Private renovation contract model

Private renovation contract Model (I) Entrusting Party (Party A):

Organizer (Party B):

Engineering project:

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.

Article 1: Project Overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Room specification: room type: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. Construction content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

4. Entrustment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total days of the project: _ _ _ _ _ _

Article 2: Project Price

The project price (in words) is _ _ _ _ _ _ _ _ Yuan (in words).

1, material _ _ _ _ _ _ _ yuan; 2, labor costs _ _ _ _ _ _ _ yuan;

3. The design fee is _ _ _ _ _ _ yuan; 4, the construction freight _ _ _ _ _ _ yuan;

5. The handling fee is _ _ _ _ _ _ _ yuan; 6. The management fee is _ _ _ _ _ _ yuan;

7. Other expenses (please specify the contents) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

4. All materials and equipment purchased by Party A shall be borne by Party A; Party B shall be responsible for the quality of the project.

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5: Method of Payment

1. After the contract is signed, Party A shall pay 100% of the project cost and 50% of the project cost; When the progress of the construction period is over half (year, month and day), Party A will pay 40% of the second project price, and the remaining 65,438+00% will be paid to Party A for settlement after the project is completed and accepted. (Note: Construction costs include labor costs).

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing the construction change form and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to pay the project price in advance within the time limit stipulated in this contract, Party A shall pay 1% of the unpaid project price to Party B for each overdue day.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party B shall pay Party A 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid 1% of the labor cost in the decoration project price as lost time.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. In the process of construction, if work is stopped due to engineering quality problems and disagreement between the two parties, it will not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.

4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7: Project Acceptance

1. Project quality acceptance, except for concealed works, which need to be accepted by sections. After all projects are completed, Party B shall organize Party A to carry out the completion acceptance. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.

Article 8: Other matters

1. Party A's responsibilities

1) The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make on-site disclosure to Party B. ..

2) Secondary decoration project, in which all or part of the house is vacated and obstacles affecting the construction are removed. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

3) If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood.

2. Party B's responsibilities

1) should take the initiative to show business license, membership card or construction qualification; The handling salesman must have a certificate of entrustment from the legal representative.

2) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.

3) Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

4) Strictly perform the contract and implement the credit period. If the completion is delayed, such as divestiture, slowdown or excuses to induce Party A to advance capital, it will be considered as a breach of contract after investigation.

5) undertake the warranty responsibility within the scope of decoration construction, and the warranty period is 12 months, counting from the date when the project is completed and accepted by Party A. ..

Article 9: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 10: dispute settlement

In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.

Article 11: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 12: Contract comes into effect

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. The supplementary contract has the same legal effect as this contract.

3. This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy.

Party A (Owner): (Signature) Party B: (Signature)

Address of domicile: address of enterprise:

Postal code:

Work Unit: Legal Representative:

Authorized Agent: Authorized Agent:

Tel: Tel:

Private renovation contract Model (II) Entrusting Party (Party A): Undertaking Party (Party B):

After friendly negotiation, Party A decided to entrust Party B to lay floor tiles and wall tiles, and signed this agreement for both parties to abide by.

I. Project Location: Room: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Two. Form and structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Third, the project:

1, four rooms (two bedrooms and two living rooms) shall be paved with 80*80 tiles and corner lines, which shall be flat; A kitchen, a bathroom wall 25*40 porcelain to the top, leaving a ceiling space, grinding angle, the ground 30*30 tiles, flat; The floors of the two balconies are paved with 30*30 tiles, which are required to be flat.

2. If no details are involved, Party A shall propose a plan and discuss it.

4. Contracting method: Party A must ensure the materials needed during the decoration period (Party B informs Party A in advance) and the lunch supply during the construction period according to Party B's requirements, and Party B shall be responsible for the construction.

Verb (abbreviation of verb) quality standard: the construction quality meets the safety requirements, and the decoration quality is not lower than the decoration standard of the same construction type, which is recognized by both parties. After the project is completed and accepted, if there are quality problems in Party B's construction within 3 months, Party B shall be responsible for rework and maintenance for free.

Engineering cost of intransitive verbs: materials are provided by Party A, and Party A pays Party B the labor cost of decoration.

Seven. Payment method: In order to ensure the quality of the project, 500 yuan deposit will be withheld and returned to Party B in full from April _ _ _ XX to July XX without any problem. After the project is completed, Party A shall pay Party B the labor cost within three days if it meets the above construction project and design requirements upon acceptance.

Eight. This agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into effect as of the date of signature by both parties.

Party A: Party B:

Signature (seal): Signature (seal):

Tel: Tel:

Year, month, sun, moon, sun.

Private renovation contract Model (III) Both parties to this contract:

Employer (hereinafter referred to as Party A):

Name? Id number? Contact number?

Contractor (hereinafter referred to as Party B):

Name? Id number? Contact number?

In order to standardize the construction of home interior decoration and protect the legitimate rights and interests of both parties, according to the Economic Contract Law of the People's Republic of China, the Regulations on Construction and Installation Contracts, the Law of People's Republic of China (PRC) on the Protection of Consumers' Rights and Interests, the Provincial Regulations on the Protection of Consumers' Legal Rights and Interests, the Trial Measures for the Management of Home Room Decoration and Decoration (1997) No.92 issued by the Ministry of Construction of People's Republic of China (PRC) and other relevant laws and regulations, Based on the specific conditions of this project, Party A and Party B have reached the following agreement on matters related to the decoration project on the basis of equality and voluntary consultation, which shall be abided by * * *.

1. Decoration Project Location: Room 2 1 02, Unit 2, Building No.2, Wanlongyuan, Datong Water Spring.

2. Decoration project contracting method: contracting labor and materials.

Decoration project content:

A, basic engineering:

1. Knock on the wall (bedroom door, bathroom door, kitchen door, footstone)

2. Feeding and garbage removal

Second, hydropower transformation.

1. Change the water in the bathroom, kitchen and warehouse.

2. Rectification of closed lines and network cables of bathrooms, kitchens, bedrooms, living rooms and air-conditioning lines.

Third, the Mei Sen part.

1. Materials (washed sand, cement)

2. Main materials (800mmx800mm polished brick, 300mmx450mm crystal brick, 10mmx800mm glass anchor wire, 300mmx300mm bathroom floor tile, kitchen and bathroom painting, floor drain, caulking agent, waterproof, stainless steel strip).

3. The above tile paving cost

Fourth, the woodworking part

1. PVC ceiling for kitchen and bathroom, kitchen and bathroom walls, sewer pipes, beams and door cards.

2. Integrated shoe cabinet

3. Take a walk in the bedroom and living room

4. Bedroom painted suit door, kitchen and bathroom titanium magnesium alloy door

5. Paint door covers, window covers, bathroom door covers and kitchen door covers.

6. Window sill kitchen marble

7. Kitchen floor cabinets and UV doors

8. Hardware handles, steel nails, air nails, row nails and hinges

9. Latex, all-purpose glue, 4 1 15 building glue

10. Woodworking installation fee

V. Petroleum part

1. Nippon special putty powder (scraped twice)

2. Nippon 120 Latex Paint

3. Accessories

4. Labor costs

Six, kitchen and bathroom facilities electrical part

1. General lighting

2. Yuba

3. Faucet, mirror, agitator, stainless steel double vegetable pond

4. Lamp switch

5. Installation fee

Seven. The decoration materials used in the decoration project shall be provided by Party B, and the decoration construction equipment and tools shall be provided by Party A. ..

Eight. Both parties agree that the total price of this renovation project is RMB (in words) 58,000 yuan (including foundation 4,500 yuan, bricklayer19,520 yuan, carpenter 2 1580 yuan, oil worker 4,600 yuan, kitchen and bathroom facilities 3,000 yuan and water and electricity renovation 4,800 yuan).

Nine, after the completion of the decoration project, Party B shall notify Party A of the acceptance two days in advance, and Party A shall organize the acceptance within three days after receiving the notice.

Ten, decoration engineering payment method:

(1) After signing this agreement, Party A shall pay Party B 30% of the total contracted decoration project within two days.

(2) After Party B completes the hydropower renovation, Party A shall pay Party B 30% of the total renovation project price within two days.

(3) After Party B finishes tiling, Party A shall pay Party B 20% of the total contracted decoration project within two days.

(4) After Party B finishes carpentry, Party A shall pay 10% of the total decoration project contracted by Party B within two days.

(5) After Party B finishes the oil work, Party A shall pay 5% of the total price of the decoration project contracted by Party B within two days.

(6) After the renovation project contracted by Party B is completed and accepted by Party A, Party A shall pay the remaining 5% of the total renovation project price contracted by Party B within 5 days.

XI。 Party B will ensure on-site supervision and management during the whole renovation process.

12. The construction site provided by Party A shall meet the requirements of fire prevention and accident prevention, mainly including unblocked qualified electrical lines, gas pipelines, tap water and other pipelines. In case of the above situation, Party A shall be responsible for maintenance and compensation.

13. In case of any quality accident caused by Party A during Party B's renovation, Party A shall bear the rework fee and material loss.

14. During the construction process, if Party A needs to propose amendments or additions or deletions, it needs to get in touch with Party B in advance, and the construction of this project can only be carried out after both parties reach an agreement through consultation.

15. If one party to the contract fails to perform the contract or violates national laws, regulations and relevant policies, and is fined or causes losses to the other party, the relevant responsible party shall bear the responsibilities and compensate the losses caused to the other party.

16. Party A and Party B directly sign this contract in duplicate, with each party holding one copy.

17. This contract shall come into effect after being signed and sealed by both parties. ..

Party A (signature and fingerprint): Party B (signature and fingerprint):

? Year? Month? sun

Private renovation contract Model (4) Owner:? (Party A) Contractor:? (Party B)

In accordance with the relevant provisions of the Contract Law of People's Republic of China (PRC) and the Construction Law, and in combination with the specific conditions of this housing construction project, and in order to clarify the rights and obligations of Party B in contracting the construction of Party A's private housing project, both parties have entered into this contract through consultation.

Rule number one. Construction projects: private construction projects.

Article 2. Construction site: Houlicheng Village. Construction method and construction preparation

1. Party A contracts its residential project to Party B in the form of contractor.

2. Party A shall provide all materials needed for the project in time. During the construction period, everyone will have a box of cigarettes every day. Party A shall provide lunch when the carpenters dismantle the formwork, and provide extra meals and lunch when watering each floor. Party A and Party B hope that Qixin will make joint efforts to improve relations and strive to complete the project before the arrival of winter.

3. Party B shall carry all the construction tools needed for the building and take rainproof measures in rainy days to avoid the rain from affecting the quality of the ground when pouring the ground.

Article 3. Construction period: 2065438+May 3, 2002.

Article 4. Construction project price and payment method:

1. The overall construction contract fee (excluding materials) shall be priced according to the construction area. The building area of the house is about ㎡, and the contract fee is 170 yuan/㎡ (including labor wages, construction tools and molds). (Nails, iron wires and other accessories are provided by Party A).

2. Material arrangement: Party B shall provide the plan to Party A three days in advance, and Party A shall arrange the materials in time, and Party B shall urge the construction personnel not to waste it.

3. Payment method: payment according to the progress of the project:

Due to the early infrastructure construction, Party A paid Party B RMB one hundred thousand Yuan only (-) by way of loan on-20 12. After all the projects are completed and accepted, they will be accounted and refunded according to the actual infrastructure cost. 70% of the total project cost will be paid after the main body construction is completed, 30% of the total project cost will be paid after the main body powder and water are completed, and the balance will be paid after the completion acceptance. In addition, 2000 yuan will be deducted from the quality guarantee, and it will be paid off after half a year without quality problems.

Article 6, the construction safety requirements

1. Party B's construction personnel must have certain construction experience and have corresponding building permits to ensure that the projects contracted by Party B meet the quality and technical requirements required for construction.

2. Party B must focus on engineering quality and safe construction, and build houses in strict accordance with the standards for earthquake-resistant housing construction. During the construction period, it is necessary to ensure the quality and safety of the project, control all possible risk factors, eliminate hidden dangers of safety accidents, and strengthen the comprehensive inspection and supervision of the three elements of project quality, progress and safety at any time.

3. Party B shall ensure that all construction workers entering the site must purchase accident insurance (Party A is willing to pay 65,438+0,000 yuan for accident insurance for construction workers, and Party B shall be responsible for the rest).

4. Party B must take strict safety protection measures according to the safety construction specifications and technical requirements. During the construction process, Party B shall pay special attention to safe construction, put an end to all accidents, and bear all expenses caused by inadequate or ineffective safety measures. If this happens, Party A has nothing to do with the responsibility. ..

Article 7, project quality.

1. Party B shall carry out the construction according to the drawings (requirements) provided by Party A. If unreasonable parts are found in the drawings, Party A and Party B shall negotiate with each other to obtain a clear and consistent construction plan before proceeding.

2. If the quality of the project fails to meet the qualified conditions due to Party B's own reasons, Party B shall rework, modify and redo according to the requirements of Party A and its appointed personnel, and bear all expenses such as labor and materials. Party B shall be liable for breach of contract for the quality of the project if it still fails to meet the agreed qualified use conditions after rework and modification.

Article 8. Liability for breach of contract and settlement of disputes

1. If Party A fails to provide relevant information in time according to Party B's project progress, resulting in the loss of Party B's shutdown, Party A shall be responsible for compensating the loss.

2. If the quality of the construction project contracted by Party B does not meet the agreed requirements, Party B shall rework, repair and redo it free of charge. If losses are caused, Party B shall compensate all the losses. If this contract cannot be performed due to other reasons of Party B, Party B shall compensate Party A for all losses caused by its breach of contract.

3. Any dispute between Party A and Party B during the performance of this contract shall be settled through patient negotiation. If no settlement can be reached through negotiation, both parties agree to submit it to Linshu Labor Arbitration Committee for arbitration.

Article 9. Entry into force and termination of the contract.

1. This contract is made in duplicate, with each party holding one copy.

2. This contract shall come into effect as of the date of signing.

3. After the completion acceptance, Party B will deliver the project to Party A, and Party A will reserve 2,000.00 yuan for the maintenance fee and pay it in full.

Both parties must abide by the above contract. If both parties agree to sign a supplementary contract through consultation, the supplementary contract shall have the same legal effect as this contract.

5. Whether the project * * * is increased or decreased is consistent with other plans.

Signature of Party A (handprint):? Signature of Party B (handprint):?

Id number:? Id number:?

Date of contract signing?

Private House renovation contract Model (V) Party A (Owner):?

Party B (contractor):

According to the Contract Law of People's Republic of China (PRC) and the Construction Law of People's Republic of China (PRC), Party A and Party B have reached an agreement on the project contracting on the principles of equality, voluntariness, fairness and honesty.

1. Project location: facade number of Hubin Community in Ludian County (126, 127)

Second, the engineering structure requirements: the first floor is the facade, and the second and third floors are the suites.

Three. Commencement time: from the date of official notice from Party A ... Completion time: within five months from the date of notice from Party A.. : MM DD YY to MM DD YY.

4. Contracting method: The contractor does not contract materials, but contracts the fixed contract price at one time. If the price rises or falls, this contract shall prevail.

Verb (abbreviation of verb) quantity and price: Party A contracts Party B for construction at the price of 220 yuan per square meter (220.00 yuan /m2). The project settlement is measured by the square area of the building roof, and other parts and ancillary facilities are not paid by measurement. The settlement of the house area is based on the measured square area after the construction, involving the area of the house surface and inclined plane (single floor) built with the word "human".

6. All tools (including mixers, vibrators, templates, scaffolding and other construction tools), workers, water and electricity required for this project shall be solved by Party B itself, and all expenses and responsibilities shall be borne by Party B. After the project is completed, the second roof panel shall pay 20% of the total project cost, and all the money shall be paid after the project is completed and accepted.

7. The main contracting contents of the project: main project, backfill soil, fence, top enclosure, external wall decoration, small blue tile buckle decoration (see the external drawings of the project for details), septic tank, clearing hardening, stair handrails, door and window installation, soil treatment of the bottom wall, floor tile paving of each floor, kitchen and bathroom walls covered with ceramic tiles, water pipes, circuits, closed-circuit television lines, network lines, telephone lines, etc. These include:

1. Tap water: two water meters with taps and gate valves must be installed on the first floor for commercial use, and one water meter with taps and gate valves must be installed on each floor of the second and third floors. The stairwell on the first floor is equipped with a toilet with septic tank and flushing gate valve. In addition to the flushing gate valve, the bathrooms of other suites need to be equipped with two more faucets, ground drainage and toilet exhaust systems. The kitchen has faucets and sewers, and the roof has faucets and sewers. All toilets must be buried with separate solar hot water pipes to the roof. All sewer pipes go down to the septic tank and then back to the sewer. All the sewer pipes on the roof are buried at one time, and taps and sewer pipes are installed in the open space.

2. Circuit: The instrument on the first floor elevation is turned on (20A), and the instruments on the second and third floors are turned on (20A). Yi Deng on each floor of stairwell is controlled, and alternating current and communication lines must be separated.

3. Two facades on the first floor are provided with a closed-circuit signal line and a network line, and one on the second and third floors.

4. All wiring installation directions, including sewer pipe installation and bottom box location arrangement, shall be installed according to the wiring and location required by Party A, and Party A has the right to refuse the location and direction arranged without Party A's consent and request rework.

5. Seismic columns must be added to the balcony before and after the main building.

Eight, construction quality and safety requirements:

1. The quality warranty system shall be implemented for buildings, and the warranty period shall be two years. Party B's construction personnel must have certain construction experience to ensure that the project contracted by Party B meets the quality and technical requirements required for construction.

2. Party B needs to strengthen the awareness of fire prevention and theft, and all responsibilities and losses arising from fire and theft during the project construction shall be borne by Party B. ..

3. Party B must carry out the construction according to the safety accident specifications and technical requirements, control all possible dangerous factors, eliminate the hidden dangers of safety accidents, and strengthen the comprehensive inspection and supervision of the three elements of project quality, progress and safety at any time. Party B shall be responsible for all safety accidents during the construction period, and bear the responsibilities caused by the accidents and all expenses arising therefrom. If this happens, Party A has nothing to do with the responsibility. ..

4. After completion, walls, windows, doors, etc. Should be smooth, wall tiles and the ground should be smooth, to prevent empty drum, in line with relevant standards.

5. Party B shall carry out the construction according to the design (requirements) provided by Party A. If any unreasonable design is found, Party A and Party B must raise it and reach an agreement on the construction plan before Party B can carry out the construction.

Nine, acceptance and punishment:

1. After the completion of this project, it must be accepted by an acceptance team composed of professionals from both parties and the new district headquarters. The acceptance criteria are strictly in accordance with the unified national acceptance criteria for housing construction. After the acceptance, pay off all the money. In case of unqualified acceptance or rework, all losses and responsibilities shall be borne by Party B, and the expenses incurred shall be borne by Party B. ..

2. It is a concealed project, and Party B can only start construction after on-site inspection by Party A before construction. Without Party A's review or approval, Party A has the right not to approve or terminate the contract.

X this contract is made in duplicate, one for each party. The change of this contract is invalid.

XI。 This contract shall come into effect as of the date of signature and seal, and shall automatically become invalid after the project is completed and accepted.

12. Where matters not covered need to be supplemented, it shall be supplemented by both parties through negotiation, and the supplementary contract shall have the same legal effect as this contract.

Party A (signature):? Id number:?

Party B (signature):? Id number:?

Date:? Year? Month? sun

I recommend it carefully.