Simple Mode of Indoor renovation contract

House decoration is a major event. In order to reduce disputes, a good contract is essential. The following is the Simple Model of Indoor renovation contract that I brought for your reference only. Welcome to read it.

Indoor renovation contract is simple. Employer: _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)

Contractor: _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

According to the Contract Law of People's Republic of China (PRC), Trial Measures for Decoration Management and other principles stipulated by relevant laws, in order to protect the contractual rights and interests of both parties, combined with the specific conditions of this project, the two parties have reached the following agreement, which shall be abided by * * *.

I. Overview and requirements

1, decorate the construction site:

2, decoration construction content:

3. Total price: settled according to the actual area, as follows:

1. includes light industry, and the unit price is RMB _ _ _ _ _ _ _ per square meter, including (bathroom wall tiles, floor tiles, mosaics, shower basin, marble, caulking and cleaning).

2. During the construction period, Party A shall provide the power box, and Party B shall provide the wires from the power box to the specific construction site. The mobile scaffold or ladder used in the ceiling process shall be provided by Party B. ..

4. Party A's requirements for decoration quality:

(1) The decoration quality conforms to the relevant national standards and must be accepted by relevant government departments;

(2) The decoration effect requirements shall be subject to the decoration construction drawing and effect drawing provided by Party A;

(3) Completed according to the decoration time specified by Party A and passed the acceptance smoothly;

Two. Material supply agreement

The materials provided by Party A shall be provided by Party A to the construction site on time, and Party B shall be responsible for transporting the materials to the specific construction site, and the garbage generated by Party B shall be cleaned by itself.

Three. Project quality and acceptance agreement

1, this project implements local standards such as DBJ08-62-97 Technical Specification for Building Decoration Engineering, DB3 1/T30- 1999 Acceptance Specification for Decoration, and the quality evaluation and acceptance standard system of the municipal construction administrative department.

2. The construction drawing of this project is designed by Party A. ..

3. If an accident is caused by Party B, the cost of rework shall be borne by Party B, and the construction period shall remain unchanged.

4. In the process of construction, when Party A puts forward design modification opinions and adds or subtracts engineering projects, it should contact Party B in advance, and the construction of this project can only start after signing the engineering project change order, which will affect the completion date agreed by both parties. If Party A agrees with the workers to change the construction content privately, all consequences shall be borne by Party A, and if losses are caused to Party B, Party A shall compensate.

5, project acceptance. Project acceptance shall be subject to the acceptance of relevant government departments.

Four. Agreement on project price and settlement

1, and the project payment method is as follows:

1. Pay _ _ _% according to the progress of the project, _ _ _% after the completion (acceptance) of the project and the remaining _ _ _% at the end of the year after the acceptance of the project.

Verb (abbreviation of verb) liability for breach of contract

1. If the construction period is delayed or stopped halfway due to Party A's reasons or other construction types, the construction period will be postponed.

2. If the project is completed late due to Party B's own reasons, Party B shall pay liquidated damages to Party A at the rate of _ _ _ _ _ _ _ _.

3. If the construction production is not carried out according to the quality of Party A, all losses shall be borne by Party B, and Party A shall be paid a penalty of _ _% of the corresponding project cost. Party A has the right not to pay the subsequent project funds.

4. If Party B breaches the contract halfway, it shall not only refund the loan paid by Party A, but also compensate the corresponding liquidated damages of _ _% of the total project amount.

5. In the process of construction, Party B shall bear all the responsibilities for personal and property losses caused by Party B, which has nothing to do with Party A. ..

Six, dispute handling methods

In case of any dispute over the quality of the project, both parties shall settle it through consultation. If negotiation fails, a lawsuit can be brought to Changxing County People's Court.

Seven. Alteration and termination of the contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party breaches the contract, the observant party has the right to demand the defaulting party to bear the liability for breach of contract, and can unilaterally terminate the contract immediately.

2. In the process of construction, if either party submits the bid, it must be submitted to the other party in writing. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract can be regarded as termination.

3. During the construction, Party B shall cooperate with other types of work and obey the arrangement of Party A. ..

Eight. Other agreements

1. This contract is made in duplicate, with each party holding one copy, with the same legal effect.

2. This agreement shall come into effect as of the date of signature and seal by both parties.

Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Phone number: _ _ _ _ _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ Phone number

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Indoor renovation contract Simple Mode 2: Employer: _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)

Contractor: _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

According to the Contract Law of People's Republic of China (PRC), the Law of People's Republic of China (PRC) on the Protection of Consumers' Rights and Interests, the Administrative Measures of the Ministry of Construction on Residential Interior Decoration and the provisions of relevant laws and regulations, combined with the characteristics of the construction of family room decoration and renovation project, on the basis of equality, voluntariness and consensus, the following agreement is reached on the relevant matters of the employer's family room decoration and renovation project (hereinafter referred to as this project):

Rule number one. Project overview

1. Project location: _ _ _ _ _ _ _ _ _ _ _

2. Project content (see attached table 1: confirmation table of family room decoration project).

3. Project contracting mode: Both parties agree to adopt the following contracting mode.

(1) Contract and materials of Party B (see Annex III: Details of Decoration Materials Provided by Party B for details)

(2) Part of the materials are contracted by Party B, and part of the materials are provided by Party A (see Schedule 3: Details of Decoration Materials Provided by Party B for details; Schedule 4: Details of Decoration Materials Provided by Party A)

(3) Party B's contracting and Party A's contracting (see Annex 5: Details of Decoration Materials Provided by Party A for details)

4. The construction period of this project is days, and the commencement date is _ _ _ _ _ _ _ _ _ _ _.

5. Contract Price: The project cost of this contract is (in words): _ _ _ _ _ _ _ _ _ _ (RMB: _ _ _ _ _ _ _).

(See Schedule 2: Budget Quotation Table for Family Room Decoration Project for details)

Article 2, the construction drawings

Both parties agree to provide construction drawings in the following ways:

1. Party A shall design and provide the construction drawing in duplicate, one for each party;

2. Party A entrusts Party B to design and provide the construction drawing in duplicate, with each party holding one copy.

Article 3. Obligations of Party A

1. On the principle of not affecting the construction, one day before the commencement, create conditions for Party B to enter the site for construction;

2. Provide water and electricity supply during construction;

3. Coordinate the relationship between Party B and its neighbors;

4. Don't dismantle the indoor load-bearing structure. If it is really necessary to dismantle the non-load-bearing structure or equipment pipeline of the original building, go through the corresponding examination and approval procedures with the relevant departments;

5. During the construction period, Party A still needs to use part of the living room, and is responsible for cooperating with Party B in security and fire control;

6. Participate in the supervision of project quality and construction progress, as well as the completion acceptance.

Article 4. Obligations of Party B

1, during the construction, strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and related quality standards, and complete the project with good quality on schedule;

2, strictly implement the relevant provisions of the construction site management, shall not be a nuisance and pollute the environment;

3. Protect the furniture and furnishings of the original bedroom and ensure the smooth flow of water pipes in the bedroom;

4, to ensure the cleanliness of the construction site, responsible for cleaning up the construction site after the completion of the project.

Article 5, engineering changes

If it is necessary to change the project and construction method, both parties shall reach a consensus through consultation, sign a written change agreement, and adjust the related project cost and construction period (see Schedule 5: Family Room Decoration Project Change Order).

Article 6. Provision of materials

1. For the materials provided by Party A, Party A shall notify Party B before the materials arrive at the construction site, and both parties shall accept and handle the handover procedures;

2. For the materials provided by Party B, Party B shall notify Party A before the materials arrive at the construction site and accept the inspection of Party A..

Article 7, the time limit for a project delay

1. If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after being confirmed by Party A:

(1) engineering quantity change and design change;

(2) Force majeure;

(3) Other circumstances that agree to postpone the construction period.

2. If Party A fails to complete the work it should be responsible for as agreed, which affects the construction period, the construction period will be postponed;

3. If Party A fails to pay the project payment on schedule, the contract period will be postponed accordingly;

4. If the construction period is affected by Party B's failure to start construction on schedule or stop work halfway for no reason, the construction period will not be postponed; If there is any problem with the project quality (including indoor air quality) due to Party B, the cost of rework shall be borne by Party B, and the construction period shall not be postponed.

Article 8. quality standard

1, engineering quality

(1) Both parties agree that the construction quality standard of this project is:

(2) In case of any dispute over the quality of the project during the construction, both parties may apply for the professional testing unit recognized by the construction administrative department to certify the quality of the project, and the relevant expenses in the certification process shall be borne by the responsible person.

2. Indoor air quality

(1) According to the Administrative Measures for Interior Decoration of Residential Buildings. After the project is completed, the indoor air quality shall conform to the Code for Indoor Environmental Pollution Control of Civil Building Engineering (GB50325—200 1).

(2) Party B shall provide Party A with an indoor air quality test report issued by a professional environmental testing unit recognized by the quality and technical supervision department at the time of project acceptance.

Article 9, project acceptance and warranty

1. Both parties agree to check and accept the project quality at the following stages in the construction process:

( 1)_______________;

(2)_______________;

(3)_______________。

Party B shall notify Party A of the acceptance two days in advance, and fill in the project acceptance form after passing the stage acceptance.

2. After the completion of the project, Party B shall notify Party A for acceptance, and Party A shall organize acceptance within two days after receiving the acceptance notice, and fill in the project acceptance form (see Schedule 6: Acceptance Form for Family Room Decoration Project); After the project payment is settled, the handover formalities shall be handled.

3. The warranty period of this project is months from the date of acceptance and signature by both parties. After acceptance and signature, Party B shall fill in the project warranty form (see Schedule 7: Warranty Form for Family Room Decoration).

Article 10 Payment method of project funds

1. Both parties agree to pay the project payment as follows:

(1) After this contract comes into effect, Party A shall directly pay the project payment to Party B according to the following table:

Payment times, payment time and payment amount

Pay _ _ _ _ _ _ _ yuan three days before the first construction;

Pay the progress payment of the second phase of the project _ _ _ _ yuan;

Pay RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

(2) Other payment methods:

2. After the acceptance of the project, Party B may propose the project settlement proposal to Party A and send the relevant materials to Party A. If Party A has no objection within days after receiving the materials, it shall be deemed as agreement. Both parties shall fill in the project settlement form (see Schedule 8: Settlement Form for Family Room Decoration) and sign it. Party A shall settle the final payment of the project with Party B when signing the contract.

Article 11 responsibility for breach of contract

1. If either party fails to perform the contract or violates national laws, regulations and relevant policies and is fined or causes losses to the other party, the responsible party shall bear the responsibilities and compensate the other party for its economic losses.

2. If the contract cannot be performed due to one party's reasons, it shall notify the other party in time and handle the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses.

3. If Party A fails to pay the project payment on time, the other party will pay RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. If the project quality and indoor air quality fail to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for repairing or reworking, and the construction period will not be postponed.

5. If the construction period is delayed due to Party B's reasons, Party B shall pay liquidated damages of _ _ _ _ _ _ yuan to the other party for each day of delay.

Article 12 Ways to solve contract disputes

Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following ways:

1, submitted to the Arbitration Commission for arbitration;

2. Bring a lawsuit to the people's court according to law.

Thirteenth, several specific provisions

1. Party B is responsible for transporting the garbage generated by the project construction out of the construction site and to the designated place, and Party A is responsible for paying the garbage clearing fee (in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. During the construction period, Party A will hand over the house key to Party B for safekeeping. After the project is completed, Party A is responsible for providing new locks, and Party B is responsible for site installation and delivery.

3. During the construction period, Party B's daily working hours are: from _ _ _ to _ _ _ _ _; From _ _ _ _ to _ _ _ in the afternoon.

Article 14 Other agreed matters.

Article 15, supplementary provisions

1. This contract shall come into effect after being signed (sealed) by both parties, and shall be terminated after the performance of the contract.

2. After this contract is signed, the project shall not be subcontracted.

3. This contract is made in duplicate, with each party holding one copy.

4. The annexes to this contract are an integral part of this contract and have the same legal effect as this contract.

Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Phone number: _ _ _ _ _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ Phone number

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Indoor renovation contract Simple Model III Employer: _ _ _ _ _ _ _ (hereinafter referred to as Party A)

Contractor: _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, this contract (including its annexes and all supplementary contracts) is hereby signed for * * * to abide by.

Article 1: Project Overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Room specifications:

Total: the construction area is _ _ _ _ _ _ _ _ square meters.

3. Construction content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

4. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5 Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total days of the project: _ _ _ _ _ _

Article 2: Project Price

The project price (in words) is _ _ _ _ _ _ _ _ Yuan (in words).

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties. See Annex (III) List of Final Accounts of Home Decoration Engineering Materials for details.

2. Regarding the acceptance standard of this project, both parties agree to refer to Zhejiang local standard "Acceptance Standard for Residential Decoration".

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

Article 4: Method of Payment

1. After the contract is signed, Party A shall pay _ _ _ _ _% of the engineering materials and _ _ _ _% of the engineering expenses; When the construction period is over half (_ _ _ _ _ _ _ _ _ _), Party A will pay _ _ _ _% of the second project payment. The remaining _ _ _ _% shall be settled by Party A after the project is completed and accepted. (Note: Construction costs include labor costs)

Party A pays off the project price, and Party B issues a unified invoice, handles the handover to Party A, and issues a decoration project warranty card.

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing the construction change form and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in this contract, Party A shall pay _ _% of the unpaid project price to Party B for each day overdue.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 5: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 6: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 7: Entry into force of the contract

1. This contract shall be sealed by both parties and come into force after being signed.

2. This contract was signed on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Phone number: _ _ _ _ _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ Phone number

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Indoor renovation contract Simple Model 4 Employer: _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)

Contractor: _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.

Article 1: Project Overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Room specification: room type: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. Construction content: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.

4. Entrustment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total days of the project: _ _ _ _ _ _

Article 2: Project Price

The project price (in words) is _ _ _ _ _ _ _ _ Yuan (in words).

1, material _ _ _ _ _ _ _ yuan; 2, labor costs _ _ _ _ _ _ _ yuan;

3. The design fee is _ _ _ _ _ _ yuan; 4, the construction freight _ _ _ _ _ _ yuan;

5. The handling fee is _ _ _ _ _ _ _ yuan; 6. The management fee is _ _ _ _ _ _ yuan;

7. Other expenses (specify content) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

4. All materials and equipment purchased by Party A shall be borne by Party A; Party B shall be responsible for the quality of the project.

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B% of the total materials provided by Party A as the management fee ... After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5: Method of Payment

1. After signing the contract, Party A shall pay% of the engineering materials and% of the engineering cost; When the construction period is over half (_ _ _ _ _ _ _), Party A will pay _ _% of the second project cost. The remaining _ _ _ _% shall be paid to Party A for settlement after the project completion acceptance. (Note: Construction costs include labor costs).

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing the construction change form and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in this contract, Party A shall pay _ _% of the unpaid project price to Party B for each day overdue.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party B shall pay a penalty of _ _% of the working expenses to Party A every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid% of the labor cost of the decoration project price as the lost time fee for each day of delay.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. In the process of construction, if work is stopped due to engineering quality problems and disagreement between the two parties, it will not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.

4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7: Project Acceptance

1. Project quality acceptance, except for concealed works, which need to be accepted by sections. After all projects are completed, Party B shall organize Party A to carry out the completion acceptance. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.

Article 8: Other matters

1. Party A's responsibilities

(1) The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make on-site disclosure to Party B. ..

(2) Secondary decoration project, in which all or part of the house is vacated and obstacles affecting the construction are removed. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

(3) If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood.

2. Party B's responsibilities

(1) should take the initiative to show business license, membership card or construction qualification; The handling salesman must have a certificate of entrustment from the legal representative.

(2) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.

(3) Be responsible for the safety, fire prevention, related certificates and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

(4) Strictly perform the contract and implement the credit period. If the completion is delayed, such as divestiture, slowdown or excuses to induce Party A to advance funds, it will be treated as breach of contract after investigation.

(5) undertake the warranty responsibility within the scope of decoration construction, and the warranty period shall be _ _ months from the date when the project is completed and accepted by Party A. ..

Article 9: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 10: dispute settlement

In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.

Article 11: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 12: Contract comes into effect

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. The supplementary contract has the same legal effect as this contract.

3. This contract (including its annexes and supplementary contracts) is in duplicate, with each party holding one copy.

Party A (signature): _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Phone number: _ _ _ _ _ _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ Phone number: _ _ _ _ _ _ _ _ _ _ _ Phone number

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.