Overall renovation contract

In renovation contract as a whole, contract is one of the ways for modern people to safeguard their own interests. Only if one party violates the contract, the other party can bring legal proceedings. The following is about renovation contract as a whole. I hope it will help everyone's life!

Overall renovation contract 1

Employer (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, the principles of equality, voluntariness, fairness, honesty and trustworthiness are followed. Both parties reached an agreement on the decoration of truffle Xintiandi and the construction of hydropower installation project, and signed this contract.

Article 1: Project Overview

Project name: Zhuzhou, Hunan

Project location: Zhuzhou City, Hunan Province

Project content: Truffle Xintiandi decoration and water and electricity installation project.

Article 2: Scope of Contract

1, decoration, water and electricity installation works:

Including but not limited to the following contents: decoration and water and electricity installation works according to the requirements of drawings, design changes and construction schemes; Transportation within the site; Measuring and setting out; Construction drainage and cleaning; Maintain temporary electricity consumption; Scaffolding and dismantling; Protection of finished products before handover after completion acceptance; Installation and removal of safety protection facilities; Construction lighting at night; Materials are stacked in a fixed way; Daily civilized cleaning of the construction area, etc. According to the requirements of drawings, design changes, new entrustment and construction scheme, all the work contents of structural construction need to be completed. The specific construction technology and work content are mainly based on the design drawings and the requirements put forward by Party A. ..

5, ancillary works and entrusted changes

Including all relevant ancillary works within the scope of the drawings. Civilization, safety and security work of this project. Party B shall not refuse to carry out various design changes, new entrustment or work within the scope of the contract for any reason. If it refuses, Party A has the right to entrust other units to carry out the work, and the price will be deducted from Party B's contract price according to 1 and 5 times of the construction drawing budget value approved by Party A. ..

6. Information:

Party B shall complete, collect and sort out all documents related to the project according to Party A's requirements, and cooperate with Party A to do a good job of data docking, and make its own backup, and submit a copy to Party A in writing.

7. Safety, civilization and environmental protection:

Party B shall do a good job in protecting underground pipelines and adjacent buildings and structures on the construction site. Where it crosses or is adjacent to high-voltage lines, communication cables or other underground facilities, it shall be handled through consultation with relevant departments to ensure its safety and no damage. All losses or consequences caused by Party B shall be borne by Party B. ..

Party B shall abide by the local regulations on civilization and public security management, and put an end to affrays, fights, riots and other disciplinary actions. In the event of an emergency, Party B shall actively assist Party A and the local government to take measures to calm the incident, prevent the situation from expanding, minimize property losses and avoid casualties.

Party B shall ensure that the construction site is clean and tidy, in line with the relevant regulations on environmental sanitation management, and bear the losses and fines caused by its violation of relevant regulations; After the completion of the project, the site must be cleaned up, temporary facilities removed, stacked and returned to Party A in time. If Party B fails to dismantle and clean up within seven days after the completion, Party A has the right to entrust other parties to clean up, and all expenses arising from cleaning up shall be borne by Party B and directly deducted from Party B's project payment.

8. Management personnel within the scope of Party B: A builder, a quality inspector, a safety officer and other management personnel shall be responsible by Party B and reported to Party A for on-site supervision. (listed and certified).

9. Party B shall bear all expenses for the damage to public property and the loss of people's interests caused by its illegal construction.

Article 3: Signing method:

This project adopts contractor and contractor.

Labor, materials, construction, time limit for a project, quality, safety and civilized construction, etc.

Article 4: Construction Period

1, the total number of calendar days (from MM DD YY to MM DD YY), and this construction period is not affected by any objective factors. Strictly implement the construction period of Party A and the owner.

2, the time limit for a project delay:

(1) In case of major design changes or irresistible natural disasters (fires caused by natural causes such as fires and earthquakes) and the suspension of work notified by relevant functional departments at higher levels such as provincial and municipal governments, the construction period will be postponed accordingly after being signed and approved by the construction party of Party A, and Party B will not be responsible for the breach of contract caused by such reasons. If it is a preventable natural disaster and Party B fails to take preventive measures to delay the construction period, Party B shall bear all relevant responsibilities;

(2) If Party B's normal construction as planned is affected by major design changes, power failure, water cut-off, waiting for materials, etc., if it continues for more than 24 hours, the excess part shall be signed and approved by Party A's representative, and the construction period shall be postponed accordingly.

3. In order to ensure that the construction period is completed on schedule, Party A will assess the construction progress of each bid section of Party B. Due to Party B's shortage of personnel, which affects the timely completion of the construction period, Party A requires Party B to increase the number of personnel to enter the site, but Party B fails to arrange personnel to enter the site, so Party A has the right to let a third party to assist in the completion of the construction, and all the expenses incurred shall be borne by Party B, and Party A will directly withhold from Party B's settlement funds and pay them to the third party.

4. During the performance of the contract, if the construction period is delayed due to the following reasons of Party A, the contractor has the right to ask the employer to extend the construction period or increase appropriate reasonable expenses: (1) increase the contract work content; (2) Suspension of construction due to the Employer; (3) Delay in providing drawings; (4) Failure to pay the progress payment in time as agreed in the contract; (5) Failing to provide a construction site with construction conditions at the time agreed in the contract. Regardless of any of the above reasons, if Party B thinks it is necessary to modify the contract schedule, it shall notify Party A in writing within 14 days from the date when the above reasons occur, and state the time limit and reasons for delaying the construction period.

5. Party B shall pay 0.3% of the contract price to Party A as liquidated damages for each day of delay in the construction period. If Party B still fails to complete the project for more than 3 months, Party B shall pay Party A 65,438+05% of the settlement price as agreed in this contract, and Party A has the right to terminate this contract with Party B at any time, or entrust a third party to complete the unfinished project of Party B, and Party B shall bear the additional expenses and management expenses incurred by Party A from this ... The project payment shall be paid to Party B in advance according to the terms of the main contract.

6. If Party B stops work, strikes or exits during the construction period due to reasons other than Party A's, Party A will hold Party B accountable, deduct liquidated damages, and have the right to send a third party to the site for construction, and all relevant expenses shall be borne by Party B. ..

Article 5: Quality Standards

The quality standard of this project must meet the national acceptance standard. If the quality of the project does not meet the specifications and design requirements, Party B must rework and bear all the expenses arising therefrom. After the completion of the project, the project quality supervision department will evaluate the project quality of this contract, and all the projects constructed by Party B shall meet the qualified standards. If the project quality is not up to standard, Party B shall unconditionally rework and rectify, and at the same time bear the liquidated damages of 10% of the project cost, and bear the corresponding legal responsibilities.

Article 6: Contract Price and Payment Method

1. Contract price: This contract is lump sum contract, and it is calculated as 30% of the final settlement amount between Party A and the owner. This price has included all the expenses that Party B may incur in the construction of this project, including but not limited to the following contents: direct expenses, indirect expenses, profits, transfer expenses of equipment and materials on the construction site, lump sum fees for the project, all risks, responsibilities, insurance and unforeseen expenses included in the contract, etc. During the contract period, the general contract will not be adjusted due to any factors (including design changes).

2. Payment method: After the contract is signed, Party B shall pay a deposit of 300,000 yuan to Party A.. Party A shall pay Party B the monthly project payment for the completed project amount according to the payment method of the constructor. After the project is completed, the quality deposit will be returned to Party B without interest.

Article 7: Safety Management

1. Party B shall abide by the safety rules and regulations, management regulations and technical specifications of the project construction safety production, and organize the construction and safety measures in strict accordance with the safety standards to ensure the construction safety.

2. Party B shall build the necessary safety protection shed at the construction site according to the construction safety requirements to ensure the construction safety, and take full responsibility for the safety accidents.

3. Party B must be responsible for all fire prevention work during the construction period, and any losses caused thereby shall be borne by Party B..

4. The subcontractor designated by Party A shall be responsible for any safety accidents in the construction process. If losses are caused to Party B, Party A shall be responsible for deducting the losses from the subcontractor's project payment.

Article 8: Construction Site Management

1. Party A shall designate the site representative at the construction site.

2. The representative of Party A (any representative of Party A stationed at the construction site) shall exercise the rights and perform the duties stipulated in the contract.

3. Party B promises to send project leaders, technical leaders, constructors and librarians with excellent project construction management experience to manage this project, and all management personnel are certified. As the person-in-charge designated by Party B, he is the representative of Party B and must be resident at the construction site.

4. Organize the construction in strict accordance with the construction drawing, general design instructions and technical operation procedures and specifications stipulated by the state to ensure the quality of the project and complete it on schedule according to the time stipulated in the contract.

5. Formulate safety protection measures to ensure safe production.

6. Provide and repair the lighting used in the construction site, the maintenance and guards required by the guards, etc. If Party B fails to fulfill the above obligations, Party B shall bear the responsibilities and all expenses arising therefrom.

7. Conscientiously carry out civilized construction, carefully protect and relocate underground pipelines on site, protect ancillary buildings and safety, control construction noise as much as possible, and ensure the cleanliness of the construction site in accordance with relevant regulations.

8. All construction personnel of Party B shall immediately report the quality accident to Party A or the supervision engineer and relevant departments. If it is Party B's responsibility, it shall be responsible for rework until it meets the specification requirements and compensate Party A for all losses.

9. All construction personnel of Party B must abide by relevant regulations, cooperate with other professional construction teams to enter the site for construction, and shall not deliberately embarrass other construction teams to enter the site for construction. And obey the unified deployment of Party A to the construction site. Equipped with necessary mechanical construction personnel. After the project is completed and accepted, Party B shall thoroughly clean up and evacuate the site within one month.

10. Before the completed project is delivered for use, Party B shall be responsible for the finished product protection of the completed project. If any damage occurs during the protection period, Party B shall repair it at its own expense. If Party A uses it in advance, the repair cost of the damage shall be borne by Party A. ..

1 1. Party B's actual mobilization behavior shows that Party B acknowledges that Party A's preparations meet Party B's mobilization conditions, so Party A does not need to perform other obligations of mobilization construction.

12. Party B shall not subcontract this project to others in any form, including others who undertake this project in the name of Party B. ..

13. Party B shall handle disputes arising from construction activities by itself and negotiate with relevant government departments, and the expenses arising therefrom shall be borne by Party B..

14. The construction contents of all subcontractors during the project construction shall be brought into the unified management of Party B. ..

15. Party B unconditionally cooperates with Party A's librarians to collect and sort out information on the spot, and is responsible for cooperating with raw material sampling.

16. Party A's responsibilities and obligations are not specified in this contract, but Party B shall be responsible for matters that need to be solved and handled when completing this contract.

Article 9: Public Safety and Civilization

1. Public security: those who fight, make trouble or destroy public property at the construction site shall be compensated according to the facts and fined at one time 1000 yuan. If the circumstances are serious, the responsibility shall be investigated.

2, civilization: do not wear uniforms to work, do not wear helmets, urinate everywhere, throw cigarette butts and confetti; Pour food everywhere, the room is unsanitary, and 50 yuan will be fined for wearing slippers to work once. If the on-site materials are untidy and unclean, and they have not been implemented within two days since Party A issued the rectification notice, Party A has the right to arrange another third party to carry out rectification, and the rectification fee shall be withheld from Party B's settlement fund and paid to the third party by Party A..

Article 10 Handling of industrial accidents:

1. Party B shall bear all the expenses caused by on-site industrial accidents, and Party A shall not be responsible for this.

Article 11: Party A's responsibilities:

1. Party A shall be responsible for the taxes, pre-settlement fees, production, collection, arrangement and submission fees of engineering data and as-built drawings, and coordinate with the owner.

Article 12: Liability for breach of contract and disputes

If Party B fails to perform various obligations or makes mistakes as agreed in this Contract, it shall be deemed as a breach of contract, and Party A has the right to charge Party B a penalty of 65,438+00% of the total settlement amount of Party B; Any dispute between Party A and Party B during the performance of this contract shall be settled through negotiation as far as possible. If negotiation fails, both parties agree to bring a lawsuit to the court where the project is located.

Article 12: Other agreements

1. This contract is signed by both parties on the basis of equality and voluntariness. If there are special provisions in this contract, it belongs to the' special agreement' of both parties.

3. Party B shall implement, abide by and maintain the civilized conventions or rules and regulations on the construction site stipulated by the Employer. If Party B is found to have violated civilized conventions and rules and regulations, the employing unit has the right to give fine education according to regulations, and those who violate the rules for three times in a row shall be ordered to leave unconditionally.

4. Party B shall bear the secondary transfer expenses of office, accommodation and building materials caused by the construction site conditions.

5. Safe and civilized construction should be carried out in accordance with the requirements of government safety and civilization.

Article 14: This contract is made in quadruplicate, with Party A and Party B holding two copies respectively, all of which have the same legal effect and shall come into force as of the date of signature and seal by both parties.

Date of signing this contract: year month day.

Party A: (Seal)

Legal representative:

Entrusted agent:

Bank of deposit:

Account number:

Unit address:

Tel: Party B: (Seal) Legal Representative: Entrusted Agent: Bank of Account: Account Number: Company Address: Tel:

Overall renovation contract II Party A:

Party B:

Through friendly negotiation, Party A and Party B reach an agreement that Party B will undertake all decoration construction of Party A, and sign this contract:

1. Party B shall undertake all the construction work for the renovation of the house, that is, implement "contracting for work and materials". For details about the construction, please refer to the attachment.

2. Total contract price: RMB; In figures: RMB. Besides, Party A does not pay any fees to Party B. ..

Iii. Terms of payment:

1. On the date when the materials enter the site for construction, Party A shall pay 40% in advance to Party B, that is, RMB Yuan only, in figures: RMB Yuan.

2. Pay 25% RMB (in figures: RMB) on the day of construction of paint materials.

3. Pay RMB 25% (in figures: RMB) on the day when the floating glue paint enters the site for construction.

4. On the day when all decoration construction is completed, Party A shall pay the balance of 10%, that is, RMB Yuan only.

Four. Duration: Party B shall complete all construction tasks within the agreed construction period on the date when both parties determine the construction period of house decoration.

Verb (abbreviation for verb) Other agreements

1. Party A shall pay in time as agreed in the contract, otherwise, it shall pay liquidated damages according to 200 yuan/day.

2. Party B shall bring its own tools, hire personnel, be responsible for construction safety, and carry out the construction in strict accordance with the requirements to ensure the quality of the project. If any unqualified behavior is found in the construction process, it shall be reworked immediately, and all losses caused by decoration materials and labor shall be borne by Party B. ..

3. Party B shall complete all construction tasks within the time limit agreed in the contract, and shall be punished according to 200 yuan/day for each day overdue. If Party A fails to pay in time, new construction contents shall be added. If Party A delays the construction period, Party B will not be liable for breach of contract.

The renovation warranty period of this house is two years. During the warranty period, Party B shall be responsible for timely and free maintenance of Party A (in case of man-made damage, the maintenance fee shall be paid accordingly).

6. This contract is made in duplicate, with each party holding one copy, which shall come into effect after being signed by both parties.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Overall renovation contract 3 Party A:

Party B: Construction Team

Design supervisor:

Venue: Building No.2/Room KLOC-0/00 Baidu Scenery, Nankai District, Tianjin

With regard to the house decoration in the above-mentioned location, the above parties reached the following agreement through consultation:

Responsibilities of all parties:

I. Party A's responsibilities:

1. Before construction, assist the construction team to handle all the formalities required by the residential property management department, and advance the decoration mortgage payable by the construction team to the property company 1500 yuan;

2. Pay Party B the decoration labor fee according to the conditions agreed by both parties;

3. Responsible for the procurement of materials needed for decoration;

4, responsible for housing demolition (including heating replacement).

II. Responsibility of Party B

1. Carry out the construction under the supervision and inspection of the design supervisor according to the construction project and process requirements agreed by both parties, including all tiles, wood, oil, water, electricity and some supporting projects that need to be installed;

2. Bring all the tools needed for construction;

3. Ensure construction safety. If there is any problem, Party B shall be responsible, and Party A shall not bear any responsibility;

4, responsible for the quality control of the whole construction, strictly do a good job in every construction process, strictly control the quality, and realize high-quality projects. The warranty period is one year after completion, and Party B shall pay the 500 yuan deposit to Party A, which shall be returned to Party B after the expiration of the warranty period.

5. During the construction period, strictly abide by the management regulations of the residential property management department on decoration construction, and solve the problems arising during the construction period.

Three. Responsibilities of the design and supervision party:

1, responsible for architectural design and construction lofting; (Construction drawings of all projects are acceptable);

Collect service fee 1200 yuan;

2. Assist Party A in selecting decoration materials;

3. Be responsible for the specific guidance and supervision of the construction quality and technology of the construction team, and check with Party A at the construction site every day during the construction of important projects.

Before the next project progress (including all tiles, wood, oil, water, electricity, etc. , and each project has at least 1-2 times of acceptance), 800 yuan technology and supervision fees will be charged.

The above expenses shall be paid in two installments, with the first payment of 1 ,000 yuan and the second payment of 1 ,000 yuan after the acceptance of Party A. ..

Labor cost and payment method

The labor cost of the whole decoration project (including design, construction and supervision costs) is * * _ _ _ _ _ _ _. Party A will pay in four phases according to the progress of the project, and the construction team will pay 65,438+0,000 yuan when they enter the site for construction. After 65,438+05 days of construction, if the performance is good (hydropower transformation is completed), they will pay RMB 65,438+0,000 after the first acceptance. After the ceiling, kitchen, bathroom and all doors are completed and accepted, the project payment is 2000 yuan.

Construction projects and technologies:

1. According to the requirements of Party A, divide the wires, telephone lines, closed-circuit television lines and network lines in the whole house, and plan the grooves and sleeves.

2. According to Party A's requirements, the hot and cold water pipes in the bathroom and kitchen have been laid, and grooves have been dug out.

After the pipe is laid, it is required to test the water for one day before sticking the wall brick.

3, bathroom, kitchen wall tiles, bathroom, kitchen floor tiles, smooth, not empty drum.

4. The living room, dining room, big bedroom, small bedroom, small hall and balcony are all plastered with cement (so that the solid wood floor can be leveled with the floor tiles after being paved), and then calendered.

5, bathroom, kitchen, balcony ceiling installation aluminum gusset plate.

6. Make a washbasin cabinet with pipes in the bathroom to assist in installing the bathroom. The kitchen is made of hanging cabinets, ground cabinets and tube cabinets. The balcony is used as a ground cabinet. The countertops are all marble. (See construction drawing)

7. Make two-bedroom door covers, window covers, kitchen door covers, household door covers, bathroom door covers and balcony door covers.

The above materials are white pine, large core board and black walnut. Paint is varnish, three times primer, four times topcoat and seven times.

8. Make a TV cabinet and TV wall in the living room, a screen shape, a clothes hanging board in the hall and a wine cabinet in the dining room. The above materials are white pine, big heart board (single board for TV cabinet) and black walnut. See the construction drawing. Paint is varnish, primer three times, topcoat two times and * * * five times.

9. The dining room shall be provided with a gypsum board ceiling (see the construction drawing), and the living room and lobby shall be provided with ceilings (see the construction drawing).

10, the living room, dining room, big bedroom, small bedroom and small hall were putty-scraped three times, and latex paint was brushed three times.

1 1. Install washbasin, bathroom, toilet, sanitary ware rack and kitchen sink for washing vegetables. Install lamps, sockets, switches, exhaust fans and faucets. Install curtain rod and clothesline. Install the door (***8 inches). Install hardware such as glass, mirror, lock and door suction.

During the construction of the above projects, all drawings provided by the designer shall be approved and signed by Party A before the construction. If there is any change, the construction will be carried out after negotiation among the three parties.

This contract is made in triplicate and comes into effect after being signed by all parties.

Signature of Party A: Signature of Party B:

Tel: Tel:

ID number: ID number:

Signature of design and supervision:

Tel: ID number: