Air conditioning installation labor service contract

Model labor contract for air conditioning installation (7 selected articles)

In today's society, people pay more and more attention to contracts, and we use them more and more. Signing a contract can effectively restrain the breach of contract. So what problems should we pay attention to when drawing up the contract? The following is a sample of air-conditioning installation labor contract (7 selected articles) I collected for you, for reference only, and I hope it will help you.

Labor Contract for Air Conditioning Installation 1 Party A (Buyer)

Party B (supplier)

According to the actual needs, Party A reached the following agreement on purchasing Gree air conditioners from Party B for office use through friendly negotiation:

1. Model, quantity, unit price, amount and installation time of products purchased by Party A:

If the installation and debugging cannot be completed within the agreed installation time due to Party A's reasons, both parties agree to implement this contract according to the actual installation quantity and amount; If Party A needs to adjust the model and quantity within the agreed installation time, Party B shall cooperate; The new model and unit price will be discussed separately. If Party A requests to continue to perform the remaining installation contract after the agreed installation time, if the price of Party B increases, it shall be calculated according to the increased price. If Party B finds that Party A's purchasing purpose and installation location are not in conformity with the contract during the execution of the contract, it will be deemed as Party A's breach of contract, and Party B has the right to terminate the contract and collect liquidated damages from Party A. ..

Second, the mode of transportation and cost burden of products: automobile transportation.

Three. Risk liability: Party B shall bear the risk liability before the goods arrive at the installation place of Party A.. After the goods arrive at the installation place of Party A, Party A shall bear the risk responsibility.

4. Installation location: _ _ _ _ _ _.

Verb (abbreviation of verb) product installation and debugging: _ _ _ _ _ _ _ _ _ _ _.

(1) shall be installed and debugged by Party B free of charge;

(2) Party A shall provide Party B with facilities such as power supply, installation and debugging sites and cooperate with Party B's installation and debugging work.

Other expenses of intransitive verbs:

(1) expenses such as air switch required for connection between split indoor unit and power socket and cabinet indoor unit and power supply shall be borne by party a. ..

(2) Party A agrees to bear the support, protective net and other materials specially required by Party A and the production costs. ..

(3) Part of the expenses for extending the pipeline and adding accessories (beyond the original packaging configuration) shall be borne by Party A. ..

Seven. Equipment acceptance: The acceptance period agreed by both parties is: Party A shall complete the acceptance within fifteen days from the date when Party B completes the installation and debugging and notifies Party A to accept the equipment. Overdue shall be deemed as qualified acceptance.

Eight. Settlement method and time limit: _ _ _ _ _ _. Party A's ten-day overdue payment shall be deemed as breach of contract.

Nine, the warranty period: in accordance with the national three guarantees law and the manufacturer's warranty regulations.

X. liability for breach of contract:

XI。 Settlement of contract disputes:

12. This contract is made in quadruplicate, one for Party A, one for Party B and two for the manufacturer.

Thirteen. Other agreements: Party A and Party B guarantee the authenticity of the project, the number of contracts signed and the installation address, and are willing to bear the responsibility if there is any falsehood. Meanwhile, Party A and Party B agree to reserve the right to directly verify the authenticity of this project with Party A's Shandong Gree Company or Zhuhai Headquarters.

Party A:

Party B:

Date:

Labor Contract for Air Conditioning Installation 2 Party A: _ _ _ _ _ _

Party B: _ _ _ _ _ _

1. Party A and Party B, in accordance with the relevant provisions of the Economic Contract of the People's Republic of China and on the principle of equality and mutual benefit, have reached the following agreement on Party B's contracting of Party A's project through friendly negotiation for common compliance.

2. If the drawings and Party A's requirements are changed, the site completion shall be settled separately according to the actual amount.

3. Project scope: Party B is responsible for producing and installing the samples provided by Party A to ensure the project quality.

4. Delivery and installation period: the goods will be produced immediately after the contract is signed, with good quality and quantity, and the goods will be installed on the construction site.

5. Settlement method: after the contract is signed, Party A shall pay _ _ _ _ _ _% of the total project price, and Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _.

6. Liability for breach of contract: This contract has legal effect once it is signed, and both parties shall strictly abide by it. Either party shall not terminate or contract this contract without authorization. In case of breach of contract, all responsibilities shall be borne by the breaching party. (Please inform Party B of production 10 days in advance according to the project schedule)

7. Due to natural factors (power failure, wind, rain, etc. ) affect the construction progress of Party B, please forgive Party A, and Party B will not be liable for breach of contract.

8. Finished product protection: Party B shall not be responsible for the pollution and damage of air-conditioning guardrail caused by human factors after installation.

9. All funds of this project do not include tax.

10. This contract is made in duplicate, one for each party, and shall come into effect after being signed and sealed. Matters not covered in this contract shall be settled by both parties through consultation.

Party A:

Party B:

Date:

3 Labor Contract for Air Conditioning Installation of Party A:

Party B:

In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and in combination with the actual situation of this project, Party A and Party B, through full consultation, conclude this contract and abide by it jointly.

I. Scope and Content of the Contract

1 Party B shall organize the installation in strict accordance with the design approved by Party A, subsequent design modifications and changes and Party A's instructions.

The specific contents of the project include: fan coil unit, main engine installation and coordinated debugging (excluding main engine hoisting, main engine foundation, mechanical start-up and main power supply).

Second, the way of contracting.

This project contract adopts the mode of general contracting and material contracting (standard fittings are common brands in the market), and the unit price of coil installation is 2000 yuan/set.

(including the three-speed control switch of air duct tuyere), the installation unit price of the module host is 2000 yuan/set, and it is settled according to the facts (excluding tax).

Third, the construction period and warranty

1. After this contract is signed and paid to Party B's account according to the contract requirements, Party B will start indoor installation.

2. Party A shall notify Party B in advance to carry out indoor installation, and the construction period of indoor works shall be 7 days from the date when Party B enters the site. After the whole system is debugged, Party B shall cooperate with the progress of the decoration company.

3. Due to force majeure, major design changes, or other reasons agreed by Party A, the construction period may be postponed accordingly.

4. The warranty period of this project is one year from the date of system completion. During the warranty period, if installation quality problems and defects are found, Party B shall send someone to repair them free of charge within 8 hours after receiving Party A's telephone call or written notice.

Four, quality standards and completion inspection and acceptance

1. Air conditioning acceptance effect of this project: refer to the national standard of comfort air conditioning.

2. Within three days after Party A's acceptance signature or Party B's acceptance, if Party A does not raise any objection, it shall be deemed as qualified.

Verb (abbreviation of verb) payment terms

1. After the contract is signed, Party A shall pay Party B RMB 10000 Yuan only, and Party B shall arrange the construction according to Party A's requirements.

2, the project completion balance is paid in one lump sum.

The responsibility of both sides of intransitive verbs

1. Party A's responsibilities:

1. 1 Provide the site required for Party B's construction.

1.2 Pay the contract money in strict accordance with the payment method stipulated in the contract. In case of violation, all losses caused thereby shall be borne by Party A. ..

1.3 Under normal operation, provide hydropower conditions for Party B to build and debug the system.

1.4 Party A or the site coordinator entrusted by Party A shall be responsible for coordinating the related matters of the property management company, decoration company and Party B. ..

1.5 If required by Party A, Party A shall be responsible for beam construction, structural load-bearing waterproofing and contact with the property management company.

1.6 Sign the confirmed construction drawings, change drawings and change orders.

1.7 If Party A needs to change the design, on the premise of not affecting the air conditioning effect, a formal written agreement will be reached through consultation between both parties as a supplementary part of the contract, and the project cost will be adjusted accordingly. The cost is subject to the unit price in the budget.

2. Party B's responsibilities:

2. 1 Accept the supervision and management of Party A. ..

2.2 Establish and improve fire prevention and construction safety systems and measures, and abide by and implement national and municipal regulations on construction noise, environmental protection, safe construction, civilized construction and night construction.

2.3 After the project is completed, clean up the site, dismantle temporary facilities and clean indoor and outdoor sanitation.

Seven. responsibility for breach of contract

1. After the contract comes into effect, if Party A fails to perform the contract without reason, Party A shall bear the losses caused by Party B's stocking.

2. After this contract comes into effect, if Party A fails to make payment according to the time stipulated in the contract, the construction period of Party B may be postponed accordingly.

3. During the warranty period, Party B shall be responsible for the direct economic losses caused by engineering quality problems.

4. If the brand of materials used by Party B is inconsistent with the annex to the contract, Party A has the right to request to change it to the brand specified in the annex.

5. If installation quality problems and defects are found, Party B must send someone to repair them within 8 hours after receiving Party A's phone call or written notice.

Eight. others

1. This contract shall come into effect as of the date of signature and seal by both parties; Installation is completed and accepted by Party A; After the expiration of the warranty period, this contract is terminated.

2. This contract is made in duplicate, with each party holding one copy.

Party A:

Party B:

Date:

Labor Contract for Air Conditioning Installation 4 Party A: _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B have reached the following agreement on the installation of air-conditioning equipment by Party B on the basis of equality and voluntariness:

Article 1 Specification, model, quantity and general situation of the equipment ordered by Party A and installed by Party B:

1, equipment:

Steam production scale, specification, model, unit quantity

2, the installation project overview:

(1) Project location and area:

(2) Project cost: RMB;

(3) Commencement date: 20xx years;

(4) Completion date: 20xx years;

(5) Payment method:

(1), cash

(2) Transfer cheque

Article 2 When Party B's engineering materials enter the site, Party A shall confirm and designate the place where the goods are stacked (the place designated by Party A must be secured), and both parties shall be responsible for the safety of the engineering materials. After Party B installed and debugged the air conditioner, Party A has passed the on-site acceptance and signed the acceptance; Materials and equipment shall not be used or installed without the acceptance and signature of both parties.

Article 3 Installation, debugging and acceptance of products:

1. Party B is responsible for the installation and commissioning of air conditioning equipment.

Party A and Party B agree that:

(1) Before (20xx), Party B shall send engineering, technical and construction personnel to the site to start the installation;

(2) Before 20xx2), complete the construction and acceptance of the early concealed works;

(3) Complete the installation of equipment and the debugging and operation of the system before 3)20xx; The completion acceptance of all air conditioning projects should be carried out at the same time as the completion of decoration. All required materials should be in place at the time agreed by both parties.

2. The installation quality standard shall meet the national standards and industry requirements, and the installation design instructions of the working nest provided by Party B and the manufacturer. Party B shall notify Party A of the acceptance on the day when the project is completed, and Party A shall organize personnel to accept the project within three days after receiving the acceptance notice. If the quality and content of the project meet the requirements, the representatives of both parties shall sign and seal the project acceptance form (form). Party B is responsible for providing product certificate, material certificate, product warranty, daily operation procedure description and fault consultation. The product installation scheme shall be based on the design drawings and selection scheme proposed by Party B and agreed by Party A; If it is necessary to change the design scheme, it must be agreed by both parties through consultation; If the aircraft type adjustment is involved, the supplementary text of the contract shall be signed for confirmation.

Article 4 Method and time limit of price settlement:

1. The contract price is the payment method (fixed price) of the installation project agreed by both parties;

2. The total cash withdrawal price of this laborer is RMB: _ _ _ _ _ _ _ (in writing);

(1) After the contract is signed, Party A shall pay (the first phase of the project payment) RMB (accounting for _ _ 50 _% of the total contract amount) _ _ _ _ _ _ _ _ _ _ _ _ _ (in writing);

(2) After Party B's engineering materials (non-finished products) enter the site, Party A shall sign and accept them, and pay Party B (the second-phase project payment) RMB (_ 47 _ _% of the total contract amount) _ _ _ _ _ (in writing) within three days;

(3) The final payment of the project (accounting for __3_% of the total contract amount) is RMB (write: _ _ _ _ _ _ _), which shall be paid by Party A within three days after the equipment debugging is completed and the project is completed and accepted. Before Party A pays the full amount, the ownership of materials and air conditioning equipment belongs to Party B. ..

3. The above price excludes residential property management fee, drilling fee for special drilling rig and equipment hoisting fee.

Article 5 Liability for breach of contract

I. Party B's responsibilities:

1. The person in charge of Party B at the project site is fully responsible for the installation and construction site;

2. Unless otherwise stipulated in the contract, if Party B fails to deliver the work within the time stipulated in the contract, Party B shall pay a penalty of 1‰ of the total price to Party A for each day overdue, but the total penalty shall not exceed 20% of the total price. If Party B still fails to deliver the work after reaching this deadline, Party A may consider terminating the contract, and the losses caused to Party A therefrom shall be borne by Party B, unless it is signed and approved by Party A. ..

3. If Party B delays the construction period without reason, it shall pay a penalty of 1‰ to Party A for each day of delay, except for Party A's reasons. ..

4. Party B shall be responsible for the responsibilities and losses caused by unqualified installation.

Two. Party A's responsibilities:

1. The person in charge of the construction site of Party A is fully responsible for the installation construction site;

2. Party A shall create conditions for Party B to enter the site for construction, vacate the site and connect the water and electricity for construction _ _ _ days before commencement;

3. Party A shall provide Party B with the confirmed design scheme and installation and construction list _ _ _ days before the commencement of construction;

4. If Party A terminates the project midway, it shall pay Party B a penalty of 0.50% of the contract price.

5. If Party A fails to pay the project payment within the time stipulated in the contract, Party A shall pay Party B a penalty of 1‰ of the total contract amount for each day overdue, but the total penalty shall not exceed 20% of the total contract amount. If Party A still fails to pay after reaching this limit, Party B has the right to terminate the contract and take back the air-conditioning equipment, and Party A shall bear the economic losses of Party B, and Party B may also pursue Party A's relevant legal responsibilities. ..

5. If Party A needs to adjust the product model, it shall notify Party B in time, and bear Party B's repeated transportation, storage, equipment price difference, material loss and other related expenses.

6. If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by both parties:

(1) engineering quantity change or design change;

(2) Force majeure;

(3) Work stoppage caused by Party A's failure to pay on time and participating in stage acceptance;

(4) Other circumstances in which Party A agrees to postpone the construction period.

Article 6 Product quality responsibility and after-sales service clauses

1. The warranty period of the project is one year from the date of acceptance (provided by Forest Refrigeration).

Due to product quality problems outside the warranty period, Party B will charge basic maintenance fees. If damaged parts are replaced, Party B will charge fees according to the ex-factory price of the replaced parts.

2. After the warranty period ends, Party B shall provide lifelong paid maintenance service for air conditioner users. The content and mode of service shall be separately signed by the user and Party B voluntarily.

Article 7 If this contract cannot be performed normally due to force majeure, both parties shall settle it through friendly negotiation.

Article 8 Ways to settle contract disputes: Any dispute arising from the execution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, either party may bring a lawsuit to the people's court where the plaintiff is located according to law.

Article 9 This contract shall come into effect as of the date of signature and seal by both parties.

Article 10 The design drawings and quotation scheme specifications of this project submitted by Party B and confirmed by Party A are annexes to this contract.

Article 11 If there are matters not covered in this contract, both parties can make supplementary provisions through consultation, which have the same effect as this contract.

Article 12 The original of this contract is in duplicate, with each party holding one copy.

Article 13 The annex to this contract is an integral part of this contract and has the same legal effect as this contract.

Party A: _ _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Labor Contract for Air Conditioning Installation 5 Party A:

Party B:

Party B promises to Party A on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

First, the work content:

1, installation of air conditioners, water heaters and other equipment;

2. Lightning protection and grounding;

3, hardware accessories installation and debugging;

Second, the installation labor costs and settlement:

Installation labor price: air conditioner: RMB/set, water heater: RMB/set, all-inclusive price.

The settlement method is monthly settlement.

Third, the quality requirements

1. Party B shall install and debug in strict accordance with this contract and the installation drawings and requirements provided by the manufacturer, with good quality and quantity, and accept the supervision of Party A. If the installation quality does not meet the requirements, Party B shall unconditionally repair or rework and bear all expenses.

2. Party B shall not hand over the contracted project to a third party for completion, and the consent of Party A is required in special circumstances. In case of violation, Party A has the right to terminate the contract, and all consequences arising therefrom shall be borne by Party B. ..

Fourth, other requirements.

1. Party B shall be fully responsible for the safety during installation and the damage to the third party;

2. Party A shall purchase accident insurance for Party B;

3. For aerial work, Party B must wear a safety belt.

4. During the construction, Party B shall not damage the installation tools of Party A, and Party B shall repair them free of charge.

5. Matters not covered shall be settled by both parties through negotiation.

6. This contract is made in duplicate, one for each party, and shall come into effect as of the date of seal or signature by both parties.

Party A:

Party B:

Date:

Labor Contract for Air Conditioning Installation 6 Party A:

Party B:

Party A assigns Party B to work, and Party A and Party B sign this agreement on the basis of equality, voluntariness and consensus.

I. Term of the Contract

The contract is valid from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Second, the employment agreement:

1. The adaptation period is 10 days after Party B signs the employment agreement. During the adaptation period, if Party B resigns, Party A will not pay the salary.

2. From the date of signing the contract, Party A will charge Party B RMB 1000 as a quality deposit, which will be deducted by 20% from the monthly salary until it is fully deducted.

3. After the expiration of the labor employment agreement. If one party is unwilling to retain the employment, the labor contract shall be terminated immediately; Party B shall refund the quality deposit six months after the date of resignation and departure. During this period, if there is any maintenance, Party A shall notify Party B, and the maintenance cost shall be deducted from Party B's quality guarantee. (During this period, if Party A is not notified for other reasons, maintenance records shall be kept and settled when the deposit is refunded. )

4. Party B shall notify Party A 30 days in advance if it requests to resign during the labor service agreement period. Party A shall not resign from May to August in the peak season, otherwise Party A will not refund the quality deposit to Party B. ..

5. During the contract period, Party B shall not contact users privately, and shall not leave personal contact information. Once found, terminate this contract. And don't pay monthly salary and quality guarantee.

6. You are not allowed to do your own private affairs during office hours. In case of special circumstances, it is necessary to obtain the consent of Party A, and 70% of the off-season settlement will be made, and the normal salary will be paid in the peak season. Otherwise, it shall be handled according to the preceding article.

7. Party B shall not do anything harmful to users' rights and personal safety when working at users' premises. If the circumstances are serious, it shall be handed over to the public security department for handling. And terminate this contract without refunding any fees and monthly salary.

Third, job responsibilities:

1. Obey Party A's work arrangement and distribution, and complete the work on time, in quality and quantity according to the post responsibilities determined by Party A;

2. Consciously abide by Party A's rules and regulations and government laws and regulations. Abide by rules and discipline to ensure attendance; Party A has nothing to do with Party B's violation of relevant state management regulations during and outside work.

3. Party B shall not disclose Party A's information and materials. It shall not be made public in any form, and shall not harm the interests of Party A during the employment period. If Party B's personal behavior causes economic losses to Party A, Party B must bear all the responsibilities. Otherwise, it will be arbitrated by the local law enforcement department.

Four. Working hours (during Party B's work in Party A)

1. Working hours: off-season: 9: 00-17: 00; Peak season: 8: 00- 18: 00 (subject to the workload in the store).

2. Party B must leave Man Qin within the specified working days, and the absentee must ask for leave from Party A by phone or in writing one day in advance, otherwise it will be treated as absenteeism. From May to August, Party B shall not ask for leave for any reason. Consult as appropriate under special circumstances.

Verb (abbreviation of verb) warranty card management

1. If there are expenses related to maintenance and installation, Party B must issue a warranty card to the user.

2. Need the user's personal signature (name). For warranty cards without user's signature, 65438 yuan +00 yuan will be deducted for each card.

3. The warranty card is the serial number. All received cards should be returned in full (including invalid cards). Don't throw away the damage yourself. One less, each button 10 yuan.

4. Without the consent of Party A, Party B shall not open this warranty card for its private business. Otherwise, it shall be handled according to point 5 of Article 2.

5. The warranty card should be kept and returned before the 5th of each month, as a proof of wage accounting. Failure to pay or loss will not be considered.

VI. Wages and benefits

1. Party A's salary distribution shall follow the principle of distribution according to work. Party B who implements the fixed-time working system works in Party A, and Party A pays Party B's salary in cash every month. Party A shall pay Party B's salary on _ _ days every month, and the default time shall not exceed _ _ days.

2. Salary accounting method:

7. Party A shall purchase personal accident insurance for Party B according to the relevant regulations of the state and labor department, and the insurance premium shall be deducted from Party B's salary. After Party B has worked for one year, Party A will refund the insurance premium to Party B. ..

Eight, work clothes:

1. Party A provides work services and deducts the work service deposit from the salary of the current month.

2. After leaving the company, Party B shall return the work clothes and return the work clothes deposit to Party B on the basis that it can be worn. Otherwise it will not be returned.

Nine. In any of the following circumstances, Party A may terminate this Agreement:

1. Party B violates Party A's labor discipline and rules and regulations;

2. Party B's negligence causes losses to Party A's interests;

3, do not obey the distribution, there are violations of law;

4. Failure to implement the post responsibility system, safety operation rules and safety fire prevention system, resulting in quality and safety fire prevention accidents;

5. Concealing health and affecting workers;

6. Party B is investigated for criminal responsibility or reeducation through labor according to law;

7. Party A is dissolved.

The latest contract model of air-conditioning maintenance installer contract model

X. others:

1. Both parties must strictly abide by and perform this agreement. If either party fails to perform this agreement, it will give economic compensation as appropriate;

2. This Agreement shall come into force after being signed by both parties;

3. Matters not covered in this Agreement shall be amended and supplemented after both parties reach an agreement through consultation;

4. This Agreement is made in duplicate, with each party holding one copy.

Party A:

Party B:

Date:

Labor Contract for Air Conditioning Installation 7 Party A:

Party B:

If the Employer fails to complete the above permission, approval or filing in time, the Employer shall bear the increased expenses and/or delayed construction period, and pay reasonable profits to the Contractor. According to the Civil Code, in line with the principle of equality and mutual benefit, in order to clarify the rights and obligations of both parties, combined with the specific conditions of this project, Party A and Party B have reached the following agreement:

I. Overview of the Project

1, project name:

2. Project location:

3, work content:

4. Signing method:

Second, product installation and debugging

1. Party B is responsible for the installation and commissioning of air-conditioning equipment. Party A and Party B agree that:

(1) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In case of disputes arising from the confirmation of the actual completion date, relevant regulations can be formulated according to the specific circumstances:

If the project passes the completion acceptance, the date when the contractor submits the application report for completion acceptance is the actual completion date, and it shall be indicated in the project acceptance certificate; Due to the reason of the Employer, the supervisor fails to complete the completion acceptance within 42 days after receiving the application report for completion acceptance submitted by the contractor, or fails to issue the project acceptance certificate after the completion acceptance, and the date of submitting the application report for completion acceptance is the actual completion date; If the project is used by the Employer without completion acceptance, the actual completion date shall be the date when the project ownership is handed over.

(2) Before _ _ _ _ _ _ _ _ _ _

(3) Complete equipment installation and system debugging before _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ All required materials should be in place at the time agreed by both parties.

2. The installation quality standards shall meet the national standards and industry requirements, as well as the engineering installation design specifications provided by Party A and the manufacturers. Party B shall be responsible for the explanation of daily operation procedures and fault consultation. The product installation scheme shall be based on the design drawings and selection scheme proposed by Party B and agreed by Party A; If it is necessary to change the design scheme, it must be agreed by both parties through consultation.

Third, the responsibilities of both parties.

1, Party A's responsibility

(1) Party A shall transport the equipment and materials to the construction site in time so as not to delay the construction period.

(2) Send people to the construction site to coordinate with the owner and other construction jobs; And the change and visa of construction drawings.

(3) timely disbursement of project funds as agreed; If the payment is not made as agreed, Party B has the right to take necessary measures to recover the money, and Party A shall be responsible for all the consequences arising therefrom.

(4) The foundation of air-conditioning main engine shall be made by Party A according to the construction drawing, and the expenses shall be borne by Party A. ..

(5) After receiving the acceptance notice from Party B, Party A shall organize the acceptance in time.

2. Party B's responsibilities

(1) Strictly abide by the management regulations of the owner, achieve safe and civilized construction, and ensure no drunken operation.

(2) Carry out the construction in strict accordance with the construction progress and quality.

(3) Party B shall carry out the construction in strict accordance with Party A's construction plan and requirements. If there is any change, Party A must inform Party B in advance, and the increased expenses due to the construction drawing or Party A's reasons shall be borne by Party A; Party B shall carry out the construction according to Party A's change notice and fee visa.

Four. accept

1. Party B shall notify Party A for acceptance on the date of project completion.

2. Party A shall organize personnel to accept the project within three days after receiving the acceptance notice. If the quality and content of the project meet the requirements, the representatives of both parties shall sign and seal the project acceptance sheet (form).

Verb (abbreviation of verb) payment terms

1. The total contract price is RMB _ _ _ _ _.

2. After the contract is signed, Party A shall pay 30% of the project payment to Party B, of which RMB yuan shall be used as the project advance payment; After 10, Party A shall pay Party B 30% of the total project cost. And RMB _ _ _ _ _ _ _ _ _ _ yuan after the completion of the indoor concealed work. Party A shall pay Party B 20% of the total project amount, namely RMB _ _ _ _ _ _ _, and 20% of the remaining project amount, namely RMB _ _ _ _ _. Risk warning: the starting point of warranty responsibility

The project warranty period is calculated from the date of project completion acceptance. The warranty period of specific sub-projects shall be agreed by both parties in the special contract terms, but it shall not be less than the statutory minimum warranty period. During the warranty period of the project, the contractor shall undertake the warranty responsibility according to the relevant laws and the contract.

If the Employer uses the project without completion acceptance, the warranty period shall be calculated from the date of transfer of possession.

Six, the project warranty period

The engineering system shall be guaranteed by Party B for _ _ _ _ _ _ years; Party A shall be responsible for all equipment warranty and material quality problems.

Seven. responsibility for breach of contract

1. During the performance of this contract, if either party breaches this contract, resulting in the failure to perform this contract or major defects in performance, the responsible party shall bear all losses caused thereby to the observant party.

2. During the performance of the contract, if one party requests to terminate the contract in advance, it shall notify the other party one month in advance, and the responsible party shall bear the reserve paid by the other party for the performance of the contract.

Eight. Other agreements

1. This contract shall come into effect after being signed by both parties; This Contract is made on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. In case of any dispute during the performance of the contract, both parties shall settle it through friendly negotiation. If negotiation fails, both parties may bring a lawsuit to the people's court of the place where the contract is signed and the place where the contract is performed.

Party A:

Party B:

Date:

;