Engineering construction contract template (electronic version) 2022

Construction contracts are also called "engineering contracts" or "contracting contracts". Refers to the contract awarding party (construction unit) and the contractor (construction unit) to complete the agreed construction and installation tasks. The following is the template of the project construction contract I compiled, welcome to read! Click "Contract Template" to get more construction templates.

Engineering construction contract template 1

Employer: _ _ _ _ _ _ (hereinafter referred to as Party A)

Contractor: _ _ _ _ _ _ (hereinafter referred to as Party B)

In order to clarify the scope of responsibility and economic relations, coordinate and restrict each other, better complete the project tasks and ensure the project quality, Party A and Party B sign this contract through consultation and abide by it jointly.

I. Project Name and Project

Road maintenance works.

Two. Responsibilities undertaken by Party A

1. Party A shall provide Party B with construction drawings and technical specifications.

2, send engineering and technical personnel to be responsible for the supervision and inspection of engineering quality and construction technology recognition, and put forward the notice of changing the construction plan of drawings.

3. Carry out project acceptance according to the construction procedure flow, and carry out project settlement according to the contract quota and actual engineering quantity.

Three. Responsibilities undertaken by Party B

1. Party B must carry out the construction in strict accordance with the construction drawings and technical specifications.

2, all the construction equipment needed in the construction to solve.

3. If the project is reworked due to construction mistakes and engineering quality problems, it shall bear all economic losses.

4. All construction procedures and processes must be reported to Party A in advance, and the construction can only be started after being approved and signed by Party A's engineers and technicians, otherwise all consequences will be borne by themselves.

5. Party B shall bear the casualties of all vehicles and personnel during the construction period.

6. All the materials needed for the project must be purchased in strict accordance with the specifications and quality required by the specifications, and the expenses shall be paid by Party B, and shall be settled uniformly after the project is completed.

Fourth, the construction time

This project starts from _ _ _ _ _ _ _ _

Verb (abbreviation of verb) completion acceptance and settlement

After the completion of the project, Party A shall organize an acceptance team to conduct preliminary inspection, and if problems are found, punish them or make them rework as appropriate. Settlement shall be made according to the provisions of the contract after it is qualified.

VI. Contract Cost and Fixed Cost

Total project cost: RMB only.

This contract is made in triplicate, one for each party and one for the project record.

Party A (official seal): _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Engineering construction contract template 2

Demander (Party A):

Supplier (Party B):

In accordance with the Contract Law of People's Republic of China (PRC) and relevant national regulations, and in combination with the specific conditions of this project, the Contract is signed by both parties through full consultation.

I. Projects

1, project name:

2. Delivery and installation location:

Second, the total project cost

1. The total cost including tax of this street lamp project is RMB:

2. The whole street lamp project must meet the functional requirements of the design scheme approved by Party A, and the design and construction scheme approved by Party A shall prevail. On this basis, the price will not be adjusted (except for the items required by Party A).

Third, payment

1. Within _3_ days from the date of signing the contract, Party A will arrange 30% of the total project cost as the production advance payment.

2. Party A shall pay 85% of the total project payment within _3_ days after the goods arrive at the construction site;

3. After all the projects are completed and accepted by Party A and relevant departments, 95% of the total project cost shall be paid.

4. Set aside 5% quality deposit, and pay the project quality deposit within 5 days after the expiration of one year.

Four. Supply and installation:

1. The installation and construction date of this street lamp project will be completed within working days in total.

2. This street lamp project must be constructed in strict accordance with the relevant national building installation specifications.

3. During the installation process, if the installation mode is changed or the construction period is delayed due to force majeure, Party A's responsibility, design change or other reasons, Party A and Party B can solve it through negotiation.

Verb (abbreviation for verb) safety responsibility

Party B must manage the construction quality and safety in strict accordance with the construction safety standards. All construction quality and safety accidents during the construction period shall be borne by Party B, and Party A shall not bear any legal responsibilities.

VI. Maintenance

The warranty period of this street lamp project is one year, counting from the date when the project is completed and accepted by Party A and relevant departments. During the warranty period, if the street lamp is found to be faulty, Party B must send someone to repair it within _24_ hours from the date of receiving Party A's notice. If the damage is not caused by Party A, Party B shall be exempted from all expenses;

Seven. responsibility for breach of contract

Party A and Party B should solve the problem through consultation.

Eight. This contract is made in duplicate, one for each party. This contract shall come into effect as of the date of signature by both parties.

Employer (official seal): Contractor (official seal):

Domicile: domicile:

Legal representative:

Authorized legal representative: authorized legal representative:

Tel: Tel:

Fax: Fax:

Date: Date:

Engineering construction contract template 3

Any unit: _ _ _ _ _ _ _ _ _

Construction unit: _ _ _ _ _ _ _ _ _ _ _

For the decoration project of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

I. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Two. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Three. Project content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Fourth, the project cycle

This project is completed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Verb (abbreviation of verb) The project cost is RMB _ _ _ _ _ _ _ _

Terms of payment for intransitive verbs

1. After the contract is signed, Party A's materials arrive at the site, and two days after the construction starts, Party A pays Party B the advance payment for the project.

2. After construction, Party A shall pay Party B the advance payment of the total project price by stages according to the project progress until the project is completed, and the balance shall be paid in one lump sum after the project is accepted. (Based on the unit price of the budget, it shall be settled according to the actual quantities)

Seven. Materials and equipment: Party B is responsible for purchasing the engineering materials needed for this project and organizing the mobilization in time. The storage site of materials and equipment is provided by Party A, which meets the needs of the project and has a good storage site. The contractor is responsible for cleaning up the garbage and wastes generated during the construction.

Eight, engineering construction

1。 Party B must carry out the construction in strict accordance with the design drawings. In case of violation, Party A has the right to propose to stop work or rework, and the losses caused thereby shall be borne by Party B..

2。 Party B is responsible for decoration design, construction drawings and material details. With the consent of both parties, this material will become an integral part of this contract, and Party B shall be responsible for the additional investment caused by design defects and insufficient material planning during scheme design.

3. If Party A adds or modifies projects in advance during the construction, it must notify Party B in advance, and both parties shall sign a supplementary agreement. Party A shall be responsible for the losses and lost time caused by the project to be added or modified, and the construction period shall be postponed accordingly.

4. Party B shall understand that it shall abide by the relevant regulations of the Property Management Office and the construction technical specifications. Personal injury or facility damage caused by Party B during construction shall be borne by the constructor.

5. If Party B fails to comply with the relevant regulations of the Property Management Office, Party B shall bear the fine.

Nine, the project quality

1. The quality evaluation and acceptance criteria of this project are construction drawings, work instructions and design changes.

2. If the quality of the materials provided by Party B is not up to standard, which will affect the quality of the project, Party B shall bear the cost of rework.

3. If any quality accident that cannot be reworked is caused by Party B, all consequences shall be borne by Party B..

4, decoration engineering quality warranty for one year.

Ten, project acceptance

Party B shall issue a notice of project acceptance, and the personnel of both parties shall go to the construction site to accept the project according to the requirements of design drawings and relevant standards. After acceptance, the responsible persons of both parties shall sign the acceptance sheet for approval. If the project has not been accepted, Party A uses it in advance or without authorization, and the quality and safety problems arising therefrom shall be borne by Party A, and the date when Party A begins to use it shall be the date of completion acceptance.

XI。 responsibility for breach of contract

Any loss caused by any party's violation of the terms of this contract shall be compensated by the breaching party.

Twelve. comment

For matters not covered in this contract, Party A and Party B shall negotiate supplementary agreements or terms, such as this contract. In case of any dispute between Party B, both parties have the right to bring an arbitration or lawsuit to the Economic Contract Arbitration Commission or the People's Court of the Administration for Industry and Commerce in the place where this contract is signed, which shall be subject to the arbitration of the Arbitration Commission or the judgment of the court.

13. The quotation sheet of this contract is made in quadruplicate, with Party A and Party B holding two copies respectively, which shall come into effect after being signed and sealed by the representatives of both parties and have legal effect.

Party A's unit (seal): _ _ _ _ _ _

Representative: _ _ _ _ _ _ _ _ _ _ _ _

Party B's unit (seal): _ _ _ _ _ _

Representative: _ _ _ _ _ _ _ _ _ _ _ _

Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Signing place of the contract: _ _ _ _ _ _ _ _ _ _ _ _ _

Engineering construction contract template 4

Party A:

Party B:

Party B hereby undertakes the "installation and construction" of Party A's street lamp installation project of Tongxin Road and Hexie Road in Huishui County, Guizhou Province, and * * * agrees as follows:

1, construction content

The construction length is about 3.2KM, and Party B undertakes excavation, foundation cage supply, foundation pouring, trenching, pipeline laying, cable supply, cable laying, protection, installation, debugging and correction of light poles, lamps and light sources.

2. Installation instructions

The length of Tongxin Road is about 1.47km, and the distance between street lamps is 30m. Install HXZX023 high school language lamp, numbered 5 1 on one side and 52/on the other. The two lamps are connected by cables, which are laid through pipes. The length of Harmony Road is about 1.78km, and the distance between street lamps is 30m. HXZX0 13 is equipped with 60 Chinese lamps on one side, namely 120 lamps on both sides. The two lamps are connected by cables, which are laid through pipes.

3. See the price list for related quantities and expenses:

4, the installation period

Under the condition that Party A's infrastructure and transformer are provided in time, at least 30 street lamps shall be installed and lit within 0/2 days of Tongxin Road/KLOC-; Before June 8, at least 30 street lamps on Harmony Road have been installed and turned on. However, during the installation period, if the construction period is delayed due to irresistible factors such as typhoon, flood, earthquake and other natural reasons, both parties shall negotiate to solve it.

5, quality standards and acceptance criteria

All engineering quality standards must be excellent (if the engineering quality does not meet the standards, Party B shall be responsible for rework losses).

The acceptance shall be conducted in accordance with the relevant national regulations, the quality requirements and technical indicators of Party A's design documents and the standards agreed in this contract.

6. Terms of payment

After the signing of the agreement, Party A shall pay the contract money in advance to Party B; When more than 50% street lamps are installed and lit, 45% of the contract price shall be paid; When more than 75% of the street lamps are installed and turned on, 70% of the contract price shall be paid; Pay 97% of the final settlement of Party B after the installation and debugging of street lamps are qualified, and the remaining 3% will be used as quality deposit. The warranty period is one year. If there is no quality problem in the project within one year, Party A will return it to Party B without interest. Party A shall provide the corresponding receipt after receiving the payment every time.

7. Others

Before the street lamps are delivered to Party A for use, Party B shall be responsible for the storage of important materials such as street lamps and cables. Construction personnel are composed of factory technicians and migrant workers.

8. This Agreement is made in triplicate, with Party A holding two copies and Party B holding one copy. It will take effect after both parties sign and pay the advance payment.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Engineering construction contract template 5

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law and the current relevant regulations, Party A and Party B, on the premise of equality, mutual benefit and voluntary cooperation, have agreed to contract out the road project of Wangjiawan residential area to Party B in the form of a single package. In order to ensure the interests of both parties, both parties have reached the following agreement:

I. Project management

Party B is a professional worker to which Party A belongs, and the daily work of all workers is carried out under the unified management of the company. In order to speed up the progress of the project, ensure the quality of the project, and give full play to the management role of professional types of work, Party B accepts the inspection and supervision of Party A within the scope stipulated in the contract and agreement, and everything must be subject to the unified management of Party A (the project management system is attached).

Second, the basic situation of the project

Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Third, the form of contracting.

In order to ensure the common interests of both parties, Party B contracts all the contents of this contract, and Party B shall meet the requirements of quality and progress as required by Party A..

Four, the specific content of project contracting

1, road engineering leveling and rolling;

2. According to the design width of road engineering, the macadam base is 10㎝, and C30 is 20㎝ thick.

3. Earthwork excavation of roadside rainwater pipes, sewage pipes and inspection wells;

4, manhole every 12 meters masonry a rainwater manhole and a sewage manhole;

5. Install roadside rainwater pipes DN300, sewage pipes DN400 and precast reinforced concrete pipes;

6. Party B is responsible for the post-construction maintenance of the road, and Party A is responsible for the expansion and excavation of the road;

7. The sidewalk is flat (excluding cushion and brick);

8. If other matters not covered actually occur, Party A and Party B shall settle them through negotiation.

5. Project price: _ _ _ _ _ _ _ _ _ _ _ _ _ _ (_ _ _ _ _ _).

Sixth, the construction period

After signing the construction agreement with Party A, Party B shall organize the construction in strict accordance with the construction period of Party A, and organize capable construction personnel and management personnel to ensure that the project is completed on time. If Party B fails to complete the project as required by Party A, all economic losses and consequences caused thereby shall be borne by Party B. ..

The proposed commencement time is: according to the requirements of the project department.

The planned completion time is: stipulated by the project department.

Seven. Project quality

1, the quality grade of this project is qualified.

2. Party B shall carefully organize the construction, carefully manage and take strict quality control measures to ensure the engineering quality level stipulated in the contract. Party A has the right to check the quality of the project at any time and put forward rectification opinions on the parts that do not meet the quality standards, which is necessary.

Party B may be subject to financial penalties, and Party B shall actively cooperate. If the quality of the project continues to be unqualified and reaches the quality level after rectification, Party A has the right to take back the contracting right, and all economic losses and consequences caused thereby shall be borne by Party B. ..

Eight, construction safety

Party B shall carry out the construction in strict accordance with the safety operation regulations, and sign a special safety contract with Party A for implementation. Party B must carry out safety education and construction safety disclosure for all workers on duty to prevent all safety accidents. If Party B neglects safety management and does not listen to Party A's safety management, resulting in safety accidents, all economic and legal responsibilities shall be borne by Party B, and Party A shall not be held responsible. Party A is responsible for providing safety supplies for Party B's construction personnel (the safety contract is attached). Including safety helmet (expenses shall be borne by Party B)

Nine, civilized construction management

Civilized construction management is a symbol of a company's comprehensive management ability. The quality of civilized construction management directly affects the company's image. Party B shall conduct management in accordance with the relevant regulations on civilized construction, ensure that the construction site is clean and tidy, and ensure that the civilized model site is reached.

X. Family planning management

Party B must carry out family planning management for the construction personnel in accordance with the relevant regulations of the State on family planning management. All construction personnel must hold the family planning certificate of floating population from the local family planning department, and those who do not meet the family planning regulations shall not use it, and shall be inspected by the relevant departments. If Party B fails to use the personnel without family planning certificate as required, all economic losses caused thereby shall be borne by Party B. ..

XI。 Public safety management

Party B must educate the constructors about public security, check their ID cards and submit copies to Party A for future reference. Those suspected of crimes of unknown origin shall not be used, and shall be inspected by the local public security department. If Party B's personnel are not managed as required, or if there is a fight in the construction process, Party B shall bear all economic and legal responsibilities.

Twelve, the project payment settlement method

1, sign the contract lump sum table according to the budgeted cost.

2. If the total budget price is not priced, it will be adjusted according to the on-site visa and included in the total settlement price.

XIII. Payment Method of the Project

After Party B's project is completed and accepted, it will be settled in one lump sum without paying any fees.

Fourteen Rights and obligations of Party A

1. Party A shall make technical disclosure and management disclosure to Party B. ..

2. Party A shall perform the terms of the contract.

3. Party A has the right to supervise and inspect Party B at any time according to the contract.

Fifteen. Rights and obligations of Party B

1. Party B shall abide by the terms of the contract.

2. Party B shall manage according to the contract.

3. Party B has the right to make suggestions to Party A. ..

4. If Party A fails to abide by the contract, Party B has the right to appeal.

Sixteen. other terms

If Party B leaves his post or fails to perform the contract, Party A will not settle the project payment for Party B, and all expenses will be borne by Party B.. In the process of construction, in order to realize convenient, timely and effective management, the first responsible person of Party B must live in the construction site.

17. This agreement is made in duplicate, with each party holding one copy. It will take effect after signing, and will automatically become invalid after the project is completed and the final payment is paid.

18. Other matters not covered shall be settled by both parties through negotiation and a supplementary agreement shall be signed.

Nineteen. Contents of the annex

1, safety contract;

2. Commitment letter

20. Any dispute arising from the performance of this contract shall be submitted to Lichuan Arbitration Commission for arbitration.

Party A's representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ Party B's representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Engineering construction contract template (electronic version) 2022 related articles:

★ Five common templates for 2022 construction contracts

★ Electronic contract template for engineering construction 2022

★ Five complete versions of the 2022 project construction contract

★ Construction Contract 2022 Format Template

★ Five templates of 2022 project construction contract

★ Electronic contract text of engineering construction 2022

★ Form 5 of formal construction contract in 2022

★ Electronic version of engineering contract 2022

★ Formal 2022 New Construction Contract Format Template

★2022 construction contract template 5.