Water and electricity installation contract for house decoration

With the popularization of legal knowledge, contracts are indispensable on many occasions. When an agreement is reached, you can enjoy certain freedom to conclude a contract. So what problems should we pay attention to when drawing up the contract? The following is a sample of the water and electricity installation contract for house decoration that I compiled for you. Welcome to reading. I hope you will like it.

Customer (Party A):

Organizer (Party B):

Party A entrusts Party B to install and construct the residential hydropower project, and both parties voluntarily sign this contract through consultation according to national laws and regulations.

Article 1 Overview of the Project

1. Project: installation of water and electricity for residential buildings.

2. Location: Yijing Garden Building, * * Avenue, Du Dong, with a building area of square meters.

3. Construction and installation contents: wall demolition, drilling and slotting (see Annex 1 Basic Engineering Project), installation of strong and weak wires and switch sockets, installation of hot and cold water pipes and sewers, and installation of lamps and faucets.

4. Total price; The project cost is RMB. The increase or decrease of the project will take effect after the two parties agree on the price, and the installation project and expenses will increase or decrease accordingly.

5. Duration: This project will take days. For this project, Party B shall complete all project installation works on time, with good quality and quantity.

Article 2 Work of Party A

1. There are no obstacles affecting hydropower installation and construction at the project site.

2. Provide water and electricity interfaces and main materials required by Party B for construction.

3. Provide the house layout (Annex 2), switch socket layout (Annex 3), water appliance layout (Annex 4) and lamps layout (Annex 5) approved by the property management department, and make on-site disclosure to Party B. ..

4. If it is really necessary to dismantle or change the original building structure or equipment and lines, it shall go through the formalities with the property management department and bear the relevant expenses. Assist Party B to handle construction application, approval, registration and other procedures.

5. Supervise and inspect the construction quality and progress of the project, and have the right to require Party B to rectify the unqualified project to meet the design and specification requirements.

6. If you need to use public parts temporarily during construction, you should greet the neighbors and handle the neighborhood relationship.

Article 3 Party B's Work

1. Confirm and sign for Party A's mobilization materials (sign Annex 6), use materials reasonably and ensure their safety.

2. Strictly implement the construction technical specifications, carry out the construction according to the contract specifications, complete the project on time with good quality and quantity, and solve all matters that Party B is responsible for.

3, civilized construction, to prevent accidents caused by construction, such as pipeline blockage, water leakage, short circuit and power failure, damage to goods, etc., once an accident occurs, it must be repaired or compensated as soon as possible.

4, strictly implement the safety operation procedures and fire safety regulations, responsible for the safety of the construction site, fight fire, absolutely guarantee the fire safety of the construction site. Be responsible for the casualties in the process of construction and installation, and bear the losses caused to Party A therefrom.

5. Carry out construction in strict accordance with the bill of quantities and drawings approved by this contract, record the trend of strong and weak current lines, and provide formal drawings of strong and weak current lines.

6. Be responsible for protecting the materials, facilities and building products on site before the project is handed over to Party A upon completion.

Article 4 Quality Requirements

1, engineering construction standard, both parties agree to refer to the national standard GB50327-20xx Code for Construction of Residential Decoration.

2. The varieties, specifications and names of the main materials used in the project shall be recognized by both parties. For details, please refer to Appendix 6 Budget Table of Decoration Engineering Materials.

3. The quality of materials, equipment and products purchased by Party A shall be borne by Party A, the construction quality shall be borne by Party B, and the quality of materials, equipment and products purchased by Party B shall be borne by Party B. ..

4. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

5. For other quality requirements and standards, see Appendix 7 "Code for Electrician Construction" and Appendix 8 "Code for Hydraulic Construction".

Article 5 Material supply

1. The materials provided by Party A shall be used in the renovation project stipulated in this contract, and shall not be used for other purposes without Party A's consent. If Party B misappropriates them, it shall compensate Party A at twice the price of the materials.

2. The materials and equipment provided by Party B shall meet the quality requirements. The use of different specifications is prohibited, and all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing shall be qualified products that meet the design requirements, and shall be supplied on time.

4. Party B shall bear the responsibility of double indemnity due to the improper storage of the materials provided by Party A. ..

Article 6 Payment Terms

1. Party B shall carry out the construction according to the time agreed in this contract, and complete the engineering projects except the installation of lamps and lanterns on time and in quantity. Party A shall pay 60% of the contract price in advance. After the installation and debugging of lamps and lanterns is completed, 30% of the project cost will be paid after acceptance and confirmation by both parties, and the remaining 10% will be the quality guarantee.

2. During the quality guarantee period stipulated in this contract, if there is no quality problem, Party A shall pay it in one lump sum.

Article 7 Construction period

1. If the completion is delayed due to Party B's reasons, it shall be handled according to the liability clause of this contract for breach of contract; If the construction period is delayed due to Party A's reasons, the completion period will be postponed.

2. If the unqualified materials and equipment provided by Party A affect the project quality and construction period, Party A shall bear the cost of rework. In case of quality accidents caused by Party B's construction, the cost of rework shall be borne by Party B, and the construction period shall remain unchanged.

3. In the process of construction, if the construction period is delayed due to the rework of Party B's construction quality problems, it shall be handled according to the liability clause of this contract for breach of contract.

4. In the process of construction, if it is necessary to rework due to Party A's reasons, or the construction period is delayed due to Party A's change of construction contents, it shall be signed and recognized, and Party A shall bear all the construction costs and postpone the construction period.

Article 8 Project acceptance

1. The project acceptance of this contract shall be carried out according to the standards of the project acceptance sheet (see Annex 8). The project acceptance agreed in this contract is divided into two stages. After the completion of all projects except the installation of lamps, Party B shall organize Party A to conduct pre-acceptance. After the project quality is qualified, both parties sign Annex 8 after confirmation, and then go through the project handover and pre-settlement procedures.

2. After the lamps are installed and turned on, both parties shall conduct overall acceptance, sign Annex 8 after passing the test, and then go through the settlement and payment procedures.

3. If Party A cannot come for acceptance within the time specified by Party B, it shall notify Party B in time. If both parties agree, the acceptance date can be determined separately, but the completion date will be postponed according to the number of days delayed by Party A, so Party A shall bear the extra expenses of Party B. ..

Article 9 Quality Assurance

1. Under normal use conditions, the warranty period of decoration engineering quality is 5 years. The warranty period is calculated from the date of acceptance of this contract project (see Annex 8 "Acceptance Sheet for Hydropower Installation").

2. During the quality guarantee period, Party B shall provide free maintenance service. For maintenance items under normal use conditions, Party B is exempt from maintenance fees and material fees. For the maintenance items beyond the warranty period and abnormal use, Party B's maintenance fees and material fees shall be charged at the cost price.

3. During the quality guarantee period, if there are quality problems in Party B's project and Party A's problems are reflected, Party B will come to repair it, and Party A will not deduct the quality deposit; If Party B comes to repair two days late every day after the problem of Party A is reported, Party A will deduct the quality deposit at the rate of 10%. Even if the warranty money is deducted, Party B's responsibility for free maintenance cannot be excluded.

Article 10 Liability for breach of contract

1. After the contract comes into effect, the party who cancels the contract without authorization during the performance of the contract shall pay 50% of the total contract price to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, compensation shall be made according to the actual loss amount.

2. If the construction period is delayed, 2% of the total contract price will be deducted for each day of delay until 50% of the total contract price.

3. Quality problems in delivery and acceptance must be rectified. Party A has the right to refuse to accept and sign the installation quality problems that have not been rectified or are still unqualified. The time thus delayed shall be regarded as the delay of the construction period, and the provisions in Article 10.2 of this contract shall be implemented.

4. If the damage caused to Party A by uncivilized construction is not repaired or compensated, Party A will deduct it when paying.

Article 1 1 Dispute settlement

1. In case of any dispute during the performance of this contract, both parties shall settle it through negotiation without affecting the project progress.

2. If both parties are unwilling to settle the dispute through negotiation, or negotiation fails, they can bring a lawsuit to the court.

Article 12 Modification or termination of a contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after consultation between both parties.

2. During the performance of this contract, if either party proposes to terminate the contract for special reasons, it shall do so in writing to the other party. After both parties agree to go through liquidation procedures and conclude a termination agreement, this contract shall be deemed to be terminated.

Article 13 the contract comes into effect

1. This contract and its annexes shall come into force after being sealed or signed by both parties.

2. The supplementary contract has the same legal effect as this contract. If there is any contradiction between the supplementary contract terms and the original contract terms, the original contract terms shall prevail.

3. This contract and its annexes are in duplicate, with each party holding one copy.

Party A (Owner):

Telephone:

ID number:

Address:

Date of signing:

Party B (seal):

Telephone:

ID number:

Address: