Maintenance contract

With the popularization of legal knowledge, more and more scenes and occasions need to use contracts, and signing contracts is also one of the best ways to avoid disputes. So how to write the relevant contract? The following are five maintenance contract samples I collected for you. Welcome to reading. I hope you will like it.

Maintenance Contract 1 Party A: (hereinafter referred to as Party A)

Party B: (hereinafter referred to as Party B)

In accordance with the Contract Law of People's Republic of China (PRC), Regulations on Quality Management of Construction Projects and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reached an agreement on house maintenance and concluded this contract.

I. Overview of the Project

1, project name:

2. Project location:

3, the scope of the project:

4. Contract duration: commencement date, completion date and completion date, including legal holidays, cross-construction and waiting time for coordinated construction. If the weather or other factors affect the construction, Party B may extend the construction period appropriately after Party A confirms and agrees.

Second, the engineering service form

Contract work, contract materials, contract term and contract quality.

Third, the settlement method

Party A, Party B and the supervisor will sign the parts and quantity to be repaired in the form of technical contact sheet, and the quantity shall be subject to the contents of the technical contact sheet signed by Party A, Party B and the supervisor to determine the total project cost.

Party A and Party B attach a technical contact list of quantities signed and sealed by settlement book, Party A, Party B and the supervisor as an annex to the contract.

Fourth, the total project price

It is tentatively set at RMB 1 ten thousand yuan (subject to the final settlement amount confirmed by both parties).

V. Supervision, Inspection and Acceptance of Project Quality

Party B shall carry out the construction in strict accordance with national, industry standards, enterprise norms and this contract, and accept the inspection of Party A at any time to provide convenient conditions for inspection and inspection. Party B shall promptly correct the problems raised by Party A.. After the maintenance project is completed, Party A and Party B and the owner of the house to be repaired shall jointly accept the project. Acceptance shall be subject to the construction record signed by the three parties. When the project is completed and accepted, Party B shall be responsible for continuing the maintenance according to Party A's requirements and bear the responsibility for overdue.

Six, the project payment

After the project is completed and accepted, 97% of the total project amount will be paid, and the remaining 3% will be used as quality deposit. After the expiration of the warranty period, Party B shall pay in full without any quality problems.

Seven. guarantee

1. After Party B's maintenance project is completed, Party B shall undertake the warranty responsibility for all projects. The warranty period is years, counting from the date when the project is completed, accepted and delivered to Party A. ..

2. The project warranty payment is 10% of the project payment. Within ten days after the expiration of the warranty period, Party A will refund the remaining warranty payment without interest.

3. During the warranty period, if there is any quality problem in the maintenance project, Party B shall guarantee to send someone to inspect and repair it within 2 hours after receiving Party A's notice, and carry out the maintenance within a reasonable period determined by Party A. If Party B fails to send someone to repair it within the time limit or the problem still occurs after the second maintenance, Party A has the right to entrust others to repair it, and all expenses and losses arising therefrom shall be borne by Party B. ..

4. In the process of construction, Party B must operate in strict accordance with the requirements of construction technology. If the repaired project has mildew and leakage again, Party B shall complete the repair within two days after receiving the notice from Party A, and bear all the impacts and economic compensation consequences caused by the recurrence of mildew and leakage. Such as home decoration, compensation for loss of goods, etc.

5. During the warranty period, Party B shall pay a regular return visit to the construction project, make a record of the return visit, and solve the quality hidden trouble in time. Party B now keeps the written address and telephone number of the person in charge of warranty so as to inform Party B to carry out maintenance.

Eight. responsibility for breach of contract

65438+

2. If Party B stops work for more than two days (including two days) without Party A's permission, Party A has the right to terminate the contract, and Party B shall leave unconditionally within two days, and both parties shall settle accounts after Party B leaves.

3. If Party B violates any other obligations under this contract and is notified by Party A to make corrections within a time limit, Party A has the right to terminate this contract, and Party B shall bear all losses caused thereby.

4. Party A or the owner has the right to claim compensation from Party B within two years from the date of knowing the quality problems caused by Party B's intentional or negligent failure to meet the technical specifications and environmental protection requirements or inconsistent with the contract, regardless of whether the project has passed the acceptance, delivery and exceeded the warranty period.

5. Without the written consent of Party A, Party B shall not transfer the rights and obligations under this contract to others, otherwise, Party A has the right to terminate this contract.

6. Before the engineering quality problems of the parts repaired by Party B are solved, Party A has the right to refuse to pay any money.

7. If the contract is terminated due to Party B's reasons, Party B shall bear the penalty of 65,438+00% of the provisional contract price. If the liquidated damages are insufficient to make up for the losses of Party A (including the compensation and liquidated damages paid by Party A to the third party), Party B shall also compensate the losses of Party A.. ..

Nine, safety construction

Party B shall take strict construction safety measures in accordance with relevant regulations, and bear the responsibility for accidents caused by its own ineffective safety measures and the expenses and consequences arising therefrom. Party B shall be responsible for the personal safety of its construction personnel. Party B shall purchase personal accident insurance and all insurance related to the project construction for the construction personnel. In case of safety accidents or other accidents during construction, Party B shall bear the responsibilities.

X. Construction responsibility

1. Party A shall provide Party B with water, electricity and other conveniences during the construction period, and be responsible for coordinating with residents and subordinate departments. Party B shall carry out the construction according to the requirements of construction technology.

2. During the construction period, Party B shall protect the square brick footpaths, flowers and trees in the residential area from damage. When maintaining tenants' houses, we must strictly abide by the property rules and regulations. If the tenant complains or Party B damages the goods, Party A has the right to deduct it from the project payment payable to Party B. ..

3. Party B shall be appointed as the site representative of this project, organize the construction according to the requirements of this contract, and complete the contents stipulated in this contract on time with good quality and quantity. And be responsible for communication and contact with Party A. Any promise, guarantee, letter, signature and confirmation made by the person in charge to Party A on this project shall be regarded as the behavior of Party B, and Party B shall bear the responsibility.

4. Party B shall carry out the construction in strict accordance with the construction specifications and quality standards confirmed by Party A, and make records of various quality inspections. Strictly implement construction specifications, safety operation procedures, fire safety regulations and environmental protection regulations to ensure that the project meets the requirements of the contract and Party A..

5. Before the project is completed and accepted, Party B shall be responsible for protecting all the facilities, finished products and semi-finished products on site and bear the expenses.

6. During the maintenance period, Party B must concentrate the garbage in the place designated by Party A every day, keep the construction site clean and remove it within the time required by Party A, otherwise Party A has the right to entrust others to clean it up, and the expenses incurred shall be deducted from the project payment payable by Party A to Party B. ..

7. Accept the quality inspection, inspection and supervision of Party A's representative and its appointed personnel at any time during the construction process, provide convenient conditions for inspection, inspection and supervision, rework and modify according to the requirements of Party A's representative and its appointed personnel, and bear the cost of rework and modification caused by its own reasons.

8. All the examination and approval procedures required for maintenance and construction (referring to the projects that need to be submitted for approval according to relevant laws and regulations) shall be handled by Party B, and all the responsibilities shall be borne by Party B. ..

9. The maintenance works agreed in this contract must be completed by Party B. Without Party A's consent, Party B shall not subcontract or hand over the works to any other third party, otherwise, Party A has the right to terminate this contract.

10. Party B shall keep good communication with the maintenance owner during the maintenance to avoid disputes. If there is a dispute with the maintenance owner due to Party B, which causes losses to Party A, Party B shall bear the responsibility, and Party A shall have the right to deduct it from the project payment payable to Party B, and Party A shall have the right to recover the insufficient amount from Party B. ..

1 1. During the maintenance and construction, Party B shall take good care of the property and articles of Party A and the owner, and shall not damage the buildings and related facilities and equipment in the community. In the maintenance project, Party B shall compensate Party A or a third party for personal or property losses caused by Party B. Party A has the right to deduct from the project payment payable to Party B, and Party A, the owner or relevant obligee has the right to recover the insufficient part from Party B. ..

XI。 others

1. If this project involves the confirmation of project price, the relevant confirmation shall be confirmed by Party A's representative and Party A's budget department and stamped with Party A's official seal. Other people (except the legal representative) sign or lack any of the above confirmations, or fail to affix Party A's official seal (such as visa stamp), Party A will not recognize it.

2. If the confirmation of engineering quantity is involved, it must be countersigned by the representative of Party A and the project manager * * * and stamped with the special visa seal of Party A, both of which are indispensable.

3. The technical contact list of quantities signed by settlement book, Party A, Party B and the supervisor as an annex to this contract has the same legal effect as this contract.

4. This contract is made in sextuplicate, with Party A holding four copies and Party B holding two copies. This contract shall come into effect as of the date of signature and seal by both parties.

5. Matters not covered in this contract or disputes arising from the execution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, it shall be settled by the people's court where the maintenance project is located.

Party A: Party B:

(Seal) (Seal)

Legal representative:

(signature) (signature)

Handler: Handler:

(signature) (signature)

Date of signature: year month day.

Maintenance Contract 2 Party A:

Party B:

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, both parties to the contract reach an agreement on the pipeline maintenance project through consultation on the basis of voluntariness and equality, and sign this contract.

1. Project name: public pipeline valves in residential quarters.

2. Project location: Shanshui Qingcheng Community, No.3 Biao North Street/KLOC-0, Pingshan County.

3. Contracting method: Party B contracts the project and materials.

Four. Project contract cost: the tentative cost is RMB eight thousand three hundred and sixty-six Yuan only, and the final total cost is subject to the final audit.

Verb (abbreviation of verb) construction period: year month day to year month day. The construction period is days; For each day of delay, the construction unit has the right to deduct the project payment from the construction unit according to 3‰ of the total contract price. If the construction period cannot be completed on schedule due to special circumstances, the construction unit shall submit a written notice to the construction unit, and the two parties shall negotiate an appropriate extension.

Six, project quality and acceptance:

The construction unit shall, according to the requirements of the relevant technical data provided by the construction unit, carry out the construction in strict accordance with the relevant technical specifications and standards promulgated by the state and the plans approved by the relevant departments to ensure the construction quality. During the construction period, the construction unit shall appoint on-site supervisors to supervise the construction quality, and negotiate with the construction unit to solve the problems in the construction process and the quality acceptance visa of concealed works. After the project is completed, full-time inspectors from the quality inspection department are invited to participate in the acceptance together with Party A and Party B, and Party B is required to provide inspection reports, certificates and other relevant certificates of materials used in this project during the acceptance.

Seven. Responsibilities of both parties:

Party A:

1. Ensure the construction conditions of "three links" (water, electricity and roads). Provide relevant drawings and technical data, and send on-site supervisors to supervise the project quality progress.

2. Have the responsibility to supervise the transfer of all project funds to the account designated by the construction unit.

3. Handle all supervision and construction procedures except the quality and technical supervision department.

Party B:

1. Check and supervise the safety of the construction environment, and take timely measures to correct potential safety hazards.

2. Party B's technicians should hold relevant certificates, study drawings carefully, arrange construction progress, ensure quality and safety, fill in construction records every day, clean up the garbage on site every day, and thoroughly clean up the site sanitation before completion.

3. In case of special circumstances, explain the situation to Party A in time to avoid unnecessary losses.

4. Ensure the construction safety of the construction site, and all safety accidents occurred by Party B during the construction period shall be borne by Party B. ..

8. Quality warranty: the warranty period is two years. During the warranty period, if the components (including equipment and pipelines) repaired, modified or installed by Party B have problems in operation (causing direct economic losses), Party B shall compensate Party A for all losses caused thereby. ) Party B shall repair, replace (or install separately) for free. The accident caused by improper operation shall be borne by Party A..

Nine. Liability for breach of contract:

This contract shall come into effect after being sealed and signed by both parties. Shall not unilaterally breach or terminate the contract; In case of unilateral breach or cancellation, 15% of the total contract cost shall be used as liquidated damages to compensate the other party.

X. Ways to settle contract disputes: In case of disputes arising from the performance of this contract, both parties shall settle them through consultation; If negotiation fails, both parties agree to submit it to Yan 'an Arbitration Commission for arbitration.

XI。 The original of this contract is in triplicate, with each party holding one copy.

Party A (signature and seal):

Owners Committee (signature and seal):

Signature of Housing Authority: Party B (signature and seal):

Date of signature: year month day.

Maintenance Contract 3 Party A:

Party B:

According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B, on the basis of equality, voluntariness and consensus, reach the following agreement on Party B's maintenance of air conditioners from Party A:

1. Party B is responsible for repairing 30 air conditioners (hanging up) in Party A's office.

Two. The maintenance contents of Party B are:

1, clean the air conditioner;

2, adding refrigeration additives;

3. Configure 10 air conditioner remote controller;

4. Other maintenance contents to ensure the normal operation of the air conditioner.

3. Party B guarantees that all the repaired air conditioners will be delivered to Party A before March 28th, 20xx. If the air conditioner breaks down again within 1 year from the delivery date, Party B shall guarantee it free of charge in time.

4. Party B must ensure that the air conditioner is intact after disassembly, bear the responsibility of stolen air conditioner during maintenance, and ensure that it is installed and fixed after maintenance.

5. Without the consent of Party A, the maintenance work shall not be subcontracted to a third party without authorization, and the air-conditioning components that do not need to be replaced shall not be replaced without authorization. If replacement is really necessary, Party A shall be informed, and the replaced parts shall be consistent with the original parts or match the functional performance of the whole machine.

6. After the air conditioner maintenance is qualified, Party A shall pay the air conditioner maintenance fee to Party B in one lump sum. The expenses are calculated according to the contents of Party B's maintenance work (including tax). These include:

1, air conditioning cleaning and maintenance plus refrigerant 120 yuan/set;

2. Configure universal air conditioner remote controller 30 yuan/piece.

Seven. In case of any dispute during the performance of this contract, both parties shall settle it through consultation; If negotiation fails, either party may bring a lawsuit to the people's court.

Eight. For matters not covered in this contract, both parties shall make supplementary provisions after consultation, and the supplementary provisions shall have the same legal effect as these provisions.

Nine. This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature and seal by both parties.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

Date of signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Maintenance Contract 4 Supplier: Demander:

1. The supplier and the buyer sign this contract on the principle of equality, mutual benefit and consensus, so that * * * can abide by it together.

2. Product name, model, serial number, fault cause, treatment method and charge amount.

Product name, specification, model, serial number, fault reason, treatment method, maintenance fee, parts fee and return freight:

Travel expenses:

On-site service fee:

Total amount of RMB (in words):

Three. Mode and location of maintenance: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Four. Delivery method and location of the repaired equipment: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. After the buyer pays according to this contract, the seller shall carry out maintenance and repair within _ _ _ _ _ _ days, and deliver (deliver) the goods in the manner specified in Article 4.

After the maintenance of the equipment, the supplier shall provide a three-month warranty for the same fault of the equipment.

7. During the execution of the contract, if it cannot be performed or needs to be modified for some reason, it shall be valid only after both parties agree and sign another contract.

Eight. Liability for breach of contract: it shall be implemented in accordance with the Contract Law of People's Republic of China (PRC) and other relevant regulations.

Nine. Ways to resolve contract disputes: Any disputes arising during the execution of this contract shall be settled by both parties through consultation. If negotiation fails, it shall be submitted to the Arbitration Commission for arbitration.

X. If there are matters not covered in the above clauses, they shall be supplemented in written form, and _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

XI。 There are _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Twelve. Other agreed matters: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Name of supplier (seal)

Name of Buyer's Unit (Seal)

Company address: Company address:

Supplier's Representative: Buyer's Representative:

Telephone fax: Telephone fax:

Bank of deposit: Bank of deposit:

Account number: Account number:

Tax registration number: tax registration number:

Date of signing: Date of signing:

Maintenance Contract 5 Client (hereinafter referred to as Party A):

Contractor (hereinafter referred to as Party B):

According to the principles of People's Republic of China (PRC) Contract Law and the specific conditions of this project, the two parties have reached the following agreement.

1 project overview

1. 1 Project name: Jiatianxia Property Maintenance Project.

1.2 Project content: designated maintenance project of Jiatianxia Property.

Article 2 Quality Grade: Qualified

Article 3 Agreement Price and Payment

3. 1 Contract awarding method: Party A contracts out the maintenance works that the developer cannot handle or the works that the property itself cannot handle to Party B..

3.2 Project price:

3.2. 1 The prices of main materials in this project shall be determined by market inquiry or comparison with relevant departments of Party A. ..

3.2.2 Any increase or decrease in quantities other than the drawings of this project shall be approved by Party B together with the representatives of Party A and relevant units and included in the settlement.

3.2.3 Party B guarantees to complete the project within the construction period, and 1‰ of the project price will be deducted for each day overdue.

3.3 Payment method:

3.3. 1 After the project is completed and accepted, Party A shall pay 95% of the project payment to Party B on a monthly basis, and keep 5% as the project warranty fund, which shall be settled in one lump sum after the warranty period expires.

3.3.2 The maintenance cost of this project does not include tax. If an invoice is required, it will be invoiced at the rate of 3.475%.

Article 4 Party A's work and its rights and obligations:

4. 1 Party A will assess the project quality and construction progress as planned, and put forward relevant opinions. Party A also has the right to supervise the project quality and construction progress, and has the right to require Party B to rectify the found problems and unqualified places.

4.2 If Party B fails to make rectification on time or refuses to listen to Party A's opinions, Party A has the right to ask Party B to stop construction or make safety rectification.

Article 5 Party B's work and its rights and obligations:

5. 1 The construction quantity shall be carried out in strict accordance with the contents of the construction drawings and budget, and the quality and quantity must be guaranteed. If the construction is not carried out as required, the corresponding project payment shall be deducted.

5.2 Ensure civilized construction during the construction period, no littering, clean environment around the construction site, clean site after work, clean sanitation and compliance with relevant regulations, and bear losses and fines caused by violation of relevant regulations.

5.3 In the process of construction, Party B must operate in strict accordance with relevant operating procedures and take safety precautions to prevent all accidents. In case of personal injury or death due to violation of operating rules, all consequences shall be borne by Party B. ..

5.4 After receiving Party A's safety rectification notice, Party B shall make rectification in time and notify Party A in writing for rectification inspection. Construction shall be carried out in strict accordance with relevant national safety codes and standards.

Article 6 Quality and Acceptance:

6. 1 The project quality shall meet the national or professional quality inspection and evaluation standards.

6.2 The construction of this project shall be carried out in strict accordance with relevant construction specifications. In case of intentional illegal operation, all consequences shall be borne by Party B. ..

Article 7 Completion acceptance

7. 1 After the completion of the project, both parties shall conduct the completion acceptance together with the user department, and the acceptance shall be subject to the technical plan approval form and the engineering construction and acceptance specifications promulgated by the state.

7.2 When the project is completed and accepted, Party B must clean up the site after the project is completed.

Article 8 Warranty Period

8. 1 warranty content and scope: it shall be implemented in accordance with the current national quality warranty measures for construction projects.

8.2 Warranty period:

8.3 Warranty time: Party B shall send someone to repair it within three days after receiving the maintenance notice from Party A.. If Party A fails to show up for maintenance within three days, Party A will entrust other units or carry out maintenance by itself, and the expenses will be directly deducted from the warranty deposit, and the insufficient part will be borne by Party B.. During the warranty period, Party B shall be timely and earnest, and shall not shirk or argue, otherwise Party A may directly use the warranty money and deposit to repair itself.

Article 9 Effective and Termination of the Agreement

9. 1 Agreement comes into effect: it comes into effect after being signed and sealed by both parties.

9.2 Termination of the Agreement: After the project payment is settled, the Agreement will automatically become invalid.

Article 10 number of agreements

This Agreement is made in * * * copies, one for Party A and one for Party B, and Party A shall send it to relevant departments.

Party A: (Seal) Party B: (Seal)

Person in charge: person in charge:

Handler: Handler:

Date of signing: Date of signing: