4. responsibility for breach of contract

1. If Party B cannot guarantee the promised quality, Party B shall rework it at its own expense.

2. If the project cannot be completed on schedule due to Party B's reasons, Party B shall pay a loss of RMB for each day of delay.

3. If the project cannot be completed on schedule due to Party A's reasons, Party A shall pay Party B _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

4. In the process of construction, if Party A changes the construction content without consulting Party B's representative, Party A shall be responsible for the quality problems caused thereby.

5. After the contract comes into effect and before the expiration of the performance period, the party who terminates the contract without authorization shall pay liquidated damages at _ _ _% of the contract price; If the losses caused to the other party by the unauthorized termination of the contract exceed the liquidated damages, it shall also compensate for the insufficient liquidated damages.

6. If one party requests to terminate the contract, causing economic losses to the other party, it shall compensate according to the actual losses.

Article 5. settlement of dispute

Disputes arising from the performance of this contract can be settled by both parties through consultation. If negotiation fails, the following methods shall be adopted:

1. Apply to the local competent department of interior decoration industry for mediation.

2. Settle by arbitration.

3. Solve it through litigation.

Article 6. Modification of contract

1. Both parties have reached an agreement. If one party requests to change the content, it needs to obtain the consent of the other party and perform the signing procedures.

2. This contract shall come into force as of the date of signing; During the warranty period, the relevant warranty clauses come into effect and the remaining clauses are terminated; After the warranty period expires, all terms and conditions will be terminated.

Article 7. treaty wording

The original of this contract is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (seal): _ _ _ _ _ _ _ _ _ Party B (seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.