Job Recruitment Website - Property management - Contract agreements selected in 2023

Contract agreements selected in 2023

In a progressive society, the frequency of using contracts is on the rise. What contracts have you seen? The following is a selection of contract agreements in 2023 compiled by me for your reference only. I hope I can help you.

Selected clauses of contract agreement in 2023 1

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

Party A and Party B have reached the following terms through consultation for both parties to abide by and implement.

1. Scope of contract: Party A is willing to contract the first floor facade located at No.8 Zaomaoliang Section of Xinjian Road in Weifen Town to Party B.

2. The term of the contract is two years, from _ _ _ to _ _ _.

Three, the contract fee of _ _ _ yuan per year, when signing the contract, paid in full.

4. Party B shall not change the main structure and facilities of the house without authorization during the contract period, and shall not dismantle the original decoration materials without authorization at the expiration of the contract period. Damaged equipment, such as glass, electric meters, wires, floor tiles, walls, doors and windows, shutters, etc. Party B shall repair it in time.

5. During the contract period, all expenses such as industry and commerce, tax, land, water, heating, electricity, house rental tax, epidemic prevention and health expenses shall be borne by Party B. ..

6. During the contract period, Party B shall be responsible for the losses caused by force majeure, and Party A shall not be liable.

7. Party B can only be a legitimate businessman, and can't do anything that violates the law and discipline. If you want to steal it privately, you will bear all the consequences.

Eight. Party A shall not interfere with all normal business activities of Party B at will, but has the right to raise questions or stop illegal events.

9. During the contract period, Party B shall not sublet the house to others without authorization. After the expiration of the contract, Party A has the right to recover or change the house price, and give priority to Party B to continue to perform the contract at the same rental price. At that time, Party A and Party B will negotiate separately.

10. If Party A requests to take back the house upon the expiration of the contract, Party B shall not postpone the time for any reason, but shall clean up the articles and return the house in time, and clear the words posted on the doors and windows when Party B leaves.

XI。 This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature and seal by both parties.

Party A (official seal): _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Selected Articles of Contract Agreement in 2023 II

Employer: Party A.

Contractor: Party B.

In order to standardize residential property, make residents enjoy perfect property services and improve the living environment. The following contents of this contract agreement are reached by the developer's community owner * * and the contractor after repeated consultations in the principle of good faith and consensus, and both parties shall abide by them:

Section 1 Basic situation of residential property

Location:No. _ _ _ _ _ _ _. Floor space: _ _ _ _ _ _ _ _ square meters; Building area: _ _ _ _ _ _ _ square meters; Residential _ _ _ _ _ _ _ square meters; Property type: _ _ _ _ _ _ (residential area or group, office building, commercial and residential building, industrial area, other/low-rise, high-rise, super-high-rise or mixed).

Article 2 Contract management matters

1, public * * * environment (internal and external walls and foundation, external walls, stairs, corridors, halls and other load-bearing structural parts) is clean and sanitary.

2. Maintenance and management of facilities and equipment (sewer pipes, downpipes, garbage tunnels, lighting, power distribution systems, water supply systems, heating systems, etc.). ) used for fitness.

3. Transportation, vehicle driving and parking.

4. Ask about the safety of people entering and leaving the community (including at night). If non-community personnel are found, they should be properly registered, and those who may cause losses in the community should be denied entry.

Article 3 Term of Contract

The term of this contract is _ _ _ _ _ _ _ _. From _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 4 Contract Fees and Payment Time

During the contract period, the Employer shall pay the contractor the contract fee of RMB/month; Time and method of payment:.

Article 5 Liability for breach of contract

1. If Party B fails to get the contract fee on time due to Party A's reasons, Party A shall compensate Party B accordingly; Party B has the right to request Party A to pay within a time limit and terminate the contract.

2. If Party B causes or directly causes economic losses to Party A, Party B shall compensate Party A for the corresponding losses. Party A has the right to request Party B to correct and terminate the contract within a time limit.

Article 6 Other agreements

1. During the contract period, Party B shall not charge any fees from Party A according to the facts of this contract except paying the agreed contract fees to Party A. ..

2. As Party B's contracting content includes 24-hour management of residential areas, Party B may entrust a trusted third party to carry out necessary contracting affairs, but the expenses incurred by entrusting a third party shall be paid by the contractor.

3. The contractor entrusts a third party not to establish any relationship with the employer, and the third party may not claim any rights from the employer according to its work content.

Article 7 Any dispute arising from this contract shall be settled by both parties through consultation. If negotiation fails, either party may bring a lawsuit to the people's court.

Article 8 This contract is made in duplicate, with each party holding one copy. This contract shall come into effect after being signed by Party A's representative and Party B. ..

Party A:

On behalf of:

Party B:

date month year

Selected Articles of Contract Agreement in 2023 3

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

Party A voluntarily contracts the pomegranate garden where the household is located to Party B to manage the income. With the consent of Party A's family, this contract is signed with Party B on the basis of equality and voluntariness.

First, the scope of the orchard is on the four boundaries of a piece of land:

Second, the term of the contract is years, from year to year.

3. Annual contract amount: RMB (yuan) per year.

Four. Payment method:

Party A issues a receipt for Party B to sign for.

Verb (abbreviation for verb) agreed terms:

1. During the contract period, the fees collected collectively by Party A according to the land area of the orchard shall be paid by Party B for business needs.

2. During the contract period, in case of any dispute arising from contracting, Party A shall assume the responsibility of eliminating the dispute to ensure Party B's operation.

3. During the contract period, Party B shall operate independently and manage the income. However, in the last year of the contract period, Party B shall not cut down the harvested fruit trees and return them to Party A unconditionally. Fruit trees will naturally die, and the two sides will not hold each other accountable.

4. During the contract period, if Party A or Party B dies unexpectedly, its legal successor will perform this contract.

5. During the contract period, if the state expropriates orchard land according to law, the land compensation fee shall be returned; The compensation fee belongs to. If the temporary land occupation and rehabilitation fee belongs to Party B, Party A will refund the contract money that Party B has paid to Party A but has not yet expired. Whoever invests in the compensation fee for fixed facilities owns it.

Liability for breach of contract of intransitive verbs: After this contract comes into effect, both parties must consciously perform it. In case of breach of contract, the breaching party shall pay RMB Yuan only to the observant party and compensate the observant party for its economic losses.

7. This contract is made in triplicate, which shall come into effect after being signed and sealed by both parties, and each party holds one copy.

Party A:

Party B:

Book substitution unit:

Handler:

date month year

Selected Articles of Contract Agreement in 2023 4

Party A:

Party B:

In accordance with the Contract Law, this Contract is hereby concluded by consensus in order to clarify the rights and obligations of both parties.

1. Party A will lease the West Shrimp Pond of the Yellow River Diversion Main Canal from Qingbei to Pingyuan Reservoir to Party B for use.

2. The lease period is 1, from February 20 to 1, February 20. The lease term is 5 years.

3. Price and payment method, five-year rent. Pay in one lump sum.

Four. During the lease term, Party B can only carry out rectification and increase of facilities with the consent of Party A, and bear all expenses.

5. Party A shall take back the fixed facilities added by Party B free of charge.

6. This contract is made in triplicate, one for each party and one for the witness.

Seven. Other matters not covered shall be settled by both parties through consultation.

Signature of Party A:

Signature of Party B:

Signature of reference:

20__ _ _ _ _ _ _ _

Selected Articles of Contract Agreement in 2023 5

Party A: _ _ _ _ _ _ _

Party B: _ _ _ _ _ _

Party A voluntarily transfers the contracted land to Party B to build a factory. The circulation period is 150 years (from 1, March 20 to 1, March 20), and the circulation fee is 700 yuan per mu.

1. Payment method: After the agreement comes into effect, the rent will be paid every two years.

2. During Party B's use, if the country needs to use the land, Party A shall refund the transfer fee paid by Party B according to the actual number of years.

During the contract period, both parties should adhere to the principle of mutual support and mutual benefit. During the execution of the agreement, the management right, site transfer right and compensation right shall be owned by Party B, and the land compensation right shall be owned by Party A. After the termination of the agreement, both parties shall have no compensation. If one party breaches the contract during the operation period, it shall compensate the other party for three times the economic loss.

4. After the expiration of150 years, if both parties have no objection, this agreement can be continued. If there is any objection, Party A intends to sublet. Under the same conditions, Party B has priority. If Party B doesn't rent it, the three parties shall settle it through negotiation.

5. If the parties change during the contract period, it can be decided according to the inheritance law, and the contract will remain valid.

Party A (official seal): _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Selected Articles of Contract Agreement in 2023 6

Employer (Party A): _ _ _ _ _ _ Address: _ _ _ _ _ _ _ _ _ Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (Party B): _ _ _ _ _ _ _ Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In accordance with the Contract Law of People's Republic of China (PRC) and the relevant provisions of _ _ _ _ _ _, this contract is signed by both parties through consultation, and the construction contract is earnestly performed.

First project

I. Project name:

Second, the project number:

III. Project Location:

Four. Scope of work: The building installation area of all projects in this contract is * * * _ _ _ _ _ _ square meters (see the project list for the building installation area of each single project).

5. Project cost: The construction drawing budget cost of all projects in this contract is RMB _ _ _ _ _ _ _ _ _ _ _.

Article 2 Project duration

A, according to the national time limit for a project quota and use needs, the two sides agreed that the total project duration is _ _ _ _ days (calendar days), from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Second, the contractor shall issue a notice of commencement to the owner _ _ _ days before commencement.

Three. In the process of organizing construction, in case of any of the following circumstances, the construction period shall be extended, and both parties shall negotiate in time and determine the extension period in writing:

1. Stop working due to natural disasters or irresistible reasons;

2. The construction cannot be continued because Party A proposes a change plan or changes the construction drawing;

3. According to the construction preparation regulations, the construction site, water and electricity cannot be provided, the roads are not smooth, and the obstacles are not removed, which affects the construction on the site;

4. Due to Party A's failure to provide drawings, materials and equipment on schedule, or the materials and equipment provided by Party A do not meet the specification requirements, the work stoppage or construction cannot be carried out smoothly.

5. In the process of construction, power failure for more than 8 hours or continuous interruption for more than 3 days (more than 4 hours at a time) will affect the normal construction;

6. The supervision visa is not timely due to the contractor, which affects the construction of next working procedure;

7. Failure to allocate advance payment, project progress payment or price difference of purchased materials as stipulated in the contract affects the construction.

8. Due to policy changes, force majeure and reasons other than Party A and Party B, the construction of the project is stopped or postponed, resulting in the inability to continue the performance of the contract. Party B shall properly protect and hand over the completed projects and purchased materials and equipment; According to the requirements of Party A, withdraw their own mechanical equipment and personnel from the construction site. Party A shall provide necessary conditions for Party B's exit as stipulated in the contract, pay the above economic expenses, pay the completed project price and compensate Party B for related losses. The orderer shall be responsible for returning the ordered materials and equipment, and Party A shall bear the non-refundable payment and the expenses arising from the return. However, the losses caused by the failure to return the goods in time shall be borne by the responsible party.

Fourth, the construction period is ahead of schedule.

If it is necessary to complete the project ahead of schedule, both parties shall sign an early completion agreement after consultation, and the contract completion date may be advanced. Party B shall modify the schedule accordingly and submit it to Party A for approval. Party A shall give approval within 5 days and provide convenient conditions for rushing to work. The early completion agreement includes the following main contents.

1. lead time;

2. Emergency measures taken by Party B;

3. The expediting conditions provided by Party A;

4. Economic expenditure and commitment to catch up with work;

5. Share the benefits of early completion (if any).

Article 3 Construction preparation

1. Party A shall complete all kinds of certificates and approvals required for construction and apply for a building permit before commencement; Remove the original pipelines, trees and other obstacles that affect the construction within the scope of the construction site; Solve the construction land (including materials and components stacking and transit sites, large temporary facilities construction land); Solve the smooth flow of construction water, electricity and transportation roads; All engineering design drawings shall be provided to Party B on _ _ _ _ _. Organize design and construction units to carry out engineering design disclosure.

2. Before starting work, Party B shall organize relevant personnel to learn and be familiar with the drawings and participate in the design disclosure; Prepare the construction drawing budget; Responsible for the preparation of construction organization design or construction scheme; Level the construction site, use water, electricity and roads in the construction battery limit, set up temporary construction facilities, arrange the overall construction progress, reserve materials and process components, and make all construction preparations.

Article 4 Material supply

1. The physical objects or indicators of the following materials and equipment shall be provided by the Employer: _ _ _ _ _ _ _ _

2. In addition to the materials and equipment supplied by the Employer, other materials and equipment shall be purchased by the Contractor;

3. The materials and equipment supplied by the Employer and purchased by the Contractor must be accompanied by product certificates before they can be used in the project. If the materials and equipment supplied by Party A are not supplied on schedule or the specifications and quality can't meet the requirements, they can't be solved through the efforts of both parties, and the losses caused to Party B shall be borne by Party A. If either party thinks that the information provided by the other party needs to be reinspected, it shall be allowed to do so. Only after the re-inspection meets the quality requirements can it be used in the project, and the re-inspection fee shall be borne by the party requesting the re-inspection; Do not meet the quality requirements, should be handled in accordance with the relevant provisions, the reinspection fee shall be borne by the material equipment supplier.

Four. Treatment method for price difference of materials and equipment in this project: _ _ _ _ _ _ _ _ _ _ _ _

Article 5 Project Quality

1. The quality of this project meets the research requirements of both parties: _ _ _ _ _ _ _

Second, the contractor must carry out the construction in strict accordance with the construction drawings, documents and construction engineering specifications, procedures and standards issued by the state, and accept the supervision of the representative sent by the employer.

Article 6 Payment and settlement of project price

1. Within _ _ _ _ days after the signing of this contract, the Employer shall pay _ _ _% of the total contract price (or the investment amount of the current year), totaling RMB _ _ _ _ _. The cost of temporary facilities is calculated as% of the total contract cost of civil engineering, RMB _ _ _ _ _ ten thousand yuan, and the labor cost of installation engineering is calculated as%, RMB _ _ _ _ ten thousand yuan; The price difference of materials and equipment is _ _ _ _ _ _ ten thousand yuan, which shall be paid by _ _ _ _ _ _ _ _ _.

Second, the employer must pay the progress payment according to the verified progress within _ _ days after receiving the monthly progress report from the contractor. When the progress payment reaches _ _% of the total contract price, the reserve fund will be deducted gradually according to the specified proportion.

Three, the project price payment reaches 95% of the total contract price, no longer pay according to the schedule, after the completion acceptance, even with interest (financial allocation does not bear interest) one-time payment to the contractor.

4. If the Employer defaults on the progress payment or the final payment of the project, it shall pay the Contractor three ten thousandths of the liquidated damages on a daily basis.

5. If the employer defaults on the difference between the project payment and the purchased materials, which really affects the progress of the project and causes the contractor to stop working or slow down, it shall be borne by the employer.

Article 5 Construction and design changes

1. Party B shall organize the construction according to the national construction acceptance specifications, quality inspection standards and design requirements, and all of them are qualified.

Second, we must adhere to the construction according to the drawings, and neither party may arbitrarily change the design. Under any of the following circumstances, the responsible party shall bear the losses such as slowdown, rework, overstock of materials and components, construction force and mechanical relocation:

1. If there is any mistake or serious irrationality in the design during the construction, Party B shall notify Party A in writing, and Party A shall negotiate with the original design unit within 7 days and propose to modify or change the design documents, and the construction can only be started after both parties sign an agreement.

2. In the process of construction, if the construction is stopped or postponed, both parties shall agree on the safety part of the project under construction.

3. In the process of construction, if it is found that Party A's investment is insufficient, it can't pay the project progress payment on time, stop work halfway or postpone the construction, and the losses caused to Party B shall be borne by Party A. ..

Article 6 Safe construction

1. Party B has the responsibility to educate workers to strictly implement the operating rules, carry out safe construction, and prevent fire and theft. During the construction period, Party B shall be responsible for the casualties and other losses caused by Party B's poor management.

2. In case of heavy casualties, Party B shall immediately report to relevant departments and notify Party A's representative according to relevant regulations. At the same time, according to the requirements of relevant government departments. Party A provides necessary conditions for the rescue. The expenses incurred shall be borne by the party responsible for the accident.

3. In case of casualties not caused by Party B, the responsible party shall bear the responsibilities and related expenses. ..

Article 7 Project Subcontracting

1. Party B may subcontract some projects according to the terms of the agreement.

2. After signing the subcontract with the subcontractor, Party B shall send a copy to the representative of Party A.. If there is any conflict between the subcontract and this contract, this contract shall prevail.

Article 8 Liability for breach of contract

Contractor's responsibilities:

A, the project quality does not conform to the provisions of the contract, responsible for free repair or rework.

Second, if the project cannot be delivered according to the time limit stipulated in the contract, the late payment fee shall be paid according to the reward and punishment provisions of this contract on the advance or delay of the time limit.

Employer's responsibilities:

1. If the contractor fails to perform its responsibilities as stipulated in the contract, it shall compensate the contractor for the actual losses caused by the delay in the completion date.

Two, due to design changes and design errors caused by the project stop, delay or rework, measures should be taken to make up for or reduce losses. At the same time, compensate the contractor for the actual losses caused by shutdown, slowdown, rework, transshipment, relocation of personnel and mechanical equipment, and backlog of materials and components.

Three, the project without acceptance, the employer in advance or unauthorized use, the resulting quality or other problems, shall be borne by the employer.

4. If the contractor fails to accept the goods within _ _ _ _ _ _ days after receiving the acceptance notice, it shall pay the overdue penalty in accordance with the regulations.

5. If the project funds are not allocated as stipulated in the contract, the contractor shall be compensated for three ten thousandths of the overdue payment amount every day according to the bank's regulations on overdue payment methods.

Article 9 Dispute settlement measures

In the event of a dispute over a construction project contract, both parties shall negotiate in time. If negotiation fails, either party may apply to the urban and rural construction committees at all levels or the superior business departments of both parties for mediation. If it cannot be solved, you can choose the following () to handle:

(1) Apply to the Arbitration Commission where the building is located for arbitration.

(2) directly to the people's court.

Article 10 Effectiveness and Termination of the Contract

1. This contract is made in duplicate, with each party holding one copy. The remaining copies shall be submitted by the Employer to this organ and the competent construction department for the record.

2. This contract shall come into effect as of the date when the representatives of both parties sign and affix their official seals; The project completion acceptance meets the requirements and will be terminated after the project payment is settled.

III. After the signing of this contract, if both parties need to propose amendments, a supplementary agreement can be signed as a supplementary contract to this contract after consultation.

Party A:

Party B:

20__ _ _ _ _ _ _ _

Selected Articles of Contract Agreement in 2023 7

Party A (Employer):

Party B (contractor):

Through negotiation between both parties, Party A contracted its factory to Party B for operation. Based on the principles of voluntariness, fairness, honesty and mutual benefit, Party A and Party B sign the following agreement:

First, the contracting method.

Party A contracts the ownership company to Party B for self-production and self-sale. During the contract period, all operating funds shall be raised by Party B; All expenses, including factory rent, water, electricity, taxes, health management fees, etc. The employee signs a labor contract with Party A, but during the contract period, relevant personnel expenses shall be borne by Party B (such as salary, overtime pay, social security, housing accumulation fund, employee welfare, economic compensation for dissolving the labor contract, liquidated damages and compensation for work-related injuries, etc.). ).

Second, the content of the contract

Signing place:

Website scope:

Contract equipment: