Engineering service subcontracting agreement

Nowadays, many citizens' awareness of rights protection is increasing, and contracts are helping us more and more. Signing a contract can effectively restrain the breach of contract. So the question is, how should we draft the contract? The following is the subcontracting agreement for engineering services that I have compiled for you. Welcome to share.

Subcontracting agreement for engineering services 1

Party A (contractor):

Party B (contractor):

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reached an agreement on the cooperation of labor services in construction projects, and signed this labor service operation subcontract, which both parties shall abide by.

I. Project name:

Second, the project site selection:

III. Contents, Nature and Quantity of the Project:

Fourth, the construction period:

Verb (abbreviation of verb) project supplementary agreement. The original of this contract is in triplicate, one for each party and the other for the construction project where the project is located.

Easy center labor operation sub-center registration for the record. A copy of this contract

Party A holds one copy and Party B holds one copy.

Party A (Contract Seal): Party B (Contract Seal):

Legal representative:

Authorized Agent: Authorized Agent:

Address: Address:

Tel: Tel:

Bank of deposit: Bank of deposit:

Account number: Account number:

Year, month, sun, moon, sun.

Project Labor Subcontracting Agreement II

Party A:

Party B:

In order to ensure the legitimate rights and interests of both parties, according to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and trustworthiness, both parties reached an agreement on the construction of this project and concluded this contract.

I. Construction contents:

1, project name:

2. Project content:

Second, the way of contracting:

1, square meter contract: including equipment, tools and labor/square meter in words:

2. The required tools shall be provided by Party B. ..

3. Party A supplies materials, delivers them every day, and pulls back the remaining materials.

4, management content:

(1) Abide by the company's rules and regulations and obey the leadership and command.

(2) If any worker steals materials from the site in any shift, the contractor shall bear the fines and consequences.

(3) Manage the whole process of the project contracted by the contracting team, that is, all-round management contracting from entry to completion acceptance.

(4) Clean up the construction site in time after the completion of each working face, and pay attention to the protection of finished products. Party B shall compensate for the damage of finished products according to the price.

Three. Term of the contract: from commencement to completion on.

Four. Quality standard: acceptance by Party A.

1, in strict accordance with the design requirements, must meet the specification requirements.

2. If the project quality exceeds the allowable deviation, Party A will severely punish Party B..

3. In case of serious consequences, Party B shall bear all economic losses.

Verb (abbreviation of verb) safety standard: safe and accident-free construction

1, strictly implement the safety operation procedures, and do not violate the rules. Team leader shall make safety disclosure before shift. Seriously study safety, achieve "three no injuries" and put an end to all accidents. In addition to investigating Party B's responsibilities, if there are casualties caused by illegal operation and construction, Party B will be fined according to relevant regulations, and the economic losses and serious consequences caused thereby shall be borne by Party B..

2. Strictly implement the company's safety regulations.

Six, material management:

Based on the unreasonable materials used by Party B, the economic losses caused by the loss and waste of materials shall be borne by Party B, and Party A shall deduct them from Party B's contract fee at the original price.

Seven. On-site management: the construction site is managed by a special person. Check with Party A whether the roof waterproof lightning rod, household windows and other facilities are in good condition before construction, and inform Party A of the original defects in time to avoid unnecessary disputes. If there is any damage during construction, compensation shall be made according to the price. After the work, the construction site should be cleaned up. If Party B fails to clear the expenses arising from other arrangements of Party A, it will be deducted from Party B's contract expenses.

Eight. Payment method: after the putty is scraped, the unit project shall be painted with primer, and Party A shall pay 60% of the total project amount after passing the acceptance, 80% of the total project amount after the external wall painting of both parties is completed, and the balance shall be paid two months after the completion of all projects.

Nine. Liability for breach of contract:

1. All losses caused by the stoppage in the middle shall be borne by Party B, and Party A shall not bear the labor and other expenses that have occurred.

2. The producer (Party B) shall be responsible for the losses caused by other types of work that do not meet the site requirements and violate the working procedures. If Party B stops work without authorization, the indirect losses caused shall be calculated according to the actual expenses and shall be borne by Party B.. ..

3. If Party B fails to complete the contract period, it will be fined 2% of the contract cost for each day of delay.

4. If the construction period is postponed due to Party A's reasons or force majeure.

X matters not covered in this contract shall be supplemented by both parties through consultation.

XI。 This contract is made in duplicate, one for each party, and shall come into effect after being signed by both parties. Conditions for termination of the contract:

1. After Party B completes all indicators as required by Party A and Party A pays the contract fee, this contract will be terminated naturally.

2. If Party A dismisses Party B halfway or Party B stops work halfway, this contract will be terminated.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project Labor Subcontracting Agreement 3

Customer (Party A):

Organizer (Party B):

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B with the house decoration. In order to ensure the smooth progress of the renovation project, this contract is specially signed in accordance with relevant laws and regulations for both parties to abide by.

Article 1: Project Overview

1, project address:

2, room specifications:

3, the construction content:

4. Entrustment method:

5. Commencement date, completion date and total days of the project:

Article 2: Project Price

____________________________________________________________________

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2, the project acceptance criteria:

3. In the process of construction, if Party A has special construction projects or special quality requirements, both parties shall sign a supplementary contract for the increased cost.

4. Party A shall be responsible for the quality of all materials and equipment purchased by it; Party B shall be responsible for the quality of the project.

Article 4: Supply of Materials

1. Party B shall clearly indicate the materials used in this contract. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall be prohibited from being used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. If the arrival of the goods is delayed, the construction period will be postponed and punished according to the delayed construction period.

Article 5: Method of Payment

1. After signing the contract, Party A shall pay% of the engineering materials and% of the engineering cost; When the construction period is over half (_ _ _ _ _ _ _), Party A will pay _ _% of the second project cost. The remaining _ _% shall be settled by Party A after the project is completed and accepted.

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party B shall pay a penalty of _ _% of the working expenses to Party A every day until the working expenses are deducted. If the completion is delayed due to Party A's reasons, Party B shall be paid% of the decoration project price as lost time for each day of delay.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. During the construction, if the work stops due to the disagreement between the two parties due to the quality problems of the project, both parties should take the initiative to ask the mediation or arbitration department of the relevant department to coordinate the handling, and the construction can continue only after the dispute is resolved.

Article 7: Other matters

1, Party A's responsibility

1) It is required to provide the house plan and water, electricity and gas circuit diagram approved by the property management department, or Party A shall provide the house plan and water, electricity and gas circuit diagram, and make disclosure to Party B on site. ..

2) Secondary decoration project, in which all or part of the house is vacated and obstacles affecting the construction are removed. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

2. Party B's responsibilities

1) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the contract requirements, and complete the construction task on time with good quality and quantity.

2) Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

Article 8: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 9: Settlement of disputes

In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If both parties are unwilling to settle the dispute through negotiation, or negotiation fails, they may bring a lawsuit to the court according to this contract.

Article 10: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in writing. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 11: Entry into force of the contract

1. This contract shall come into effect after being sealed by both parties.

2. This contract is made in duplicate, with each party holding one copy.

Party A:

Party B:

Signature:

Signature:

Date of signing:

Date of signing:

Subcontracting Agreement for Engineering Services 4

Entrusting party (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _

ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _ _ _ _ _ _

ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, this contract (including its annexes and all supplementary contracts) is hereby signed for * * * to abide by.

Article 1 General situation of the project

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Specification of the living room: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ square meters.

3. Construction content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 2 Project Price

Project price (amount in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _,

Article 3 Quality requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. Regarding the acceptance standard of this project, both parties agree to refer to Zhejiang local standard "Acceptance Standard for Residential Decoration".

3. In the process of construction, if Party A has special construction projects or special quality requirements, both parties shall sign a supplementary contract for the increased cost.

Article 4 Payment Terms

1. After the contract is signed, Party A shall pay 100% of the engineering material cost and _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ When the construction period is over half (_ _ _ _ _ _ _ _ _ _ _ _ _ _ _), Party A will pay _ _ _ _ _ _ _ _% of the second project cost. The remaining _ _ _ _ _ _% shall be settled by Party A after the project is completed and accepted. (Note: Construction labor costs include labor costs) Party A pays off the project price, and Party B issues a unified invoice to hand over the warranty card of the decoration project to Party A. If Party A fails to pay the price due, it is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall issue a construction change form and notify the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in this contract, Party A shall pay _ _ _ _% of the unpaid project price to Party B for each day overdue.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 5 Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay _ _ _% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 6 Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 7 This contract comes into effect.

1. This contract shall be sealed by both parties and come into force after being signed.

2. This contract shall take effect on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A (Owner):

Party B (Commitment Letter): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project Labor Subcontracting Agreement 5

Party A:

Party B:

In accordance with the Contract Law of People's Republic of China (PRC), Construction Law of People's Republic of China (PRC), Regulations on Quality Management of Construction Projects and other relevant regulations, in order to clarify the responsibilities and rights of Party A and Party B, ensure the safe, civilized and smooth construction of the project, and in combination with the specific conditions of this project, and to clarify the responsibilities of both parties, this contract is signed on the basis of equality and unity.

I. Project name:

Second, the project site selection:

Third, contracting light industry:

IV. Contract Price:

1, dressing room, bathroom ceiling:

Calcium silicate board ceiling, aluminum veneer ceiling (including flat ceiling, irregular ceiling and aluminum grid square pipe ceiling), labor cost: 25 yuan /M2, calculated according to the occupied area.

2. Corridor ceiling: aluminum veneer ceiling, blockboard as lamp trough, and blockboard with calcium silicate board. Labor cost: 30 yuan /M2 is calculated according to the occupied area.

3. If every room has windows, calcium silicate board will be added at the bottom of the joinery board, and the labor cost will be 25 yuan /M2, calculated according to the developed area.

5. Party A is responsible for providing building materials and providing power supply. Among other things, all other machinery and tools are provided by Party B. ..

Six, the time limit for a project requirements:

1, duration:

2. According to Party A's general, monthly and daily construction schedule and the construction tasks assigned by the constructor, Party B shall complete it within the time limit specified in the list. If Party B fails to complete the project on schedule, Party A shall have the right to punish Party B accordingly, with a fine of 500- 1000 yuan for each day of delay.

Seven, quality standards and acceptance requirements:

1. During the construction of this project, Party B shall strictly implement the current national standards and the quality acceptance evaluation standards of this project in the region. After the completion of each construction site or working procedure, Party B shall report to Party A for re-inspection and acceptance, and conduct actual measurement according to the national standard (GB 50300-2001+0) for quality inspection and evaluation standards of this project.

2. According to the Regulations on the Management of Construction Projects, Party B shall be responsible for the quality of the projects contracted by Party A, and Party B must carefully organize the construction according to the technical and quality disclosure of the design institute, Party A, the supervisor and relevant departments. If there is any problem, Party A must obey Party A's rectification opinions and make rectification within a time limit. If Party A fails to make rectification within the time limit, Party A has the right to impose a fine on Party B. Due to Party B's poor construction quality and repeated reminders, Party A has the right to terminate the contract, and Party B shall bear the consequences caused this time.

3. Party B has the obligation to protect all completed projects and finished products on site. If there is any damage, Party B shall repair it to its original state at its own expense.

4. In the self-contracted subdivisional work, there is an obligation to protect the finished product. During the warranty period, if the ceiling is uneven or falls off, Party B shall repair it for free.

5, the overall quality of construction must meet the quality requirements between examples.

6. If the project constructed by Party B fails to meet the above quality standards, safe production and civilized construction, and the construction progress is seriously lagging behind, Party A will impose a fine on Party B. ..

Eight. Payment terms:

Party B shall pay the living expenses during the construction period, 55% after the completion of the construction and 100% after the completion acceptance.

Nine, health:

1, do a good job in the construction site after work every day, clean the environment inside and outside the dormitory, and ensure that the construction site is civilized and tidy, and the living quarters are clean and hygienic.

2. Clean up the garbage after construction.

X. Human safety accidents during the construction period shall be borne by Party B. ..

1 1. Fighting and collective disturbances are strictly prohibited. If it happens, Party A will fine Party B 200-500 yuan each time.

12. This contract is made in duplicate, with each party holding one copy. It will take effect after being signed by both parties. After the expiration of the warranty period, the warranty terms will automatically expire.

Party A: Party B:

Authorized Agent: Authorized Agent:

Date: _ _ _ _ _ _ _ _

Clauses related to engineering service subcontracting agreement:

★ Model project contract agreement

★ Simple engineering labor contract mode

★ Model construction labor contract

★ Model project labor service cooperation agreement

★ Standard labor subcontracting contract template

★ Template project labor service contract agreement

★ The latest labor subcontracting contract mode

★ The latest model of labor contract agreement

★ 3 copies of model clauses of engineering labor outsourcing contract.

★ Engineering Labor Subcontract Sample (2)