Model project package settlement contract

The significance of the agreement is that both parties are in a state of trust or distrust, because the signing of the agreement has legal support. In the process of cooperative performance, the written commitments of both parties are legally based and well documented. The following is the template of the project construction agreement I brought to you. Welcome to read the reference. Let's have a look!

Demonstration Agreement on Settlement of Engineering Package (I)

Party A:

Party B:

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, following the principles of equality, voluntariness, fairness, honesty and credit, and in combination with the specific conditions of this project, both parties have reached an agreement on labor subcontracting through consultation.

A, the construction name:

Second, the construction site:

Third, the way of contracting:

Four. Scope of contract:

This agreement contains 1? The underground garage of 7# building serves under the roof (including the roof) of the main building, and all services are within the scope of the given construction drawings for civil construction, including trench cleaning, setting-out, cushion making, template making and installation above the cushion, round nails and steel wires, steel bar processing and installation, shelf construction, indoor masonry construction, concrete pouring and interior wall plastering.

Materials provided by Party A include: all turnover materials and mechanical equipment, tower cranes, auxiliary materials, consumables, other tools, round nails and steel wires are provided by Party B. ..

5. Start and end date: MM DD YY to MM DD YY. For every day of delay in the normal construction period, RMB 5,000 will be deducted from the project payment, which will be accumulated in turn. If the construction period is delayed for more than 10 days, Party A has the right to arrange another team for construction, and Party B will leave unconditionally.

VI. Construction area and unit price:

1, according to the construction design drawings, calculate the total construction area of this project.

2. The total project area is about16000m2.

3. Construction contract price: 2 18 yuan per square meter, excluding tax.

4. The total construction price is about 348,000 yuan.

Seven. Payment terms:

Without advance payment, Party A shall pay 70% of the project cost to Party B within 5 days after the completion of all the contents of this agreement; Pay all the remaining construction funds within three months.

Eight. Responsibilities of both parties:

Party A's responsibilities:

1. Provide Party B with complete drawings and exchange drawings. If there is any change, Party B shall be informed as soon as possible to avoid unnecessary losses. If Party A fails to notify Party B in writing in time, Party A shall be responsible for the losses caused thereby.

2. Strictly control the construction quality, and order unqualified construction to be rectified within a time limit, otherwise all losses caused thereby shall be borne by Party B. ..

3. Provide Party B with electricity, water, water, living space and beds for on-site construction and living.

4. Coordinate the construction contractors to ensure that the construction materials are supplied to the site in time and correctly. If the construction period is delayed, the responsibility shall be borne by Party A..

5. Ensure that Party B pays the project payment on time and stops work for 5 days every month. Party A shall be responsible for the lost time and the construction period will be extended.

6. Provide Party B with information on construction geology and underground pipelines at the construction site, and be responsible for the authenticity and accuracy of the information.

Party B's responsibilities:

1, form an excellent construction team, complete with all kinds of technical personnel, management personnel and working tools, equipped with full-time personnel responsible for on-site coordination, safe and civilized construction; The main person in charge guarantees to eat and live at the scene.

2. Party B must obey the command of Party A's management personnel, strictly abide by the rules and regulations of the site, and shall not conflict with the competent department and relevant functional departments; The rectification notice to relevant departments must be completed on time.

3. Strictly implement special types of work, such as welders and electricians.

4. Strictly standardize the construction to ensure that all subdivisional works meet the standards, and Party B shall bear any fines caused by quality progress, safe and civilized construction and human factors.

5. Pay attention to safety during construction to prevent casualties.

Nine, building safety construction production target commitment:

1, put an end to major safety accidents and zero fatal accidents.

2, put an end to major equipment, fire accidents.

3. Safe production and civilized construction shall be implemented simultaneously with Party A and the construction agreement.

X. contents of the guarantee agreement:

1. Party A must pay the safety insurance premium for the laborers. In case of casualty accident during construction, all expenses within 10000 yuan shall be borne by Party B, 80% of the part exceeding 10000 yuan shall be borne by Party A, and 20% of the insurance premium paid by the insurance company shall be borne by Party B, so as to offset the casualty expenses first. If it is caused by a third party, the responsibility and all expenses shall be borne by the causing party, which shall be settled by Party A through coordination.

2. Party A and Party B must consciously abide by and implement the Construction Safety Inspection Standard of the Ministry of Construction and related specifications, and consciously study and abide by the laws, regulations, norms, standards and regulations on safety production promulgated and implemented by the local government, relevant safety construction regulations and industry authorities, so as to effectively protect the safety and health of construction personnel. Party A shall ensure the safety protection of the main building.

3. Party B shall have a safety management organization system, including leaders in charge of safety production, full-time and part-time safety officers at all levels, safety operation rules for various types of work, assessment system for special operations personnel with certificates, post responsibility system for safety production at all levels, regular safety inspection system and safety education system.

4. Party B must implement the following safety management system:

(1) According to the construction content and characteristics, Party A and Party B shall make safety technical disclosure, with disclosure materials, one for each party.

(2) Party B must implement the system of safety education and training at all levels and work with certificates.

(3) Party B's technical personnel in charge of production must undergo safety training, pass the examination and obtain the subcontractor's safety qualification certificate before organizing construction.

(4) Party B's foreman, technicians, mechanical operators and other department heads, as well as various professional safety management personnel and other department heads must receive safety technical training and hold relevant certificates.

(5) All workers of Party B shall receive safety education when they enter the site, and they can enter the site for construction only after they are qualified.

(6) The configuration of Party B's special operators must meet the construction needs, and Party B must hold a temporary operation certificate for special operations issued by the labor department and hold relevant certificates.

(7) Party B must establish its own regular and irregular safety production inspection system according to the requirements of Party A, and strictly implement it.

(8) Party B must set up full-time security personnel, and implement daily safety production inspection system, foreman and monitor follow-up inspection system and team self-inspection system.

(9) After the construction operation is changed, Party B must implement safety protection measures, equipment acceptance system and handover inspection system.

(10) Party B must implement safety measures.

Eleven, the civilized construction and personnel behavior management:

1. Party B must abide by the management regulations of site safety and civilized construction and meet the requirements of site standardized layout.

2. Party B shall take all reasonable measures to prevent its workers from engaging in any illegal or disturbing public order, otherwise all losses and expenses caused thereby shall be borne by Party B. ..

3. Party B's workers and managers should behave in a civilized manner, behave in a standardized way, abide by rules and regulations, be polite to others, and prohibit drinking and making trouble during working hours.

Party A (signature): Party B (signature):

Date: Date:

Model Agreement on Settlement of Engineering Package (2)

Owner (hereinafter referred to as Party A): Tel:

Construction Team (hereinafter referred to as Party B): Tel:

In the spirit of friendly cooperation and in accordance with the Agreement Law and other relevant laws, Party A and Party B sign the following agreement on the basis of equality and fairness:

I. General situation of construction

Construction name:.

Second, the project quantity and price

1, unit price: RMB/m2.

2. Project cost: RMB.

3. If it is necessary to increase the engineering quantity, negotiate.

3. Payment method: cash payment.

Fourth, design.

Party A shall provide Party B with a set of drawings and construction plan.

5. Materials and water and electricity shall be provided by Party A. ..

Sixth, the construction period

From year month day to year month day, the construction period is days.

Seven, material transportation

Party A is responsible for the vertical transportation conditions of materials on the construction site.

Eight. Construction machines and tools shall be provided by Party B. ..

9. Party B shall repair the quality problems caused by Party B's construction free of charge.

X. Any safety accident during construction shall be borne by Party B. ..

Xi。 Agreement dispute

In case of any dispute, Party A and Party B shall first settle it through consultation. If negotiation fails, they can bring a lawsuit to the court where the dispute is located.

This agreement is made in duplicate,

Party A and Party B each hold one copy.

Party A (signature): Party B (signature):

Date: Date:

Demonstration Agreement on Settlement of Engineering Package (3)

Employer (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After friendly negotiation, Party A decides to entrust Party B with the house decoration. In order to protect the legitimate rights and interests of both parties, combined with the specific conditions of this project, the two parties reached the following agreement for common compliance.

I. Overview of the Project

1. Decoration construction site: _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. House structure: Fangxing apartment with a construction area of _ _ _ _ _ _ square meters.

3. Method of contracting: _ Contractor.

4. Duration: from _ _ _ _ _ _ _ _ _

Second, the project price and settlement agreement

1. Total project price: ￥, in words (RMB): _ _ _ _ _.

2. The project payment method is as follows:

(1) For the first time, pay 50% of the total project cost before construction after signing the agreement, totaling _ _ _ _ _ _ _ _.

(2) For the second time, when the construction period is over half, 40% of the total project cost will be paid, totaling _ _ _ _ _ _ _ _.

(3) Pay 10% of the total project cost on the day of completion acceptance for the third time, totaling _ _ _ _ _ _ _ _.

(4) The warranty period of the project is two years. The warranty period is calculated from the date of signing the completion acceptance.

Three. Material supply agreement

1. Materials supplied by Party A: The materials and equipment purchased and supplied by Party A for this project shall be qualified products that meet the design requirements, and shall be supplied to the site on time, and Party B shall go through the acceptance formalities.

2. The decoration materials and equipment purchased by Party B from Party A shall be used for the residential decoration agreed in this agreement, and shall not be used for other purposes without Party A's consent ... If Party B violates this regulation, Party B shall compensate Party A at twice the price of the misappropriated materials and equipment. The losses caused by improper storage shall be compensated by Party B. ..

3. The materials and equipment provided by Party B shall not be used if they do not meet the quality requirements or have different specifications. If it has been used, Party B shall be responsible for the losses caused to the project. If the materials and equipment provided by Party B are fake and shoddy goods, Party A shall be compensated twice the price of the materials and equipment.

Four. Project quality and acceptance agreement

1. If the unqualified materials and equipment provided by Party A affect the project quality, the rework cost shall be borne by Party A, and the construction period shall be postponed. In case of quality accident due to Party B, the rework cost shall be borne by Party B, and the construction period shall remain unchanged.

2. The construction unit must carry out the construction in accordance with the current construction quality acceptance specifications, ensure the construction quality, and correct the construction quality problems in time. If quality problems are found during the completion acceptance, the construction unit shall immediately rectify them, and the owner has the right to refuse to pay labor costs before the rectification requirements of the owner are met. During the construction process, when Party A puts forward design modification opinions and adds or subtracts engineering projects, it shall contact Party B in advance, and the engineering construction can only be carried out after both parties agree. The result affects the completion date, and both parties agree.

3. Acceptance of Works Both parties shall handle the acceptance procedures of concealed works and intermediate works in time.

4. Project completion: Party B shall notify Party A for acceptance three days in advance, and Party A shall organize acceptance within three days after receiving the notice. If Party A fails to organize the acceptance within the specified time, it shall notify Party B in time and set another acceptance date.

Five, safety production and fire prevention agreement

The construction drawings or practice instructions provided by Party A and the construction site shall meet the requirements of fire prevention and accident prevention, mainly including the smoothness and qualification of electrical lines, gas pipelines, tap water and other pipelines. During the construction process, Party B shall take necessary safety protection and fire control measures to ensure the safety of construction workers and nearby residents, and prevent accidents such as pipeline blockage, water leakage, power failure and damage to houses and articles of nearby residents. In case of the above situation, it shall be the responsibility of Party A, and Party A shall be responsible for and compensate; Where Party B is responsible, Party B shall be responsible for repair and compensation.

Other matters of intransitive verbs

1. Before the commencement of construction, Party A shall provide Party B with the construction drawings approved by the property management department, and make on-site disclosure to Party B. At the same time, Party A shall provide Party B with the necessary conditions such as water and electricity required for the construction, and explain the matters needing attention. Do a good job in the construction of temporary use of public parts and the coordination of neighborhood relations.

2. Party B shall participate in the on-site disclosure of the construction drawings or instructions organized by Party A, organize the construction as required, complete the construction tasks with good quality and quantity on schedule, and solve all matters for which Party B is responsible, and Party B shall recognize its actions. Without the consent of Party A and the approval of the local housing management or property management department, the original building load-bearing structure, various equipment and pipelines shall not be dismantled and modified at will.

Seven. responsibility for breach of contract

1. If the construction period is delayed or suspended due to Party A's reasons, Party A shall compensate Party B for the losses caused by suspension or slowdown, and Party A shall pay RMB to Party B for each day of suspension; If Party A fails to make payment according to this agreement, Party A shall pay RMB as liquidated damages for each day overdue.

2. If the completion of the project is delayed due to Party B's reasons, Party B shall pay _ _ _ _% of the payment made by Party A as liquidated damages for each day overdue.

Eight, dispute handling methods

Any dispute arising from the execution of this Agreement shall be settled through friendly negotiation. If negotiation fails, a lawsuit may be brought to the people's court.

Nine. Alteration and dissolution of the agreement

After this agreement is signed by both parties, both parties must strictly abide by it.

X this agreement is made in duplicate, one for each party, with the same legal effect.

Party A (signature and seal):

Party B (signature and seal):

Year month day:

Model Agreement on Settlement of Engineering Package (4)

Owner (hereinafter referred to as Party A):

Construction Team (hereinafter referred to as Party B):

In the spirit of friendly cooperation, Party A and Party B, in accordance with the People's Republic of China (PRC) Agreement Law and other relevant laws, combined with the characteristics of family room decoration, signed the following agreement on Party B's contract for the renovation project of Party A's Shouyang Mashou Junting Villa and 17# building on the basis of equality, voluntariness and consensus.

I. Overview of the Project

1, project address:

2. Decoration scope:

(1) Building No.71townhouse (four bathrooms, one kitchen, three bedrooms and two halls) with a construction area of 223m2;

(2) Building No.6 1 Villa (three bathrooms, one kitchen, four bedrooms and two halls), with a construction area of190m2;

(3) The first and second floors of17 # building, with a construction area of 374.86㎡.

2. Contracting method: Party B contracts and all materials are supplied by Party A. ..

Third, the project cost and settlement method

1. Labor cost of cleaning package: different unit prices are determined through consultation according to different types of work (see annex 1), including carpentry, bricklaying, garbage removal fee and material handling fee.

2. Fixed project unit price, that is, the project unit price in the quotation remains unchanged, and the project cost is calculated according to the actual completed quantities.

Four. mode of payment

1. After the workers enter the site for construction, they shall pay the living expenses in 20 yuan per person per day according to 10 day. (According to the attendance sheet of field staff)

2. After the completion of the project, Party B can deduct 5% of the quality deposit according to the agreement only after the on-site engineer of Party A, the general office of the headquarters, the purchasing and warehousing department, the agreed cost department and other relevant departments jointly review and agree. The warranty period shall be paid in one lump sum within two years without quality problems, and the warranty period shall be calculated from the date of project completion.

Verb (abbreviation for verb) architecture

1. Party A shall provide Party B with a set of drawings and be responsible for disclosure;

2. Where there is no indication in the drawings, Party B shall draw a sketch or discuss with Party A for approval before construction;

3. Each professional working procedure (concealed engineering, structural engineering, carpentry, bricklayer) of the construction project can be carried out only after it is approved by Party A, and the branch project acceptance form can be filled in (see Annex 2);

4. The construction quality will be checked and accepted according to the content specified in the Acceptance Standard for Residential Decoration.

Intransitive verb material

1. Party B shall provide Party A with a material procurement schedule 8 days in advance, and Party A shall timely purchase materials for the use of the construction team within 7 days, and both parties shall bear their respective responsibilities for the construction delay and economic losses caused thereby;

2. Without the consent of Party A, Party B shall not purchase materials by itself. If it has been purchased, Party A has the right to unconditionally refuse to use the materials and refuse to pay the materials fee;

3. Party B shall check and accept the quality of building materials purchased by Party A, and raise quality problems with Party A in time, and have the right to refuse to use them. If Party A insists on using it, it shall request Party B in writing, and the losses caused by the quality of materials shall be borne by Party A;

4. Party B shall assist Party A to receive the goods and check the accuracy of the quantity and accessories;

5. Party B shall properly keep the materials and prohibit other personnel from entering the site;

6. Party B shall protect the finished products after construction;

7. Without Party A's permission, Party B shall not take any building materials out of the house. If theft is found, it will be deducted from the labor cost by double the material price.

Seven, time limit for a project

1, completed within 45 days after the construction conditions are met. If the construction period is delayed due to Party A's reasons, the construction period will be postponed; If the construction period is delayed due to Party B's factors, Party A may deduct Party B's labor cost of 300 yuan/day.

2. According to the requirements of Party A's total time limit for a project, Party B shall prepare the divisional project schedule.

Eight, material loss and treatment

1. The material loss rate is: 2% for ceramic tile, 0/.5% for stone, 7% for aluminum gusset plate, 6% for wood and 6% for keel. The losses incurred by Party B in the decoration process are greater than the actual losses of materials, and Party A has the right to deduct the excess from the settlement.

2. After Party A's materials arrive at the construction site, any construction personnel of Party B shall unload and carry them unconditionally.

Nine, garbage removal

1, garbage bagging;

2. Garbage should be cleaned up every day;

3. The garbage shall be transported by Party B to the garbage dump designated by Party A. ..

X. Labor force management

1. Party B designates Shi as the person in charge of the construction site;

2. Within the agreed price, Party B shall provide person-times to follow Party A in selecting materials;

3. Without the consent of Party A, Party B shall not change the construction personnel at will, and must keep more than two construction personnel on site;

4. Without the consent of Party A, Party B shall not stop work or stop work under any circumstances.

XI。 Construction machinery and tools

1. Party B shall bring its own tools needed for construction, and ensure the safety and good usability of the tools, and the maintenance expenses of the tools shall be borne by Party B;

2. Consumables (such as drills, brushes, emery cloths, towels, cutting blades, saw blades, etc.). ) The tools generated shall be borne by Party A. ..

XII. On-site management

1. Open flames are prohibited on site. In case of fire, all consequences shall be borne by Party B;

2. Smoking is prohibited on site;

3, paint materials must be placed separately from other materials;

4. Party B shall carry out the construction on the premise of ensuring safety. In case of industrial accidents, Party B shall bear all the responsibilities.

Thirteen. maintain

1. For quality problems caused by Party B's construction, Party B shall repair them free of charge within one year, and for general maintenance, Party B shall timely repair them within three days after Party A notifies Party B. ..

2. If Party B fails to complete the maintenance in time as agreed, Party A can arrange other construction teams to carry out the maintenance work, and the labor costs incurred will be deducted from the warranty fund.

Fourteen Agreement dispute

1. In case of any dispute, Party A and Party B shall first settle it through negotiation;

2. If negotiation fails, a lawsuit can be brought to the court where the dispute is located.

This agreement is made in duplicate, one for each party, and shall come into force after being signed by both parties. These two agreements have the same legal effect.

Signature of Party A: Signature of Party B:

Date of signing: Date of signing:

Model Agreement on Settlement of Engineering Package (5)

Owner (hereinafter referred to as Party A): Tel:

Construction Team (hereinafter referred to as Party B): Tel:

In the spirit of friendly cooperation and in accordance with the Agreement Law and other relevant laws, Party A and Party B sign the following agreement on the basis of equality and fairness:

I. Overview of the Project

Project address: contract mode: contractor.

Second, the cost

Settlement labor cost: ￥ in words:

Payment method:

1. When the construction team enters the site, the first day of construction will be paid in advance: ￥

2. The construction progress exceeds RMB.

3. Receipts shall be issued for the capital transactions between the two parties.

Third, the construction cycle

From year month day to year month day, the construction period is days. If the construction period is delayed due to Party A's reasons, the construction period will be postponed; If the construction period is delayed due to Party B's reasons, Party A may deduct Party B's labor cost by ￥ days.

Fourth, materials.

1. Party B shall provide Party A with a list of materials to be purchased, and Party A shall timely purchase materials for the use of the constructor.

2. Without the consent of Party A, Party B shall not purchase materials by itself. If it has been purchased, Party A has the right to unconditionally refuse to use the materials and refuse to pay the materials.

3. Party A's materials should be sent to the project site, and both Party B and Party A are responsible for checking the accuracy of quantity and accessories.

4. Party B shall properly keep the materials and prohibit other personnel from entering the construction site.

5. Without the permission of Party A, Party B shall not take any building materials out of the house. If such a phenomenon is found, twice the material price will be deducted from the labor cost.

6. The quantity error of materials provided by Party B is between 5% and 10%. If Party B's material estimation exceeds the error range, Party B shall bear the losses caused by the re-purchase of materials and equipment or the non-return of materials and equipment.

7. Party B shall carry the tools needed for construction and ensure the safety and good usability of the tools.

V. Site management

1. Open flames are prohibited on site.

2. Smoking is prohibited on site.

3, paint materials must be placed separately from other materials.

Intransitive Verb Project Management and Project Change Agreement

1. Before starting work, Party B shall check the water, electricity, floor and hollowing on the top of the wall, and notify Party A in time if any problems are found, and Party A shall be responsible for solving and coordinating them.

2. In the process of construction, Party B shall take necessary safety protection and fire control measures to ensure the safety of workers and nearby residents, and prevent accidents such as pipeline blockage, water leakage, power failure and destruction of houses and articles of nearby residents. In case of the above situation, if it is Party B's responsibility, Party B shall be responsible for maintenance and compensation.

3. Keep the site clean. After the construction is completed every day, Party B is responsible for removing the garbage generated in the construction process and stacking it in the place designated by the property management enterprise. This fee has been included in the total price.

Seven, project acceptance

Party A and Party B shall handle the acceptance formalities of concealed works and intermediate works in time, and Party B shall notify Party A of the acceptance 48 hours in advance, and both parties shall negotiate the acceptance date. After the completion of the hydropower project, Party B shall make a hydropower wiring diagram and submit it to Party A within 5 days. If the acceptance is unqualified, the site will be completely closed and Party B will rework it until it is qualified. The expenses and losses caused by rework shall be borne by Party B. ..

Eight. Dispute mediation

During the performance of this agreement, if there is any dispute between the two parties, both parties shall settle it through consultation without affecting the progress of the project. If both parties are unwilling to settle the dispute through consultation, or negotiation fails, they may bring a lawsuit to the people's court according to this agreement.

Nine. This agreement is made in duplicate, each party holds one copy, which has the same legal effect.

Party A: Party B:

Signature: signature: