Home improvement construction contract agreement

Home improvement can make our house more suitable for our life, but we need to sign a contract. The following is the "Home Improvement Construction Contract Agreement" compiled by me for your reference only. Welcome to read it.

Agreement on home decoration construction contract (I) Party A: _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _

Projects: interior decoration engineering, construction and installation.

Sign this contract on matters related to Party B's contracting Party A's family room decoration project (hereinafter referred to as the project). In order to successfully complete this project, based on the principle of mutual benefit, the rights and obligations of both parties are specified as follows, and both parties shall abide by them.

Article 1: Project Overview

1. Project address: Room 60 1, Haishengge, beautiful homeland, Jiahe New City, No.28 Airport Road, Foshan City.

2. Construction content: See Appendix (I) Quotation Budget of Decoration Project and Appendix (II) Design Drawings of Decoration Project for details.

3. Entrusting method: Party B is responsible for design, construction, installation, contracting and materials (some materials are purchased by Party A).

4. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Total days of the project: _ _ _ _ _ _ _

Article 2: Project Price

1. The total project budget cost (in words) is RMB 45,395.80 Yuan only. For details, please refer to Appendix (I) Quotation Budget Table for Decoration Engineering.

2, the increase or decrease of the price of quantities, according to the actual increase or decrease of quantities. New projects need to be designed and quoted first, which shall be subject to the quotation budget table of decoration engineering in Annex (I) of this contract.

3. According to Appendix (i) of this contract, if no new projects are added, the project price at the time of settlement shall not exceed 2% of the budgeted project price.

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties. For details, please refer to the column of "Material and Technological Requirements" in Appendix (I) Quotation Budget Table for Decoration Engineering.

2. Engineering construction standards: Party B shall carry out the construction in strict accordance with the engineering design drawings and annex (III) decoration engineering construction and acceptance standards, and make records of various quality inspections.

3. In the process of construction, if Party A has special construction projects or special quality requirements, both parties shall sign a supplementary contract for the increased cost. Based on Appendix (I) of the Contract, the quotation budget table of decoration engineering.

4. The quality of materials, equipment and other products purchased by Party A shall be borne by Party A; Party B shall be responsible for the quality of the project.

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. For details, please refer to Appendix (I) Quotation Budget Table for Decoration Engineering. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall be prohibited from being used. If it has been used, Party B must correct it and rework it, with the same construction period, and Party B shall be responsible for the losses caused to the project.

3. The materials provided by Party B must be accepted by Party A before construction. Party B shall ensure that the materials provided are well packed and unopened before Party A's acceptance, and within the product calibration warranty period. If it is found that the materials provided by Party B are fake or inferior, or do not conform to the brand, model and specification indicated in Annex (I) of this contract, it can be regarded as a breach of contract.

3. For the materials and equipment that Party A is responsible for purchasing and supplying, see Appendix (IV) of this contract for the list of decorative materials provided by Party A. The decorative materials should be qualified products that meet the design requirements and be supplied to the site on time. Delayed arrival will postpone the construction period. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5: Method of Payment

1. Three days before the project starts, Party A shall pay% of the total contract price to Party B, that is, RMB _ _ _ _ _ _ _ _.

2. Party A shall pay _ _ _% of the total contract price to Party B within _ _ _ _ days after the three working procedures of mud, water and electricity are basically completed, carpentry is started, and the materials are accepted in the site, that is, RMB _ _ _ _ yuan only;

3. Party A shall pay Party B _ _ _% of the total contract price, that is, RMB Yuan only, within three days after the timber production and painting are basically completed and the fan ash materials are transported to the site and passed the inspection;

4. Party A shall pay Party B (_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Balance of RMB _ _ _ _ _ _ _ _ _

6. If Party A adds projects and settlement projects according to the actual situation, according to the unit price signed by Party A and the quantity determined by both parties in Annex (I) of this contract, after deducting the quality deposit, the accurate amount shall be calculated and paid to Party B according to the above proportion;

7. If Party A reduces the number of projects, it will deduct the relevant amount from the contract amount and pay the project payment according to the adjusted amount. If Party A has paid in advance, the excess will be deducted from the next project payment;

8. Party A's project payment must be paid to the payee designated or entrusted by Party B, and can only be paid after receiving the special financial receipt from Party B, otherwise Party A will bear the responsibility. ..

