Download the attachment of Beijing renovation contract Model (Standard Edition).

Renovation contract Model (Standard Edition)

Customer (Party A):

Organizer (Party B):

Engineering project:

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.

Article 1: Project Overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Room specification: room type: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. Construction content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

4. Entrustment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total days of the project: _ _ _ _ _ _

Article 2: Project Price

The project price (in words) is _ _ _ _ _ _ _ _ Yuan (in words).

1, material _ _ _ _ _ _ _ yuan;

2, labor costs _ _ _ _ _ _ _ yuan;

3. The design fee is _ _ _ _ _ _ yuan;

4, the construction freight _ _ _ _ _ _ yuan;

5. The handling fee is _ _ _ _ _ _ _ yuan;

6. The management fee is _ _ _ _ _ _ _ yuan;

7. Other expenses (please specify the contents) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

4. All materials and equipment purchased by Party A shall be borne by Party A; Party B shall be responsible for the quality of the project.

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2.？ If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5: Method of Payment

1.？ After the contract is signed, Party A shall pay 100% of the project cost and 50% of the project cost; When the construction period is in the middle (? Party A will pay 40% of the second project cost. The remaining 10% shall be paid to Party A after the project is completed and accepted. (Note: Construction costs include labor costs).

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing the construction change form and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to pay the project price in advance within the time limit stipulated in this contract, Party A shall pay 1% of the unpaid project price to Party B for each overdue day.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party B shall pay Party A 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid 1% of the labor cost in the decoration project price for each day of delay? Yuan.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3.？ In the process of construction, the shutdown caused by engineering quality problems and disagreement between the two parties shall not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration, coordinate the settlement of disputes as soon as possible, and continue the construction.

4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7: Project Acceptance

1. Project quality acceptance, except for concealed works, which need to be accepted by sections. After all projects are completed, Party B shall organize Party A to carry out the completion acceptance. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.

Article 8: Other matters

1.？ Party A's responsibilities

1) The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make on-site disclosure to Party B. ..

2) Secondary decoration project, in which all or part of the house is vacated and obstacles affecting the construction are removed. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

3) If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood.

2. Party B's responsibilities

1) should take the initiative to show business license, membership card or construction qualification; The handling salesman must have a certificate of entrustment from the legal representative.

2) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.

3) Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

4) Strictly perform the contract and implement the credit period. If the completion is delayed, such as divestiture, slowdown or excuses to induce Party A to advance funds, it will be considered as a breach of contract after investigation.

5) undertake the warranty responsibility within the scope of decoration construction, and the warranty period is 12 months, counting from the date when the project is completed and accepted by Party A. ..

Article 9: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 10: dispute settlement

In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.

Article 11: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 12: Contract comes into effect

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. The supplementary contract has the same legal effect as this contract.

3. This contract (including annexes and supplementary contracts) is in duplicate? Party A and Party B hold each other? Share it.

Party A (Owner): Party B:

(signature)? (signature)

Address of domicile: address of enterprise:

Postal code:? Postal code:

Work unit:? Legal representative:

Entrusted agent:? Entrusted agent:

Telephone:? Telephone:

Signing address: Signing date:

? Renovation contract Model (Standard Edition 2)

_ _ _ _ _ _ _ (hereinafter referred to as Party A)

Agreement _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Agreement

This agreement is reached by both parties through consultation, and both parties shall abide by it. By mutual consent, this agreement was drafted by _ _.

I. Project:

1, three rooms (two rooms and one living room, hereinafter referred to as three rooms) shall be marked with corner lines, including heating and pipes (the living room shall be symmetrical), and plaster lines shall be marked around the roof to cover the doors and windows of the three rooms; The living room and bedroom are covered with laminated wood floors; Remove the original paint from all rooms, putty from the living room and bedroom, and paint with Nippon paint twice.

2. Put a crossbar at the doors and windows of the balcony, and make a shelf on it according to Party A's requirements (drawings); On the east side of the balcony, a multi-purpose cabinet (shoes below and bookcases above) and a hanging cabinet on the west side are used to cover the balcony, lay tiles and hang PVC boards.

