How to write renovation contract in hardcover room? Renovation contract model of hardcover room

Hardcover room is a means used by many real estate developers to attract customers. The owner will show the hardcover room renovation contract when signing the purchase contract, so how to write the hardcover room renovation contract? Next, I will bring you a detailed renovation contract model of hardcover room, hoping to help you.

_ _ _ _ _ renovation contract model of hardcover room

Party A: _ _ _ _ _ _ Real Estate Development Co., Ltd. (hereinafter referred to as Party A)

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and relevant laws and regulations, combined with the relevant contents of the bidding documents and the actual situation, Party A agrees to sign "_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

I. Overview of the Project

1, project name: _ _ _ _ _ _ Fine decoration and renovation project

2. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Project address

3. Engineering structure: frame shear wall structure.

4. Building area: _ _ _ _ _ _ _ _ square meters

5. Project quality: ensure the one-time acceptance rate of 100%, and the quality is excellent.

6. Employer: _ _ _ _ _ Real Estate Development Co., Ltd.

Second, the way of project contracting

Adopt the methods of labor, materials, machinery, time limit for a project, quality, civilized construction, safety, public security and finished product protection.

Third, the scope of project contracting

Scope of contract: all the projects in the _ _ _ _ _ _ _ fine decoration project shown in the construction drawing.

Four. Party B's contracting indicators

1, construction period: _ _ _ _ _ _ days

2. Project quality: ensure the one-time acceptance rate of 100%, with excellent quality.

3, safety in production:

3. 1 Strictly implement the relevant regulations of the local government on industry management and the rules and regulations of Party A;

3.2 put an end to casualties;

3.3 No major mechanical equipment accidents and major fire accidents;

3.4 In case of any safety accident caused by Party B's negligence during the construction, Party B shall bear all responsibilities and losses;

4. Civilized construction: it meets the requirements of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

5. Technical data: timely, accurate and complete filing, responsible for sorting out the project completion files according to government industry regulations and submitting them to Party A for unified filing.

6 Applicable specifications:

A. Code for acceptance of construction quality of building electrical engineering; B. Code for construction and acceptance of building ground engineering; C. Code for quality acceptance of building water supply, drainage and heating engineering; D. construction project management norms; E. Provisions on filing and arrangement of construction project documents; F all other existing standards, norms, regulations and rules applicable to this project.

V. Term of the Contract

1. construction period: commencement date _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. If Party B fails to complete the project within the time stipulated in the contract, Party B shall bear the liability for breach of contract and pay liquidated damages to Party A; If the delay is caused by the increase of the project or the employer's reasons, the employer shall actually notify the extension in writing. If all extension notices cannot be completed on schedule after adding the above completion date, compensation shall be paid at the rate of 0.5 ‰ of the contract amount for each day of extension; Party A may deduct the compensation fee from any money payable to Party B or recover the money in other ways, and the payment of the compensation fee cannot relieve the contractor of his responsibility for completing the project or other responsibilities stipulated in the contract.

3. Party B must organize production according to the "construction organization design" approved by Party A, attend the regular production meeting organized by Party A, complete the construction task on time or ahead of schedule according to Party A's schedule requirements, and accept Party A's inspection and supervision of the schedule. When the actual progress of the project is inconsistent with the confirmed progress, Party B shall propose corrective measures according to Party A's requirements and implement them after Party A's confirmation.

Six, quality standards

1. Quality objective: the first pass rate reaches100%; Excellent quality; Projects without acceptance criteria must achieve satisfactory results for Party A and designers.

2. If the project quality fails to meet the above requirements, the contractor will directly deduct the performance bond from the project price settlement, and must unconditionally rework it until it is excellent and satisfactory to Party A and the designers. If it still does not meet the requirements after rework, it shall bear all the losses caused thereby.

3. Party B shall undertake the quality assurance of its construction project, and the quality assurance covers all the construction quality problems related to the decoration project.

4. The quality guarantee period is two years. During the warranty period, Party B shall send someone to repair it within 24 hours after receiving the warranty notice, otherwise Party A may entrust a third party to repair it, and the expenses incurred shall be borne by Party B. Party A shall deduct it from the warranty fund, and the insufficient part can be recovered from Party B as a debt. ..

5. The quality bond is the nature of the performance bond, and there is no interest.

Seven. Contract price

1. This contract adopts the lump sum contracting method, and the total contract price is _ _ _ _ _ _ _ _ _ (RMB _ _ _ _ _ _ _ _).

2. The business tax of the construction project shall be borne by Party A, who shall provide Party B with the tax exemption certificate and the official project invoice.

3. The above price has included labor costs (including overtime, catching up with work, etc.). ), material costs, machinery costs (including entrance and exit fees), vertical transportation costs, fees paid to government departments, loading and unloading fees, insurance premiums, work-related injury medical expenses, sewage charges, garbage disposal fees, cleaning fees inside and outside the site, safety and civilized construction measures, coordination fees for surrounding residents, on-site seedling protection fees, and protection fees for pipe networks and pipelines in the site and surrounding cities.

4. This contract includes all reconstruction projects in the drawings.

5. Quantity confirmation:

① In the total price, the increase of workload and materials of Party B caused by the deviation of construction quality of the main structure has been fully considered, and Party A will not handle any visa formalities and increase fees for this part.

(2) If there are any design changes, technical verification sheets, work contact sheets (to be confirmed by the design institute) and Party A's work instructions, Party B shall submit a partial budget for this month's changes to Party A before 25th of each month, and Party A shall complete the audit according to the contract within 5 days after receiving the budget, and notify Party B to confirm the engineering quantity within 24 hours after the audit. The quantities and budget confirmed by both parties will be added to the final settlement price, and it will not be accepted if it is not submitted to Party A within the time limit.

(3) If it is necessary to add the project site visa form (which must be signed and confirmed by the project manager), Party B shall send the visa form and budget report of this month to Party A before 25th of each month, and Party A shall complete the audit according to the contract within 30 days after receiving the budget report, and notify Party B to confirm the engineering quantity within 24 hours after verification. The quantities and budget reports confirmed by both parties will be added to the final settlement price. If they are not submitted to Party A within the time limit, Party A will not accept them.

(4) Party A does not recognize Party B's quantities beyond the scope of design drawings and rework caused by the contractor.

⑤ Party B will not participate in the verification of quantities and pricing within 5 days after receiving the notice, and the final result will be subject to the results of quantities and pricing verified by Party A.. ..

⑥ The verification of visa and engineering quantity change shall be subject to Party A's final approval, and Party B shall assist Party A in visa and change.

⑦ The Employer has the right to arrange the quantities of the winning bidder according to the engineering conditions and the capacity of the construction unit; After winning the bid, due to the reasons of the construction unit, the project cannot be started on time to ensure the construction period and meet the construction quality requirements. The Employer will adjust the engineering quantity of the construction unit or repel the construction unit at any time, and the losses caused thereby shall be borne by the construction unit.

4. The utilities required for the construction shall be paid in advance by Party A; Both parties negotiate to deduct at the time of settlement; However, waste of electricity should be punished on the spot. Party B is responsible for the water and electricity expenses required for accommodation and living; If provided by Party A, Party B shall pay relevant fees according to Party A's regulations.

5. In the total price, all possible impacts and workload increase caused by connection and cross-construction with other professional jobs and contractors should be fully considered.

6. Party B shall be responsible for repairing the wall slotting and opening caused by the electromechanical contractor in its construction area, and this cost has been included in the total price.

Eight. terms of payment

1. Party A will not pay any related advance payment, reserve fund, workers' living expenses and down payment for this project;

2. After the completion of this project is accepted by Party A, it will be paid to 85%; Party A shall pay 95% of the total price after review, and keep 5% of the quality deposit, which shall be paid within 1 month after the expiration of the warranty period.

3. Creditor's rights and debts arising from Party B's implementation of this project shall be paid off by Party B itself, and Party A shall not bear any responsibilities.

4. Any increase or decrease in the contract price caused by the change shall be borne by Party A; Unless there are major design changes (subject to the tenderer or engineer), the delayed construction period shall not be postponed.

Nine, construction safety

1. Party B shall abide by the regulations on safety production in engineering construction, organize the construction in strict accordance with local standards of standard chemical industry, accept the supervision and inspection carried out by industry safety inspectors and Party A according to law at any time, and take necessary safety measures to eliminate potential accidents. Party B shall bear the responsibility and expenses for accidents caused by Party B's failure to comply with safety rules and regulations or ineffective measures.

2. With the cooperation of Party B's on-site safety management personnel, Party B shall conduct safety education for all operators in its construction site and establish corresponding materials. Party B shall not allow persons without safety education to enter the site for construction, and Party A shall not require Party B to carry out construction in violation of safety management regulations. In case of safety accidents caused by Party A, Party A shall bear corresponding responsibilities and related expenses.

3. In case of major safety accidents and other safety accidents of Party B's personnel, both parties shall try their best to rescue and protect the site, and Party B shall conduct investigation and appraisal according to the opinions of relevant departments. If the casualty accident is determined to be the responsibility of Party B or the accident caused by Party B's illegal operation, Party B shall make economic compensation to the injured employees or their families according to national regulations, and Party A shall not bear any economic and administrative legal responsibilities, but Party A shall actively assist Party B in the aftermath; In case of casualty accidents caused by Party A's responsibility, in addition to handling the responsible person according to regulations, Party A shall make economic compensation to Party B's employees or their families according to relevant national regulations, but the specific aftermath shall be arranged and handled by Party B itself, and Party A shall not directly handle Party B's employees or their families.

4. Party B shall provide and maintain all lights, guards, fences, warning signals and on duty at its own expense at the necessary time and place, or according to the requirements or regulations of relevant authorities, to protect the project or provide safety and convenience for the public.

5. Party B shall be equipped with full-time safety production management personnel, and prepare a special safety construction plan for dangerous sub-projects.

6. During the execution of the contract, Party B shall take all reasonable measures to protect the environment near the site, so as to avoid the pollution, noise and other factors caused by its construction from causing damage or obstruction to the public or public property.

7. When the inevitable pollution and noise caused by Party B's responsibility need to be dealt with, Party B shall put forward a plan and report it to the engineer for approval before implementation, and the expenses incurred shall be borne by Party B..

8. According to Party A's on-site safety management regulations, Party B must pay a security management deposit of 20,000 yuan. If Party B's on-site management and operation personnel violate the safety management regulations, Party B must accept the management of Party A's on-site safety management personnel and deduct the fine and penalty from the safety management deposit. If the deposit is insufficient, the insurance shall be renewed separately.

9, put an end to casualties; No major mechanical equipment accidents and major fire accidents.

Ten, civilized construction

1. Party B shall organize the construction according to the standards of standard chemical sites and civilized construction sites, and ensure that municipal standard chemical sites and civilized construction sites are created on the construction site. If Party A, the supervisor and the relevant government departments fail to meet the standards in the civilized construction inspection, Party B shall bear the fines caused by its own reasons.

2. When Party A and Party B sign this project contract, Party B shall report and register with the Municipal Construction Management Office and go through relevant formalities.

3. Party B must provide the employee roster before entering the site, and attach a copy of its ID card, temporary residence permit (original), work unit filing certificate (original) and work permit for special operators (original), and pay the industry-related expenses on time (including the change of Party B's personnel, it must report to Party A in time, and Party B shall be responsible for the fines and other related expenses caused by irregular employment.

4. According to Party A's requirements, Party B must be equipped with full-time personnel in charge of the site, such as general manager, technician, quality engineer, material engineer, builder, logistics, electrician, etc. Independent management, the corresponding personnel should hold the corresponding documents. And the actual management conforms to the general contractor's standards to ensure the performance of this contract.

5. Party B shall strengthen the management of labor cost allocation to avoid labor disputes.

6. Party B shall abide by the rules and regulations of Party A's unit and shall not participate in gambling, fighting and other disciplinary acts. Party B shall use healthy male citizens over 18 and under 50 years old in this project, and shall not use foreign vagrants or employees of Party A's unit. If it happens, all consequences shall be borne by Party B..

7. The company provides housing and places for workers to eat, but the construction unit must obey the unified arrangement and management of the company. Party B's accommodation personnel must observe the hygiene of the dormitory and shall not damage the public goods in the dormitory. Party B shall arrange the sanitation and cleaning work in the accommodation area of Party B and the salary of personnel.

8. Party B shall not bring family members and children to the construction site for accommodation, and all employees shall have meals in the canteen, and shall not use electric stoves, electric cookers, electric woks, kerosene stoves and other cooking and cooking tools in the dormitory.

9, in the process of construction, each layer of support frame and template should be immediately arranged to clean up after dismantling, until Party A's acceptance.

10. The accommodation and office location of Party B's on-site personnel shall be provided by Party A. ..

XI。 Material and equipment management

1. Control of materials purchased by Party B:

A. Material brands are purchased according to the first-line brand standards.

B, in line with the types and standards stipulated in the contract documents.

C materials supplied by Party B must be approved by Party A before they can be used; Before ordering bulk materials, Party B shall provide samples for approval free of charge.

D party b shall keep the samples approved by the owner at the site as the acceptance standard of the project.

E party a's approval of any sample shall not relieve party b of its responsibilities under this contract.

F. If there is a better choice for the materials or technologies originally designated for use due to resource shortage or time limitation, Party B may put forward suggestions for alternative materials or technologies for the Employer's consideration, and the Employer has the absolute right to approve or disapprove. Before approval, the alternative scheme cannot be implemented, and the approved scheme cannot increase the cost unless it is accepted at the time of approval. Any approval or disapproval by the owner will not relieve the contractor of his responsibilities under the contract documents. The approval shall be issued in writing, otherwise it will be invalid.

G. The price of the original project or new project shall include any patent right, procedure or invention. If Party B infringes or is suspected of infringing the patent right of any article, program or invention, thus causing Party A to suffer claims, lawsuits, compensation fees and expenses, Party B shall compensate.

H. Party A does not consider the loss of materials supplied by Party B and the loss of labor and materials caused by subsection construction. Party B has considered and included in the unit price, and shall not use this as an excuse to ask for compensation or work by the hour.

2. Party B is responsible for site safety work.

3. The materials, machinery and equipment entering the site shall be managed by Party B..

4. Party B shall be equipped with certified electricians, who shall be responsible for on-site electrical work outside the secondary box (including on-site duty, lighting and switch circuit maintenance).

5. The inspection expenses of various materials shall be borne by Party B. ..

6. Party B is responsible for the transportation of various materials on the construction site (including horizontal transportation and vertical transportation) and stacking them according to the layout of the construction site, so as to keep the construction site clean and civilized, and the roads are smooth.

7. During the construction process, Party B shall be responsible for the material loss caused by rework due to Party B's reasons.

Twelve. Rights and obligations of both parties

(I) Rights and obligations of Party A

1. Party A entrusts Comrade _ _ _ _ _ to be responsible for comprehensively supervising the contents of this subcontract and providing Party B with all-round and whole-process support, service, supervision, management, coordination and control for the performance of this contract.

2. Party A is responsible for handling all kinds of approval documents and certificates for the construction in _ _ _ _ _ _ _, and the expenses shall be borne by Party B. ..

3. In accordance with the relevant provisions of the state and _ _ _ _ _ _, check and urge Party B to do a good job in the management of project quality, safe production, civilized construction, comprehensive management and standard implementation, so as to realize the enterprise brand goal.

4. Review the construction organization design prepared by Party B, and participate in the discussion and implementation of major technical issues in the construction process; Have the final authority to approve the construction scheme and construction sequence of this project.

5. Participate in the handling of safety and quality accidents, and the expenses incurred during the handling of accidents shall be borne by Party B; Grasp the construction progress, help Party B achieve the predetermined planned objectives, and collect the project progress payment from the owner on time. Control the rational use of funds to ensure the smooth progress of the project.

6. At the construction site, the water and electricity expenses consumed by Party B in the project shall be deducted according to the amount of the fixed content at the time of settlement.

7. Party A shall timely handle the project progress payment and project balance payment, and timely allocate the project funds.

8. Guide and supervise Party B's standard, badge, management system and image layout of safety helmet, and the expenses incurred shall be borne by Party B. ..

9. The materials provided by Party A shall be supplied according to the list of materials provided by Party A, and the project payment shall be deducted according to the facts.

10. Provide Party B with a set of construction drawings and timely provide drawings such as design modification.

1 1. If Party A thinks that Party B's construction progress can't meet the requirements of the construction period, Party A has the right to set aside part of the workload within the scope of Party B's contract to be completed by other contractors, and Party B shall make settlement according to the actual workload and bear all losses caused thereby. Party B shall not raise any objection.

12. Party A has the right to impose various penalties on the project constructed by Party B due to factors such as quality, safety and civilized construction. Such fines must be signed by the project manager, notified or delivered to Party B's representative, and Party A's fines will take effect soon, and the amount will be deducted directly from the cheque settlement.

(II) Rights and obligations of Party B

1. Party B entrusts Comrade _ _ _ _ to be fully responsible for the implementation of this contract, and set up a strong project management team according to the project scale and Party A's requirements.

2. Party B has the right to organize independent construction independently, but it must be carried out under the unified leadership of Party A. According to Party A's construction progress plan, Party B must organize enough labor and equip with enough machinery to ensure the project is completed on schedule, otherwise all the impacts and losses caused thereby shall be borne by Party B. ..

