Construction contract for external wall insulation of houses

Thermal shrinkage formwork for building external wall thermal insulation construction

With the establishment of people's legal awareness, there are more and more occasions where contracts can be used, and the signing of contracts is the best norm for the rights and obligations of both parties. So what are the common contracts? The following is a popular contract template for building external wall insulation construction, which I compiled for you. I hope it will help you.

Party A:

Party B:

In accordance with the relevant provisions of the Civil Code of People's Republic of China (PRC), this contract is signed by both parties through full consultation. It is hoped that * * * will keep its promise, strictly perform it, and accept the supervision and inspection of the contract management authority.

1. Party A contracts out the thermal insulation and exterior wall coating works of the comprehensive building project of Yin Hui Farmers' Market to Party B for construction, and guarantees the materials, safety and quality.

1. engineering material: the external thermal insulation of the external wall is made of inorganic glass beads, and the thickness of the residential building is 3.

5, non-residential for 4

5. The roof thickness is 50, and the exterior wall is waterproof.

2. Comprehensive unit price: the comprehensive price of external wall insulation is 54.00 yuan ㎡, indoor insulation is 55.00 yuan ㎡, and external wall waterproof coating is 20 .00 yuan ㎡ (including tax and supporting fees).

3. Building area: The external wall area is tentatively set at 5000.

2. The roof area is tentatively set as 16002, and the external wall coating is 50002.

4. The project cost is tentatively set at 458,000.00 yuan.

Two. Duration: The commencement date is the second day after Party A notifies Party B to enter the site, and the total duration is 60 days.

Third, the engineering quality requirements

1, the quality of this project must meet the national standards, and it has passed the acceptance of quality supervision, design and supervision units.

2. Vitrified beads and accessories used for external wall insulation materials shall provide the manufacturer's test report, corresponding product certificate and use certificate, and can only be used after being accepted by Party A and the supervisor.

3. The paint, putty, primer and auxiliary materials used for external wall construction shall provide the manufacturer's test report and corresponding product certificate, and can only be used after being accepted by Party A and the supervisor. At the same time, the construction times of putty, primer and topcoat shall be specified according to the requirements of design and operation procedures.

4. Party B voluntarily accepts the technical supervision and spot check by Party A and the supervisor during the construction.

4. Settlement of engineering quantity: according to the actual construction completion area.

5. Payment method: 25% after the completion of external wall insulation construction, 65,438+00% after the completion of external wall primer construction, 65,438+00% after the completion of topcoat construction, and 20% after the completion of the project. The balance will be settled to 95% at one time within 30 days after the acceptance of the project, leaving 5% as the project quality warranty fund, totaling _ _ _ _.

Scope and content of intransitive verb contract: supply, transportation and construction of external wall insulation, and external wall coating includes putty, primer and topcoat construction. Party A is responsible for cleaning the wall foundation, and the deviation of verticality and flatness meets the requirements of national standards.

Seven. Responsibilities of both parties:

Party A:

1. Party A is responsible for the coordination and cooperation between Party B and the general contractor.

2. Party A shall supervise the quality, progress, safety and civilized construction of Party B, and control the quality of materials for Party B's construction.

3. Party A has the responsibility to supervise Party B to carry out the construction in strict accordance with the technical standards for thermal insulation construction, and has the right to require Party B to unconditionally rework those that do not meet the requirements of the specification until they are qualified.

Party B:

1. Party B shall carry out the construction in strict accordance with the safety construction standards;

2. Party B shall be responsible for all its safety responsibilities in the operation area;

3. Party B shall be responsible for the internal and external safety of all its workers, and Party A shall not be responsible for any safety;

4. Party B shall conduct safety education for workers, and Party B shall be responsible for any safety problems caused by Party B's workers;

5. Before construction, Party B shall provide Party A with the business license of the construction enterprise, the enterprise qualification registration certificate and the project contracting situation in recent years;

6. Party B shall provide quality certificates, test reports, hidden materials of engineering construction and other materials related to construction and acceptance. At the same time, Party B shall comply with the provisions of _ _ _ _ _ _ _ _.

7. Party B shall pay% of the total contract service fee to the general contractor.

8. Party B must be responsible for the protection of other finished products in the operation area. If there is any damage, Party B shall compensate at the original price.

9. Party B must strictly abide by the safety and civilized construction, environmental sanitation, environmental protection, fire protection and other management regulations, and all responsibilities and losses caused by violation of the regulations shall be borne by Party B. ..

10. Party B is responsible for putting the garbage dump generated during the construction to the designated place.

Party B shall prepare the construction plan and general construction schedule plan according to the characteristics of this project, and submit them to Party A and the supervision unit for examination and approval. After approval, it shall be implemented in strict accordance with the requirements of this plan.

Eight, engineering warranty:

This project warranty shall be implemented according to the current national project quality warranty regulations. During the warranty period, Party B will unconditionally repair the water seepage, shedding and cracking caused by construction.

Nine. Liability for breach of contract:

1. Party B's unqualified construction quality requires rework, which exceeds the original contract period. Party B shall bear all losses caused by Party A's delay in acceptance.

2. If one party fails to perform the contract and the contract is terminated, the breaching party shall bear 5% of the total contract amount as liquidated damages.

X. Disputes and dispute resolution:

Disputes should be settled through friendly negotiation. If no settlement can be reached, they can apply to the court for a judgment.

XI。 This contract is made in quadruplicate, one for each party, one for the supervisor and one for the general contractor. This contract shall come into effect immediately after being signed and sealed by both parties.

Party A: Representative Year _ _ _ _ _ _ _ _

Party B: on behalf of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

;