9. Party A pays off the project payment after deducting the quality deposit (subject to the financial receipt bill issued by Party B), and Party B handles the handover with Party A and issues a decoration project warranty card;

10. Party A's failure to pay on time (including increasing the project payment) is a breach of contract, and Party B has the right to stop the construction, and Party A shall be responsible for the impact. If the project price is not settled after acceptance, it shall not be delivered for use. If Party A uses it without authorization before settlement, it shall be deemed that Party A has passed the acceptance and agreed to settle with Party B to pay off the balance.

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party A shall pay a penalty of 1‰ of the total contract amount every day until the total contract amount is deducted. If the completion is delayed due to Party A's reasons, Party B shall be paid 1‰ of the labor cost in the decoration project price for each day of delay until the total contract amount is deducted.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, the cost of rework shall be borne by Party A; In case of quality accidents caused by Party B's construction, the cost of rework shall be borne by Party B, and the construction period shall remain unchanged.

3. During the construction, due to the quality problems of the project, both parties disagree, resulting in the suspension of work, failure to act as punishment for delaying the work or the construction period. Both parties should take the initiative to ask the relevant departments to mediate or the arbitration department to coordinate and deal with the dispute as soon as possible, so as to continue the construction.

4. In the process of construction, if rework is required due to Party A's reasons, or the construction period is delayed due to Party A's change of construction contents, a visa is required, and Party A shall bear all the construction costs; If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged. If the scheme changes due to Party B's design mistakes, Party B shall bear the cost of the built part.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7: Project Acceptance

1. See Annex (III) Decoration Engineering Construction and Acceptance Criteria for the acceptance criteria of engineering quality. Party B shall organize Party A to carry out the completion acceptance after the project is completed, except that the concealed works need to be accepted by sections. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A of the process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project.

4. If any items that do not meet the acceptance requirements are found during the acceptance, the construction party shall make rectification, and the unqualified items shall be reinspected after rectification until they meet the requirements.

Article 8: Other matters

(1) Party A

1. The house floor plan and water, electricity and gas circuit diagram approved by the property management department must be provided, otherwise Party A shall provide the house floor plan and water, electricity and gas circuit diagram and make on-site disclosure to Party B. ..

2. If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses.

3. Party A has the right to ask Party B to unconditionally replace the construction personnel and Party B's on-site representatives.

(II) Party B

1, should take the initiative to show business license, membership card or construction qualification; If it is a subordinate branch, it must also have a certificate issued by the superior company; The handling salesman must have a certificate of entrustment from the legal representative.

2. Appoint (name) _ _ _ _ _ _ _ as the on-site representative of Party B, be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction tasks with good quality and quantity on time.

3, responsible for the safety of the construction site, do fire prevention, show certificates, civilized construction, to prevent accidents such as pipeline blockage, water leakage, power failure, damage to goods caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible. During the construction period, the indoor load-bearing structure shall not be altered or destroyed. Party B shall take full responsibility for any damage to the load-bearing structure.

4. The electrician appointed by Party B to install the hydropower reconstruction project must show the electrician qualification certificate.

5. Strictly perform the contract and implement the credit period. If the completion is delayed, such as divestiture, slowdown or excuses to induce Party A to advance funds, it will be treated as breach of contract after investigation.

6. Responsible for the warranty within the scope of decoration construction. The warranty period is _ _ _ _ months from the date of project completion and acceptance by Party A. ..

Article 9: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 10: dispute settlement

1. In case of any dispute during the performance of this contract, both parties shall settle it through negotiation without affecting the project progress. Or complain to the Jiezhuang Professional Committee of the Interior Decoration Industry Association of this Municipality and ask for a solution.

2. If both parties are unwilling to settle the dispute through negotiation or mediation, or negotiation or mediation fails, they may apply to the Arbitration Commission for arbitration or court judgment according to this contract.

Article 11: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 12: Contract comes into effect

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. The supplementary contract has the same legal effect as this contract.

3. This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy.

Party A (signature): _ _ _ _ Party B (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Agreement on home decoration construction contract (II) Party A: _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _

In accordance with People's Republic of China (PRC) Contract Law, People's Republic of China (PRC) Construction Law, People's Republic of China (PRC) Consumer Protection Law and other relevant laws and regulations, and following the principles of fairness, honesty and credibility, both parties have reached an agreement on matters related to this decoration project through consultation.

I. Overview of the Project

Decoration project construction site: _ _ _ _ _ _ _

Construction content: _ _ _ _ _ _ _

Mode of contract: _ _ _ _ _ _ _

The total term of this contract is _ _ _ _ _ _ _ _ days, and it shall come into effect on _ _ _ _ _ _ _ _ _ _.

Total Contract Price (amount in words): _ _ _ _ _ _

In which: labor cost is RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (See Annex I)

Second, the work of both parties

1. Party A's work

1. 1 Before the commencement of construction, Party A shall provide Party B with the decoration scheme and instructions on practices, and make on-site disclosure. Empty the house and remove obstacles that affect the construction. Take protective measures for the furniture and furnishings stranded in the house that can only be partially vacated, and Party B shall confirm in writing. ..

1.2 handle all kinds of application and approval procedures involved in the construction of this project, coordinate neighborhood relations, and ensure the construction time of Party B. ..

1.3 Provide Party B with water, electricity, gas and other equipment needed for the construction, and explain the matters needing attention in use. Coordinate the garbage cleaning work and bear the corresponding expenses.

2. Party B's work

2. 1 According to Party A's intention and requirements, provide Party A with construction drawings and practice instructions, make on-site disclosure, and submit them to Party A for written confirmation.

2.2 Party B appoints _ _ _ _ _ _ _ (name) as Party B's on-site representative to be responsible for the performance of this contract. Organize the construction as required, and solve all matters that Party B is responsible for.

2.3 Without the consent of Party A and the approval of the local housing management or property management department, the original building structure and various equipment and pipelines shall not be dismantled at will.

2.4 Abide by the national or local government and relevant departments' regulations on construction site management, and strictly implement the construction specifications, safety operation procedures, fire prevention and environmental protection regulations.

2.5 Before the completion of the project is handed over to Party A, be responsible for protecting all facilities and finished products at the site.

Third, the construction cycle

1. delay

1. 1 If the construction period is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party A:

(1) Party A cannot provide the starting conditions as agreed.

(2) Design change and engineering quantity change.

(3) Other circumstances in which Party A agrees to postpone the construction period accordingly.

1.2 In case of shutdown due to Party A's reasons, Party A shall compensate Party B for the losses caused by shutdown or idle equipment, and Party A shall pay Party B _ _ _ _ _ _ _ _ _ yuan for each day of shutdown.

1.3 If the completion is delayed due to Party B's reasons, Party B shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Fourth, the project price payment

Three days before the commencement date, Party A shall pay _ _ _ _ _ _ _% of the total price, namely _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Over half of the construction period, Party A shall pay _ _ _ _ _ _ _% of the total price, that is, _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Within three days after the acceptance, the remaining part of the total price paid by Party A is RMB _ _ _ _ _ _.

Verb (abbreviation of verb) material supply

1. Materials provided by Party A The materials and equipment provided by Party A shall have a list of materials and equipment (see Table 2). If there is any quality problem or specification difference in the materials and equipment supplied by Party A, Party B shall promptly raise it with Party A, and if Party A still agrees to use it, Party A shall bear the losses caused thereby. The materials and equipment supplied by Party A shall be kept by Party B within _ _ _ _ _ _ days after they arrive at the site. Party B shall be responsible for the losses caused by improper storage. Without the consent of Party A, Party B shall not use the materials and equipment supplied by Party A for other purposes, otherwise, Party B shall compensate Party A at twice the corresponding price and bear the losses caused thereby.

2. Materials purchased by Party B For the materials and equipment purchased by Party B, there must be a list of materials and equipment indicating the brand, specification, grade, quantity, unit price and total price (see Annex 3), which shall be signed by both parties. If the materials and equipment purchased by Party B are inconsistent with the list of materials and equipment, they shall not be used. If Party B uses it without the consent of Party A, the losses caused thereby shall be borne by Party B. ..

Six, engineering change

In the process of engineering construction, when Party A puts forward design modification opinions and adds or subtracts engineering projects, it must contact with Party B's representative in advance and sign a change order (see Annex 4) before starting engineering construction. Party A shall bear all the consequences caused by privately negotiating with the construction personnel to change the construction content. Where losses are caused to Party B, Party A shall be responsible for compensation.

VII. Quality and Acceptance

1. Engineering quality

1. 1 The project is based on construction drawings, practice descriptions and design changes, and the quality evaluation standard is the quality inspection evaluation standard of Tianjin architectural decoration project.

1.2 Party B shall seriously carry out the construction according to the agreed technical quality standards and design requirements, and accept the inspection of Party A at any time to provide convenient conditions for the inspection. If the quality of the project fails to meet the agreed conditions, Party B shall rework and modify it according to Party A's requirements, and bear the expenses for rework and modification due to its own reasons.

