How to write the model houses in renovation contract and renovation contract?

House decoration is a very professional and complicated project, which is difficult for ordinary individuals to complete. Therefore, we need to find a suitable decoration team before the house decoration. After negotiation, both parties shall sign the house renovation contract. So, how to write the housing renovation contract is the norm? The following is a detailed introduction: renovation contract model of housing, I hope it will help you.

Residential renovation contract model

Entrusting party (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _ _ _ _ _ _

Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After consultation, Party A and Party B decide to entrust Party B to decorate the house. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * to abide by.

Article 1: Project Overview

1. Address: unit _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Specification: Room: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. Content: The quotation of the renovation project in this contract.

4. Contracting method: _ _ _ _ _ _ _ _ _ _ _ _.

5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total days of the project: _ _ _ _ _ _

Article 2: Project Price

Project price ￥, in words (RMB): Please refer to the quotation sheet of renovation project in this contract for details.

Article 3: Quality Requirements

1. The varieties, specifications and names of materials used in the project shall be approved by both parties.

2. Acceptance criteria, both parties agree to refer to the relevant provisions of the state.

3. During the construction, if Party A has special requirements, both parties shall sign a supplementary contract.

4. The quality of materials and equipment purchased by Party A shall be borne by Party A, and the construction quality shall be borne by Party B. ..

5. If Party A hires the supervisor by itself, it shall notify Party B before the commencement of work, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10 of the total amount of materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5: Method of Payment

1. After the house is signed in renovation contract, Party A will pay 50% of the renovation project cost to Party B in advance, and when the construction period is halfway through, Party A will support 40% of the second construction cost. The remaining 10% shall be settled after Party A's acceptance.

2. If there is any increase, decrease or change in the construction, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing a construction change order to inform the person in charge of the construction site, and the increase or decrease in the project price shall be settled on the spot.

3. If Party A fails to pay the project payment in advance as stipulated in the contract, Party A shall pay 1% of the unpaid project payment to Party B for each day overdue.

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party A shall pay the liquidated damages of 1 of the contract amount every day until the work expenses are deducted. If the completion is delayed due to Party A's reasons, Party B shall be paid 1 of the contract amount for each day of delay.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. In the process of construction, if work is stopped due to engineering quality problems and disagreement between the two parties, it will not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.

4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7: Project Acceptance

1. Project quality acceptance, except for concealed works, which need to be accepted by sections. After all projects are completed, Party B shall organize Party A to carry out the completion acceptance. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.

Article 8: Other matters

1. Party A's responsibilities

1 The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make disclosure to Party B on site. ..

In the second decoration project, all or part of the house should be vacated to remove obstacles that affect the construction. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood.

2. Party B's responsibilities

1 You should show your business license, membership card or the entrustment certificate of the legal representative of the construction qualification agent. (Individuals or construction teams need to show relevant identification documents)

Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.

3. Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

4. Strictly perform the contract and implement the credit period. If the completion is delayed, such as divestiture, slowdown or excuses to induce Party A to advance funds, it will be considered as a breach of contract after investigation.

5 undertake the warranty responsibility within the scope of decoration construction, and the warranty period is 12 months, counting from the date when the project is completed and accepted by Party A. ..

Article 9: Liability for breach of contract

After the renovation contract comes into effect, during the performance of the contract, the party who cancels the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 10: dispute settlement

During the performance of renovation contract House, if there is any dispute between the two parties, it shall be settled through negotiation without affecting the progress of the project. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.

Article 11: Modification and Termination of the Contract

1. After the house renovation contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at 10 of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 12: Contract comes into effect

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. The supplementary contract has the same legal effect as this contract.

Party A (owner): _ _ (signature) Party B: _ _ _ _ (signature)

Tel: Tel: _ _ _ _ _ _

Date of signing: Date of signing: _ _ _ _ _ _

Abstract: Here, we introduce some knowledge about renovation contract model of housing and how to write renovation contract of housing. I'm done.