Engineering construction labor service contract

In a society where people pay more and more attention to contracts, the binding force of contracts on us is becoming more and more obvious. Signing a contract is an important measure to reduce and prevent disputes. So how is the general contracting drafted? The following is a sample project construction labor contract (generally 6 copies) that I have carefully sorted out, hoping to help everyone.

1 Employer of engineering construction labor contract (full name): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (full name): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this building project and conclude this contract.

I. Overview of the Project

Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project approval number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Source of funds: self-raised funds

Second, the scope of project contracting

Scope of contract: all the labor, materials, equipment, construction machinery and services required for the construction and completion of civil works, installation works and embedded works, except the subcontracted works agreed by the Employer in the construction drawing (some materials and steel structures are provided by the Employer).

Third, the term of the contract.

Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (The actual commencement date is subject to the commencement order issued by the Employer and the Supervisor);

Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total calendar days of contract term: _ _ _ days.

Fourth, quality standards.

Engineering quality standard: qualified (in which the main body is high-quality structure)

Verb (abbreviation of verb) contract price

Amount (in words): _ _ _ _ _ _; The budget price is about _ _ _ _ ten thousand yuan.

Composition of intransitive verb contract documents

This contract document includes:

1, as agreed in this contract;

2. Drawings;

The written agreement or document on project negotiation and change between both parties shall be regarded as an integral part of this contract.

Seven. Breach of Contract, Claims and Disputes

1. The Employer and the Contractor shall abide by the above agreement. If one party violates the agreement and causes economic losses to the other party, it shall pay corresponding compensation.

2. Any dispute arising from the performance of this contract shall be settled by both parties through negotiation or a third party shall be invited for mediation. If negotiation or mediation fails, both parties agree to apply to the _ _ _ _ _ _ _ _ _ Arbitration Commission for arbitration.

Eight. Engineering settlement

1. within _ _ days after the project completion acceptance report is approved by the employer, the contractor shall submit the completion settlement report and complete settlement data to the employer, and both parties shall adjust the project completion settlement according to the contract price agreed in the agreement and the contract price agreed in the special terms and conditions.

2, the general formula of the project price completion settlement is:

Project payment for completion settlement = budget (or budgetary estimate) or contract price+adjustment amount of budget or contract price under construction-prepaid settled project price-quality guarantee fund.

3, the developer and the contractor agreed in the construction project contract quality deposit, the developer set aside from the project payment payable, to ensure the contractor's funds for defect maintenance of the construction project during the defect liability period, and the quality deposit is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. In words _ _ _ _ _ _ _ _ _ _ _ _ _ Yuan only (RMB).

Nine. Entry into force of contract

1. Date of contract conclusion: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. ______________________________

2. Place of conclusion of the contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

3. This contract shall come into effect after being signed and sealed by both parties. This contract will be automatically terminated after the provisions of the terms of the project quality warranty signed by both parties are met and there is no dispute.

Employer: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Legal Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Legal Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Construction Labor Contract 2 Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction project of this construction project and concluded this contract.

I. Overview of the Project

Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Second, the scope of project contracting

Contract scope: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Third, the term of the contract.

Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Completion date of the Property: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total calendar days of the contract period: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Fourth, the construction period delay

If the construction period is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party A. ..

1. Design change and engineering quantity increase;

2. Water, electricity and gas cut-off for more than _ _ _ _ _ hours within one week due to reasons not attributable to Party B;

3. Force majeure natural conditions;

Verb (abbreviation for verb) project completion

Party B must complete the project according to the completion date agreed in this agreement. If the project cannot be completed according to the completion date agreed in this agreement due to Party B's reasons, Party B shall be liable for breach of contract.

Engineering quality standard of intransitive verbs: subject to _ _ _ _ _ County Quality Inspection Bureau (excluding material quality).

Seven. Contract price

Amount: RMB per square meter of construction area × total square meter of construction area.

Advance payment for the project: ￥ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Payment on completion date: _ _ _ _ _ _ _ _% of the remaining total amount.

Settlement of project funds: after acceptance of the project completion, there is no project quality problem within _ _ _ _ _ months, and the project funds will be settled.

Eight. Documents constituting the contract

1. The provisions of this contract.

2. Standards, specifications and related technical documents.

3. drawings.

The written agreement or document on project negotiation and change between both parties shall be regarded as an integral part of this contract.

Party B promises to Party A to carry out the construction and completion in accordance with the contract, and undertake the responsibility of project quality warranty within the quality warranty period.

Party B must submit a written application to Party A _ _ _ _ working days in advance for the building materials needed in the construction process, and Party A shall provide them in time without delay to ensure the smooth flow during the construction period. If Party B causes unnecessary waste in the construction process, it shall compensate according to the market price.

Party A has the right to supervise Party B's project. In the internal structure of pigsty, Party B shall carry out the construction according to Party A's requirements. During Party B's construction, Party A shall not transfer Party B's construction personnel at will.

The original of this contract is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Construction Labor Contract 3 Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

According to the relevant spirit of People's Republic of China (PRC) Contract Law and Regulations on Construction Project Contracts, Party A agrees to contract _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

I. Project Name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Two. Mode of contracting: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Three. Contents of project contracting: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Four. Contract price: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Verb (abbreviation of verb) payment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Six, the total time limit for a project requires _ _ _ _ _ _ _ working days.

Seven. Party A's responsibilities

1. When Party A notifies Party B to enter the site, the construction site shall meet the conditions of three links and one leveling.

2. Party A shall pay the project payment to Party B in time according to the contract payment method. If Party A fails to pay the project payment according to the contract, resulting in the construction failure, Party B may stop the construction, and Party A shall bear the losses of the completed project and all economic losses of Party B.. ..

Eight. Party B's responsibilities

1. Party B shall complete the construction within the time limit agreed in the contract and meet the acceptance requirements.

2. Party B shall be responsible for the project quality problems and construction delay caused by Party B: Party B shall be responsible for repairing the quality problems until they are qualified, and the daily liquidated damages for the construction delay shall be _ _ _ _ _ _ _ _ _ _ _.

Nine, engineering quality, safety and warranty

1. Party B shall carefully construct according to the drawings, and the project quality shall meet the acceptance standard.

2. All safety accidents caused by Party B shall be borne by Party B. Party A shall not bear any responsibility.

3. After the project is completed and accepted, Party B shall be responsible for the project quality warranty for one year.

X. Disputes and solutions

Matters not covered in this contract shall be settled by both parties through consultation. When mediation or mediation fails, the dispute shall be settled by the following methods:

The first solution: the two parties reach an arbitration agreement and apply to the agreed arbitration commission for arbitration; The second solution: bring a lawsuit to the people's court with jurisdiction.

XI。 This contract is made in triplicate, one for Party A and two for Party B, and shall come into effect after being signed and sealed by both parties.

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Construction Labor Contract 4 Party A: _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _

In order to implement _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

I. Project name:

_ _ _ _ _ Annual Fund Project for Large and Medium-sized Reservoirs.

Second, the construction content and scale

1, content: _ _ _ _ _ _ _ _ _ _ human drinking water project.

2. Proportion: According to the design drawings and budget.

Third, the project cost

The total investment of the total project cost is about 340,000 yuan, and the project cost shall be subject to the audit and settlement of the actual acceptance quantities.

4. Contracting method: the work, materials and quality of the project contracted by Party B..

5. Project date: The commencement date is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

The responsibility of party a and party b with intransitive verbs

Party A: Provide construction design drawings on time. During the construction period, Party A will send supervisors to the site for technical guidance and quality supervision from time to time.

Party B: Carry out the construction according to the construction contract and the construction design drawings provided by Party A.

Work, strictly control the quality, and accept the quality inspection and supervision of Party A during the construction period.

All expenses for rework caused by unqualified project quality shall be borne by Party B. ..

Seven. Do a good job in production safety: Party B should pay attention to safety during the construction process. Party A has nothing to do with the accidents of Party B's personnel during the construction process, and Party B is responsible for them.

Eight. Payment method of the project: After the project is completed, Party A will pay 80% of the project cost after organizing relevant departments to pass the acceptance. Pay 15% after the audit department issues the project settlement audit report. Set aside 5% as the project quality deposit. If there is no quality problem in the project after one year, the deposit will be refunded in full.

Nine, this contract shall come into effect as of the date of signature and seal by both legal persons, and will be automatically terminated after the project is completed and accepted and the deposit is returned clearly.

X this contract is made in quadruplicate, two for party a, one for party b and one for the finance bureau.

Party A: _ _ _ _ _ _ County Reservoir Immigration Administration

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Construction Labor Contract 5 Party A: (Employer) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: (Contractor) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, in order to clarify the rights, obligations and responsibilities of both parties in the project contracting and ensure the comprehensive completion of the project tasks, Party A and Party B sign this contract on the principle of voluntariness, equality and mutual benefit through consultation.

Article 1 General situation of the project

(1) Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(2) Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(3) Project scope: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(IV) Total project cost: Both parties determine that this project is a double contract (including frame, internal and external powder, doors and windows, water and electricity installation). The comprehensive unit price is 500 yuan per square meter, and the quantities are settled by the actual recipient. The total project cost is tentatively set at RMB _ _ _ _ _ _ _.

Article 2 Project duration

According to the negotiation between both parties, the construction period starts from May 20th, _ _ _ _ and ends on June 5th, _ _ _ _. Party B must complete the construction within the time limit agreed by both parties. If it is overdue, all consequences shall be borne by Party B.. If the work is postponed due to bad weather or natural disasters, the construction period will be postponed.

Article 3 Project Quality

Party B shall carry out the construction according to Party A's requirements to ensure the project quality.

Article 4 Settlement of project price

(1) The settlement of all engineering costs in this contract shall be handled as follows: The quantities in this contract are provisional quantities, which shall be taken as the basis for final settlement after mutual consent. According to the actual visa settlement.

(II) Settlement and payment method of the project price: 80% of the project quantity of the second floor is paid when the second floor is completed, 100% of the project quantity of the third floor is paid after the third floor is completed, and the final payment is paid after all the projects are completed and accepted by Party A. ..

Article 5 responsibilities of both parties

(I) Party A's responsibilities

1. Party A is responsible for coordinating the neighborhood relations at the construction site to ensure the smooth entry and exit of building materials and equipment.

2. Party A shall provide the water and electricity interfaces required by Party B for construction.

3. After the completion of the project, Party A shall organize special personnel to conduct acceptance within _ _ _ _ _.

(II) Party B's responsibilities

1. Party B shall work out the construction plan according to Party A's requirements and carry out the construction after Party A's consent.

2. Party B shall organize the construction in strict accordance with the construction plan agreed by both parties.

3. Party B shall formulate safety measures and strengthen the safety education for on-site construction personnel. Any accident shall be borne by Party B. ..

4. Party B shall reasonably organize the construction and deployment of mechanical vehicles to ensure that the project is completed on schedule.

5. Party B shall obey the unified command of Party A's on-site representative.

Article 6 Contract disputes

All disputes arising from the performance of this contract shall be settled by both parties through consultation or mediation. If negotiation or mediation fails, please choose one of the following two ways (if arbitration is selected, please indicate the specific arbitration commission).

1. Submit to _ _ _ _ _ _ _ _ Arbitration Commission.

2. Bring a lawsuit to the people's court according to law.

Article 7 Supplementary Provisions

(1) This contract shall come into effect after being signed by both parties, and shall be invalid after completion.

(II) If there are any matters not covered in this contract, both parties may negotiate additional terms according to the specific conditions for both parties to abide by.

(III) Party A and Party B shall hold one copy of the original contract, and the copy shall be filed with the relevant departments for visa in accordance with relevant laws and regulations.

Article 8 Additional clauses

Party A (official seal): _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Construction Labor Contract 6 Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After repeated consultations, Party A and Party B reached the following agreement on the premise of equality, voluntariness and mutual benefit:

First, the way of contracting:

Contracting projects and materials.

Second, the contract price:

Calculated according to the construction area of 530 yuan/square, paid in.

III. Contents of the contract:

1. Foundation works: the pile foundation is within the range of1.5-2m, and the cement threaded steel bars shall be borne by Party B, which is a brick-concrete structure of 0. The height of the first floor is 4.8m, which is calculated as 1.5 times. The second/third floor brick-concrete structure is 3m high and the roof is 3m, calculated as 0.5.

The cement used in the construction is the authentic No.500 cement of Three Gorges Project, and the steel bars used are the national standard, the main girder is the No.25 steel bar, and the bracket is the No.22 steel bar. The structure is subject to the drawing scheme provided by Party A. If there are any quality problems, all responsibilities shall be borne by Party B..

2. Decoration project: interior and exterior walls are mixed with mortar for lighting, indoor lime is marked with cement on the ground in the building for lighting, and genuine hydropower materials are installed in the house. The front tile shall not be less than 20 yuan/m2, and the window price shall be 120 yuan/m2. Party A shall bear the excess.

Fourth, the division of responsibilities:

1. Responsibilities of both parties: Party B is responsible for site construction, production safety and construction personnel management, Party A is responsible for peripheral relations, Party A and Party B are jointly responsible for urban management relations, and Party A is responsible for coordinating the expenses incurred.

2. Safety responsibility: Party B is responsible for the safety construction. In the event of a safety accident, all expenses incurred shall be borne by Party B, and Party A shall not be held responsible.

Verb (abbreviation for verb) calculation method:

The stair area shall be calculated by 1.5 times, but the floor area shall be subtracted. The cast-in-place part shall be calculated as 1.3 times, but the floor space shall be reduced. The rest is actually hard work.

The intransitive verb Party A's requirements for Party B's awning are as follows:

1. Not less than 8- 10 purlins with a weight of 50cm/ purlin.

2. The red tile adopts Anlu high-quality red tile.

3. The eaves on the left and right sides of the building 15-20cm, and the roof top is divided downwards according to 3m, 3m and a half water.

Seven. Payment terms:

Pay 40 thousand for the pile foundation downstairs. After Party A's imported materials are priced in advance, Party B will check and accept them, and issue a receipt for the advance payment of the project, which can offset the settlement of the project after the completion of the pile foundation. 40,000 yuan for the first floor, 40,000 yuan for the second floor cover and 30,000 yuan for the third floor beam. After the remaining part of the building is completed, 90% of the total construction cost will be paid, and the remaining 65,438+00% will be paid in one lump sum at the end of _ _ _.

This contract is made in duplicate, one for each party. Matters not covered in this contract shall be settled by both parties through consultation.

This contract shall come into force as of the date of signing.

Party A (official seal): _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _