Model civil engineering contract

Civil engineering involves the existence, activities and development of all walks of life in the national economy. Without the space and place for civil construction activities, there would be no existence and development of all walks of life. So how to write the project contract? What do you usually need to pay attention to? The following is a sample project contract that I have compiled for you. Thanks for reading it.

Model civil engineering contract 1

Both parties to the contract:

Employer: _ _ _ _ _ _ (hereinafter referred to as the employer)

Owner: _ _ _ _ _ _ (hereinafter referred to as the contractor)

After full consultation, both parties reached the following agreement:

Article 1: Project Name: Wall Project of Ningxia Baolida Chemical Industry Park

Article 2: Project Location: Baolida Chemical Industry Park, lingwu city, Ningxia.

Article 3 Scope and content of project contracting:

1. Ningxia baolida chemical co., ltd. All requirements in the design drawings: construction projects of the peripheral wall (including foundation works, main works, decoration works, installation works and electrical works).

Article 4: Payment and settlement of project price The payment and settlement of project price shall be implemented in accordance with the Measures for Settlement of Capital Construction Project Price formulated by the People's Construction Bank of China.

A, within _ _ days after the signing of this contract, by the contractor in the construction; Pay the project payment according to the image of the project progress completed every month, and report the progress payment to the examination and approval form before the 25th of each month; If the entry is less than one month, the monthly progress payment will be reviewed and paid to the next monthly report by accumulation.

Second, the employer must pay the progress payment according to the verified progress within _ _ days after receiving the contractor's monthly progress report, and the monthly progress payment of the project shall be settled at _ _% of the total price of the month.

Three, the project price payment reaches 95% of the total contract price, no longer pay according to the schedule, after the completion acceptance, after the expiration of the warranty period, even with interest (financial allocation does not bear interest) one-time payment to the contractor.

4. If the Employer defaults on the progress payment or the final payment, it shall pay the Contractor a penalty of _ _ _ _ _ _ _ _ _ ten thousand yuan.

5. If the employer defaults on the difference between the project payment and the purchased materials, which really affects the progress of the project and causes the contractor to stop working or slow down, it shall be borne by the employer.

Settlement method of intransitive verb contract expenses: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Seven, the contractor within _ _ days after the completion acceptance of a single project, the completion settlement documents will be sent to the employer and the handling bank for review, and the employer will complete the review within _ _ days after receiving the settlement documents. If no written objection is raised at the expiration of the period, the undertaking bank may request the handling bank to allocate funds after examination and approval.

Article 5: Construction Period and Construction Preparation (Commencement and Completion Time)

According to the national time limit for a project quota and use needs, the agreed time limit for a project is _ _ _ days (calendar days), starting from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Two, _ _ days before commencement, the contractor shall issue a notice of commencement to the employer.

Three. In case of any of the following circumstances, the construction period shall be postponed accordingly after the visa of the on-site representative of the Employer:

1. According to the construction preparation regulations, the construction site, water and electricity roads cannot be provided, and obstacles cannot be removed, which affects the construction on the site;

2. Major design changes that are not within the scope of the lump sum coefficient, and the engineering geological data provided are not allowed, resulting in changes in the design scheme or affecting the progress due to the inability to construct;

3. In the process of construction, power failure for more than 8 hours or continuous interruption for more than 3 days (more than 4 hours at a time) will affect the normal construction;

4. The supervision visa is not timely due to the contractor, which affects the construction of next working procedure;

5. Failing to allocate the advance payment, project progress payment or the price difference of purchased materials as stipulated in the contract, which affects the construction;

6. Force majeure factors delay the construction period.

Four. Contractor:

1. Responsible for the laying, management, use and maintenance of temporary roads, temporary facilities and water and electricity pipelines in the construction area; 2. Organize construction management personnel, materials and construction machinery to enter the site; 3. Prepare the construction organization design or construction scheme, construction budget, general construction schedule, mobilization plan (including monthly plan) of materials, equipment, finished products and semi-finished products, and water and electricity utilization plan, and send them to the owner.

Article 6: Engineering Quality Standards

A, the contractor must be in strict accordance with the national construction drawings, documents and construction engineering specifications, procedures and standards, and accept the supervision of the employer's representative.

Second, the contractor must comply with the following provisions in the construction process:

1. The main raw materials, components and electrical equipment provided by the contractor must provide quality certificates in accordance with relevant regulations, or can be used in the project only after passing the inspection;

2. The concealed works must be inspected and accepted by the owner's representative before the next working procedure can be carried out;

3. The contractor shall evaluate the project quality by item, division and unit according to the quality inspection evaluation standard, and send the unit project quality evaluation results to the employer and the quality supervision station in time. After the completion of the unit engineering structure, the intermediate acceptance of the structure shall be carried out in conjunction with the construction unit and the quality supervision station;

4. The contractor shall promptly report the quality accidents in construction to the employer's representative and the local construction engineering quality supervision station. General quality accident treatment results should be sent to the employer and the quality supervision station for the record; The treatment scheme of major quality accidents shall be studied by design units, quality supervision stations, contracting units and other units, and implemented after being signed by design and construction units;

5. After the completion of the project, the contractor shall guarantee the project in accordance with the regulations, and the warranty time shall be calculated from the date of completion acceptance.

Article 7: Contract Format and Supply of Materials and Equipment

1. The materials and machinery used for contracted projects in this contract table shall be provided by the contractor.

Second, the materials and equipment supplied and purchased by the contractor must be accompanied by product certificates before they can be used in the project. If the materials and equipment provided by the contractor need to be reinspected by the Employer, the reinspection shall be allowed. Only after the re-inspection meets the quality requirements can it be used in the project, and the re-inspection fee shall be borne by the party requesting the re-inspection; Do not meet the quality requirements, should be handled in accordance with the relevant provisions, the reinspection fee shall be borne by the material equipment supplier.

Article 8: Obligations of the employer:

1. Party A shall provide _ _ copies of construction drawings to Party B _ _ days before the commencement of construction, and realize "three links and one leveling"; Do a good job of construction permit. (Party A may entrust Party B to do the work of "three links and one leveling" and sign another agreement for implementation)

2. Responsible for organizing the design and construction unit, * * * reviewing the construction organization design, organizing the acceptance work and supervising the project quality.

3 responsible for the timely disbursement of funds according to the agreement.

Article 9 Construction and design changes

1. The design drawings, specifications and relevant technical data delivered by the Employer shall serve as an effective basis for construction. Before construction, the owner shall organize design disclosure and tripartite joint review, and form joint review minutes as supplementary basis for construction. The employer and the employer shall not modify it without authorization.

2. If design errors or serious irrationalities are found during the construction, the contractor shall promptly notify the Employer in writing, and the Employer shall study and determine the modification opinions or change the design documents in time together with the design and other relevant units, and the contractor shall carry out the construction according to the modified or changed design documents.

3. On the premise of ensuring the engineering quality and not lowering the design standard, the contractor puts forward reasonable suggestions to modify the design and process, which will be implemented with the consent of the employer, the design unit or the relevant technical department, and the saved value will be distributed according to the provisions of the state.

4. If the Employer needs to change the design, the original design unit must issue a formal notice of change and modify the drawings before the Contractor can implement it. Major modification or cost increase must be negotiated separately, and the contractor can only implement it after obtaining the investment implementation certificate and complete technical data and design drawings.

Article 10: obligations of the contractor

1. Responsible for material supply according to the agreement.

2. Prepare the construction organization design and construction image schedule. Party B shall submit two copies to Party A five days before the commencement of construction.

3. Organize the construction according to the construction drawing and finish it on schedule.

4. After completion, the completion data shall be sorted out and submitted to Party A within 5 days as required.

5. Ensure the construction quality, in strict accordance with the national construction acceptance specifications.

Article 11 Project acceptance

The basis of completion acceptance is the Interim Provisions on Completion Acceptance of Capital Construction Projects, Code for Construction and Acceptance, Standard for Quality Inspection and Evaluation of Construction and Installation Projects promulgated by the state, as well as the provisions on completion acceptance formulated by relevant departments in the State Council, construction drawing design instructions and construction technical documents. Within the specified warranty period, all quality accidents and quality defects caused by construction shall be guaranteed by the contractor free of charge. Warranty conditions, scope and duration shall be implemented in accordance with the Measures for Warranty of Construction Projects (Trial) issued by the Ministry of Urban and Rural Construction and Environmental Protection (84) No.79.

Article 12: Liability for breach of contract and reward clauses

A, the project quality does not conform to the provisions of the contract, responsible for free repair or rework. If the delivery is delayed due to repair or rework, the overdue penalty shall be paid.

2. If the project cannot be delivered within the time limit stipulated in the contract, the Employer shall punish the Contractor for 5000 yuan for each day of delay.

Article 13: Supplementary Articles

1. This contract is in duplicate, with annexes. Party A and Party B each hold one original, and the other copies shall be submitted by the Employer to the handling bank, the local industrial and commercial administrative authority and the competent construction department for the record. According to the regulations, the authentication (notarization) contract must be handled and sent to the industrial and commercial and notary departments where the building is located for authentication (notarization).

2. This contract shall come into effect after being signed by representatives of both parties and stamped with official seals or special seals for the contract. If it is necessary to apply for certification (notarization), it will take effect from the date of completion of certification (notarization); The project completion acceptance meets the requirements and will be terminated after the project payment is settled.

III. After the signing of this contract, if both parties need to propose amendments, a supplementary agreement can be signed as a supplementary contract to this contract after consultation between both parties.

Article 14 Dispute Resolution If either party violates the provisions of this contract and cannot reach an agreement through negotiation, it shall be settled by the following () method:

First, apply for arbitration to the economic contract arbitration organ where the employer is located;

Two, to the people's court where the employer is located.

Employer: (Seal) Contractor: (Seal)

Legal representative: _ _ _ _ _ _ Legal representative: _ _ _ _ _ Address: _ _ _ _ _ _ Address: _ _ _ _ _ _ _ Bank: _ _ _ _ _ _ Bank: _ _ _ _ _ _ Account number: _ _ _ _ _ _ _.

Model essay on civil engineering contract II

Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

Party A will contract out to Party B the civil engineering and greening works of the outdoor activity venue of the kindergarten located in the backyard of Beichen Building on Hutian North Road. In accordance with the Construction Law of People's Republic of China (PRC), the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, Party A and Party B, based on the principle of equality and mutual benefit and in combination with the specific conditions of this project, have reached the following contract terms through consultation:

I. Overview of the Project

1, project name: outdoor civil engineering and greening of Beichen Branch of Aiyier Kindergarten.

2. Project location: Houping, Beichen Building, Hutian North Road

3. Building proportion: area

4.2. Contracting method: Contract the project to Party B in the form of contract work and materials. Party B shall ensure the construction quality, construction period, construction safety and completion acceptance of the project.

Third, the project cost:

The total project cost is 1 150000 yuan (in words: one million one hundred and fifty thousand yuan only). Account designated by Party B: 62270757903443 17 Tang Rong Construction Bank.

Four. Scope of contract:

1. This project is subject to all the contents of the construction drawing provided by Party A (the following items are not within the scope of the contract: 1, and interior doors are not required. 2, sanitary ware does not do. 3. Leave a mouth for the heating branch pipe if there is no floor heating. 4, electrical engineering lamps and lanterns don't do weak current, just don't thread. 5, stair railings do not do. 6. The rough wall is not paved, and the cast-in-place roof with thermal insulation layer is changed to tile roof, and the materials and backfill earthwork provided by Party A are provided by Party A.)

2. Party B shall cover the following items:

1), the main project: this project is a brick-concrete structure, and the height is constructed according to the design drawings.

2) Decoration works: ① Cement mortar is used for plastering the interior wall. (2) Exterior wall painting.

Five, the project payment method:

1, the total project cost is paid in one lump sum.

Six, the construction period:

1. Through negotiation between Party A and Party B, it starts from the construction of foundation pile caps to the completion acceptance, that is, from June 2000 to June 2000 10.

2. If the progress of the project is affected by irresistible objective circumstances, the construction period can be postponed accordingly through negotiation between Party A and Party B. ..

Seven. Work and responsibilities of Party A:

1. It is necessary to go through legal procedures such as project construction application, temporary land occupation of roads for construction, and bear the cost of this work.

2. Before the project starts, do a good job of "three links and one leveling", connect the construction water and electricity lines to the construction site, lay temporary transportation roads that meet the construction requirements, and bear the expenses of the above work.

3. Before construction, accurately provide the control points, leveling points and 0.00 positions of the four corners of the building.

4. Before commencement, Party A and Party B shall organize the blue prints.the design and technical disclosure. Construction can only start after a consensus is reached.

5. Party A shall pay the project progress payment according to the project site agreed in the contract. In case of breach of contract, Party A shall bear the responsibility.

Eight. Work and responsibilities of Party B:

1. Party B must have enough building materials and machinery during the construction period to ensure the smooth completion of the project.

2. Party B must carry out the construction according to the drawings provided by Party A and relevant building regulations and mandatory standards. In terms of engineering quality, it is necessary to meet the quality acceptance standards stipulated by the state and complete all the projects within the specified time.

3. During the construction, Party B must obey the supervision of Party A's representative (or supervisor) and strengthen the management of each team member. Improve the awareness of safe construction and do a good job in safe and civilized construction. All losses caused by safety accidents or fights shall be borne by Party B..

4. Party B is responsible for all insurance expenses of workers in the construction unit and construction safety and civilized measures.

5. All building materials are purchased and kept by Party B, and the main building materials can only be used in this project after passing the inspection.

6, the construction of temporary facilities such as temporary enclosure, Party B is responsible for the labor. Party B is responsible for installing the water and electricity pipelines required for the temporary work shed office and construction.

7. Party B shall pay wages and materials to workers on time. If Party B defaults on wages or materials, it has nothing to do with Party A. ..

8, completes the engineering data. Party B shall bear all expenses of the materials submitted for inspection. After the project is completed and accepted, Party B shall handle the engineering materials for Party A as soon as possible, and Party B shall be responsible for the engineering quality or unqualified materials of Party B..

Nine, engineering quality requirements:

1. Party B shall carry out the construction in strict accordance with the current construction acceptance specifications and the design drawings provided by Party A. The next working procedure can only be carried out after the concealed works are accepted by Party A and the supervisor.

2. All unqualified items shall be reworked, and all responsibilities shall be borne by Party B. ..

3. If defects are found in the construction site, Party A and Party B must negotiate with relevant personnel in time and take remedial measures to prevent the loss from expanding and ensure the project quality and smooth progress.

X. Engineering change and engineering settlement

1. In the process of construction, if Party A really needs to make structural changes, it must obtain the consent of the design unit and issue a design change form to Party B before continuing the construction. At the same time as the basis for completion settlement and completion acceptance.

2. Party A shall be responsible for the direct economic losses caused by the rework of some parts due to the untimely engineering changes.

3. If the project content changes, it shall be calculated according to the unit price negotiated by both parties, and the project cost shall be increased or decreased accordingly.

XI。 Project warranty: This project belongs to the warranty period of Party B within one year after completion. During the warranty period, if there are quality problems of Party B, Party B shall be responsible for the warranty .. Problems caused by force majeure or natural disasters or improper use by Party A are not covered by Party B's warranty.

Twelve. If matters not covered in this contract are found during the construction, both parties shall negotiate separately.

Thirteen. This contract is made in duplicate, one for each party. This contract shall come into effect as of the date of signature and seal by both parties.

Party A's signature and seal: Party B's signature and seal:

Date of signing the contract: year month day.

Model essay on civil engineering contract 3

Party A:

Party B: ID number:

Party A hereby signs this construction agreement with Party B in order to complete the construction task contracted by the woodworking team of New Era Project on time with good quality and quantity. In order to clarify the responsibilities, rights and obligations of Party A and Party B, the two parties reached the terms of this agreement through consultation on the principle of equality, mutual benefit and voluntariness, so as to abide by and implement it jointly.

I. Introduction of the Project

Project name:

Project location:

Project content:

Second, the scope of project contracting

Manual digging pile formwork, ground beam formwork, main project formwork (including columns, beams and wall formwork of foundation part), structural columns, coping, lintel and other small component formwork, roof rigid layer formwork, outdoor project formwork (stepping and aproll), formwork, steel pipe and fastener in-site inventory, formwork stacking and inventory after use, and fastener and steel pipe collection and inventory.

Third, the contract unit price

All work within the scope of project contracting is based on the template expansion area (the area calculated according to the calculation rules of the national unified construction engineering foundation quota # # # # #) as the valuation basis of the contracting engineering unit, and the price is RMB # #/m2;

Fourth, the term of the contract.

Start date: year month day.

Completion date: year month day.

Total calendar days of contract duration: days

Verb (abbreviation of verb) quality standards and requirements:

Party B's construction content must meet the requirements of quality standards stipulated in the relevant clauses of the current national construction quality acceptance code, and the requirements of Party A for technical disclosure of a certain operation before Party B starts construction.

The quality of the partial projects constructed by Party B must reach (qualified) standards. If the division and subdivisional works constructed by Party B fail to meet the quality standard requirements stipulated in the relevant provisions of the Code for Acceptance of Construction Quality of Building Projects and the technical disclosure requirements of Party A's operations, they must be reworked immediately until they meet the standards. Labor, materials and machinery costs caused by rework shall be borne by Party B. If adverse effects and construction period delay are caused by rework, Party A shall demand compensation from Party B according to the losses and may impose economic penalties on Party B..

Six, the project payment

The contractor shall be responsible for the construction of this project until the length of the main body exceeds 0.000m, and ten layers of concrete shall be poured. After that, 80% of the project progress payment will be paid according to the monthly progress. Before the pre-acceptance of the project, the project payment shall be paid to 90%. Party B shall pay the performance bond of RMB10,000.00 Yuan to Party A when signing this subcontract, and pay the contract bond of RMB to Party A within five days after entering the site. Return time: 30% within ten days after the main frame arrives at the tenth floor, and 70% within ten days after the theme frame is capped. The performance bond of this contract is interest-free.

Seven. Entry into force of contract

Date of conclusion of the contract: year month day.

Contract signing place:

Both parties agree that this contract will come into effect after being signed and sealed by both parties.

Eight, safety responsibilities and requirements

1, safety construction and inspection

Party B shall abide by the management regulations on production safety in engineering construction, organize the construction in strict accordance with safety standards, accept the supervision and inspection carried out by industry safety inspectors according to law at any time, and take necessary safety protection measures to eliminate hidden dangers of accidents. The responsibility for accidents caused by Party B's ineffective safety measures and the expenses arising therefrom shall be borne by Party B. ..

2. Party B must abide by the construction safety inspection standards, and achieve civilized construction and safe production. All accidents such as injury, death, disease and disability. Everything that happens to Party B in this project shall be borne by Party B (including the responsibilities of the third party), and Party A shall not bear any responsibilities (including legal and economic responsibilities).

Nine, quality warranty

Party B shall undertake the quality warranty responsibility for the project delivered to Party A for use during the quality warranty period according to laws, administrative regulations or relevant national regulations on project quality warranty.

The warranty period of this project is 10 years.

X. Breach of contract and disputes

1, default

1. 1 Party A breaches the contract. When the following happens:

(1) If Party A fails to pay the project payment as agreed in the contract, resulting in the failure of construction, Party B has the right to stop the normal construction of the project;

(2) Party A fails to pay the project completion settlement price without justifiable reasons;

1.2 Party B breaches the contract. When the following happens:

(1) Due to Party B's reasons, the project cannot be completed according to the completion date agreed in this agreement or the extension period agreed by Party A ... If it cannot be completed on time, the liquidated damages payable to Party A due to its breach of contract shall be RMB yuan per day;

(2) If Party B's construction period cannot meet Party A's construction needs, it will be regarded as a breach of contract, and Party A has the right to unilaterally terminate the agreement. Party B shall not have any objection and immediately leave the construction site, and all losses caused thereby shall be borne by Party B. ..

(3) If the quality of the project fails to meet the quality standards required by the relevant national construction quality acceptance specifications due to Party B, Party B must unconditionally repair or replace the unqualified parts. If Party B fails to repair or replace the unqualified parts in time after receiving the notice from Party A, Party A can handle it by itself, and the expenses incurred will be deducted from the quality warranty money deducted by Party B;

(3) Party A will punish Party B by economic means, and Party A can directly pay the remaining project funds of Party B to the migrant workers who are working in Party B's team.

XI。 others

1. Party B must obey the leadership and management of Party A and abide by the rules and regulations formulated by the project department. If there is any violation, it will be handled according to the regulations.

2. All personnel of Party B must abide by the regulations on public security management and various systems and disciplines of the construction unit. If there is any violation, the relevant units will handle it according to the regulations.

3. This Agreement is made in triplicate, with Party A holding two copies and Party B holding one copy. It shall take effect after being signed by the representatives of Party A and Party B, and have the same legal effect. This agreement will automatically expire after the account is settled.

Party A: Party B:

Date: Year Month Day

Clauses related to the civil engineering demonstration contract:

★ Demonstration agreement of construction project contract

★ The latest construction project contract model.

★ 3 Model construction contract

★ Classic construction project contract template

★ Standard Edition of Engineering Contract Template

★ Model construction labor contract

★ There are 3 model articles on the construction project contract.

★ Construction project contract agreement

★ Simple construction contract template

★ Project contract agreement