2. Completion acceptance and warranty

2. 1 After the project is completed, Party B shall submit the project acceptance form to Party A (see Annex 5). Party A shall accept the project acceptance form within seven days after receiving it, and sign the acceptance form. If Party A fails to make acceptance on time without justifiable reasons, it will be deemed as completion acceptance confirmation if it exceeds seven days.

2.2 The concealed works and intermediate acceptance parts agreed by both parties are _ _ _ _ _ _ _.

2.3 The term of the warranty items agreed by both parties is _ _ _ _ _ _ _ _. (If paragraphs 2.2 and 2.3 of this article are too much, you can add another page. )

Eight. Safety and fire prevention

1. The construction drawings or descriptions provided by Party A or Party B shall comply with the Fire Protection Law of People's Republic of China (PRC) and relevant fire protection design specifications.

2. In case of any safety or fire accident caused by Party B's violation of relevant safety operation regulations during the construction and production, Party B shall bear all economic losses.

Nine. responsibility for breach of contract

Party A and Party B shall strictly perform all the terms stipulated in this contract. If Party A fails to give necessary instructions and confirmation in time, fails to perform its obligations as agreed in this contract, or has other behaviors that make this contract impossible to perform, Party A shall be liable for breach of contract. If Party B fails to complete the project within the contract period, the construction quality fails to meet the standard requirements, or there are other behaviors that make the contract impossible to perform, Party B shall bear the liability for breach of contract. Party A and Party B shall pay liquidated damages to each other at _ _ _ _% of the total contract price. If the liquidated damages are insufficient to make up for the losses, the parties may ask the other party to increase them.

X. Contract dispute settlement methods

Both parties agree that disputes arising from the performance of this contract shall be settled through negotiation or mediation by both parties. If negotiation or mediation fails, both parties can choose the following option _ _ _ _ _ _ _ _ _ _:

1. Arbitration by _ _ _ _ _ _ Arbitration Commission;

2. Bring a lawsuit to the people's court.

XI。 Other agreements _ _ _ _ _ _ _

Twelve. Matters not covered in this contract

Supplementary provisions are made by both parties through consultation, and have the same legal effect as this contract.

Thirteen. The documents constituting this contract include

1. Terms and schedules of this contract;

2. Construction drawings and practice notes;

3. Other written agreements between the two parties on the negotiation of this project;

4. Supplementary provisions.

Fourteen others

1. This contract is made in duplicate, each party holds one copy, which has the same legal effect. Both parties agree that the number of copies of the contract can be determined as needed, and it will take effect after both parties agree (signature, authentication and notarization).

2. When Party B receives the final payment of the decoration project price, this contract is terminated.

Party A (signature): _ _ _ _ Party B (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Agreement on home decoration construction contract (III) Party A: _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _

Party A entrusts Party B to carry out the renovation project of xx suite, and through friendly negotiation, both parties hereby sign the following contract terms:

I. Project and Content:

Laying floors, oil walls, making cabinets and installing new lines. See the construction instructions and project budget provided by Party B and approved by Party A for details. ..

Second, the way of contracting: _ _ _ _ _ _.

Three. Project cost (RMB)

RMB _ _ _ _ _

Fourth, the project payment settlement method

Within _ _ _ days after Party B enters the site, Party A shall pay Party B _ _ _ Yuan (RMB _ _ _) in advance of the project price, and the balance shall be paid within one month after the project is completed and accepted.

Party B must carry out the construction on time according to the quality and quantity, and abide by the relevant state regulations. If the construction project is unqualified due to the quality of materials or the failure to construct according to the drawings, Party B shall rework it by itself, and all the materials and labor costs used for rework shall be solved by Party B. If Party A proposes to change the ongoing or completed project during the construction period, all the materials and labor costs used for the change shall be borne by Party A. ..

If Party A proposes to add construction items or change the materials used during the construction period, it must be signed and approved by the person in charge or technical personnel of Party A. ..

Verb (abbreviation for verb) delivery and use date

The total construction period is _ _ _ _ days, that is, from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. In case of overdue, Party B shall pay compensation to Party A at the rate of _ _ _ _ of the total daily expenses. If Party A prevents Party B from normal construction for any reason, the delay date will be postponed.

Other conventions of intransitive verbs: 1, _ _ _ _ _ _ _ _ _ _

This contract has the same legal effect as the construction instructions and project budget provided by Party B to Party A for approval.

This contract is made in duplicate, one for Party A, one for Party B and one for each party.

This contract shall come into effect after being signed by both parties.

Party A (signature): _ _ _ _ Party B (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.