Housing renovation and demolition contract

Model text of house decoration and demolition contract

? When decorating, some items may need to be removed properly in order to be well decorated. The following is a sample contract for house renovation and demolition that I have compiled for you. Welcome to reading.

Model Law on House Decoration and Demolition Contract 1: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

Party A entrusts Party B to undertake the demolition construction and muck removal of some buildings in XXXX demolition project. In order to clarify the rights and obligations of both parties, through consultation, * * * unanimously agreed to sign this agreement.

A, the construction content and quantity:

1. Construction content: building demolition, muck removal.

2. Project quantity: 934 square meters

3. Demolition standard: buildings and houses within the scope of demolition shall be demolished, and muck shall be removed to indoor level.

4. pay attention; All kinds of wastes generated in the construction process shall be owned by Party A, and shall be disposed of by Party A itself. ..

Second, the project price and settlement method:

1, project price:

(1) Both parties agree that the unit price of this project is 15 yuan/m2.

(2) Total amount of the project; Fourteen thousand yuan (14000 yuan)

2. Settlement method:

(1) Since the commencement date of contract signing, Party A will only pay 30% of the project payment (4,200 yuan);

(2) Within 2 working days after Party B completes all demolition work, Party A shall pay the final payment of the project in one lump sum.

Third, the construction date:

1. The contract project is scheduled to start on 20 1 1 day and be completed on 20 1 1 day.

2. If the project cannot be started or completed on time due to force majeure or weather, Party A and Party B can reschedule the start or completion date.

Four. Responsibilities and powers of both parties:

Party A:

1. After Party B enters the site, Party A shall make a construction disclosure to Party B, explain the underground obstacles around the construction site and construction precautions, and provide relevant technical data.

2. Responsible for coordinating and cutting off the water supply, power supply, heat source, gas and communication lines leading to the demolition area.

3. Cooperate with Party B to conduct safety education for construction personnel.

4. Party A is appointed as the person in charge of the project, responsible for coordinating related matters in the construction and supervising the whole construction process of Party B. ..

Party B:

1, responsible for the preparation of construction scheme, safety and environmental protection measures.

2. Actively cooperate with Party A's work.

3. Seriously implement the requirements and regulations put forward by the state and relevant departments of Dalian Development Zone on building construction, so as to achieve civilized construction, safe construction and timely completion of construction tasks.

4. Construction work must be carried out in strict accordance with relevant laws and regulations, and attention should be paid to environmental protection requirements: sprinkling water to reduce dust, controlling noise and avoiding unsafe factors.

5, responsible for the safety of machinery and personnel, strengthen the safety education and preventive measures for construction personnel, to ensure that the construction is foolproof; Party B shall bear the responsibility for safety accidents caused by poor management.

6. Obey the command of Party A's on-site management personnel and respect Party A's management system.

7. Designate Party B as the project leader, be fully responsible for the project demolition, and notify Party A of the project demolition in time.

Verb (abbreviation of verb) liability for breach of contract:

1. In case of violation of the provisions of this contract, Party A and Party B shall bear their respective responsibilities. All losses caused shall be borne by the responsible party (including economic losses).

2. In case of any dispute during the execution of this contract, both parties shall settle it through negotiation. If negotiation fails, they can bring a lawsuit to the Beijing People's Court.

Other intransitive verbs:

1. After the signing of this contract, if both parties have any unfinished matters or modify the terms of the contract, both parties shall reach an agreement through consultation and sign a supplementary agreement.

2. This supplementary agreement and its annexes have the same legal effect as the text of this contract, and both parties shall abide by it.

3. This contract shall come into effect as of the date when the legal representatives or authorized agents of both parties sign and affix their respective official seals.

4. This contract is made in quadruplicate, and each party holds two copies, which have the same legal effect.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

The entrusting party (Party A) model house decoration demolition contract Article 2:

Organizer (Party B):

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project,

In accordance with relevant national laws and regulations, this contract is specially signed for * * * to abide by.

Article 1; Project overview

1. Project address: Zheng 'an Power Garden

2. Living room specifications: three bedrooms and one living room, with a total construction area of143m2.

3. Construction content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

4. Entrusting method: turnkey project of contracting and materials.

5. Commencement date: 20 13 12.5, completion date: 20 14.3, and total project days: 90 days.

Article 2: Project Price

Project price (in words) two hundred and fifty thousand yuan. For details, please refer to Annex (II) Budget Table of Home Decoration Engineering Materials.

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

4. The quality of all materials, equipment and products purchased by Party A shall be borne by Party A; The project quality shall be borne by Party B. ..

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5: Method of Payment

1. After signing the contract, Party A shall pay1()% of the engineering materials and 50% of the engineering expenses; When the construction period is over half, Party A will pay 40% of the second project cost. The remaining 10% shall be paid to Party A after the project is completed and accepted. (Note: Construction costs include labor costs).

Party A's failure to pay at the same time as the payable amount is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party B shall pay Party A 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the completion is delayed due to Party A's reasons, Party B shall be paid 1% of the labor cost in the decoration project price as the lost time fee for each delay.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. In the process of construction, if work is stopped due to engineering quality problems and disagreement between the two parties, it will not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.

Article 7: Other matters

1. Party A's responsibilities

1) The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make on-site disclosure to Party B. ..

2) Secondary decoration project, in which all or part of the house is vacated and obstacles affecting the construction are removed. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

2. Party B's responsibilities

1) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the contract requirements, and complete the construction task on time with good quality and quantity.

2) Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

Article 8: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 9: Settlement of disputes

In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.

Article 10: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 11: Entry into force of the contract

1. This contract shall come into effect after being signed by both parties.

2. This contract is made in duplicate, with each party holding one copy.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Model House Decoration and Demolition Contract 3 Party A:

Party B:

Based on the principle of equality and voluntariness, Party A and Party B cooperate amicably, and Party A agrees to entrust the demolition work to Party B. Now, through negotiation, both parties have reached the following terms for their compliance:

A, the safety responsibility in the process of demolition:

During the demolition process, Party B shall carry out civilized construction in strict accordance with the relevant provisions of the Regulations on Work Safety. In case of any safety accident, Party B shall bear all the responsibilities.

2. Demolition scope and price: All materials demolished by Party B to a flat level shall be owned by Party B, and the muck generated by building demolition shall be removed by Party B. After the demolition work is completed, Party A shall pay Party B the demolition time of square meters.

Third, the demolition time:

The demolition time is (from) to (from) to (from) to (from) to (from) to (from) to (from) to (from) to (from) to (from) to (from). This contract is made in duplicate.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

;