House decoration agreement

House Decoration Agreement 1 Party A: _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After friendly negotiation, Party A decided to entrust Party B to lay floor tiles and wall tiles, and signed this agreement for both parties to abide by.

1, project location:

__________________________________。

2. Formal structure:

__________________________________。

3. Project:

(1) Four rooms (two rooms and two halls) shall be paved with 80x80 tiles and corner lines, which shall be smooth; The walls of the kitchen and bathroom are paved with 25x40 porcelain to the top, leaving room for ceiling, grinding corners, and laying 30x30 tiles on the ground, which is required to be flat; The floors of two balconies are laid with 30x30 tiles, which are required to be flat.

(2) Where the details are not involved, Party A shall put forward the scheme and discuss it.

4. Signing method:

Party A must, according to Party B's requirements, ensure the materials needed during the renovation period (Party B shall notify Party A in advance) and the lunch supply during the construction period, and Party B shall be responsible for the construction.

5, quality standards:

The construction quality shall meet the safety requirements, and the decoration quality shall not be lower than the decoration standard of the same building type, which shall be approved by both parties. After the project is completed and accepted, if there are quality problems in Party B's construction within 3 months, Party B shall be responsible for rework and maintenance for free.

6, the project cost:

The materials shall be provided by Party A, and Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

7. Payment method:

In order to ensure the engineering quality, the deposit is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ After the project is completed, Party A shall pay Party B the labor cost within three days if it meets the above construction project and design requirements upon acceptance.

8. Supplementary provisions:

This agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into effect as of the date of signature by both parties.

Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Agreement II of the entrusting party (Party A) for house decoration: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

1, project overview

(1) Project Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Project Address

(2) Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total: the construction area is _ _ _ _ _ _ _ _ square meters.

(3) Construction Contents: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

(4) Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(5) Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Total days of the project: _ _ _ _ _ _ _ _ days.

2, the project price

The project price (in words) is _ _ _ _ _ _ _ _ Yuan (in words).

3. Quality requirements

(1) The varieties, specifications and names of the main materials used in the project shall be approved by both parties. See Annex (III) List of Final Accounts of Home Decoration Engineering Materials for details.

(2) For the acceptance criteria of this project, both parties agree to refer to the provisions of local standard _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(3) During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm the increased expenses and sign a supplementary agreement.

4. Method of payment

After signing the (1) agreement, Party A will pay 100% of the engineering materials and 50% of the engineering expenses; When the time limit for a project is over half (_ _ _ _ _ _ _ _ _ _ _ _ _ _ _), Party A will pay 40% of the second project cost. The remaining 10% shall be paid to Party A after the project is completed and accepted. (Note: Construction costs include labor costs)

When Party A pays off the project price, Party B issues a unified invoice, handles the handover, and issues a decoration project warranty card to Party A. If Party A fails to pay when due, it is a breach of contract and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

(2) If there is any increase or decrease in the project or need to be changed during the construction, both parties shall sign a supplementary agreement, and Party B shall be responsible for issuing the construction change form and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

(3) If Party A fails to pay the project price in advance within the time limit agreed in this agreement, it shall pay 1% of the unpaid project price to Party B for each day overdue.

(4) If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

5. Liability for breach of contract

After this agreement comes into effect, during the performance of the agreement, the party that terminates the agreement without authorization shall pay 5% of the total amount of the agreement to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the agreement exceeds the liquidated damages, it shall be compensated.

6. Alteration and termination of the agreement

(1) This agreement shall come into effect after being signed by both parties, and both parties shall strictly abide by it. If either party needs to change the contents of the agreement, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the agreement, the party who proposes to terminate the agreement shall do so in writing, and pay a penalty of 65,438+00% of the total agreement price, and go through the termination procedures.

(2) In the process of construction, if either party proposes to terminate the agreement, it shall submit it to the other party in writing. After both parties agree to go through the liquidation procedures and sign the termination agreement, this agreement shall be deemed to be terminated.

7. The agreement comes into effect.

(1) This agreement shall be sealed by both parties and come into force after being signed.

(2) This Agreement was signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A: _ _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Agreement III of the entrusting party (Party A) for house decoration: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After friendly negotiation between Party A and Party B, Party A decided to entrust Party B to decorate the house and signed this agreement for both parties to abide by.

I. Project Location:

____________________________

Second, the formal structure:

___________________________________

Third, the construction period:

Within one and a half months (_ _ _ _ _ days) from the commencement date.

Fourth, the way of contracting:

Part of the materials are contracted by Party B, and part of the materials are provided by Party A (see Schedule 1: List of Decoration Materials Provided by Party A for details). Schedule 2: List of Decoration Materials Provided by Party B)

Verb (abbreviation for verb) item:

1. Party B is responsible for laying tiles, laying corner lines and leveling the floors of five rooms (three bedrooms, one living room and one living room); The top of a kitchen and two bathrooms are covered with porcelain, leaving room for the ceiling and polishing the corners. Tiles shall be provided by Party A, and other materials shall be provided by Party B. ..

2. Party B is responsible for the circuit waterway reconstruction;

3. Party B is responsible for the integrated ceiling: kitchen and two bathrooms.

Step 4 Pack three water pipes

5. Party B is responsible for plastering the top of the living room and the top of the living room corridor. Materials shall be provided by Party B. ..

6. The wall should be coated with double lime powder. Party A shall provide paint materials, and Party B shall be responsible for the rest.

7. Party B is responsible for installing two bathroom door, lamps and sanitary ware, and the materials are provided by Party A. ..

8. After the renovation is completed, Party B shall be responsible for cleaning up.

9. Kitchen cabinets. The specific decoration scheme is proposed by Party A and determined through negotiation.

For matters not covered, Party A shall propose a plan and determine it through negotiation.

Supply of intransitive verb materials and equipment

1. The materials and equipment provided by Party A shall be qualified products that meet the requirements of design and national standards, and shall be supplied to the site in time according to the construction schedule, and Party B shall be notified in advance. Both parties shall accept the quantity and appearance of the supplied materials, and Party B shall be responsible for keeping them after handling the handover procedures.

2. The materials supplied by Party A shall not be used for other purposes without Party A's consent. If Party B misappropriates the materials, it shall compensate Party A at twice the price of the misappropriated materials.

3. The materials and equipment provided by Party B must conform to the variety, specification, model, quality, measurement standard and quantity in the list of materials provided.

4. If the materials and equipment provided by Party B do not meet the quality requirements of national standards or have different specifications, it is prohibited to use them; If it has been used, the consequences and losses shall be borne by Party B. ..

Seven, quality standards

The construction quality shall meet the safety requirements, and the decoration quality shall not be lower than the decoration standard of the same building type, which shall be approved by both parties. After the project is completed and accepted, if there are quality problems in Party B's construction within 3 months, Party B shall be responsible for rework and maintenance for free.

Eight, the project cost

Party A * * * pays Party B * * _ _ _ _ _ _ _ _ _ _ _ _.

Nine, the project payment is paid in the following ways:

(1) Within two to five days after the signing of this contract, Party A shall pay _ _ _ _% (RMB _ _ _ _) of the total price;

(2) Within three days after completing 50% of the project payment, Party A shall pay the project payment equivalent to _ _ _ _ _ _ _ _ _.

(3) Within three days after the completion acceptance, Party A shall pay _ _ _ _% (_ _ _ _) of the total price for the project.

(IV) After one year of completion acceptance or the expiration of the warranty period agreed by both parties, if there is any quality problem in the decoration, Party B will check for Party A free of charge, otherwise, the damaged amount will be refunded!

X this agreement is made in duplicate, one for each party, with the same effect. This agreement shall come into effect as of the date of signature by both parties.

Party A: _ _ _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _

Signature (Seal): _ _ _ _ _ _ _ _ _ _ Signature (Seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Phone number: _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ Phone number

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Entrusting Party (Party A) of House Decoration Agreement 4: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _ _ _ _ _ _

Project: _ _ _ _ _ _ _ _ _ _ _ _ _

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, this contract (including its annexes and all supplementary contracts) is hereby signed for * * * to abide by.

Article 1: Project Overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ Room specifications

1, _ _ _ _ _ _, which is _ _ _ _ square meters;

2._ _ _ _ _ _ Hall, which is _ _ _ _ _ square meters;

3, _ _ _ _ _ kitchen, meter _ _ _ _ square meters;

4, _ _ _ _ _ _ toilet, meter _ _ _ _ square meters;

5, _ _ _ _ _ balcony, meter _ _ _ _ _ square meters;

6._ _ _ _ aisle, _ _ _ _ _ square meters per meter;

7. Other (specify location) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ square meters.

Total: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ m2.

3. Construction content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. Entrustment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Total project days: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 2: Project Price

Project Price (amount in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties. List of final accounts of home decoration engineering materials.

2. Regarding the acceptance standard of this project, both parties agree to the local standard DB3 1/T30- 1999 Acceptance Standard for Residential Decoration.

3. In the process of construction, if Party A has special construction projects or special quality requirements, both parties shall sign a supplementary contract for the increased cost.

All materials and equipment purchased by Party A shall be borne by Party A; Party B shall be responsible for the quality of the project.

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. Budget table of home decoration engineering materials. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall be prohibited from being used. If it has been used, all losses caused to the project shall be borne by Party B. ..

Article 5: Method of Payment

1. Once the contract is signed, Party A shall pay RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Payment percentage

According to the table of payment methods (omitted)

Party A shall pay off the project price and the settlement sheet of the home decoration project, and Party B shall issue a unified invoice or receipt in accordance with the Administrative Measures for Interior Decoration of Residential Buildings, hand it over to Party A and issue a warranty card for the decoration project.

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. In case of any project increase or decrease or need to be changed during the construction process, both parties shall sign a supplementary contract for Home Decoration Project Change Sheet, and Party B shall be responsible for issuing the construction change sheet and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in this contract, Party A shall pay _ _ _ _ _ _ _ _% of the unpaid project price to Party B for each day overdue.

Article 6: Construction Period

1. If the construction period is delayed due to Party B's reasons, Party A shall pay _ _ _ _ _ _ _% of the working expenses as liquidated damages every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid _ _ _ _ _% of the labor cost in the decoration project price as the lost time fee for each day of delay.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. During the construction, due to the quality problems of the project, both parties disagree, resulting in the suspension of work, failure to act as punishment for delaying the work or the construction period. Both parties should take the initiative to ask the relevant departments to mediate or the arbitration department to coordinate and deal with the dispute as soon as possible, so as to continue the construction.

4. In the process of construction, if rework is required due to Party A's reasons, or the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged. In case of fire, theft and personal injury accidents during construction, Party B shall be responsible.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7: Project Acceptance

1. See Annex (VI) Home Decoration Engineering Quality Acceptance Form for the project quality acceptance. Party B shall organize Party A to carry out the completion acceptance after the project is completed, except that the concealed works need to be accepted by sections. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.

Article 8: Other matters

1, Party A

1. The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided; otherwise, Party A shall provide the house plan and water, electricity and gas circuit diagram and make on-site disclosure to Party B. ..

2. The second decoration project, all or part of the empty house, remove obstacles that affect the construction. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

3. If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood.

2. Party B

1, should take the initiative to show business license, membership card or construction qualification; If it is a subordinate branch, it must also have a certificate issued by the superior company; The handling salesman must have a certificate of entrustment from the legal representative.

2. Appoint (name) _ _ _ _ _ _ _ as the on-site representative of Party B, be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction tasks with good quality and quantity on time.

3, responsible for the safety of the construction site, do fire prevention, show certificates, civilized construction, to prevent accidents such as pipeline blockage, water leakage, power failure, damage to goods caused by construction from affecting others. If there are 10 thousand x's, they must be repaired or compensated as soon as possible. If Party B violates the property management regulations during the construction, the economic and other consequences arising therefrom shall be borne by Party B. ..

4. Strictly perform the contract and implement the credit period. If the completion is delayed, such as divestiture, slowdown or excuses to induce Party A to advance funds, it will be treated as breach of contract after investigation.

5. Under normal use conditions, the minimum warranty period of residential interior decoration engineering is two years, and the leakage prevention of kitchen, bathroom and external wall with waterproof requirements is five years. The warranty period is calculated from the date when the residential interior decoration project is completed and accepted.

Article 9: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay _ _ _ _ _ _ _% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 10: dispute settlement

1. In case of any dispute during the performance of this contract, both parties shall settle it through negotiation without affecting the project progress.

2. If both parties are unwilling to settle the dispute through negotiation or mediation, or negotiation or mediation fails, they may apply to the Arbitration Commission for arbitration according to this contract; -the people's court brought a lawsuit.

Article 11: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at _ _ _ _% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 12: Contract comes into effect

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. If necessary, Party A and Party B may sign a supplementary contract, which has the same legal effect as this contract.

3. This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy.

Party A (Owner): Party B (Contractor): Party A (Owner): Party B (Contractor): Party B.

(Signature or seal) (Signature or seal)

Phone number: _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Date of signing: _ _ _ _ _ _ _ _ _ _ _ Date of signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

House Decoration Agreement V (hereinafter referred to as Party A) : _ _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ ID card

Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

This agreement is reached by both parties through consultation, and both parties shall abide by it. With the consent of both parties, this agreement was drafted by _ _ _ _ _ _.

I. Projects

1, three rooms (two rooms and one living room, hereinafter referred to as three rooms) shall be marked with corner lines, including heating and pipes (the living room shall be symmetrical), and plaster lines shall be marked around the roof to cover the doors and windows of the three rooms. The living room and bedroom are covered with laminated wood floors. Remove the original paint from all rooms, putty from the living room and bedroom, and paint with Nippon paint twice.

2. Make a crossbar at the doors and windows of the balcony, and make a shelf on it according to Party A's requirements (drawings). On the east side of the balcony, a multi-purpose cabinet (shoes below and bookcases above) and a hanging cabinet on the west side are used to cover the balcony, lay tiles and hang C boards.

3, bathroom, bathroom, kitchen tiles to the top, the roof hanging C board. The kitchen floor was tiled and a stove was built.

4. The power supply circuit of the room should be properly adjusted according to the requirements of Party A, and there is a multi-purpose cabinet behind the living room door (shoes are placed below and clothes are hung on it).

5. If no details are involved, Party A shall put forward a plan and discuss it.

Second, the way of contracting Party A must guarantee the materials needed during the renovation according to Party B's requirements (Party B shall notify Party A in advance), and Party B shall be responsible for the construction.

Third, the quality standard The construction quality should meet the safety requirements, and the decoration quality should not be lower than the decoration standard of the same building type, which is recognized by both parties.

Four. If the construction period is _ _ _ _ _ _ _ _ _ _ years, then

Five, the project cost materials are provided by Party A, and Party A only pays Party B _ _ _ _ _ _ _ _ for the decoration labor.

After the completion of the intransitive verb payment project, if it meets the above-mentioned construction project and design requirements after acceptance by Party A, the decoration labor cost shall be paid in one lump sum within three days.

Seven. Specific requirements for other renovation projects shall be put forward by Party A, and Party B shall implement ... Matters not covered in this agreement shall be settled by both parties through consultation. This agreement shall come into effect as of the date of signature by both parties.

Eight. This Agreement is signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _