Aluminum alloy doors and windows installation protocol format

3. Model clauses of aluminum alloy doors and windows installation agreement format

Aluminum alloy doors and windows installation agreement Part I: Aluminum alloy doors and windows production and installation contract

Employer: Hengyang Zhong Yi Real Estate Co., Ltd.

Contractor: (hereinafter referred to as Party A) (hereinafter referred to as Party B)

According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws, regulations and bidding documents, combined with the construction contract and the specific conditions of this project, Party A, Party B and Party C reached an agreement on the manufacture, installation and construction of aluminum alloy doors and windows for the l# 1 # 4 building project in He Xinyuan residential district on the principles of equality, voluntariness, fairness and good faith.

I. Overview of the International Day:

1, project name:

2. Project address: Huaxing Development Zone, Hengyang City

3. Project scale: the area of aluminum alloy doors and windows is about 2 (subject to the completed size of the hole area).

Two. Scope of construction of this contract:

Production and installation of aluminum alloy doors and windows in He Xinyuan residential district 1#-4# building project, including raw material procurement (powder-sprayed aluminum alloy profiles, glass, hardware fittings, rubber strips, etc. ), aluminum alloy doors and windows processing and manufacturing, transportation, on-site coordination, on-site installation, on-site acceptance, maintenance and replacement caused by quality problems, technical guidance and training, and finished product protection. Carry out the construction according to Party A's progress.

Three. Contract price

Length The settlement of this project shall be subject to the agreement signed by Party A and the owner, and the summary of Party B and the owner shall prevail. Party A charges 10% profit, 5.6% tax and 2.4% supporting fee.

2. Party B shall be responsible for the direct expenses, acceptance and other expenses of this project.

Four. Rights and obligations of all parties

1. Rights and obligations of Party A

(1) was appointed as the on-site representative of Party A, and entrusted the supervision company, Party B and Party A to supervise and inspect the project quality, progress and acceptance of concealed works, handle the procedures of design change, visa payment and acceptance, and coordinate the cooperation and collaboration among the construction units on site.

(2) Provide Party B with the site and water and electricity connection points needed for construction, and the construction elevators and scaffolding shall meet the reasonable requirements of Party B's construction, and explain the matters needing attention in use.

(3) Organize the project acceptance as agreed in the contract, and handle the completion settlement within the time limit agreed in the contract.

(4) Party A is responsible for perfecting the data and making all settlement data of aluminum alloy windows.

(5) After the door window frame is installed, Party A shall fill the gap between the door window frame and the wall with cement mortar. ..

2. Rights and obligations of Party B:

(l) Party B, the supervision company and Party A * * * are responsible for supervising and inspecting the project quality, progress and acceptance of concealed works, and coordinating the cooperation and collaboration between the site construction units.

(2) Enter the site for construction as required by Party A, organize the procurement, transportation and protection of semi-finished products in advance, and actively cooperate with the requirements of civil construction progress.

(3) According to the construction safety regulations, technical measures such as construction safety shall be taken to ensure the safety of on-site construction personnel and third parties, and be responsible for the protection of on-site facilities and finished products.

(4) Accept the supervision and management of Party A and the supervision company, and obey the arrangement and construction coordination of Party B's overall project progress.

(5) Carry out the construction in strict accordance with the approved processing drawings and the current national construction and technical acceptance specifications to ensure the project quality and contract time limit.

Five, the construction safety guarantee measures

1, safe and civilized construction, put an end to death and serious injury accidents. In case of casualties and other accidents, Party B shall bear all losses.

2. Carry out the policy of "safety first, prevention first", do a good job in various protection work, and make safety production regular, institutionalized and standardized.

3. Seriously implement various safety management systems, and resolutely put an end to illegal command and illegal operation. Party B shall continue to provide safety education to employees, check them in time and eliminate hidden dangers in time.

4. Obey Party A's management in safety production and civilized construction, and actively cooperate.

Payment method of contract price of intransitive verb

For this project, Party B directly negotiates the payment method with the Tobacco Bureau. Party A deducts 65,438+08% of the project payment according to each payment amount, and the rest is directly paid to Party B by the owner.

Seven. Supply of materials and equipment

1. The specifications and quality of the equipment and materials purchased by Party B shall meet the requirements of national standards, design drawings and this contract, and the brand and place of origin shall be consistent with the tender. Otherwise, Party A and the entrusted supervision company have the right not to accept it. Losses and expenses caused by quality problems of materials and equipment shall be borne by Party B..

2. Agreement on Party B's procurement of materials:

(1) aluminum alloy window profiles are selected from series profiles. The wall thickness of the main profile of aluminum alloy window should be determined by calculation or experiment, which conforms to the relevant national standards. The wall thickness of the window is 1.4 mm.

(2) The appearance color of the profile shall be confirmed by Party A.

(3) The glass is 5+6+5 double white single steel insulating glass, and its technical performance should meet the national or related industry standards. Insulating glass that meets the relevant national standards should be selected according to the technical specifications for architectural glass application and the size and installation position of doors and windows required by specific drawings.

(4) Door and window hardware:

A. holding hands:

B. sliding ratio of casement window:

C. sliding the window pulley:

(5) Doors and windows should be fixed.

(6) The sealing method of the gap between glass and aluminum alloy is as follows

(7) The technical grade, glossiness and appearance quality of various materials shall conform to the design drawings, Party A's requirements and current national industry standards.

(8) The wind pressure resistance, air tightness and water tightness of windows shall comply with the current national and industrial regulations.

Eight. insurance

Party B guarantees to handle accident insurance for all managers and constructors who enter the construction site of this contract project.

IX. Contract Quantity

This contract is made in duplicate, with Party A and Party B holding one copy respectively. ..

X. supplementary provisions

1. Party B must undertake the construction and installation of this project, and shall not be affiliated or subcontracted in any form. Otherwise, once discovered, Party B shall pay liquidated damages to Party A at 20% of the provisional total price of this contract, and Party A shall have the right to terminate this contract unilaterally immediately, and Party B shall also compensate Party A for all losses caused thereby.

2. Project quality: In the monthly comprehensive inspection organized by Party A and attended by the supervision company, the project quality evaluation implemented by Party B must meet the national qualification standards and contract requirements.

Party A (official seal)? Party B (official seal)

Legal representative (signature or seal) Legal representative (signature or seal)

Year, month and day? Date, year and month

Aluminum alloy doors and windows installation agreement Part II: Aluminum alloy doors and windows installation contract Party A: Yongzhou XXX Tourism Development Co., Ltd.

Party B:

Party A and Party B reach an agreement through consultation, and Party B shall undertake the customization and installation of the aluminum alloy window of XXX Hotel, and this contract is hereby formulated.

1. Project name: customized installation of aluminum alloy windows in XXX Hotel.

2. Project address: in XXX Forest Park, XX County, Yongzhou City.

Scope of work: measurement, customization and installation of aluminum alloy window size.

Four. Quantity: tempered glass aluminum alloy window is about 300m2.

Verb (abbreviation for verb) engineering requirements and unit price

1. The window style determined by Party A is customized by Party B, the aluminum alloy frame is brand, the thickness is 1.2mm, and the window glass is 5mm tempered glass.

2. The unit price of customized installation of aluminum alloy windows is calculated according to 280 yuan/㎡ (this price includes main and paving materials, hardware materials, personnel salaries, transportation expenses, etc.). ), and the total price shall be settled according to the area actually measured by both parties at the time of acceptance.

Duration of intransitive verbs: site installation in 20 1 14 10, and installation completed in 2014 10.

7. Payment method and settlement method. After signing the contract, Party A shall pay Party B a deposit of 65,438+00,000 yuan, and pay 40% of the project cost after the installation of the outer frame is completed. After the project is completed and accepted, Party A will make a one-time payment within 15 working days.

Eight. Responsibilities to be performed by Party A

1. Party A shall select the shape of aluminum alloy window and determine its installation position.

2. Party A shall provide the water and electricity required for installation and related cooperation.

3. Party A shall provide Party B with the installation and construction conditions and storage points of window materials.

4. According to the contract, pay Party B the full project payment.

Nine. Party B's responsibilities

1. The product quality and customized quality must conform to the current national engineering quality acceptance specifications and meet the requirements agreed in the contract. If the quality is unqualified, Party B shall bear the losses;

2. Party B shall organize personnel to complete the production and installation of aluminum alloy windows with good quality and quantity according to the requirements of the construction period.

3. Party B shall comprehensively manage the safety in the construction process and take full responsibility for the safety accidents in the production and installation process.

4. Party B shall bear the accommodation, transportation and wages of the production and installation personnel.

5. The warranty period of aluminum alloy window is one year. During the warranty period, if there are any quality problems, Party B shall repair them free of charge within 24 hours after receiving the notice.

X. Matters not covered in this contract shall be settled by both parties through consultation.

XI。 This contract shall come into effect after being signed and sealed by both parties. This contract is made in triplicate, with Party A holding two copies and Party B holding one copy.

Party a:? Party B:

Year, month and day? Year, month and day?

Installation Agreement for Aluminum Alloy Doors and Windows Part III: Demonstration Contract for Aluminum Alloy Doors and Windows Employer: (hereinafter referred to as Party A) Contractor: (hereinafter referred to as Party B) Basis < < And other relevant laws and administrative regulations, this Contract is concluded through friendly negotiation between both parties, so that * * * can abide by it together.

Article 1: Project Overview

1, project name:

2. Project content:

3. Project location:

Article 2: Contract Price

The total cost of this project is about RMB (in words) (see Annex I: Project List).

Article 3: Settlement Method

After both parties sign the contract, Party A will pay Party B 20% of the total contract price as a reserve fund, 50% of the total project price within one week after the window frame is installed and accepted by the supervision unit and Party A * *, 70% of the total project price within one week after the fan and glass are installed and accepted by the supervision unit and Party A * *, and the project will be settled within one week after all the projects are installed and accepted by relevant functional departments. 95% of the total project price shall be paid within one week after settlement, and the remaining 5% shall be used as quality deposit. If there is no quality problem within one year after the completion acceptance, Party A will pay within one week after the expiration of the one-year warranty period.

Article 4: Material Use Agreement

1. Aluminum alloy window profile adopts glue injection and broken bridge series energy-saving profile. The color is subject to the color sample provided by Party A, and the wall thickness of the profile is:

2. Glass is made of hollow glass.

3. Selection of door and window fittings for this project

Article 5: Construction Period

1. The construction period of this project is days. From the date when Party B enters the site (subject to Party A's written notice), the fabrication and installation will be completed along with the construction progress of civil external wall.

2. If the construction cannot be carried out due to Party A's reasons or irresistible factors, the construction period will be postponed;

Article 6: Work of both parties

I. Work of Party A

1, provide the power needed for construction, and the entry of scaffolding, elevators and other door and window projects should meet the starting conditions.

2. Assist Party B to apply to the quality supervision department for inspection, and the expenses required shall be borne by Party A. ..

3. Supervise and inspect the progress and quality of aluminum alloy doors and windows.

Two. Party B's work

1. Party B shall complete the agreed work contents on time according to the construction plan arranged by Party A, abide by various safety and civilized construction systems on the construction site, and obey the command of the site leader of Party A..

2. Carry out the construction in strict accordance with the design and construction drawing of aluminum alloy window provided by Party A and the sample confirmed by the supervisor.

Article 7: Project Quality Requirements and Acceptance Criteria

1, the manufacture and installation of doors and windows should comply with the design and the acceptance standards stipulated by the state.

2, aluminum alloy doors and windows into the site, after inspection, Party B can install construction.

3. After completion, Party B must provide three complete sets of engineering technical data. If the materials do not meet the filing requirements due to Party B's reasons, Party B shall supplement and improve them within the agreed time limit, and the expenses arising therefrom shall be borne by Party B..

3. Party A, the supervision department and the quality supervision department randomly check unqualified products and process practices, and Party B will unconditionally rework them.

Article 8: Liability for breach of contract

Contractor's responsibilities:

1. If it does not conform to the contract due to construction reasons, it shall be responsible for free repair or rework. If the delivery is delayed, the overdue penalty shall be paid.

2, the project can not be delivered within the time limit stipulated in the contract, pay overdue liquidated damages. If losses are caused, Party A shall also be compensated.

Employer's responsibilities:

1. If the contractor fails to complete his own work as stipulated in the contract, the completion date shall be postponed and the contractor shall be compensated for the actual losses caused thereby.

2. If the project is stopped, postponed or reworked due to design changes and design errors, measures should be taken to make up or reduce the losses. At the same time, bear the actual losses caused by Party B. ..

3. If the project fails to pass the acceptance, the Employer shall use it in advance, and the quality problems arising therefrom shall be borne by the Employer.

4. If the project funds are not allocated as agreed in the contract, the contractor's compensation shall be paid according to the bank's regulations on overdue payment.

Article 9: After-sales Service and Warranty

The warranty period is one year from the date of acceptance. If there are quality problems, Party B is responsible for free maintenance, not quality.

Reason, Party B is not responsible for maintenance.

Article 10: supplementary provisions

1. Any dispute arising from the performance of this contract shall be under the jurisdiction of the court in the place where the contract is performed.

2. This Agreement is made in duplicate, with each party holding one copy.

Party A: (Seal) Party B: (Seal)

Entrusted agent:? Entrusted agent:

Account number: Account number:

Bank of deposit:? Bank of deposit:

Year, month, year, month, year

;