Family indoor renovation contract

Three indoor renovation contract models.

Interior decoration includes room design, decoration, furniture arrangement and various small decorations. The following is a sample of renovation contract in my room. I hope it helps you!

1 bedroom renovation contract Fan Benyi, overview

1. The house decorated by Party A is legally inhabited. Party B is a civil decoration enterprise legal person approved by the administrative department for industry and commerce and the relevant departments of the Municipal Construction Committee.

2. Decoration construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. House structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. Contents of decoration construction: See Annex 1 Table of Decoration Construction Contents for details.

5. Contracting method: _ _ _ (contracting, contracting, contracting).

6. Total price: RMB _ _ _ _ _ _ _ _, in words: _ _ _ _ _ _, in which: if the construction content is changed by mutual consent, the project payment for the changed part shall be calculated separately.

7. Construction period: from _ _ _ _ _ _ _ to _ _ _ _ _ _ _ _ _

Second, about the agreement of the material supply:

1. Materials provided by Party A: See Annex II "List of Materials and Equipment Provided by Party A" for details. The materials and equipment that Party A is responsible for purchasing and supplying for this project shall be qualified products that meet the design requirements, and shall be supplied to the site on time, and Party B shall go through the acceptance formalities. If there is any quality problem or specification difference in the materials and equipment supplied by Party A, Party B shall promptly raise it with Party A in written form. If Party A still says that it will be used, Party A shall bear the responsibility for the engineering losses. After the materials supplied by Party A arrive at the site, they shall be kept by Party B after passing the acceptance. Party B may charge a storage fee for the materials provided by Party A, and the rate shall be determined by both parties. Party B shall be responsible for compensating the losses caused by improper storage.

2. The decoration materials and equipment purchased by Party B from Party A shall be used for residential decoration agreed in this contract, and shall not be used for other purposes without Party A's consent ... If Party B violates this regulation, Party B shall compensate Party A at twice the price of the misappropriated materials and equipment.

Three. Agreement on project quality and acceptance:

1, this project implements the local standards and quality evaluation acceptance standards formulated by the municipal construction administrative department, such as dbj08-62-97 Technical Specification for Residential Building Decoration Engineering, db3 1/t30- 1999 Acceptance Standard for Residential Decoration.

2. The construction scheme of this project is designed by Party A..

3, project acceptance. Party A and Party B shall handle the acceptance formalities of concealed works and intermediate works in time. If Party A fails to attend the acceptance as scheduled, Party B shall organize personnel to carry out the acceptance, and Party A shall approve it. Thereafter, if Party A requests reinspection, Party B shall reinspect as required. If the reinspection is qualified, the expenses for reinspection and rework shall be borne by Party A, and the construction period shall be postponed.

4. Project completion: Party B shall notify Party A of the acceptance three days in advance, and Party A shall organize the acceptance within three days after receiving the notice, and go through the acceptance handover procedures (see the Annex "Project Quality Acceptance Sheet" for details). If Party A fails to organize the acceptance within the specified time, it shall notify Party B in time and set another acceptance date. If it passes the completion acceptance, Party A shall acknowledge the original completion date and bear Party B's storage expenses and other related expenses.

Four, about the project price and settlement agreement:

1. Payment method of project funds:

2. Project settlement:

3. The warranty period of the project is one year. Party A and Party B can sign the project warranty only after the project price is fully settled, and the warranty period starts from the date of signing the completion acceptance.

4. Receipts shall be issued for the capital exchanges between the two parties, and invoices shall be issued at the end of construction.

Verb (abbreviation for verb) Other matters

1, Party A's work:

(1) Party A shall provide Party B with _ _ _ copies of construction drawings or practice instructions approved by the property management department one day before the start of construction, and make on-site disclosure to Party B. Empty all or part of the house and remove obstacles that affect the construction. Protective measures should be taken for furniture and furnishings stranded in houses that can only be partially vacated. Provide Party B with necessary conditions such as construction water and electricity, and explain matters needing attention.

(2) Do a good job in the coordination of the temporary use of public parts in the construction and the influence on neighborhood relations.

(3) If it is really necessary to dismantle or change the original building structure or design the pipeline, it shall be responsible for going through the corresponding examination and approval procedures at the local housing management department or property management department, and bear the relevant expenses.

2. Party B's work:

(1) Participate in the on-site disclosure of construction drawings or practice instructions organized by Party A. ..

(2) Appoint _ _ _ _ as the representative of Party B at the site to be responsible for the performance of the contract. Organize the construction as required, complete the construction task on time with good quality and quantity, and solve all matters that Party B is responsible for, and Party B shall recognize its behavior. If there is any personnel change, Party B shall promptly notify Party A in writing.

(3) Without the consent of Party A and the approval of the local housing management or property management department, the original building load-bearing structure and all kinds of equipment and pipelines shall not be dismantled at will.

Liability for breach of contract of intransitive verbs:

1. If the project is delayed or stopped halfway due to Party A's reasons, Party A shall compensate Party B for the losses caused by the stoppage or slowdown, and Party A shall pay RMB to Party B for each day of stoppage or slowdown; If Party A fails to make payment as agreed in the contract, Party A shall pay% of the overdue payment as penalty for each day overdue.

2. If the completion is delayed due to Party B's reasons, Party B shall pay _ _% of the project payment to Party A for each day overdue.

3. Without going through the relevant formalities, Party A forcibly requests Party B to dismantle and rebuild the original load-bearing structure of the building and the equipment and pipelines used by * * *, and Party A shall be responsible for the losses or accidents (including fines) caused thereby.

4. If Party B dismantles or changes the original building load-bearing structure or equipment pipeline, the losses or accidents (including fines) caused thereby shall be borne by Party B..

Seven. Dispute handling method:

1. In case of any dispute over the quality of the project, both parties may consult and mediate with the Family Decoration Committee of Shanghai Building Decoration Association on the basis of the text of this contract and the unified invoice issued by the construction enterprise, or apply to the district/county construction administrative department or the consumer association for mediation. 2. If the parties are unwilling to settle the dispute through negotiation or mediation, or if negotiation or mediation fails, they may apply to the Municipal Arbitration Commission for arbitration in accordance with this contract and bring a lawsuit to the people's court.

Eight. Modification and dissolution of the contract:

1, signed by both parties (the contract signed in the tangible market must be sealed by the market management department)

After the entry into force, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in writing. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Nine. Other agreements:

This contract was signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (signature): Party B (signature):

Authorized Agent: Legal Representative:

Address: Address:

Tel: Tel:

Post: post:

Date of signature: year month day.

Signing place:

Renovation contract Model for Home Interior Part II Party A (Owner): _ _ _ _ _ _ _

Company name: _ _ _ _ _ _

Address: _ _ _ _ _ _

ID number: _ _ _ _ _ _

Mailing address: _ _ _ _ _ _

Postal code: _ _ _ _ _ _

Tel: _ _ _ _ _ _

Fax: _ _ _ _ _ _

Account number: _ _ _ _ _ _

E-mail: _ _ _ _ _ _

Party B (contractor): _ _ _ _ _ _

Qualification certificate number:

Legal address: _ _ _ _ _ _

Legal Representative: _ _ _ _ _ _

Title: _ _ _ _ _ _

ID number: _ _ _ _ _ _

Mailing address: _ _ _ _ _ _

Postal code: _ _ _ _ _ _

Contact person: _ _ _ _ _ _

Tel: _ _ _ _ _ _

Fax: _ _ _ _ _ _

Account number: _ _ _ _ _ _

E-mail: _ _ _ _ _ _

Article 1 General situation of the project

1. 1 Project Location:No.: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

1.2 building structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

1.3 project cost: the price of family bedroom decoration project is agreed as follows according to the principle of market competition, with high quality and good price: total price: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. In which: material cost: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ With the consent of both parties, the construction content is changed, and the project payment for the changed part shall be calculated separately according to the actual situation.

1.4 project contracting method: both parties agree to adopt the following _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(1) Party B contracts all materials. (See Annex V: List of Decoration Materials Provided by Party B)

(2) Party B contracts some materials and Party A provides some materials (see Annex 4: List of Decoration Materials Provided by Party A and Annex 5: List of Decoration Materials Provided by Party B);

(3) All materials contracted by Party B and Party A (see Annex 4: List of Decoration Materials Provided by Party A).

1.5 The construction period is _ _ _ _ _ _ _ _ days; The commencement date is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1.6 project contents and practices (see Annex I: Confirmation Form of Decoration Project Construction Project and Annex II: List of Decoration Project Contents and Practices).

Article 2 Qualification of the construction unit

2. 1 Any unit undertaking the decoration project of family rooms shall hold the qualification certificate of construction enterprises with the scope of decoration project contracting issued by the construction administrative department.

2.2 Party B is an enterprise legal person approved and registered by the administrative department for industry and commerce, and has passed the latest annual inspection of the enterprise, and has the qualification of engaging in civil architectural decoration projects approved by the construction administrative department, and the qualification grade meets the requirements of this construction. If Party B does not have the business qualification or corresponding qualification, Party A has the right to terminate this contract, and Party B shall immediately return the fees paid by Party A and compensate for the losses.

2.3 Individual decoration workers who undertake family room decoration projects should register with the construction administrative department or its designated institution where the project is located with the work permit, identity card and temporary residence permit issued by the relevant competent departments of local people's governments at or above the township level, and implement the system of "registration, training and assessment, skill appraisal and holding certificates". Specific measures shall be formulated by the construction administrative departments of the people's governments of provinces, autonomous regions and municipalities directly under the Central Government.

2.4 No unit or individual without the Qualification Certificate of Construction Enterprise or the Qualification Certificate of Individual Decoration Practitioner issued by the construction administrative department may undertake the decoration project of family rooms.

Article 3 Project supervision

If it is a supervision project, Party A (or Party B) shall sign a project supervision contract with the supervision company separately, and notify Party B (or Party A) of the name, unit, contact information and responsibilities of the supervision engineer.

Article 4 Construction drawings

Both parties agree to provide the construction drawings in the following ways:

4. 1 Party A designs and provides the construction drawings by itself, and the submission time is _ _ _ _ _ _ _ _ _ (see Annex 6: Design Drawings of Home Decoration Project);

4.2 Party A entrusts Party B with the design and construction drawings in triplicate, with Party A, Party B and the construction team holding one copy respectively (see Appendix 6: Design Drawings of Home Decoration Project), and the design fee shall be paid by Party A (this fee is not included in the project price);

4.3 The construction drawings shall take effect after being signed by both parties.

Article 5 Rights and obligations of Party A

5. 1 _ _ _ _ days before commencement, to create conditions for Party B to enter the site for construction. Empty all or part of the house and remove obstacles that affect the construction; Protective measures should be taken for furniture and furnishings that can only be partially vacated, so as not to affect the construction. Party B's construction personnel shall carefully check and protect the animals on Party A's construction site, and both parties shall sign the "List of Articles";

5.2 Remove the original telephone equipment before construction; Provide water and electricity during construction, and explain the matters needing attention in use;

5.3 Responsible for coordinating the relationship between the construction team and the neighborhood;

5.4 It is forbidden to dismantle the indoor load-bearing structure. Need to dismantle, change the load-bearing and non-load-bearing structure of the building, or move the kitchen, bathroom, equipment and pipeline, shall be responsible for the relevant departments to handle the corresponding examination and approval procedures;

5.5 Participate in the supervision of project quality and construction progress, and participate in the acceptance of materials entering the site and project completion;

5.6 The construction deposit and various property management fees collected by the property management department where the project is located shall be paid by Party A (except for the pass), and Party B shall assist in providing relevant materials required for property management;

5.7 Party A shall not change the main body and load-bearing structure of the building without the original design unit or a design unit with corresponding qualification grade;

5.8 Party A has no right to ask Party B to move or change the heating and gas pipelines;

5.9 Waste generated from house decoration shall not be thrown about. Party A shall pile it up at the place, manner and time designated by the property management unit, the neighborhood committee where the house is located or the housing management department of the unit, and remove it according to relevant regulations;

5. 10 Party A shall not refuse or hinder the property management unit from supervising and inspecting the residential interior decoration activities according to the Residential Interior Decoration Management Service Agreement;

5. 1 1 Party A's decoration shall not damage the original energy-saving facilities of the house and reduce the energy-saving effect;

Article 6 Provision of materials

6. 1 The specifications and quality of materials and equipment provided by Party A shall meet the design requirements (see Annex 4: List of Decoration Materials Provided by Party A). Party A shall deliver the materials and equipment to the construction site on time and notify Party B, and both parties shall accept and handle the handover procedures; If Party A fails to provide materials on time or the specifications and quality of materials do not meet the design requirements, thus delaying the construction period or affecting the project quality, Party A shall bear the responsibilities;

6.2 For the materials and equipment provided by Party B (see Annex 5: List of Decoration Materials provided by Party B), Party B shall inform Party A in advance of the time when the materials and equipment will arrive at the construction site, and both parties shall jointly accept them; If the brand, specification and quality of the materials provided by Party B are inconsistent with the quotation, Party A has the right to refuse to use them, thus delaying the construction period or affecting the project quality, and Party B shall bear the responsibilities;

6.3 Party A shall determine the brand, specification, model or price standard of the materials, and Party B shall be responsible for purchasing them for Party A (see Annex 4: List of Decoration Materials Provided by Party A). Party B should pay attention to the procurement), and the materials can only be used after they arrive at the construction site and are accepted by Party A. The material procurement fee charged by Party B from Party A is the material collection management fee (_ _% of the material payment)+the material transportation fee (determined according to the actual situation); If the construction period is delayed due to material quality problems, Party A shall bear the responsibility;

6.4 Unless otherwise stipulated in the contract, hardware (door locks, handles, faucets, etc. ), stone, ceramic tile, equipment, sanitary ware and lamps are purchased by Party A and delivered to the site on time; If Party B is required to purchase materials, the purchase fee and transportation fee of _ _ _ _% of the purchased materials will be increased.

Article 7 Time limit for a project is delayed

7. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party A:

(1) engineering quantity change and design change;

(2) Force majeure;

(3) Work stoppage caused by Party A's failure to attend the stage acceptance on time;

(4) Other circumstances in which Party A agrees to postpone the construction period.

7.2 If the time limit for a project is affected by Party A's failure to complete the work it should be responsible for as agreed, the time limit for a project will be postponed; If the unqualified materials and equipment provided by Party A affect the project quality, the cost of rework shall be borne by Party A, and the construction period shall be postponed;

7.3 If Party A fails to pay the project payment on schedule, the contract period shall be postponed accordingly;

7.4 If the project cannot be completed on schedule due to Party B's material supply or construction reasons, the construction period will not be postponed; If there is any problem in the quality of the project due to Party B, the cost of rework shall be borne by Party B, and the construction period shall not be postponed.

Article 8 Quality standards

8. 1 project quality

(1) Party B must carry out the construction according to the design documents and the current national technical standards and specifications.

(2) All the projects contracted by Party B must meet the current national engineering quality acceptance standards, with the first acceptance rate of 100% and the excellent rate of _ _ _ _ _.

(3) If the project quality is unqualified due to Party B's reasons, Party B shall rework it free of charge within the time specified by Party A to reach the acceptance standard of the project quality. If the rework still fails to meet the requirements, Party B shall be liable for breach of contract. If the project quality fails to meet the standard due to Party A's reasons, Party A shall bear the responsibility for rework and economic expenses.

8.2 Both parties agree that the construction quality of this project shall be accepted according to the following item _ _ _ _ _ _ _:

(1) GB 502 10-XX Code for Quality Acceptance of Building Decoration Engineering

(2) "_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(3) Other acceptance criteria: _ _ _ _ _ _

10.3 in case of any dispute between the two parties on the project quality during the construction:

(1) You can complain to _ _ _ _ _ _ _ _ _ Family Decoration Complaint Center.

(2) If mediation is not accepted, it shall be appraised by an engineering quality inspection agency agreed by both parties, and the expenses and losses arising therefrom shall be borne by the responsible party. Both parties have responsibilities, which shall be borne by both parties according to their respective responsibilities.

Article 9 Project Acceptance and Warranty

9. 1 Both parties agree to check and accept the project quality in the following three stages during the construction process:

(1) Acceptance of concealed works such as hydropower pipeline, waterproof layer and suspended ceiling base;

(2) Acceptance of paint and surface coating before construction;

(3) Completion acceptance. Party B shall notify Party A two days in advance to carry out the acceptance of each stage, and fill in the project acceptance form after the acceptance of each stage is qualified (see Annex 8: Project Acceptance Form). If Party A fails to attend the acceptance on time after receiving the notice, Party B has the right to stop work and wait, and all delays and other losses caused to Party B shall be borne by Party A;

9.2 Warranty

(1) After the project is completed and accepted, and the balance of the project is settled, Party B shall go through the handover procedures with Party A (see Annex 9: Project Settlement Form) and fill in the project warranty form (the warranty period is two years) (see Annex 10: Project Warranty Form).

(2) Under normal use conditions, the minimum warranty period for interior decoration of residential buildings is two years, and the leakage prevention of kitchens, bathrooms and external walls with waterproof requirements is five years. The warranty period is calculated from the date when the residential interior decoration project is completed and accepted.

Article 10 Payment method of project funds

X. 1 Both parties agree to pay the project payment in the following _ _ _ _ _ _ _ _ _:

(1) After the signing of this contract, Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(2) Within _ _ _ _ _ _ _ _ years

(3) Within _ _ _ _ _ _ days after the completion inspection and acceptance, Party A shall pay _ _ _ _ _% of the total price for the project.

(4) Party A shall pay _ _ _ _ _ _% of the total price of the project after _ _ _ _ years after the completion acceptance or the expiration of the warranty period agreed by both parties.

If Party A pays the project payment, and Party B's sales staff or construction personnel collect it, it shall be regarded as Party B's collection.

10.2 If the total price increases or decreases due to the change of construction contents, Party A shall pay or collect the increased or decreased amount on the day when the completion acceptance is qualified.

10.3 Receipts shall be issued for capital transactions between both parties. After the completion of the project, Party B shall issue a legal invoice after Party A has paid off the payable amount.

10.4 After the completion acceptance, Party A has the right to keep the warranty money equivalent to _ _ _ _% of the total project price. If there is no engineering quality problem within _ _ _ _ _ years after the completion acceptance, Party A shall return the warranty money to Party B in full.

Article 11 Liability for breach of contract

1 1. 1 After the signing of the contract, if either party proposes to terminate the contract or fails to perform the contract for any reason, it shall notify the other party in time, and the performance of the contract may be terminated or postponed after both parties agree through consultation, and the defaulting party shall pay liquidated damages of _ _ _ _ _ _ _ _ _ _ _% of the project cost to the observant party; If losses are caused, the breaching party shall compensate.

1 1.2 If the project fails to pass the acceptance or the final payment is not settled, and Party A uses or uses the completed project without authorization, the project will be deemed as qualified, and the losses caused thereby will be borne by Party A, and it will be deemed that Party A has automatically waived its warranty and maintenance rights, and Party B still has the right to recover the final payment.

1 1.3 If Party A fails to pay the project payment on schedule, Party B has the right to stop work and pay Party B a penalty of 2‰ of the total project cost for each day of delay.

1 1.4 If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for the repair, and the required repair expenses shall be borne by Party B, and the construction period shall not be postponed.

1 1.5 If the construction period is delayed due to Party A or Party B, the responsible party shall pay the other party 2‰ of the total project cost as liquidated damages for each day of delay.

Article 12 Ways of settlement of contract disputes

In case any dispute between the two parties cannot be settled through negotiation, the following _ _ _ _ _ method shall be adopted for settlement:

12. 1 apply to the _ _ _ _ _ _ _ Arbitration Commission for arbitration;

12.2 bring a lawsuit to the people's court.

Article 13 Other specific provisions

Used for 13. 1 decoration works outside the project site.

13.2 the garbage generated by the project construction shall be removed by party b to the garbage dump designated by the government, and the garbage removal fee paid by party a shall be _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

13.3 During the construction period, Party A will give _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

13.4 During the construction period, Party B's daily working hours are: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 14 Supplementary Provisions

After the signing of this contract, the project shall not be subcontracted.

14.2 If Party A and Party B directly sign the contract, this contract shall be made in duplicate, which shall come into effect after being signed (sealed) by both parties, with each party holding one copy.

14.3 where the contract is signed in the _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

14.4 The contract will be automatically terminated after the completion of performance.

14.5 this contract must be voluntarily authenticated by the parties to protect the legitimate rights and interests of the parties to the contract.

14.6 the annex to this contract is an integral part of this contract and has the same legal effect as this contract.

Article 15 Interpretation of the Contract

Matters not covered in this contract or terms are not clear. Both parties to this contract can make a reasonable interpretation of this contract according to the principles, purposes, trading habits and relevant clauses of this contract. This interpretation is binding unless it conflicts with the law or this contract.

Party A (signature): _ _ _ _ Party B (seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _ entrusted agent (signature): _ _ _ _ _ _

Signing place: _ _ _ _ _ Signing place: _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Comments on Contract Certification of Home Decoration Market (Seal for Contract Certification of Shopping Mall): _ _ _ _ _ _ _

Authorized Agent (signature): _ _ _ _ _ _

Tel: _ _ _ _ _ _

Signing place: _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Renovation contract Model III for Home Indoor Party A: xx Property Management Co., Ltd.

Party B (Owner): Property Unit: Street No.

Party C (decoration enterprise):

In order to strengthen the management of property decoration in this residential area, maintain public order in the residential area and ensure a good environmental order during the decoration period, the responsibilities, rights and obligations of the property management company, the owner and the decoration enterprise are defined according to Article 1, point 8 of the original Property Management Service Agreement, and the following agreement is reached through tripartite consultation:

Article 1 Rights and obligations of the parties

Party A is the decoration management department of residential property, responsible for filing, service, management, supervision and inspection of Party B's decoration application; Party B (the owner) has the right to decorate his personal property in the area according to relevant laws and regulations and relevant regulations of the community; And entrust Party C to be responsible for the construction of the decoration project; Entrusted by Party B, Party C has the right to carry out normal construction and decoration, but it is subject to the supervision and inspection of Party A. ..

Article 2 Agreement on Handling Decoration Procedures

1. If Party B needs to decorate the store or residence, it must comply with the renovation regulations of Villa X, apply for registration and approval at the property service center, provide relevant renovation plans and go through relevant renovation procedures.

2. The application for house decoration submitted by Party B and Party C must be examined and approved by Party A and relevant departments for the record, and Party B can only carry out the decoration construction after paying a decoration deposit of * * * 5,000 yuan per household and obtaining a decoration construction permit issued by Party A; Where the decoration is carried out without going through the examination and approval procedures, Party A has the right to order the decoration unit to stop work immediately, and Party B shall pay Party A a penalty of 1 0,000 yuan and go through the relevant formalities.

Article 3 Decoration and acceptance

1. In the process of decoration, all parties must strictly abide by the decoration and renovation regulations of Villa X. ..

2. After the renovation project is completed, if Party B or Party C does not violate the renovation regulations of Villa X through inspection, Party A will refund the renovation deposit in full; If Party B or Party C violates this agreement, it will be implemented according to this agreement. If the circumstances are serious, in addition to the confiscation of the deposit, it will also be required to restore to its original state according to its violations, and bear all other responsibilities caused by violations; In case of pipeline blockage, water leakage, power failure, telephone, doorbell, TV line damage or other items, public facilities and equipment damage caused by Party B's renovation project within half a year after the renovation is completed, Party B shall be responsible for repairing or bear corresponding compensation responsibilities.

3. Party C shall go through the relevant entry and exit formalities for its decoration workers in Party A. ..

Article 4. Garbage removal and disposal protocol

1. In order to ensure a good public environment order during the renovation of the residential area, the removal and treatment of renovation garbage in the residential area shall be managed in a unified way, and Party A shall carry out unified paid cleaning. Party B's decoration garbage shall be piled up at the location designated by Party A, and decoration garbage and other garbage shall not be piled up in any public place in the community.

2. If Party B is the owner of the house, it shall pay Party A the corresponding renovation garbage cleaning fee (one-time) before the renovation is approved. According to the construction area, the decoration garbage cleaning fee is divided into the following standards (excluding the garden part):

1. 400 yuan/household with a construction area of 200m2 (excluding 200m2);

2. 600 yuan/household with a construction area of 200-300m2 (excluding 300m2);

3. 900 yuan/household with a construction area of 300-400 m2 (excluding 400 m2);

4. The construction area is 400-600㎡ (excluding 600㎡) and above 1300 yuan/household;

5. The building area is over 600㎡ (including 600㎡) 1500 yuan/household;

(Party A reserves the right to adjust the above fees appropriately according to the actual decoration situation)

3. If Party B is the owner of the store, the generated garbage should be piled up in front of the store and cleaned by itself (it must be done in daily production); Where Party B or Party C requests to pile up the decoration garbage at the place designated by Party A, it shall pay the decoration garbage removal fee of 500 yuan/household. If stacking is not paid, Party A shall be paid a penalty of 600 yuan. In addition, if the garbage piled up in the public places at the entrance of the store is not cleaned on time, and Party B or Party C still does not consciously clean it after receiving Party A's notice twice, Party A will send someone to clean it on its behalf, and the cleaning fee will be 500 yuan/time, and the expenses will be deducted from the decoration deposit.

4. All decoration garbage shall be bagged and transported away, and placed at the place designated by Party A; If decoration materials and garbage are not piled up at the designated location, or public parts and walls are damaged in the process of carrying decoration materials and garbage, and the toilet basin and drainage pipeline are blocked by dumping decoration garbage, once found, Party B or Party C shall pay liquidated damages to Party A for 200 yuan times in addition to cleaning and repairing the damage.

Article 5. Other agreements

1. If Party C cannot be present to sign this Agreement, it shall be signed by both parties, with the same legal effect.

2. If Party C fails to perform or assume the responsibilities of this Agreement, Party B shall assume joint and several liabilities.

3. In case of any dispute during the performance of this Agreement, it shall be settled through negotiation first. If negotiation fails, a lawsuit may be brought to the people's court where the property is located.

4. This agreement shall come into effect as of the date of signature by both parties, in triplicate, with each party holding one copy, with the same legal effect.

Party A: X Property Management Co., Ltd. Party B (signature of the owner):

X. Property Service Center

Year, month, sun, moon, sun.