How to write the indoor renovation contract model in the formal contract of the decoration company?

At present, when we decorate our home, we often look for a decoration company, but when we determine the decoration company, we need to sign a formal contract with the decoration company. What are the formal contracts of decoration companies? Today, let's take a look at the details of the formal contract signed between the decoration company and Bian Xiao for your reference.

Formal contract of decoration company

Employer (hereinafter referred to as Party A): _ _ _ _ _ _

Authorized Agent: _ _ Company: _ _ Address: _ _ Tel: _ _ Tel

Contractor (hereinafter referred to as Party B): _ _ _ _ _ _

Legal Representative: _ _ Registered Address: _ _ Tel: _ _ _ _

According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, on the basis of equality, voluntariness and consensus, Party A and Party B hereby sign this contract (including its annexes and all supplementary contracts) in order to ensure the smooth progress of the project, so that * * * can abide by it together.

Article 1 General situation of the project

1. 1 project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

1.2 building structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

1.3 project contracting mode, both parties agree to adopt the following _ _ _ _ _ _ _ contracting mode:

(1) Party B contracts all materials.

(2) Party B contracts some materials and Party A provides some materials.

(3) Party B contracts the work and Party A contracts all the materials.

1.4 total price: _ _ yuan, in words (RMB): _ _ _. In which: material cost: _ _ _ _ _ _ _ _, labor cost: _ _ _ _, management fee: _ _ _ _ _, design fee: _ _ _ _ _, garbage removal fee: _ _ _ _ _, taxes and fees: _ _ _ _ _. (For details, please refer to the attached table: Quotation for Family Room Decoration Project). With the consent of both parties, the construction content is changed, and the project payment for the changed part shall be calculated separately according to the actual situation.

1.5 project duration _ _ _ _ days; Commencement date _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _; Completion date _ _ _ _ _ _ _ _ _ _;

1.6 project contents and practices (see Annex I: Confirmation Form of Decoration Project Construction Project and Annex II: List of Decoration Project Contents and Practices).

Article 2 Qualification of the construction unit

Party B is an enterprise legal person approved and registered by the administrative department for industry and commerce. Through the latest annual inspection of the enterprise, Party B has the qualification approved by the construction administrative department to engage in civil building decoration engineering, and the qualification grade meets the requirements of this construction. If Party B does not have the business qualification or corresponding qualification, Party A has the right to terminate this contract, and Party B shall immediately return the fees paid by Party A and compensate Party B for its losses.

Article 3 Material supply

3. 1 For the materials and equipment provided by Party A according to the contract (see Annex 4: List of Decoration Materials Provided by Party A), Party A shall notify Party B before the materials arrive at the construction site, and both parties shall accept and handle the handover procedures;

3.2 According to the materials and equipment provided by Party B under this contract (see Annex 5: List of Decoration Materials Provided by Party B), Party B shall notify Party A before the materials arrive at the construction site, and both parties shall jointly accept them.

Article 4 Project Quality

4. 1 This project shall implement local standards and quality evaluation acceptance standards such as _ _ _ (technical specification for building decoration engineering) and _ _ _ _ (acceptance standard for decoration) formulated by the municipal construction administrative department.

4.2 The construction scheme of this project is designed by Party A..

4.3 The unqualified materials and equipment provided by Party A will affect the project quality, and the cost of rework shall be borne by Party A, and the construction period shall be postponed. 4.4 In case of any quality accident due to Party B, the cost of rework shall be borne by Party B, and the construction period shall remain unchanged.

4.5 During the construction, Party A shall contact Party B in advance when proposing design modification opinions and adding or subtracting engineering projects. The construction of this project can only be carried out after signing the project change order (see annex for details). If this affects the completion date, it should be agreed by both parties. Party A agrees with the workers to change the construction content privately, and all the consequences arising therefrom shall be borne by Party A, and Party B shall be compensated for the losses caused. ..

4.6 In the process of construction, both parties disputed the project quality, and applied for the project quality certification to the _ _ _ department. If the quality of the certified project fails to meet the standards agreed in the contract, Party B shall be responsible for the relevant expenses incurred in the certification process, and Party A shall be responsible for the relevant expenses incurred in the certification process.

Article 5 Project acceptance

5. 1 Both parties agree to check and accept the project quality in the following stages during the construction process: _ _ _ _. Party B shall notify Party A to participate in the acceptance _ _ days in advance, and fill in the project acceptance form after passing the stage acceptance (see Schedule 8: Project Acceptance Form);

5.2 After the completion of the project, Party B shall notify Party A for acceptance, and Party A shall organize acceptance within two days after receiving the acceptance notice and fill in the project acceptance form (see Annex 8: Project Acceptance Form). After the project payment is settled, handle the handover procedures (see Schedule 9: Project Settlement Sheet);

5.3 The warranty period of this project is _ _ _ _ years from the date of acceptance and signature by both parties. After acceptance and signature, fill in the project warranty form (see attachment 10: project warranty form).

Article 6 Method of payment for project funds

6. 1 Both parties agree to pay the project payment according to the following _ _ _ method: (1) After the signing of this contract, Party A shall pay the project payment equivalent to _ _ _% of the total price _ _ days before the commencement of construction; (2) Party A shall pay _ _ _% of the total project price within _ _ days after completing _ _% of the project amount; (3) Within _ _ _ days after the completion acceptance, Party A shall pay the project payment equivalent to _ _ of the total price. (4) Party A shall pay the project payment equivalent to the total price _ _ _ years after the completion acceptance or the warranty period agreed by both parties expires. If Party A pays the project payment and Party B's sales staff or construction personnel collect it, it shall be regarded as Party B's collection.

6.2 If the total price increases or decreases due to the change of construction contents, Party A shall pay or collect the increased or decreased amount on the day when the completion acceptance is qualified.

6.3 Receipts shall be issued for capital transactions between both parties. After the completion of the project, Party B shall issue a legal invoice after Party A has paid off the payable amount.

6.4 After the completion acceptance, Party A has the right to keep the warranty money equivalent to _ _% of the total project price. If there is no engineering quality problem within _ _ years after the completion acceptance, Party A shall return the warranty money to Party B in full.

Article 7 Agreement on Safety in Production and Fire Prevention

The construction drawings and practices provided by Party A and the construction site shall meet the requirements of fire prevention and accident prevention, mainly including the smoothness and qualification of electrical lines, gas pipelines, tap water and other pipelines. During the construction period, Party B shall take necessary safety protection and fire control measures to ensure the safety of operators and nearby residents, and prevent accidents such as pipeline blockage, water leakage, power failure and damage to houses and articles of nearby residents. In case of the above situation, Party A shall be responsible for compensation; Where Party B is responsible, Party B shall be responsible for repair and compensation.

Article 8 Project supervision

8. 1 If Party A entrusts the project supervision, it shall sign a supervision contract with the supervision unit. And in the terms of this contract agreement, the supervision unit, chief supervision engineer and their responsibilities are clearly defined.

8.2 The responsibilities of the Chief Supervision Engineer and Party A's representative in this contract cannot cross each other. Without the consent of Party A, the chief supervision engineer and his representative have no right to relieve Party B of any obligations under this contract. During the performance of the contract, the chief supervision engineer shall make a fair treatment when an event occurs that affects the rights and obligations of both parties.

8.3 In order to ensure the normal construction, Party A and Party B shall respect the decision of the chief supervision engineer. If there is any objection to the decision of the chief supervision engineer, it shall be handled according to the terms of the agreement. If the chief supervision engineer is replaced, Party A shall notify Party B at the same time after receiving the notice from the supervision unit, and the successor shall continue to perform the rights and obligations entrusted to the predecessor.

Article 9 Construction drawings

Both parties agree to provide the construction drawings in the following way:

9. 1 Party A shall provide Party B with complete construction drawings on the date and number of copies agreed in the terms of this agreement _ _ days before the commencement date. If Party B needs to exceed the number of drawings agreed by both parties in the terms of the agreement, Party A shall make copies on his behalf, and the copying expenses shall be borne by Party B. ..

9.2 Party A entrusts Party B to design the construction drawing in _ _ _ copies, with Party A, Party B and the construction team holding one copy respectively (see Appendix 6: Design Drawings of Family Room Decoration Project), and the design fee is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

9.3 If the use of foreign drawings can't meet the construction needs, both parties shall stipulate the copying, redrawing, translation and procurement of standard drawings in the terms of the agreement.

Article 10 On-site Representative of Party B

Party B appoints the person in charge of the site to exercise the rights and perform the obligations stipulated in the contract according to the following requirements:

10. 1 Party B's request, requirement and notice shall be signed by Party B's representative in writing and sent to Party A's representative, and shall take effect after Party A's representative signs his name and the time of receipt.

10.2 The representative of Party B shall organize the construction according to the construction organization design (or construction plan) approved by the representative of Party A and the instructions and requirements issued according to the contract. In case of emergency, if Party A's representative cannot be contacted, emergency measures can be taken to protect personnel's life, engineering and property safety, and report to Party A's representative within 24 hours after taking measures. The responsibility lies with Party A, and the resulting additional contract price shall be borne by Party A, and the construction period shall be postponed accordingly; The responsibility lies with Party B, and the expenses shall be borne by Party B. ..

10.3 if the ownership of Party B's agency changes, Party B shall notify Party A _ _ days before the ownership changes, and then continue to perform the rights and obligations of its predecessor as stipulated in the contract documents.

Article 11 Work of Party A

1 1. 1 Party A shall provide Party B with _ _ _ copies of construction drawings or practice instructions approved by the property management department, and make on-site disclosure to Party B .. Empty all or part of the house and remove obstacles that affect the construction. Protective measures should be taken for furniture and furnishings stranded in houses that can only be partially vacated. Provide Party B with necessary conditions such as construction water and electricity, and explain matters needing attention.

1 1.2 coordinate the temporary use of public parts during construction and the impact on neighborhood relations.

1 1.3 If it is really necessary to dismantle or change the original building structure or design pipeline, it shall be responsible for going through the corresponding examination and approval procedures at the local housing management department or property management department, and bear the relevant expenses.

1 1.4 Do not dismantle the indoor load-bearing structure. If it is really necessary to dismantle the non-load-bearing structure or equipment pipeline of the original building, go through the corresponding examination and approval procedures with the relevant departments;

1 1.5 If Party A still needs to use part of the living room during the construction period, it will be responsible for public security and fire control at the construction site;

1 1.6 Participate in the supervision of project quality and construction progress, and be responsible for material mobilization and project completion acceptance.

Article 12 Work of Party B

12. 1 During the construction process, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project with good quality on schedule;

12.2 strictly implement the regulations on the management of the construction site in this municipality, so as not to disturb the people or pollute the environment;

12.3 protect the furniture and furnishings of the original living room and ensure the smooth flow of water pipes in the living room;

12.4 Ensure the cleanliness of the construction site and be responsible for the cleaning of the construction site after the project is completed.

12.5 Participate in the on-site disclosure of construction drawings or instructions organized by Party A. ..

12.6 Appoint _ _ _ as the representative of Party B at the construction site to be responsible for the performance of the contract. Organize the construction as required, complete the construction task on time with good quality and quantity, and solve all matters that Party B is responsible for, and Party B shall recognize its behavior. If there is any personnel change, Party B shall promptly notify Party A in writing.

12.7 party b shall submit the manual, warranty, environmental protection manual and copies of purchase invoices. If Party A requests to check the original, Party B shall agree. The invoice shall indicate the product name, brand, model, specification, grade, price and quantity.

Article 13 Engineering change

If it is necessary to change the project or construction method, both parties shall reach a consensus through consultation, sign a written change agreement, and adjust the related project cost and construction period (see Schedule 7: Decoration Project Change Order).

Article 14 Time limit for a project is delayed

14. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly upon confirmation by Party A: (1) engineering quantity change or design change; (2) Force majeure; (3) Other circumstances in which Party A agrees to postpone the construction period.

14.2 If the construction period is affected by Party A's failure to complete its responsible work as agreed in the contract, the construction period will be postponed; If the unqualified materials and equipment provided by Party A affect the project quality, the cost of rework shall be borne by Party A, and the construction period shall be postponed.

14.3 If Party A fails to pay the project payment on time, the contract period will be postponed accordingly.

14.4 If the project cannot be completed on schedule due to Party B's responsibility, the construction period will not be postponed; If there is any problem in the quality of the project due to Party B, the cost of rework shall be borne by Party B, and the construction period shall not be postponed.

Article 15 Liability for breach of contract

15. 1 If either party fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall bear the responsibilities and compensate the other party for its economic losses;

15.2 if party a uses the finished project in advance or uses it without going through the acceptance formalities, party a shall be responsible for the losses;

15.3 if the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and handle the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses;

15.4 If the project is delayed or stopped halfway due to Party A's reasons, Party A shall compensate Party B for the losses caused by the stoppage or slowdown, and Party A shall pay Party B RMB for each day of stoppage or slowdown; If Party A fails to make payment as agreed in the contract, Party A shall pay _ _ _% of the overdue payment as liquidated damages for each day overdue.

15.5 If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for the repair, and the construction period will not be postponed;

15.6 If the project is completed late due to Party B's reasons, Party B shall pay _ _ _% of the payment made by Party A as liquidated damages for each overdue day.

15.7 Without going through the relevant formalities, Party A forcibly requires Party B to dismantle and rebuild the original building load-bearing structure, equipment and pipelines, and Party A shall be responsible for the losses or accidents (including fines) caused thereby.

15.8 if party b dismantles or changes the original building load-bearing structure or equipment pipeline, the losses or accidents (including fines) caused thereby shall be borne by party b.

Article 16 Modification and rescission of a contract

16. 1 After both parties sign the contract (the contract signed in the tangible market must be witnessed by the seal of the market management department), both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.

16.2 in the course of construction, if either party proposes to terminate the contract, it shall submit it to the other party in writing. After both parties agree to go through liquidation procedures and conclude a termination agreement, the contract shall be deemed to be terminated.

Seventeenth garbage removal

Party B is responsible for transporting the garbage generated by the project construction out of the construction site and to the designated place, and Party A is responsible for paying the garbage removal fee (RMB) _ _ _ _ _ (this fee is not included in the project price).

Article 18 representations and warranties

Party A:

18. 1 Party A is an enterprise established and existing according to law, and has the right to sign and have the ability to perform this contract.

18.2 All procedures required for Party A to sign and perform this contract have been completed and are legal and effective.

18.3 at the time of signing this contract, no court, arbitration institution, administrative organ or regulatory body has made any judgment, ruling, ruling or specific administrative act that may have a significant adverse impact on Party A's performance of this contract.

18.4 All internal authorization procedures required for Party A to sign this contract have been completed, and the signatory of this contract is the legal representative or authorized representative of Party A. After this contract comes into effect, it is legally binding on both parties.

Party B:

18. 1 Party B is an enterprise established and existing according to law, and has the right to sign and have the ability to perform this contract.

18.2 All procedures required for Party B to sign and perform this contract have been completed and are legal and effective.

18.3 at the time of signing this contract, no court, arbitration institution, administrative organ or regulatory body has made any judgment, ruling, ruling or specific administrative act that may have a significant adverse impact on Party B's performance of this contract.

18.4 The internal authorization procedures required for Party B to sign this contract have been completed, and the signatory of this contract is the legal representative or authorized representative of Party B. After this contract comes into effect, it is legally binding on both parties.

Article 19 confidentiality

Both parties promise to keep confidential the business secrets (technical information, business information and other business secrets) obtained from the other party that cannot be obtained through public channels. Without the consent of the original provider of the trade secret, one party shall not disclose all or part of the trade secret to any third party. Unless otherwise stipulated by laws and regulations or otherwise agreed by both parties. The confidentiality period is _ _ _ _ years. If one party violates the above confidentiality obligations, it shall bear the corresponding liabilities for breach of contract and compensate the losses caused thereby.

Article 20 Force Majeure

Force majeure as mentioned in this contract refers to unforeseeable, insurmountable and unavoidable objective events that have a significant impact on one party, including but not limited to natural disasters such as floods, earthquakes, fires and storms, and social events such as wars, turmoil and government actions. If the contract cannot be performed due to the occurrence of force majeure, the force majeure party shall immediately notify the other party in writing, and shall provide the details of the accident and the written information that the contract cannot be performed or needs to be postponed within _ _ _ _ days, and terminate the contract or temporarily postpone the performance of the contract after mutual agreement.

Article 21 Notice

2 1. 1 All notices issued according to the requirements of this contract, documents exchanged between both parties and notices and requirements related to this contract must be in written form and can be delivered by _ _ _ _ _ (letter, fax, telegram, face-to-face delivery, etc.). ). If the above methods cannot be delivered, you can take the form of announcement.

2 1.2 The mailing addresses of all parties are as follows: _ _ _ _ _ _.

2 1.3 if one party changes its notice or mailing address, it shall notify the other party in writing within _ _ _ days from the date of change; Otherwise, the uninformed party shall bear the corresponding responsibilities arising therefrom.

Article 22 Handling of disputes

22. 1 This contract shall be governed by and interpreted in accordance with the law.

22.2 Any dispute arising from the performance of this contract shall be settled by both parties through consultation, or mediated by relevant departments; If negotiation or mediation fails, it shall be settled in the following _ _ _ way: (1) Submit it to the _ _ _ Arbitration Commission for arbitration; (2) bring a lawsuit to the people's court according to law.

Article 23 Interpretation

The understanding and interpretation of this contract should be based on the purpose of the contract and the original intention of the text. The title of this contract is only for the convenience of reading and shall not affect the interpretation of this contract.

Article 24 Supplements and Annexes

Matters not covered in this contract shall be implemented in accordance with relevant laws and regulations. Where there are no provisions in laws and regulations, both parties may reach a written supplementary agreement. The annexes and supplementary contracts of this contract are an integral part of this contract and have the same legal effect as this contract.

Article 25 the validity of a contract

This contract shall come into effect as of the date when both parties or their legal representatives or authorized representatives sign and affix their official seals. The period of validity is _ _ _ years, from _ _ years to _ _ _ years. The original of this contract is in duplicate, each party holds one copy, which has the same legal effect; The contract is made in _ _ copies, with _ _ copies sent and one copy kept.

Party A (seal): _ _ _ _ Party B (seal): _ _ _ _ _ _

Authorized Agent (signature): _ _ Legal Representative (signature): _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Signing place: _ _ _ _ _ Signing place: _ _ _ _ _ _