3. Party B shall, according to Party A's requirements and the actual situation of the construction site, formulate various construction plans in advance and report them to the Project Technology Department for approval, arrange the construction sequence and the cooperation of various types of work, fully understand the situation of the construction site, make reasonable arrangements and ensure work efficiency.

4. Party B shall provide a quality safety officer to Party A at the same time when the project starts, and ask for certificates, and Party A shall arrange the work in a unified way.

5. In the process of construction, if the construction sequence and the construction site are crossed or reversed due to the construction site conditions or other special requirements, Party B must be responsible for the construction as required, and its expenses will not be increased; After the construction of a large-scale project, if a small amount of sporadic parts are left to give up the construction, Party A will arrange other teams to carry out the construction, and deduct 3 times the amount payable by Party B..

6. Party B must ensure the construction according to the drawings.

7. Accept the instructions of Party A and the supervisor on safety production, quality and time limit for a project, and Party B shall take full responsibility for the economic and legal responsibilities arising therefrom.

8. Party B is responsible for the family planning management of its own team, and any penalties and fines imposed by either party shall be borne by Party B.. ..

9. Party B shall be responsible for the overall cleaning of the construction site and accommodation site according to the relevant requirements of Party A.. In order to make it conform to the relevant provisions of _ _ _ _ _ _ _ _

10. Party B is responsible for cooperating with various departments of the local government in various inspections of the labor force to ensure the legality of its employment and the completeness of procedures. If any party imposes any penalty or fine on Party B, Party B shall bear it by itself.

1 1. In the process of construction, if Party A and the supervisor temporarily increase the project, it needs to be confirmed on site, and Party B shall not stop the construction because Party A fails to sign the visa in time, otherwise it will be treated as breach of contract.

12. Party B must register all the workers entering the site according to Party A's requirements and report them to the project for the record, and at the same time do a good job in the three-level education of the workers entering the site.

13. Party B must insure the life and property of its personnel and construction machinery and equipment at the construction site and pay the insurance premium.

14. Party B promises to Party A to carry out the construction and completion in accordance with the contract, and undertake the responsibility of engineering quality warranty within the quality warranty period.

15, in the process of construction, all involved in material sample approval, price approval, material use, etc. Must be carried out in accordance with the requirements of the project department.

16, and bear all risks in the performance of corresponding construction projects.

17. Cooperate with Party A to guide the subcontractor's work, and bring it into the management scope of Party B, and all losses caused by the delay of construction period and unqualified quality shall be borne by Party B..

Thirteen. Other agreements

1. Party B shall set up a project management team of at least five people, including the project manager, to meet the needs of site construction. Within one week after the signing of this contract, the list of personnel to be appointed, resumes and copies of qualification certificates shall be submitted to Party A for confirmation, and the key management personnel confirmed by Party A shall not be replaced without Party A's consent. If Party B replaces the key management personnel confirmed by Party A or fails to replace the unqualified management personnel as required by Party A, Party A will impose a fine of 5,000 yuan per day on Party B. ..

2. Party B shall not subcontract this project to others in any form. If Party A regards this project as a subcontract project or Party B subcontracts a special professional construction project to others without the consent of the owner, Party A has the right to give Party B financial penalties.

3. If Party A is not satisfied with Party B's performance, Party A has the right to unilaterally terminate the subsequent project contract at any time, and all direct or indirect losses caused to Party A and Party B therefrom shall be borne by Party B. ..

4. Any change of this contract shall be indicated in written form and shall come into effect only after being signed by all parties.

Fourteen Project delivery and warranty

1. If the project meets the completion acceptance conditions, Party B shall submit complete completion data and completion report to Party A's representative according to the relevant national regulations on project completion, and provide Party A with three completion drawings.

2. The representative of Party A shall organize the acceptance within 10 days after receiving the completion acceptance report.

3. If the project fails to pass the acceptance, Party B shall be responsible for the repair and bear all expenses. If the project quality fails to meet the claim, all fines and penalties arising therefrom shall be borne by Party B. ..

4. After the completion acceptance, both parties shall complete the handover procedures within 2 days. Within 2 days after the handover procedure, Party B shall leave the site and hand over all relevant completion data to Party A according to the relevant national regulations on project completion.

5. When the project enters the warranty period after completion and acceptance, Party B shall guarantee the project according to the warranty scope specified in the project quality warranty, and all expenses and responsibilities incurred during the warranty period shall be borne by Party B. ..

XV. Archives Management

1. Party B shall provide a complete set of materials, including a copy of ID card and performance data, for Party A's file for future reference.

2. During the construction process, Party B must carry out the construction in strict accordance with the construction procedures and specifications, and make good information such as hidden acceptance, intermediate acceptance and construction log, and assist Party A in making good completion acceptance information when the project is completed and accepted.

3. Party B shall cooperate with the relevant materials of this project, which shall be uniformly arranged and managed by Party A.. If the information is incomplete due to Party B, it is necessary to contact the relevant departments, and the travel expenses and contact expenses shall be borne by Party B. ..

4. Party B's production statistics, financial final accounts, labor, equipment and other reports shall be submitted to the centralized department for filing.

5. Party B shall cooperate with Party A to prepare the construction management data, and the final completion data shall be uniformly prepared by Party A. ..

Sixteen. Default and dispute

1. In case of breach of contract during the performance of this contract, it shall be implemented in accordance with the relevant laws of People's Republic of China (PRC).

2. If Party B leaves midway without Party A's permission, all losses caused thereby shall be borne by Party B, and the settlement price of the completed project shall be reduced by 20%.

3. When one party breaches the contract and the other party requests the breaching party to continue to perform the contract, the breaching party shall continue to perform the contract after assuming the above liabilities for breach of contract.

4. If Party B fails to complete the project on time according to the time limit agreed in this contract, or the construction quality fails to meet the conditions agreed in this contract and fails to perform other obligations stipulated in this contract, Party A's representative may notify Party B to pay liquidated damages according to the terms of the agreement and compensate the losses caused to Party A due to overdue breach of contract.

5. Both parties agree that the penalty is 10% of the final settlement fee of the contract.

6. Disputes arising from the performance of this contract shall be settled by both parties through consultation based on the principle of seeking truth from facts. If negotiation fails, the case may be submitted to the Arbitration Commission where the construction project is located for arbitration, but:

(1) Projects not involving arbitration shall proceed as usual;

② Where Party B withdraws, it shall be withdrawn before arbitration;

(3) Arbitration shall be completed before completion or expiration of the contract;

(4) If Party B refuses to perform the provisions in Item (2) and Item (3) of Paragraph 2 of Article 11 of this Agreement by other means or reasons, Party A may apply to the Arbitration Commission (or the court) for execution first, and remove the obstruction, and all losses caused thereby shall be borne by Party B. ..

Seventeen. force majeure

1. Force majeure refers to the fact or reason that the project is affected by war, turmoil, falling objects in the air or other explosions and fires not attributable to Party A and the following natural disasters:

(1) an earthquake with a magnitude of 7 or above on the Richter scale;

(2) gale and rainstorm with magnitude 10 released by Hubei Meteorological Observatory for more than 48 hours;

(3) Rain, snow, flood, etc. Declared as a natural disaster by the municipal government;

(4) Other causes of force majeure.

2. After the force majeure event occurs, Party B shall immediately notify Party A and take measures to reduce losses as soon as possible. If Party A deems it necessary to temporarily stop the construction, Party B shall suspend the construction and notify Party A of the losses suffered within 48 hours after the end of the force majeure event; If the force majeure event continues to occur, Party B shall report the losses to Party A every 7 days; Within 14 days after the end of the force majeure event, Party B shall submit a formal report and information about cleaning and repair to Party A. ..

3. The expenses and delays caused by force majeure events shall be borne in the following ways respectively:

(1) The damage of the project itself shall be borne by Party A. ..

(2) The subordinate units of both parties shall be responsible for casualties and bear relevant expenses.

(3) The expenses for cleaning and repairing the project shall be borne by Party A. ..

(4) The delayed construction period shall be postponed accordingly.

Eighteen. Entry into force and termination of the agreement

1. This agreement is made in sextuplicate, with each party holding three copies, all of which are equally authentic.

2. This agreement shall come into effect as of the date when the representatives of both parties sign and affix their official seals. After the performance of the project contract agreement, the project warranty period expires and all kinds of funds are settled, this agreement will be automatically terminated. Matters not covered in this agreement shall be settled by both parties through consultation.

3. Other matters not covered shall be settled by both parties through consultation.

Owner: _ _ _ _ _ Real Estate Development Co., Ltd. Contractor: _ _ _ _ _ _ _

Representative: _ _ _ _ _ _ _ Representative: _ _ _ _ _ _ _ _

The above is the hardcover room renovation contract brought by Bian Xiao. The whole content of renovation contract model of hardcover room.