High voltage installation contract

Demonstration contract of high voltage equipment

In a progressive society, people use contracts more and more, so it is very necessary to sign contracts. So the question is, how should we draft the contract? The following is the template of high-voltage installation contract that I collected for reference only. Welcome to reading.

Employer of High-voltage Installation Contract 1 (Party A):

On behalf of:

Contractor (Party B):

Person in charge:

In order to clarify the rights and obligations of Party A and Party B in the installation project of high-pressure heat pipes, on the premise of equality and mutual benefit, both parties reached an agreement on matters related to this project in accordance with the provisions of the People's Republic of China (PRC) Construction Law and the Contract Law, and entered into this contract for both parties to abide by.

I. Overview of the Project

1, project content:

2. Project location:

3. Scope of contract:

4. Signing method:

Second, the construction period

Commencement date: subject to Party A's commencement notice. Tentatively: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Third, the engineering specification

Party B must carry out the construction according to the construction drawing and the relevant standards of the country and the project location.

Four. Responsibilities and obligations of both parties

Responsibilities and obligations of Party A

1. When the contract is signed, Party A shall provide Party B with engineering construction drawing materials and other basic materials, and complete technical disclosure. Party A shall be responsible for the authenticity, legality and completeness of the materials.

2. Party A has the right to inspect Party B's construction at any time and pay attention to quality and safety.

3. Pay the expenses to Party B in time according to the contract.

3. After receiving Party B's notice of completion acceptance, Party A shall organize personnel to conduct acceptance in time.

Responsibilities and obligations of Party B

1 Complete the project progress with good quality and quantity as stipulated in the contract, and be responsible for the project quality. Party B shall be responsible for any construction quality and safety accidents during the construction period.

2. After receiving Party A's entrustment, construction drawings and other documents, make a construction plan according to the scheduled project nodes, and complete the project according to the construction plan.

3. Party B shall ensure safe and civilized construction, and shall not work after drinking.

4. On the day of project completion, issue a notice of completion acceptance to Party A. ..

Five, engineering rework

1. If Party B has any questions about the design, drawings or construction scheme during the construction, and the project changes or affects the construction period, it shall submit them to Party A in writing, and Party A shall give a written reply or approve the corresponding technical measures or special protection measures within _ _ _ hours.

2. Before the project acceptance, Party A shall bear the cost of rework loss caused by Party A and Party B shall bear the cost of rework loss caused by Party B. ..

3. After Party A arranges for Party B to carry out the construction, if Party B stops working halfway, Party A shall make handling suggestions and notify Party B to resume work within _ _ _ hours. If Party B stops work halfway due to reasons not attributable to Party A, Party B shall put forward handling opinions within _ _ _ _ hours and resume work in time. No matter which party fails to resume work for more than 48 hours, the party that caused the resumption of work shall compensate the other party for its economic losses. The construction period is delayed again and again.

Confirmation of the number of intransitive verbs

1. If Party B proposes to change the design, it must obtain the consent of Party A, otherwise, Party B will bear the extra expenses.

2. The quantities of this project shall be settled according to the facts.

Seven. Settlement and payment of project funds

1. Party B shall submit the monthly project progress plan to Party A before 25th of each month, and pay 60% of the confirmed amount after confirmation by the owner.

2. When the monthly progress payment reaches 85% of the contract price, the payment shall be stopped.

3. After the project is delivered after passing the project audit, the remaining 5% of the project funds will be used as quality deposit, and the warranty period is _ _ _ _ _ _ _. If there is no quality problem, it shall be paid to Party B at one time without interest after the warranty period expires.

There is no advance payment for this project.

VIII. Supply of Materials and Equipment

All materials and equipment purchased by Party B must have the manufacturer's qualification certificate and meet the "qualified" standards required by the state. Before purchasing, samples of materials and equipment must be submitted to Party A for confirmation and signature, and the samples can be sealed before ordering. The materials can only be used after the acceptance of Party A and the supervision unit, otherwise Party A has the right to ask Party B to return them. Party B shall be fully responsible for the losses caused by the quality of materials and equipment.

Nine. responsibility for breach of contract

1. If Party B fails to complete the project as agreed in the contract, the quality is unqualified, and it is unable to resume work for 48 hours due to other reasons without justifiable reasons, it shall bear the liability for breach of contract and terminate the contract.

2. Party A shall timely perform relevant obligations including payment according to this contract.

3. After the breaching party assumes the liability for breach of contract, both parties can continue to perform the contract through consultation.

If either party proposes to terminate the contract in writing, the other party shall give a reply within seven days. Those who fail to reply are deemed to agree.

X. others

1. This contract shall come into effect after being signed by both parties, and shall become invalid after the obligations of both parties are fulfilled.

2. This contract is made in duplicate, one for each party, with the same legal effect.

3. Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, both parties may bring a lawsuit to the people's court where the project is located.

4. Matters not covered in this contract shall be settled by both parties through consultation.

Party A:

Address:

Contact person:

Contact information:

Signing time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B:

Address:

Contact person:

Contact information:

Signing time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

High voltage installation contract 2: ×××× Co., Ltd.

Contractor: ××× Co., Ltd.

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and the Electricity Law, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction of power supply and distribution project and signed this contract.

I. Overview of the Project

1. Project name: XXX power supply and distribution project.

2. Project location: ××××××.

3. Project content: Laying, installation, commissioning and acceptance of power supply and distribution project within the scope of construction drawing.

Second, the scope and content of the contract

1. Contract scope: See the construction drawing and bill of quantities quotation (project cost summary table and project budget table) confirmed by both parties for details.

2. Contract content: 4 box-type transformers, external high-voltage cables, internal low-voltage cables and corresponding trench excavation and backfilling; Cable passing through the hole in the basement and its repair: installation and debugging of high-voltage connection equipment; The path of the low-voltage cable changes from the inside of the box to the upper connection point of the starting box (including the cable head of the incoming terminal); High and low voltage system debugging; All technical data within the construction scope of this project; Handle all procedures, approval and acceptance, power sector inspection and related power transmission procedures in the process of power supply project construction.

Third, the construction cycle

1. Commencement date: The notice of commencement shall be signed by the employer and counted from the next day.

2. Completion date: 20xx65438+February 30th 1#, 3# buildings completed temporary power supply conditions, and 20xx065438+1October 25th 1#, 2#, 3#, 4#, 5# buildings and all shops were completed and officially completed.

Fourth, the quality requirements

Quality requirements meet the national standards "Code for Construction and Acceptance of Electrical Installation Engineering" (GBJ232-82) and "Unified Standard for Quality Inspection and Evaluation of Building Electrical Installation Engineering" (GBJ300-88) as qualified.

Verb (abbreviation of verb) contract price

1. The total contract price of this project is RMB three million nine hundred and ninety-two thousand six hundred Yuan only. After the signing of the total contract price, neither party may change it without authorization unless both parties reach an agreement through consultation.

The contract price is the price after the project construction and transmission acceptance. Including: procurement, transportation and storage of materials and equipment (all materials and equipment agreed in the contract), construction and installation, garbage removal, coordination expenses with other units, project acceptance and related procedures, construction utilities, social security fees and profits and taxes. The project price is fixed lump sum contract, and the total contract price is the total price.

2. The total project price agreed in this contract includes all quantities within the contractor's contracted scope. If there is any change in the visa project, only the change and visa part will be calculated when the project is completed and settled, and the original bill of quantities quotation will not be reviewed.

3. All-in contract is implemented for this project, that is, contracted projects, contracted materials, contracted quality, contracted safety, contracted civilized construction, contracted construction period, contracted materials price increase and government adjustment, contracted taxes and fees, contracted warranty, contracted construction acceptance, power supply, etc. In case of the following circumstances, the contract price can be adjusted accordingly:

(1) Technical verification, negotiation records and design changes within the scope of the contract;

(2) the project cost adjustment approved by the visa of the designated representatives of both parties;

The above fees shall be determined according to the owner's visa change procedure at the construction site. Failure to go through the visa change formalities on time shall be regarded as the contractor giving up the right to make additional changes to the visa fees, and the reduced part of the changes shall be adjusted only according to the information of the Employer during the final accounts.

Calculation method of change increase or decrease expenses: the change increase or decrease expenses shall be calculated according to the quotation approved in this contract, that is, a 7% discount shall be calculated after the quantities approved by both parties to the contract are priced, and the price of materials in the quotation approved in this contract shall not be adjusted due to market price factors.

(3) When adjusting the contract price, only the changed part will be considered, and the unchanged part will not be rechecked.

Payment and settlement of project price with intransitive verbs

1. The contractor shall pay 10% of the total contract price after the construction personnel officially enter the site.

2. 40% of the total contract price shall be paid after all the main materials such as high-voltage equipment and cables are accepted in the site.

3. After the trial operation, Party A passed the preliminary inspection and Xinzheng Power Supply Bureau passed the acceptance, and paid 45% of the total contract price.

4. Pay 5% of the total cost of outdoor high-voltage power supply system (internal and external pipe network system, box transformer) after all technical data are handed over.

5. The contractor shall fulfill the warranty obligations of special parts (shops, elevators, public lighting and pump room equipment). 54,500 yuan is reserved for this part of the warranty fund, which will be paid to Party B at one time without interest after the expiration of the warranty period (one year).

6. Before each payment, the contractor shall provide the employer with a written application for payment and issue an invoice of the same amount in the current period in line with the national tax regulations; Otherwise, the employer can refuse to pay.

Seven. Supply of materials and equipment

The contractor is responsible for purchasing and supplying all the equipment, main materials and auxiliary materials needed for the project, which should be qualified products, meet the requirements of design and national specifications, and be accompanied by factory certificate or material certificate, and meet the relevant requirements of xinzheng city Power Supply Bureau. All equipment, main materials and auxiliary materials required for the project shall be issued in writing in advance, and can only enter the site after being confirmed by the owner. Equipment and materials that have not been confirmed by the owner are regarded as unqualified materials. If the equipment and materials provided fail to pass the acceptance or fail to pass the acceptance of xinzheng city Power Supply Bureau, the contractor shall bear the losses.

Eight. Design change and project settlement

1. During the construction period, the Employer needs to change or supplement the original engineering design. The employer sends a change notice to the contractor in written form, communicates with the design institute and goes through the drawing formalities, and the contractor cooperates.

2. During the construction period, the contractor shall not change the original engineering design. The expenses incurred by the contractor in changing the design without authorization and the direct losses caused to the Employer shall be borne by the contractor, and the delayed construction period shall not be postponed.

3. The rationalization proposal put forward by the contractor in the construction involves the change of design drawings or construction organization design and the replacement of materials and equipment, which shall be subject to the written consent of the supervision engineer and the employer. If it is modified or replaced without authorization, the contractor shall bear the expenses arising therefrom and compensate the relevant losses of the Employer, and the delayed construction period will not be postponed.

4. If the contractor proposes to change the design, it must obtain the written consent of the employer, and the design unit shall issue a notice of design change.

5. The contractor shall, within 7 days after the confirmation of the engineering change, submit a report on the engineering price change, and adjust the contract price after the written confirmation by the supervision engineer and the employer. Change the contract price as follows:

(1), this contract is applicable to changing the price of the project, and changing the contract price according to the existing contract price;

(2) If there is only a change in the price of similar projects in the contract, the contract price can be changed with reference to similar prices;

(3), this contract is not applicable to or similar to change the price of the project, the contractor puts forward the appropriate change price, which will be implemented after written confirmation by the supervision engineer and the employer.

6. When an extra project happens, the employer needs to give a written notice. After the contractor's quotation is confirmed by the Employer, the contractor must truthfully and rigorously submit the project visa to the Employer within 7 days after the completion of the project, otherwise the Employer has the right to refuse, and it is deemed that the additional project does not involve increasing the contract price.

7. The Employer shall confirm the increased project change price as additional contract price and pay it at the time of completion settlement.

8. If the project changes due to the contractor's own reasons, the contractor has no right to request additional contract price.

9. If a visa is issued for this project, the following conditions must be met simultaneously:

(1), the contractor shall put forward in writing within 7 days;

2, signed and sealed by the contractor's project manager;

(3), signed and sealed by the chief supervision engineer;

(4), signed by the owner's on-site person in charge, the manager of the cost control department, the vice president of the project, the general manager and the assistant to the chairman, and sealed by the company for the record.

10. within 28 days after the project completion acceptance report is approved by the employer in writing, the contractor shall submit the completion settlement report and complete settlement data to the employer, and both parties shall adjust the project completion settlement according to the contract price agreed in the contract.

Nine, project acceptance

1. After the project installation is completed, it shall be responsible for all relevant procedures such as acceptance and formal power supply in time, and the resulting tests and related expenses shall be borne by the contractor. After the power supply is completed, the project shall be deemed to be completely completed.

2. After the acceptance of the project experience and the formal power transmission, the contractor fills in the project handover certificate in duplicate, and after both parties sign and seal it, each party holds one copy, which is the project handover.

3. Within/0/4 days after the project acceptance, the Contractor shall provide the Employer with three sets of binding complete project completion data (including project completion drawings and electronic documents).

X. Building safety

1. The contractor is responsible for fire prevention, theft prevention and finished product protection in the construction contract area. Observe the employer's safety system at the site.

2. In the process of construction, the contractor shall take full responsibility for accidents or losses caused by the contractor's illegal operation, and the employer shall not bear joint liability.

XI。 Responsibilities and obligations of both parties

1, responsibilities and obligations of the employer

(1), appoint XXX as the project leader of the employer, and be responsible for the performance of the contract.

(2) Before construction, the owner shall confirm the cable direction and outlet interface position of the low-voltage power supply system in writing.

(3), the employer is responsible for providing the site construction site and material storage location.

(4) The Employer shall be responsible for coordinating the construction of the temporary water and electricity access port, and the Contractor shall install the electric meter by himself, and notify the Employer of the number of bargainers after installing the electric meter, and the expenses incurred in the construction shall be borne by the Contractor.

5], provide three sets of construction drawings.

[6], responsible for organizing the owners, contractors, design, supervision and other units to organize the blue prints.the design.

A, the project implementation of engineering supervision system, the employer will notify the contractor in writing before the implementation of supervision unit name, content and authority, supervision will be carried out in strict accordance with the relevant national supervision standards.

(8) Supervise and inspect the project progress, project quality, concealed works and contract implementation, be responsible for design drawing processing and design change visa, and be responsible for intermediate acceptance of the project, project progress visa and other necessary visas.

Levies, assist the general contractor to coordinate the relationship with the general contractor of the project.

⑽. When the employer finds that the contractor purchases and uses materials and equipment that do not meet the design and standard requirements, he has the right to require the contractor to purchase again within a time limit, and the expenses arising therefrom shall be borne by the contractor, so that the delayed construction period will not be postponed, and he shall bear the corresponding liability for breach of contract.

⑾, the employer has the right to require the contractor to replace unqualified construction management personnel within a time limit, and the delayed construction period will not be postponed, and the contractor shall bear the corresponding liability for breach of contract.

⑿. After completing the work, the contractor shall handle and pass the special acceptance of the electric power department in time and electrify it, and pay the project payment on time.

2. Responsibilities and obligations of the Contractor

(1), responsible for applying to Xinzheng Power Supply Bureau for power agreement and all relevant procedures.

He was appointed as the on-site representative of the contractor, fully performing the contract on behalf of the contractor, being responsible for arranging all the construction work of this project, and handling all the docking, construction application, approval, test, acceptance, handover and training related to relevant government departments and design units in this project.

(2) After receiving the written confirmation notice from the Employer about the cable direction and outlet interface position of the low-voltage power supply system, the contractor shall measure the cable path according to the confirmation opinions and carry out procurement construction, and only adjust the cable quantity during settlement.

(3), according to the time agreed in the contract to complete the construction task, the construction quality must meet the requirements of the design and the current national power engineering specification.

(4) After receiving the owner's notice of commencement, organize the construction personnel, materials and mechanical equipment to enter the site the next day. Materials and equipment used in the construction must be accepted by the owner and supervision unit before they can be used.

5], the preparation of construction organization design or construction scheme, construction progress plan, equipment, materials, finished products, semi-finished products in the plan, submitted to the supervision engineer for examination and approval to the party awarding the contract.

[6], the contractor's personnel to enter the site, should carry out safety education and wear relevant safety protection articles, abide by the safety rules and regulations of the site, to achieve safe and civilized construction. All accidents, responsibilities and losses caused by the contractor shall be borne by the contractor.

A, the contractor is responsible for the storage of equipment, materials, construction tools during the construction period, and is responsible for the finished product protection of the completed project.

Being, the contractor in the construction process, take cover engineering covers three days before, should be written notice to the employer, supervision and relevant power acceptance functional departments for intermediate inspection. If there are any nonconformities, the contractor shall make rectification within a time limit according to the opinions put forward by the owner, supervision and power acceptance functional departments. Re-apply for re-inspection of concealed works after rectification, and cover the concealed works only after passing the inspection.

Levies, according to the drawings and construction instructions, design modification (change or notice), the current national construction and technical acceptance specifications, and according to the inspection and supervision of the employer or site supervision engineer, make construction records, inspection, concealed engineering records and construction technical data.

⑽. Safe and civilized construction should be carried out during the project construction, and the garbage should be removed in time. The contractor's construction personnel's office and materials should be stacked in the area approved by the Employer.

⑾. The contractor shall avoid potential accidents in the construction process. For any accident caused by the contractor, the contractor shall bear the relevant accident responsibility and loss expenses.

⑿. The materials, finished products and semi-finished products purchased by the contractor shall have the factory certificate and quality guarantee, which shall be inspected by the supervision engineer and the site engineer of the employer when they enter the site.

[13], the contractor is responsible for providing detailed equipment list and operating instructions to the employer, supervision and relevant functional departments.

[14]. The contractor shall carry out the construction according to the construction plan. After the completion of all engineering construction and test, submit the acceptance application and completion report to the owner, supervisor and relevant power acceptance functional departments in written form, and handle the completion acceptance and power-on procedures.

⒂ After the project is completed and accepted, the contractor is responsible for the daily equipment maintenance, operation training and handover of relevant personnel in the residential property department.

[14]. The contractor must appoint a project manager, a professional engineer and a technician at the construction site (must have a valid license), and provide the supervision engineer and the construction unit with the work list, qualification certificate, copy of license and contact telephone number of on-site construction personnel.

⒄. After the completion acceptance 14 days, deliver three complete sets of completion data to the owner, and be responsible for training the employer's personnel.

⒅. The contractor shall timely and fully pay the wages of personnel engaged in engineering, construction and management, and purchase effective work-related injury insurance during the project to ensure that the project construction is not affected by the above reasons, otherwise all losses caused thereby shall be borne by the contractor; If the contractor fails to pay the wages in full and on time, resulting in shutdown or partial shutdown, the employer may deduct the wages payable from the project funds payable to the contractor and pay them to the construction and management personnel; At the same time, the employer may require the contractor to bear the liability for breach of contract and compensate for the losses.

Pet-name ruby the contractor shall go through the formalities of approval and construction application according to this contract, or unconditionally cooperate with the employer to go through the formalities of construction application, acceptance and filing. If the contractor violates the provisions of this article, it shall bear the direct and indirect economic losses caused by the employer, and the employer has the right to terminate this contract.

⒇ During the construction period, it shall be subject to the management of the general contractor and the party awarding the contract.

Twelve. Project warranty

During the quality warranty period, the contractor shall undertake the quality warranty responsibility of this project in accordance with the management provisions of relevant laws, regulations and rules and the agreement of both parties.

1. Scope and content of project quality warranty: The scope of quality warranty includes the damage of all lines and equipment and the maintenance of use functions of the power supply and distribution project of Huafu Oasis Project in Huafu International Eco-city.

2, the project quality warranty period

According to the Regulations on Quality Management of Construction Projects and related regulations, both parties agree that the quality warranty period of this project is as follows:

(1) The warranty period of the power supply and distribution project is one year, during which the contractor provides technical support and maintenance services free of charge.

(2) After the expiration of the free warranty period 15 days, both parties shall pay the project quality warranty money in one lump sum (interest-free) after completing the settlement procedures for later warranty acceptance.

(3) The quality warranty period shall be calculated from the date when the project is officially electrified after the completion acceptance.

3, quality warranty responsibility

(1), which belongs to the warranty scope and content of the project, the contractor puts forward opinions on the quality problems of the employer during the warranty period, and requires the contractor to arrive at the site for maintenance treatment within 24 hours after receiving the notice from the employer, and bear the maintenance responsibility. If the contractor fails to send someone for warranty within the agreed time limit, the employer may entrust others to repair it. The resulting responsibilities and all losses shall be borne by the contractor.

(2) In case of emergency repair accident, the contractor shall arrive at the scene of the accident immediately after receiving the accident notice for emergency repair.

(3) Establish project user files, and the contractor will pay a regular return visit to listen to opinions and give timely feedback.

(4) After the quality warranty is completed, the employer shall organize the acceptance.

4. Warranty fee

(1) During the free warranty period, if the late maintenance is caused by the contractor's construction quality or the contractor fails to carry out the warranty within the agreed time limit, the maintenance expenses entrusted by the employer shall be borne by the contractor.

(2) If the contractor violates the warranty commitment or has quality problems, causing losses to the employer, the employer shall have the right to compensate the employer for the losses in part or in whole with the final payment of the contractor's project. If the final payment is not enough to compensate the losses of the Employer, the Employer has the right to recover from the Contractor.

Thirteen. responsibility for breach of contract

1. If the contractor cancels the contract without the consent of the Employer, it shall return the money paid by the Employer and pay 20% of the total project price as compensation.

2. Any shutdown, rework and loss of materials and equipment caused by the contractor shall be borne by the contractor. If the completion of the project is delayed due to the contractor's responsibility, a penalty of 3% of the total project cost shall be paid to the employer for each day overdue from the next day; If the delay exceeds 30 days, the Employer has the right to terminate the contract, and the Contractor shall pay liquidated damages to the Employer at 20% of the total contract price.

3. After the completion of the project, if the acceptance of xinzheng city Power Supply Bureau is unqualified, the contractor shall be responsible for rework at his own expense and bear the liability for breach of contract such as overdue construction period to the employer. If the project fails to supply power normally on time due to the contractor's reasons, the contractor shall bear all the liabilities for breach of contract and compensate the Employer for 30% of the total contract price.

4. The contractor shall carry out the construction in strict accordance with the materials specified in the drawings and list quotation. If the materials are changed without the consent of the employer, the contractor shall unconditionally replace the materials that meet the requirements of the contract, and the employer may also impose a penalty of 5% of the total contract price.

5. Without the consent of the Employer, the project shall not be subcontracted or subcontracted to other construction units or individuals, otherwise the Employer shall have the right to unilaterally terminate this contract and refuse to pay the project payment, and the Contractor shall pay liquidated damages to the Employer at 20% of the contract price.

Fourteen Conditions for modification or termination of the contract

1. Both parties agree through voluntary negotiation that the public interests of the state and society will not be harmed.

2. Due to force majeure, all obligations under this contract cannot be fulfilled.

3. On the other hand, the contract was not performed within the time limit agreed in the contract, and it was not performed within a reasonable time limit for delayed performance.

4. Due to one party's breach of contract, the expected purpose of the project contract is seriously affected or the performance of the contract is unnecessary.

Fifteen. Dispute handling method

During the performance of this contract, if there is any dispute between the two parties, both parties can settle it through consultation without affecting the progress of the project. If negotiation fails, both parties may bring a lawsuit to the people's court of XX City.

Sixteen. supplementary terms

1. Within 7 days after the project completion acceptance, the contractor shall submit the project warranty to the Employer as the warranty certificate. Overdue, the employer has the right to postpone the settlement period.

2. The original of this contract is in duplicate, with each party holding one copy; Four copies, two for each party. All of them have the same legal effect, and shall come into effect from the date when the representatives of both parties sign and affix their official seals, and shall become invalid after both parties have fulfilled their rights and obligations stipulated in the contract.

3. If both parties terminate the contract through consultation, the contract terms related to liquidation, compensation and settlement shall remain valid until the corresponding liquidation, compensation and settlement are completed.

As a mature construction contractor, the contractor has given full and comprehensive consideration to this contract and any risks it covers, and will perform the contract and its contents according to the requirements of professionalism.

5. In case of any dispute between the two parties over the quality of the project, the technical unit designated by the local government of XXX shall conduct quality appraisal.

6. During the execution of this contract, if there are matters not covered, both parties shall sign a supplementary agreement on the basis of friendly negotiation, so as to facilitate the smooth performance of this contract.

7. The annexes to this contract are an integral part of this contract and have the same legal effect as this contract. However, if there is any conflict between the annex and this contract, the terms of this contract shall prevail.

8. Party A and Party B agree to send various notification letters and documents to each other by express mail according to the address specified in this contract. If any party's address changes, it shall notify the other party in writing within 7 days after the change.

Seventeen. Annex to the contract

1, construction drawings

2. The bill of quantities quotation approved by both parties to the contract (project cost summary table and project budget table)

Employer (seal): Contractor (seal):

Legal representative (signature): Legal representative (signature):

Or entrusted agent (signature): or entrusted agent (signature):

Bank of deposit: Bank of deposit:

Account number: Account number:

Xx year x month xx day xx year x month xx day

;