3, bathroom, bathroom, kitchen tiles to the top, PVC board hanging on the roof; The kitchen floor was tiled and a stove was built.

4. The power supply circuit of the room should be properly adjusted according to the requirements of Party A, and there is a multi-purpose cabinet behind the living room door (shoes are placed below and clothes are hung on it).

5. If no details are involved, Party A shall put forward a plan and discuss it.

Second, the way of contracting:

Party A must ensure the materials needed during the renovation according to Party B's requirements (Party B shall notify Party A in advance), and Party B shall be responsible for the construction. Renovation contract sample 3 of individual housing. Quality standard: the construction quality meets the safety requirements, and the decoration quality is not lower than the decoration standard of the same construction type, which is recognized by both parties.

Fourth, the construction period:

20XX August 20th to 20XX1October 10. If it cannot be completed on time, 50 yuan will be fined every day.

Five, the project cost:

Materials are provided by Party A, and Party A only pays Party B five thousand six hundred yuan for decoration labor.

Terms of payment for intransitive verbs:

After the completion of the project, if Party A meets the above-mentioned construction projects and design requirements after acceptance, the decoration labor cost shall be paid in one lump sum within three days.

Seven, other issues:

The specific requirements of the renovation project shall be put forward by Party A and implemented by Party B. Matters not covered in this agreement shall be settled by both parties through consultation. This agreement shall come into effect as of the date of signature by both parties.

Eight. This agreement is made in duplicate, each party holds one copy, which has the same effect.

Party A: Party B:

Signature (seal): Signature (seal):

Year? Month? Day? Year? Month? sun

? Renovation contract Model (Simplified Edition)

Party A (employer): _ _ _ _ _ _

Company name: _ _ _ _ _ _ Tel: _ _ _ _ _ _

Address: _ _ _ _ _ _ Mailing address: _ _ _ _ _ _

Party B (contractor): _ _ _ _ _ _

Legal address: _ _ _ _ _ _ Legal representative: _ _ _ _ _ _ Title: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contact person: _ _ _ _ _ _ ID number: _ _ _ _ _ Tel: _ _ _ _ _ _ _

Mailing address: _ _ _ _ _ _ Postal code: _ _ _ _ _ _ _

Article 1 General situation of the project

1. 1 Project Location:No.: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

1.2 building structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

1.3 project cost: the price of family bedroom decoration project is agreed as follows according to the principle of market competition, with high quality and good price: total price: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. In which: material cost: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ With the consent of both parties, the construction content is changed, and the project payment for the changed part shall be calculated separately according to the actual situation.

1.4 project contracting method: both parties agree to adopt the following _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(1) Party B contracts all materials. (See Annex V: List of Decoration Materials Provided by Party B)

(2) Party B contracts some materials and Party A provides some materials (see Annex 4: List of Decoration Materials Provided by Party A and Annex 5: List of Decoration Materials Provided by Party B);

(3) All materials contracted by Party B and Party A (see Annex 4: List of Decoration Materials Provided by Party A).

1.5 The construction period is _ _ _ _ _ _ _ _ days; The commencement date is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 2 Construction drawings

Both parties agree to provide the construction drawings in the following ways:

1 Party A designs and provides the construction drawings by itself, and the submission time is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2 Party A entrusts Party B with the design and construction drawings in triplicate, with Party A, Party B and the construction team holding one copy respectively (see Appendix 6: Design Drawings of Home Decoration Project), and the design fee shall be paid by Party A (this fee is not included in the project price);

3 The construction drawings shall take effect after being signed by both parties.

Article 3 Rights and obligations of Party A

1 Provide water and electricity supply during construction before construction, and explain the matters needing attention in use;

2. Participate in the supervision of project quality and construction progress, and participate in the acceptance of materials entering the site and project completion;

3. The construction deposit and various property management fees collected by the property management department where the project is located shall be paid by Party A (except for the pass), and Party B shall assist in providing relevant materials required for property management;

4. The waste generated by house decoration shall not be dumped. Party A shall pile up in the place, manner and time designated by the property management unit, the residents' committee where the house is located or the housing management department of the unit, and remove it according to relevant regulations;

5. If Party B is responsible for pipeline blockage, water leakage, power failure and damage to articles caused by the renovation of family rooms, Party A shall ask Party B to be responsible for maintenance and compensation.

Article 4 Rights and Obligations of Party B

1 During the construction process, the national Code for Construction of Residential Decoration Engineering shall be strictly implemented to ensure the project quality and complete the project on schedule.

Units and individuals undertaking family room decoration projects shall take necessary safety protection and fire control measures to ensure the safety of workers and neighboring residents;

3. Protect the furniture and furnishings of the original bedroom and ensure the smooth flow of the upper and lower pipes in the bedroom;

All kinds of wastes formed in the decoration of family rooms should be piled up and removed according to the location, method and time stipulated by the relevant departments. It is strictly forbidden to throw away the waste and other items produced by the decoration of the living room from upstairs to the ground or from garbage passages and sewers;

Party B's designer is responsible for providing consulting, design, quotation and other related services to Party A. After the signing of this contract, the representative of Party B who implements the construction of this project shall contact Party A on the relevant matters of this project to ensure this project.

6 If Party B purchases or recommends to Party A the use of decoration materials that do not meet the national standards, causing excessive air pollution and losses, it shall be liable for compensation according to law;

7 The decorative materials used by Party B shall not be shoddy or fraudulent.

8 Party B's construction shall meet the requirements of relevant specifications, and Party B shall not cut corners or cut corners;

9 Party B shall not carry out barbaric construction, endangering the safety of the building itself;

Article 5 Provision of materials

1 The specifications and quality of materials and equipment provided by Party A shall meet the design requirements (see Annex 4: List of Decoration Materials Provided by Party A). Party A shall deliver the materials and equipment to the construction site on time and notify Party B, and both parties shall accept and handle the handover procedures; If Party A fails to provide materials on time or the specifications and quality of materials do not meet the design requirements, thus delaying the construction period or affecting the project quality, Party A shall bear the responsibilities;

2 For the materials and equipment provided by Party B (see Annex 5: List of Decoration Materials provided by Party B), Party B shall inform Party A in advance of the time when the materials and equipment will arrive at the construction site, and both parties shall jointly accept them; If the brand, specification and quality of the materials provided by Party B are inconsistent with the quotation, Party A has the right to refuse to use them, thus delaying the construction period or affecting the project quality, and Party B shall bear the responsibilities;

3 Party A shall determine the brand, specification, model or price standard of the materials, and Party B shall be responsible for purchasing them for Party A (see Annex 4: List of Decoration Materials Provided by Party A). Party B should pay attention to the procurement), and the materials can only be used after they arrive at the construction site and are accepted by Party A. The material procurement fee charged by Party B from Party A is the material collection management fee (_ _% of the material payment)+the material transportation fee (determined according to the actual situation); If the construction period is delayed due to material quality problems, Party A shall bear the responsibility;

Unless otherwise specified in the contract, hardware (door locks, handles, faucets, etc. ), stone, ceramic tile, equipment, sanitary ware and lamps shall be purchased by Party A and delivered to the site on time.

Article 6 Time limit for a project is delayed

1 If the construction period is affected by Party A's failure to complete the work it should be responsible for as agreed, the construction period will be postponed; If the unqualified materials and equipment provided by Party A affect the project quality, the cost of rework shall be borne by Party A, and the construction period shall be postponed;

2 If Party A fails to pay the project payment on schedule, the contract period will be postponed accordingly;

3 If Party B fails to complete the project on schedule due to material supply or construction reasons, the construction period will not be postponed; If there is any problem in the quality of the project due to Party B, the cost of rework shall be borne by Party B, and the construction period shall not be postponed.

Article 7 Quality standards

(1) Party B must carry out the construction according to the design documents and the current national technical standards and specifications.

(2) All projects contracted by Party B must meet the current national engineering quality acceptance standards.

(3) If the project quality is unqualified due to Party B's reasons, Party B shall rework it free of charge within the time specified by Party A to reach the acceptance standard of the project quality. If the rework still fails to meet the requirements, Party B shall be liable for breach of contract. If the project quality fails to meet the standard due to Party A's reasons, Party A shall bear the responsibility for rework and economic expenses.

Article 8 Project Acceptance and Warranty

1 Both parties agree to check and accept the project quality in the following three stages during the construction process:

(1) Acceptance of concealed works such as hydropower pipeline, waterproof layer and suspended ceiling base;

(2) Acceptance of paint and surface coating before construction;

(3) Completion acceptance. Party B shall notify Party A two days in advance to carry out the acceptance of each stage. After the acceptance of each stage is qualified. If Party A fails to attend the acceptance on time after receiving the notice, Party B has the right to stop work and wait, and all delays and other losses caused to Party B shall be borne by Party A;

2 warranty

(1) After the project is completed and accepted, and the balance of the project is settled, Party B shall go through the handover procedures with Party A (see Annex 9: Project Settlement Form) and fill in the project warranty form (the warranty period is two years) (see Annex 10: Project Warranty Form).

(2) Under normal use conditions, the minimum warranty period for interior decoration of residential buildings is two years, and the leakage prevention of kitchens, bathrooms and external walls with waterproof requirements is five years. The warranty period is calculated from the date when the residential interior decoration project is completed and accepted.

Article 9 Method of payment for project funds

1 Within _ _ _ _ _ _ _ days after the completion acceptance, Party A shall pay the project payment equivalent to _ _ _ _ _ _% of the total price.

If Party A pays the project payment, and Party B's sales staff or construction personnel collect it, it shall be regarded as Party B's collection.

2 If the total price increases or decreases due to the change of construction contents, Party A shall pay or collect the increased or decreased amount on the day when the completion acceptance is qualified.

Receipts should be issued for the capital exchanges between the two parties. After the completion of the project, Party B shall issue a legal invoice after Party A has paid off the payable amount.

Article 10 Liability for breach of contract

1 1. 1 After the signing of the contract, if either party proposes to terminate the contract or fails to perform the contract for any reason, it shall notify the other party in time, and the performance of the contract may be terminated or postponed after both parties agree through consultation, and the defaulting party shall pay liquidated damages of _ _ _ _ _ _ _ _ _ _ _% of the project cost to the observant party; If losses are caused, the breaching party shall compensate.

1 1.4 If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for the repair, and the required repair expenses shall be borne by Party B, and the construction period shall not be postponed.

1 1.5 If the construction period is delayed due to Party A or Party B, the responsible party shall pay the other party 2‰ of the total project cost as liquidated damages for each day of delay.

Article 11 Supplementary Provisions

After the signing of this contract, the project shall not be subcontracted.

12.2 If Party A and Party B directly sign the contract, this contract shall be made in duplicate, which shall come into effect after being signed (sealed) by both parties, with each party holding one copy.

12.4 The contract will be automatically terminated after the completion of performance.

12.5 this contract must be voluntarily authenticated by the parties to protect the legitimate rights and interests of the parties to the contract.

12.6 the annex to this contract is an integral part of this contract and has the same legal effect as this contract.

Party A (signature): _ _ _ _ Party B (seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _ entrusted agent (signature): _ _ _ _ _ _

Signing place: _ _ _ _ _ Signing place: _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Comments on Contract Certification of Home Decoration Market (Seal for Contract Certification of Shopping Mall): _ _ _ _ _ _ _

Authorized Agent (signature): _ _ _ _ _ _

Tel: _ _ _ _ _ _

Signing place: _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

You can learn about the decoration quotation and the current decoration quotation first, so that you can estimate the decoration material cost and labor cost to a certain extent, and you can also have confidence when you talk about the price with the decoration company. I suggest you apply for free intelligent quotation of Tuba Rabbit, and use the online intelligent quotation gadget of Tuba Rabbit to input basic information such as housing area and apartment type, so that you can quickly generate a decoration quotation in line with our market situation. Come and click to receive it!

Tubatu Online provides you with "every decoration quotation, 1-4 local decoration companies, 3 sets of decoration design schemes" and the decoration pit avoidance strategy for free! Click this link:/Zhu Ye /zxbj-cszy.php? to8to _ from = SEO _ zhidao _ m _ jiare & amp； Wb, you can get it for free ~