20 18 model contract for entrusted supervision

Party A: Party B:

According to the Contract Law of People's Republic of China (PRC), on the basis of the Contract for Entrusted Supervision of Construction Project (hereinafter referred to as the "original contract") signed by both parties through friendly negotiation, and in combination with the specific conditions of this project construction, the terms of the fee supplementary agreement are reached for both parties to abide by.

1 Supervision content: Party B shall undertake the whole process supervision in the construction stage. From the commencement of the project to the delivery of the completion acceptance project, all construction contents such as civil works, installation, decoration, general landscape and roads of the main building and sales center of this project, as well as the quality, progress and cost control management of pipe network, power communication channel, street lamps, landscape and greening in the whole construction stage.

2 supervision cycle:

2。 The supervision period of 1 shall be from the date of commencement of this project to the date of completion of this project and completion of relevant filing procedures, and shall be terminated after the completion of all supervision work related to this project.

2。 2. Calculation period of lump sum supervision fee (i.e. on-site supervision period): the start time of each part of supervision shall be subject to the written notice of Party A. ..

3 supervisors: See Annex 3 for the list of supervisors and specific requirements.

4 Relevant requirements of supervision work:

4。 1 Party B shall supervise this project in strict accordance with the working standards required by Party A. For details, please refer to the attachment 1 Working Standards for Entrusted Supervision Contracts of Construction Projects.

4。 Party B must set up a supervision team for this project according to the list of supervisors listed in Annex 3 to this agreement. The professional supervision engineer must be a person who has the right to sign and is registered and approved by the competent construction department. Supervisors and other supervisors are not included and must be assigned separately. At the same time, the staffing should meet the needs of supervision work in various stages and professions, and meet the needs of on-site project progress. When Party B's supervisors enter the site, they must submit the following documents (copy of professional title certificate, supervision qualification certificate and ID card in A4 format, stamped with the official seal of the company) to Party A's representative. The specific requirements are as follows:

4。 2。 1 chief supervision engineer (engineer title, national supervision engineer, more than eight years working experience).

4。 2。 1。 1 The chief supervision engineer must attend the important acceptance, supervision meeting and important meeting notified by Party A of this project.

4。 2。 2. Professional supervision engineer (engineer or above, with supervision qualification certificate and more than six years of work experience).

4。 2。 3. Supervision (assistant engineer or above, with supervision qualification certificate and more than three years working experience).

4。 2。 4 Party B shall be responsible for the authenticity of the qualification and experience of the supervisor, and shall bear all the responsibilities arising therefrom in case of fraud.

4。 The chief supervision engineer of this project has confirmed that it shall not be replaced without the permission of Party A..

4。 4 For unqualified supervisors, Party A has the right to request replacement, and the replaced supervisors shall be approved by Party A. ..

4。 Party B shall reply and confirm relevant documents (including records, material certificates, certificates of conformity, payment application reports, etc.). ) be completed in time according to the time limit in Appendix 1, and bear the losses caused by the delay of the construction period due to the untimely inspection and approval. Party B shall promptly inform Party A in writing of the relevant contents that need to be replied, and inform Party A of the information about the progress and quality of the project.

4。 6 If the delay of key working procedures and image progress in the weekly project schedule may affect the implementation of the master control plan, Party B shall notify Party A in writing of the inspection situation and the measures taken.

4。 7 In case of any engineering quality and safety accident during construction, Party B shall notify Party A in writing within 2 hours after the accident, and conduct on-site evidence collection.

4。 8 The supervision plan and detailed rules for the implementation of supervision compiled by Party B (including the contents of safety supervision and detailed rules for safety supervision of dangerous sub-projects) must be submitted to Party A for confirmation and approval. Party B's supervisors shall supervise the project in strict accordance with the supervision plan, supervision implementation rules and working standards required by Party A. For specific work contents, standards and time limit, please refer to the working time limit requirements in Annex 1 Working Standards for Entrusted Supervision Contracts of Construction Projects.

4。 9 This Supplementary Agreement

The fourth one. The requirements in Article 8 will serve as the basis for Party A to assess Party B. ..

