How to write the exhibition hall renovation contract?

Before the renovation of the exhibition hall, the organizer and the decoration company negotiated and signed this contract on the basis of equality, voluntariness and consensus in accordance with the provisions of relevant laws and regulations. Then how to write the exhibition hall renovation contract? Next, I would like to share with you the model of renovation contract in Hall 20 18, hoping to help you.

Contract mode of exhibition hall renovation

Employer (hereinafter referred to as Party A):

Contractor (hereinafter referred to as Party B):

In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, combined with the characteristics of this project, Party A and Party B have reached the following agreement on matters related to Party B's contracting of Party A's decoration project (hereinafter referred to as the project) on the basis of equality, voluntariness and consensus:

I. Overview of the Project

1. Project Location _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Contents of project construction (see attached table: project budget table)

3. Project contracting mode. Both parties agree to adopt the contracting mode of Party B for all materials in the budget construction project.

4. The duration of the project is _ _ _ days, and the commencement date is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Second, the contract price

The contract project cost is (RMB) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. The above funds do not include procurement and uncertainty, and the final settlement of procurement and uncertainty shall be subject to the specified standard and actual amount. The above amounts are all pre-tax quotations. (See attached table: project budget table for details. )

Third, the construction drawings

Construction drawings Party A designs construction drawings and renderings.

Four. Party A's work

1. Create conditions for Party B to enter the site for construction two days before commencement, including: demolishing indoor furnishings or stacking and covering indoor furniture and furnishings that are difficult to move without affecting the construction;

2. Provide and ensure water and electricity consumption during the construction period;

3 responsible for coordinating the relationship between the construction project and the urban management, fire protection and property where the project is located, and handling the corresponding procedures;

4. If it is necessary to dismantle and change the structure or equipment pipeline of the original building, it is responsible for handling the corresponding examination and approval procedures with the relevant departments;

5. If Party A still needs to use some areas during the construction period, it shall be responsible for the safety and fire control of the site.

6. Participate in the supervision of project quality and construction progress, and be responsible for the acceptance of materials entering the site, the acceptance of project stage and the acceptance of project completion.

Verb (abbreviation of verb) Party B's work

1. During the construction, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards, and complete the project with good quality on schedule;

2. Strictly implement the regulations on the management of construction sites in this Municipality, so as not to disturb the people and pollute the environment;

3. Ensure the cleanliness of the construction site, and be responsible for cleaning the construction site before the project acceptance;

4. Strictly guarantee the construction quality and ensure the quality and quantity of materials used.

Six, engineering change

If it is necessary to change the project or construction method, both parties shall reach an agreement through consultation, sign a written change agreement, and adjust the related project cost and construction period.

Seven, material supply

The materials and equipment provided by Party B as agreed in this contract shall be notified to Party A before the materials arrive at the construction site and accepted by both parties.

8 time limit for a project delay

1. If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party A; (1) engineering quantity change or design change; (2) Force majeure; (3) Other circumstances in which Party A agrees to postpone the construction period.

2. If the time limit for a project is affected by Party A's failure to complete the work that should be responsible under the contract, the time limit for a project will be postponed.

3. If Party A fails to pay the project payment on schedule, the contract period will be postponed accordingly.

4. If the project cannot be completed on schedule due to Party B's responsibility, the construction period will not be postponed; If there is any problem in the quality of the project due to Party B, Party B shall bear the cost of rework.

Nine, quality standards

Both parties agree that the construction quality of this project shall be implemented in accordance with the Standard of Quality Specification for Decoration Engineering (QBP60 16—97-97). Party B shall not be responsible for any engineering quality problems caused by unqualified materials and equipment provided by Party A. ..

X. Project acceptance and warranty

1. Both parties agree to inspect the materials used in the project during the construction process, and conduct single acceptance after the single project is completed.

2. After the completion of the project, Party B shall notify Party A for acceptance, and Party A shall provide a written project acceptance form within two days after receiving the acceptance notice. After the project acceptance certificate is issued, the balance of the project shall be settled within three days. After the project payment is settled, handle the handover procedures (see attached table: project settlement table);

3. The warranty period of this project is one year from the date of acceptance and signature by both parties. If Party A fails to settle the final payment according to the regulations, it will be deemed as an automatic waiver of the warranty.

XI。 Payment method of project funds

1. After the contract comes into effect as agreed by both parties, Party A shall pay the project funds directly to Party B as agreed in the following table: 30% three days before the first commencement; 40% for the second project; Balance after the third acceptance by both parties.

2. Half of the project means that the frame project is completed, except the customized project.

Twelve. responsibility for breach of contract

1. If either party fails to perform the contract or violates national laws, regulations and relevant policies, causing economic losses to the other party, the responsible party shall bear the responsibilities and compensate the other party for the economic losses;

2. Party A shall be responsible for the losses caused by Party A's early use or unauthorized use of the completed project without going through the acceptance formalities;

3. If the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and handle the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses;

4. If Party A fails to pay the second (third) project payment on schedule, it shall pay the other party RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. If Party A delays for more than 5 days, Party B has the right to leave the construction site, and Party A shall be responsible for the project delay.

5. If the project is delayed due to Party B's reasons, one thousandth of the total project amount shall be paid to the other party as liquidated damages for each day of delay.

Thirteen. Ways to solve contract disputes

If the dispute between the two parties cannot be settled through consultation, it shall be settled in the following way: 1

1. Apply to the Contract Arbitration Commission of Baoding Administration for Industry and Commerce for arbitration;

2. Bring a lawsuit to Baoding People's Court.

Fourteen Matters needing attention

During the construction period, Party A shall hand over the site keys to _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Fifteen. supplementary terms

1. This contract shall come into effect after being signed by both parties.

2. This contract is made in duplicate, with each party holding one copy.

3. The contract will be automatically terminated after the completion of performance.

4. The engineering change agreement has the same effect as this contract.

5. The amount incurred in this project shall be subject to the attached project budget table, and the final settlement shall be subject to the actual engineering quantity.

Remarks: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

_______________________________________________________________________________

Representative of Party A (signature) _ _ _ _ _ _ _ Representative of Party B (signature) _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Bian Xiao brought it to you. How to write the exhibition hall renovation contract? 20 18 Exhibition Hall renovation contract model.