5 supervision fee:

5。 1 The total contract price of this project supervision is RMB (in words: RMB only), including but not limited to all expenses (including holidays) incurred in the process of project supervision, including but not limited to labor costs, management fees, profits, taxes, overtime, on-site supervision equipment costs, on-site supervision equipment use fees, household acceptance fees, transportation fees, office expenses and other expenses related to this project supervision.

5。 Party A has the right to adjust the specific construction scope according to the site conditions. The adjusted scope, corresponding supervision fee, payment method and supervision period shall be subject to the supplementary agreement signed by Party A and Party B through consultation. If negotiation fails, Party A has the right to choose another supervision unit for this project, and will not bear all economic losses and legal responsibilities.

5。 3 If the project is not started within 7 months from the date of issuance of the bid-winning notice, the total supervision fee of the supervision project is invalid, and the supervision fee shall be negotiated separately by Party A and Party B; If negotiation fails, Party A has the right to choose another supervision unit, and will not bear all economic losses and legal responsibilities.

5。 4 beyond this agreement

The second point. Article 2 The supervision fee for the agreed on-site supervision period shall be collected in the following ways: if it is overdue for less than one month (including one month), the supervision fee and related expenses during the overdue period shall be exempted; If the overdue period is less than one month (including one month), the supervision fee and related expenses during this period shall not be deducted; If the overdue/reduction period exceeds one month, Party A and Party B shall separately negotiate the corresponding increased/deducted supervision service fee.

6 Payment of contract price:

6。 1 Payment method: payment by transfer check.

6。 Before Party A pays the contract price to Party B, Party B shall provide Party A with legal and valid invoices of other service industries equal to the paid amount.

6。 3 Payment Proportion: [Reference Terms]

6。 3。 1 Party A shall pay Party B% of the total supervision fees of each part as advance payment within ten working days after the supervisors of each part enter the site;

6。 3。 2 each part of the construction is plus or minus 0. 00, and within ten working days after the foundation acceptance, Party A shall pay% of the total supervision fee to Party B, and this part of the advance payment shall be converted into a part of the contract price;

6。 3。 3. Party A and the government quality supervision department shall pay% of the total supervision fee for each part to Party B within ten working days after the main project is capped.

6。 3。 4 Party A shall pay% of the total supervision fee to Party B within ten working days after the completion of all parts of equipment installation and overall leveling works;

6。 3。 5. After all parts of the project have been completed and passed the comprehensive acceptance by government departments, Party B shall provide the completion data as required by Party A and complete the completion filing. Within 10 working days after both parties handle the financial accounts of this contract, Party A shall pay 85% of the settlement amount of this contract project to Party B, and deduct the amount payable by Party B (including the portion withheld by Party A) from the financial accounts;

6。 3。 6. Party A shall pay 95% of the total settlement price of all parts of Party B within 10 working days after confirming that the internal acceptance of all parts is qualified (the qualified rate of the parts delivered to customers is 90%);

6。 3。 7 Within 6 months after the handover of all parts of the project, if there is no quality complaint within the scope of supervision, Party A will pay the balance of this part to Party B in one lump sum within 10 working days after confirmation by Party A..

6。 4. During the performance of the contract, or during or after settlement, if both parties confirm that the actual payment ratio exceeds the payment ratio agreed in the contract, Party B agrees to return the overpaid part within 65,438+00 calendar days after Party A sends a written notice. If Party B fails to return the loan on time, Party B shall pay interest to Party A according to the bank loan interest rate for the same period.

7 Rights and obligations of Party A

7。 1 Party A shall exercise Party A's rights to supervise and manage Party B's supervision work according to the relevant provisions of this Agreement.

7。 Party A shall confirm the plans and documents submitted by Party B in time. ..

7。 Party A shall assist Party B in handling cooperation matters related to the supervision of this project.

7。 Party A has the right to enjoy other rights and perform other obligations agreed in this agreement.

8 Rights and obligations of Party B

8。 1 Party B shall supervise the whole process, all-weather and all-round according to the current relevant national laws and regulations, engineering technical specifications, technical standards and inspection and evaluation standards.

8。 Party B shall participate in all aspects of cooperation and acceptance (including household acceptance).

8。 3. Supervise the project agreed in this agreement in strict accordance with the supervision plan, the detailed rules for the implementation of this project supervision approved by Party A, and the attachment 1 Work Standard for Entrusted Supervision Contract of Construction Project.

8。 4. Supervise this project according to the general control plan of project schedule and quality control requirements approved by Party A. ..

8。 5 Supervise the project according to the supervision tenet of "enthusiastic service and strict supervision".

8。 6. Confirm relevant information (records, material certificates, certificates, etc.). ) submitted by the contractor in time. For the specific confirmation time limit, please refer to the relevant annex "Construction Project Entrusted Supervision Contract 1 Work Standard".

8。 7 supervision engineer should have corresponding qualifications. If Party A finds that its supervisor does not have the qualifications agreed in the agreement, it will be regarded as a breach of contract.

8。 8 The working hours of resident project supervisors at the construction site shall not be less than 48 hours/week (the working hours of chief supervision engineer at the construction site shall not be less than 40 hours/week), and they shall not be late, leave early or be absent at will. When the resident supervision engineer leaves the construction site due to special circumstances, he should inform the representative of Party A in advance, and the director will make appropriate temporary deployment of personnel according to the actual situation to meet the needs of on-site supervision.

8。 9. Organize on-site regular meetings, and compile and publish the minutes of regular meetings.

8。 10 work shall be carried out in accordance with the attachment 1 Work Standard for Entrusted Supervision Contract of Construction Project, and Party A shall assess it once a month.

8。 1 1 Party B shall sign the payment application report of the construction unit for confirmation. Please refer to the attachment 1 Work Standard for Entrusted Supervision Contract of Construction Project for details of the confirmation time limit.

8。 12 during the warranty period of this project, Party B has the obligation and responsibility to deal with the project quality problems and other remaining problems together with Party A. ..

8。 13 party b guarantees to inspect and guide the on-site supervision once a month.

8。 14 All personnel of Party B's supervision department clock in to work with Party A. ..

8。 15 Party B has the right to enjoy other rights and perform other obligations agreed in this agreement.

9 Liability for breach of contract:

9。 1 If Party A fails to pay the agreed amount to Party B as agreed in this Agreement, Party A shall pay 0.5 ‰ of liquidated damages to Party B for each day overdue.

9。 2 If Party B fails to complete all the supervision work specified in Annex 1, Party B shall reduce the supervision expenses of relevant parts. If losses or delays are caused to the project, Party A shall also be compensated for the actual losses, but the total compensation shall not exceed the total contract price of the project supervision.

9。 3 If Party B's staff colludes with contractors, subcontractors and manufacturers (suppliers) of materials and equipment and maliciously damages the interests of Party A, they shall pay Party A liquidated damages at twice the actual losses, and the total amount of liquidated damages shall not exceed the total price of the project supervision contract, and shall be investigated for legal responsibility according to law.

9。 4 Party B must set up a supervision team for this project according to the list of supervisors in Annex 3, and be responsible for the authenticity of the qualifications and experience of supervisors; If the supervisors on the list are not on duty or change their qualifications and experience without Party A's consent, they shall pay Party A a penalty of 1% of the total supervision contract price for each discovery.

9。 Party B's supervisor shall not be late, leave early or absent from work at will. If Party B is absent from work without reason, it shall pay liquidated damages to Party A according to the standard of 500 yuan/day.

9。 6 If Party B fails to organize weekly safety and civilized construction inspection, Party B shall pay Party A a penalty of 500 yuan/time.

9。 7 Party B connives at the construction unit, and the safety protection measures of the construction unit can't keep up with the progress of the project. If there are risks in the construction, Party B shall pay Party A a penalty of ￥ 200-500 yuan/time; Party B shall pay Party A a penalty of ￥1000-3,000 yuan/time if it is notified by the superior department or the media and the reputation of Party A is affected.

9。 8. If Party B fails to complete the supervision work within the time limit specified in Annex 1, it shall be handled in the following ways after each discovery:

9。 8。 1 If it does not cause economic losses or delay in construction period, it shall pay liquidated damages to Party A at 1% of the total supervision contract price;

9。 8。 2. If economic losses are caused but the construction period is not delayed, in addition to paying 2% of the total supervision contract price to Party A, it shall also compensate the actual losses, but the total amount shall not exceed the total supervision contract price of this project;

9。 8。 3. If economic losses are caused and the construction period is delayed, in addition to paying 3% of the total supervision contract price to Party A, it shall also compensate the actual losses, but the total amount shall not exceed the total supervision contract price of this project.

9。 9. If leakage (waterproof leakage caused by construction quality problems) is found in the internal acceptance organized by Party A, Party B shall pay a penalty of RMB 500 yuan to Party A for each occurrence. If Party A finds that Party B has not conducted on-site supervision on the construction of important and key parts with on-site requirements, Party B shall pay Party A the liquidated damages of 500 yuan for each discovery.

9。 10 In the internal acceptance organized by Party A, if the first acceptance rate of indoor engineering is less than 85%, Party B shall pay Party A a penalty of RMB 5,000 only.

9。 1 1 Party B failed to carry out the supervision work according to the provisions of annex 1, failed to discover or timely discover the hidden dangers of safety and quality in the project, or failed to report them in time after discovery, and failed to take effective measures, resulting in safety and quality problems in the project. After each discovery, it shall be handled as follows:

9。 1 1。 1 has minor safety and quality problems, and if it can be corrected in time after discovery, it shall pay liquidated damages to Party A at 1% of the total supervision contract price.

9。 1 1。 2. In case of safety and quality problems, if it is found that some rework and repair are needed, and the total construction period is not delayed, in addition to paying 3% of the total supervision contract price to Party A, it shall also compensate the actual losses, but the total amount shall not exceed the total supervision contract price of this project;

9。 1 1。 3. If the contractor fails to implement the project according to the requirements of the drawings and specifications, and once confirmed, or a major safety and quality accident occurs, causing serious economic losses and delaying the construction period, he shall pay Party A the liquidated damages in addition to 5% of the total supervision contract price, but the total amount shall not exceed the total supervision contract price of this project.

9。 12 in case of the liquidated damages agreed by party b in this agreement, party a has the right to directly deduct them from the performance bond, the total supervision contract price or any other benefits deposited by party b in party a, and party a has the right to further recover the unpaid part.

10 performance guarantee:

10。 1 When this agreement is signed, the bid bond paid by Party B shall be converted into the performance bond of this agreement.

10。 2 The performance bond of this agreement shall be returned to Party B in one lump sum within 28 days after the project completion acceptance and supervision work are completed and the supervision filing materials are submitted, and the performance bond does not bear interest.

1 1 reward:

1 1。 1 If Party B discovers the problems in the drawings in time and avoids heavy losses of the project, Party A will give appropriate rewards.

1 1。 2 Party B has carried out supervision in strict accordance with Annex 1 and achieved remarkable results. If the quality of the project supervised by Party B is excellent, and Party A wins the Tianfu Cup or above, Party A will give appropriate rewards.

1 1。 In the process of supervision, if Party B puts forward reasonable suggestions and is adopted by Party A, which reduces the project cost and produces obvious economic benefits, it will be rewarded according to 3% of the actual economic benefits.

12 About delivery

12。 1 Party B's mailing address is, and Party B must ensure that the mailing address is valid and can receive all mails, and shall not change it at will (Party A must be informed one month in advance if there is any change). If Party A needs to notify Party B of relevant matters by e-mail, the above address shall prevail.

12。 Any matters related to Party A that need to be notified to Party B by mail shall be delivered by express mail. If Party B's mailing address is in Sichuan Province, it has been three days since Party A delivered it to the post office or other postal services.

7 (subject to the postmark), it is deemed to have been delivered; If Party B is in China outside Sichuan Province, it shall be deemed as delivered five days after Party A delivers it to the post office or other postal institutions (subject to the postmark).

12。 3 Party B's telephone number is: contact fax number is; Party B shall ensure that the above telephones and fax machines are attended by special personnel, and shall not be cancelled or shut down at will.

12。 4 The telephone number of Party A contacting Party B through the above telephone number will take effect at this time; If Party A contacts Party B at the above fax number, it shall be deemed that Party A has informed Party B of relevant matters 30 minutes after the fax is sent.

13 Other agreed matters

13。 1 This supplementary agreement is a supplement to the original contract. If the original contract is inconsistent with this agreement, this agreement shall prevail.

The terms not mentioned in this agreement shall be implemented according to the original contract.

13。 Matters not covered in this contract shall be settled by both parties through consultation. The supplementary agreement reached and all annexes to this agreement are an integral part of this agreement and have legal effect.

13。 This agreement shall come into force after being signed and sealed by both parties. This agreement is made in quadruplicate, with each party holding two copies. This agreement and its annexes have the same legal effect.

Attachment 1: Work Standards for Entrusted Supervision Contract of Construction Project

Appendix 2: Detailed Rules for the Implementation of Safe and Civilized Construction in Construction Site of Construction Project

Appendix 3: List of Contractors Entrusted with Supervision of Construction Projects

Appendix 4: Configuration Requirements for Commissioned Supervisors of Construction Projects

Appendix 5: List of spot checks and joint spot checks by entrusted supervision of construction projects

Appendix 6: Supervision Work Evaluation Form

Appendix 7: Anti-Commercial * Agreement

Party A: (Seal)

On behalf of:

Party B: (Seal)

On behalf of:

Date of signature: year month day.

Signed on

extreme

ContractNo.: Client:

Supervisor: * * Engineering Consulting Co., Ltd.

This contract is signed by both parties through consultation.

Article 1 The general situation of the project entrusted by the client to the supervisor (hereinafter referred to as "the project") is as follows:

1, project name: * * Bridge reconstruction project.

2. Project location: within the territory of * District.

3. Project scale: the total length of the bridge is 12m, and the width of the bridge is 5m.

4. Total investment:.

Article 2 The meanings of relevant words in this contract are the same as those given to them in the standard clauses in Part II of this contract.

Article 3 The following documents are an integral part of this contract:

1, supervision bidding or letter of acceptance;

2. Standard conditions of this contract;

3. Special terms and conditions of this contract (including supplementary contract).

4. Supplementary and revised documents signed by both parties during the implementation.

Article 4 The supervisor shall undertake the supervision business to the client within the scope agreed in the special terms and conditions of this contract as agreed in this contract.

Article 5 The client shall pay remuneration to the supervisor in the time limit, manner and currency agreed in this contract.

Article 6 This contract shall be implemented from (to) until the date of filing and acceptance of the project completion (the project construction supervision period is calendar days).

Article 7 This contract is made in sextuplicate, with the same legal effect, including three for the entrusting party and three for the supervising party.

Client (signature):

Supervisor (signature): * * Engineering Consulting Co., Ltd.

Domicile: domicile:

Legal representative: (signature) Legal representative: (signature)

Tisso

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Address: _ _ _ _ _ _ _ Postal Code: _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ Legal Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ Title: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC), both parties sign this contract on the basis of equality, voluntariness and mutual benefit, and abide by it jointly.

Article 1 Scope of supervision project

Party A entrusts Party B to use _ _ _ _ _ _ _ _ _ _.

Article 2 Regular expenses

The service period is from year month day to year month day. The total cost is _ _ _ _ _ _ ten thousand yuan.

Article 3 Definition of Clauses

1。 The supervision basis of Party A and Party B is the Trial Provisions on Construction Supervision and other relevant regulations and construction contracts.

2。 Party A is the organizer of this project, responsible for raising funds, land acquisition, resettlement, coordinating relations with the local area, and fully responsible for the construction benefits of this project to the state.

Entrusted by Party A, Party B, as the project supervision unit, shall supervise the project according to this contract, exercise the entrusted rights and responsibilities, and be responsible to Party A.. ..

3。 The scope and content of the project supervision referred to in this contract can be found in the scope and content of services in Appendix B. ..

4。 The supervision fees and payment methods mentioned in this contract are detailed in Appendix D. ..

5。 During the execution of the contract, all contacts between the two parties shall be subject to written notice. Special circumstances can be notified orally first, and then supplemented by written notice. The relevant documents signed by both parties are supplementary documents to this contract. Specific provisions (representative, place, method, etc.). The contact information of both parties is specified in the special terms and conditions.

Article 4 Commencement, completion and alteration of this contract.

1。 This contract shall come into effect immediately after all valid signatures and seals stipulated in this contract are completed.

2。 The supervision unit shall start its service within the time limit specified in the special terms and conditions of this contract.

3。 The supervision unit shall complete the service within the time limit agreed in the special terms and conditions of this contract.

4。 If the situation changes and the contract needs to be changed, it can only be established with the written consent of both parties. Therefore, suggestions made by one party need to be sent to the other party for proper consideration.

5。 If this contract needs to be extended (force majeure, etc.). ), both parties shall sign a supplementary contract or explain in advance in the special terms and conditions.

6。 After the signing of this contract, when the national laws, regulations and policies change, both parties to the contract can make adjustments through consultation and agree in the special terms.

Article 5 Rights and Responsibilities of Party A ..

1。 Party A shall supervise and inspect Party B's project according to the supervision contract.

2。 If Party A thinks that Party B's poor performance of the contract seriously affects the progress of the project, Party A has the right to request the replacement of Party B's key personnel until the contract is terminated.

3。 Changes in major issues such as project duration, quality and cost shall be finally determined by Party A and handled in accordance with national infrastructure procedures.

4。 Party A supports Party B's work and ensures the unity of Party B's responsibilities and rights under this contract. Party A shall provide Party B with the specified equipment, facilities and materials on time according to Appendix C. ..

5。 Party A shall provide Party B with the contract texts, materials, drawings and data required for the supervision work stipulated in this contract. At the same time, the method, number of copies, recycling and confidentiality should be clearly stipulated in the special terms and conditions.

6。 Party A shall be responsible for coordinating the external conditions of the project and its relationship with local authorities.

7。 Party A shall make a decision on the reports and documents decided by Party B submitted to Party A within the time limit agreed by both parties in the Special Terms and Conditions.

8。 Party A shall pay the supervision fee to Party B on time according to Annex D. ..

Article 6 Rights and responsibilities of Party B..

1。 Party B shall enjoy the rights stipulated in this contract and bear all corresponding responsibilities.

2。 Party B must have the skills, prudence and diligence required to perform this contract, and must complete all its duties according to the professional standards of the supervisor.

3。 In the process of supervision, if the supervision unit needs to hire other experts for consultation or assistance, the expenses incurred within the scope of supervision service responsibility shall be borne by Party B; If the supervision service responsibility is exceeded, the expenses incurred shall be borne by Party A after obtaining the written consent of Party A. ..

4。 Party B shall bring the designated equipment, materials and facilities on time according to Appendix C ... The specific use agreement is stipulated in Appendix C..

5。 Party B must dispatch supervisors and project supervision institutions required for supervision work according to Appendix E ... The qualifications and service conditions of its main personnel must be reviewed and agreed by Party A, and Party A shall not refuse without reason. Party A agrees to the project supervision organization proposed by Party B according to the supervision objectives, and determines the chief supervision engineer.

6。 Supervision shall be carried out by the personnel specified in this contract within the specified time limit. In order to ensure the effective implementation of supervision, Party B may make reasonable adjustments during this period. If field personnel are replaced, they shall be replaced by personnel with the same skills, among which the replacement of main supervisors shall be subject to the consent of Party A, and the field supervisors stationed by Party B shall be continuous and stable to ensure the normal supervision work.

7。 Party B has veto power over the quality of this supervision project, and has the right to issue payment vouchers, start, stop, rework and resume work.

8。 The remuneration charged by Party B from Party A is the remuneration of this contract. Party B and its personnel shall not accept other allowances, kickbacks and other remuneration and indirect payments related to this Contract or its obligations.

9。 In the process of supervision, Party B shall not disclose the secrets declared by Party A, nor the secrets provided and declared by the design and contracting units.

Article 8 Mediation and arbitration.

During the execution of the contract, if there is any dispute between Party A and Party B, both parties shall first fully negotiate to solve the dispute on the principle of mutual understanding, trust, equality and mutual benefit. If negotiation fails, either party may apply to the competent supervision department for mediation; If mediation fails, either party may request arbitration according to law. Both parties agree that _ _ _

The Arbitration Commission conducts arbitration. In the process of mediation and arbitration, both parties shall ensure the normal construction of the project.

Article 9 Liability for breach of contract

If the contract is terminated due to Party A's reasons, Party A shall notify Party B at least two months in advance, and bear the liability for breach of contract and pay the agreed compensation fees.

If the contract is terminated due to Party B's reasons, Party B shall notify Party A at least two months in advance, and bear the liability for breach of contract and pay the agreed compensation fees.

If Party A or Party B fails to reply within 15 days after receiving the notice of termination of the contract, the contract shall be deemed to be terminated.

Compensation for breach of contract or other breach of contract shall be specifically agreed by both parties in the special terms and conditions.

Article 10 Party A may reward and punish Party B according to its supervision work. The specific content shall be agreed by both parties in the special terms and conditions.

Article 1 1 Special Terms and Conditions

In view of the characteristics and actual needs of this project, Party A and Party B agree to sign the following special terms and conditions as a supplement to the general terms and conditions of this contract. In case of any inconsistency between the General Terms and Conditions, the Special Terms and Conditions shall prevail. The specific terms are as follows:

1。 Additional services: If Party A entrusts Party B to complete tasks beyond the scope of this contract, Party A shall sign another entrustment contract. If Party A or the contracted construction unit obstructs or delays the service, thus increasing the workload and duration of the service, Party B shall inform Party A of this situation and the possible impact, and Party A shall increase the extra service fee.

2。 Contact information of both parties: the important issue is the letter, and the general issue is telephone or oral, but it must be recorded. The meeting shall be subject to the minutes.

3。 Supervision service period:

4。 During the performance of the contract, if part or all of the contract cannot be performed due to force majeure (flood, earthquake, etc.). ), and Party B is not liable for breach of contract, and is allowed to postpone or partially or completely fail to perform, and both parties shall sign a supplementary agreement.

5。 After the signing of this contract, if the national laws, regulations and policies change, resulting in changes in the supervision fee, the supervision fee of this contract should also be adjusted accordingly.

6。 Party A shall provide Party B with 5 copies of drawings (blueprints) and materials (technical requirements, notices, etc.). ) and technical data related to the supervision project, as well as two copies of the contract signed by Party A and the contractor. Party B shall not disclose the above information to other irrelevant units during the use, and return it to Party A after the project is completed.

7。 When accepting the reports and documents submitted by Party B that need Party A's decision, Party A shall give clear instructions and notify Party B in writing within 7 days.

8。 Party B shall not be held responsible for any work-related accidents during construction.

9。 Liquidated damages: If the contract is terminated due to Party A or Party B, it shall be handled within the time limit stipulated in Article 9 of the General Conditions. If the Contract is terminated due to Party A's reasons, Party A shall pay Party B RMB as liquidated damages. If the Contract is terminated due to Party B's reasons, Party B shall pay Party A RMB as liquidated damages. If Party A's improper decision affects the progress and quality of the project, Party A shall bear the economic responsibility.

In case of violation of Article _ _ _ of the Contract, Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

In case of violation of Article _ _ _ of the Contract, Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

In case of violation of Article _ _ _ of the Contract, Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

In case of violation of Article _ _ _ of the Contract, Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

10。 Reward and Punishment: Party A may reward and punish Party B according to his work achievements. Capital within the scope of _ _ _ _ yuan, fine within the limit of _ _ _ _ _.

In order to promote the construction unit to ensure the progress, quality and safety, Party B may write written materials and suggestions to reward relevant personnel. The specific amount and expenditure method shall be determined by both parties through consultation, and Party B shall accept the supervision of Party A when using it. And make records for future reference.

Article 12 This contract shall come into force as of the date of signing. The original of this contract is in duplicate, with each party holding one copy.

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _