Heating pipeline construction contract

Now the public's legal awareness is increasing, and contracts can be used anytime, anywhere and in various scenarios. Signing a contract is also one of the most effective legal basis. I believe everyone is worried about rewriting the contract. The following is a template of heating pipeline construction contract (generally 6 copies) compiled by me for reference only. Welcome to reading.

Heating Pipeline Construction Contract 1 Party A: _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _

According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B have reached the following agreement on the installation of heating pipes by Party B on the basis of equality and voluntariness:

Article 1 General situation of the project:

1. Overview of main materials:

Used to heat pipes. For the radiator.

2, the installation project overview:

(1) Project location:

(2) Project cost:

(3) Commencement date: 20 _ _ _ _ _ _ _;

(4) Completion date: 20 _ _ _ _ _ _ _;

(5) Payment method: After the installation is completed, the project payment will be paid after the acceptance.

Article 2 When Party B's engineering materials enter the site, Party A shall designate the stacking place of the goods, and Party B shall be responsible for the safety of the engineering materials.

Article 3 Installation, debugging and acceptance of products:

1. Party B is responsible for the installation and commissioning of heating pipelines.

2. The installation quality standards shall conform to the national standards and industry requirements, as well as the engineering installation design instructions provided by Party B. Party B shall notify Party A of the acceptance on the day of project completion, and Party A shall organize personnel to accept it within three days after receiving the acceptance notice. Party B is responsible for providing product certificate and material certificate. The product installation scheme shall be based on the design drawings and selection scheme proposed by Party B and agreed by Party A; If it is necessary to change the design scheme, it must be agreed by both parties through consultation.

Article 4 Liability for breach of contract

I. Party B's responsibilities:

1. The person in charge of Party B at the project site is fully responsible for the installation and construction site;

2. Unless otherwise stipulated in the contract, if Party B fails to deliver the work within the time stipulated in the contract, Party B shall pay a penalty of 1‰ of the total price to Party A for each day overdue, but the total penalty shall not exceed 20% of the total price. If Party B still fails to deliver the work after reaching this deadline, Party A may consider terminating the contract, and the losses caused to Party A therefrom shall be borne by Party B, unless it is signed and approved by Party A. ..

3. If Party B delays the construction period without reason, except for the reasons of Party A, it shall pay Party A a penalty of 5‰ of the price for each day of delay. ..

4. Party B shall bear the responsibilities and losses caused by unqualified materials and installation.

Two. Party A's responsibilities:

1. Party A shall create conditions for Party B to enter the site for construction and provide water and electricity access;

2. If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by both parties:

(1) design change;

(2) Force majeure;

(3) Other circumstances in which Party A agrees to postpone the construction period.

Article 5 Product quality responsibility and after-sales service clauses

The warranty period of the project is one year from the date of acceptance.

Article 6 If this contract cannot be performed normally due to force majeure, both parties shall settle it through friendly negotiation.

Article 7 Ways to settle contract disputes: Any dispute arising from the execution of this contract shall be settled by both parties through friendly negotiation. If negotiation fails, either party may bring a lawsuit to the people's court where the plaintiff is located according to law.

Article 8 This contract shall come into effect as of the date of signature and seal by both parties.

Article 9 If there are any matters not covered in this contract, both parties can make supplementary provisions through consultation, which have the same effect as this contract.

Article 10 The original of this contract is in duplicate, with each party holding one copy.

Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Heating Pipeline Construction Contract 2 Party A: _ _ _ _ _ _ _

Party B: _ _ _ _ _ _

According to the Economic Contract Law of the People's Republic of China and the relevant regulations of the Ministry of Construction and the provincial and municipal construction committees on building maintenance projects, through consultation, the heating device is delivered to Party B for construction according to the actual area of 32 yuan per square meter, and this contract is hereby signed as follows:

A, project contracting way:

The building material is galvanized steel pipe, shrink-packed (except radiator and main staircase). Construction can only be started after the materials are accepted by Party A. ..

Second, the quality requirements

Party A shall supervise the quality of materials used by Party B. If the engineering quality of Party B's construction fails to meet the requirements specified in the specification, or the materials used are unqualified, Party A has the right to stop Party B's construction and order it to make rectification, and the expenses shall be borne by Party A.. If the completion acceptance does not meet the requirements or is unqualified, Party B shall rectify or rework at its own expense.

Three. terms of payment

1. After the construction team enters the site, Party A shall pay 40% of the project payment to Party B..

2. After half of each building construction, Party A shall pay 40% of the total project cost to Party B, and then pay 95% of the total project cost of each building after passing the acceptance examination.

3. The warranty fee is 5%, and the two heating periods will be paid in one lump sum without quality problems.

Four. Responsibility of both parties

1. Party A is responsible for providing the use and design requirements of the whole project; Provide the location of water and electricity on site; Provide material transportation channels and necessary material stacking places.

2. Party B: Provide Party A with engineering decoration construction design drawings and engineering quotation.

Verb (abbreviation for verb) Other matters

Party A and Party B agree to reach the following agreement:

1. If the construction cannot be carried out due to special circumstances or force majeure, the construction period can be postponed; All losses caused by breach of contract shall be borne by the breaching party.

2. Party B shall solve the safety problems in the construction by itself. Any safety problem has nothing to do with Party A. ..

3. When the materials and technology of the project or project other than the quotation of this project are changed, after Party A confirms the comprehensive unit price, the "on-site visa form" shall prevail and be included in the addendum to the final accounts of completion. (If the project beyond the quotation of this project or the project materials and processes have changed, Party A has recognized it, but Party A does not have a visa, and the expenses incurred will also take effect. ) ensure that the construction is beautiful and generous. (The influence caused by house decoration has nothing to do with Party B) When the engineering technology changes, the construction can only be started after the approval of Party A..

4. When the engineering quantity changes, the engineering quantity calculation of the project audit after completion shall prevail.

5. If Party A or Party B breaches the contract and fails to implement it according to the contract, they may appeal to the superior competent department or arbitration institution.

6. Other matters not covered shall be settled by both parties through consultation.

7. This contract is made in duplicate, which shall come into effect after being signed by both parties, and each party holds one copy, with the same legal effect.

Signature of Party A: _ _ _ _ _ _ _

Signature of Party B: _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Heating Pipeline Construction Contract 3 Party A: _ _ _ _ _ _ _

Party B: _ _ _ _ _ _

In accordance with the Economic Contract Law of the People's Republic of China and the relevant regulations of the Ministry of Construction and the provincial and municipal construction committees on building maintenance projects, this contract is hereby signed by both parties through consultation:

I. Project Overview and Contracting Method

1, project name:

2. Project location: Shangqiu Development Zone

3. Project contracting method: contracting for work and materials.

Second, the project installation content:

Install heating pipes in the courtyard pipe network and stairwell. Contract price: _ _ _ _ _ _ yuan.

Third, the construction period:

From _ _ _ _ to _ _ _ _.

Fourth, the quality requirements:

According to the industry standards stipulated by the Ministry of Construction and the standards stipulated by the provincial and municipal construction committees, the project will be accepted by the engineering department and the company's competent leaders after completion. If there are any quality problems after the completion of the project, it is Party B's responsibility, and Party B will provide free warranty. The warranty period is a heating period, and it is maintained for life.

Verb (abbreviation for verb) Terms of payment:

From the date of signing the contract, Party A shall pay 40% of the project payment in advance to Party B within three days, and then pay 40% after the courtyard pipe network is laid. After the acceptance of the project, 2% of the quality deposit will be retained, and the remaining project funds will be paid in one lump sum.

The responsibilities of both sides of intransitive verbs:

1. Party A is responsible for providing the use and design requirements of the whole project; Provide the location of water and electricity on site; Provide material transportation channels and necessary material stacking places; Responsible for indicating the location of power distribution system, piping system and water supply and drainage master valve involved in the decoration project; The construction site should be flat.

2. Party B: Provide Party A with engineering decoration construction design drawings and engineering quotation.

Seven. Other matters agreed by both parties are as follows:

1. If the construction cannot be carried out due to special circumstances or force majeure, the construction period can be postponed; All losses caused by breach of contract shall be borne by the breaching party.

2. When the materials and technology of the project or project other than the quotation of this project are changed, after Party A confirms the comprehensive unit price, the "on-site visa form" shall prevail and be included in the addendum to the final accounts of completion. (If there is a change in the project or the project materials and technology other than the quotation of this project, which is approved by Party A, but Party A does not have a visa, the expenses incurred will also take effect).

3. Party B must carry out the construction safely and have a special person in charge of the command.

4. If Party A or Party B breaches the contract and fails to implement the contract, they may appeal to the superior competent department or arbitration institution.

5. Other matters not covered shall be settled by both parties through consultation.

6. This contract is made in quadruplicate, which shall come into effect after being signed by both parties, and each party holds two copies, with the same legal effect.

Representative of Party A: _ _ _ _ _ Representative of Party B: _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Heating Pipeline Construction Contract IV (hereinafter referred to as Party A):

Contractor (hereinafter referred to as Party B):

In accordance with the relevant provisions of the Economic Contract Law of the People's Republic of China and the Regulations on the Contract of Construction and Installation Projects, and in order to clarify the rights, obligations and economic responsibilities of both parties in the construction, this contract is signed by both parties through consultation.

I. Projects

Project name: _ _ _ _ _ Project location: _ _ _ _ _ _ _

Second, the scope and content of the contract:

The indoor floor heating project in the drawing design, including the distribution main pipe, the laying part of floor heating and the pouring of concrete protective layer, is attached as a supplementary content of this contract.

Third, the project price:

The settlement price is _ _ _ _ _ _ _/m2. After the floor heating construction is completed, Party A and Party B shall calculate the actual floor area of the floor heating according to the construction drawings.

Fourth, the construction preparation

1. signing of this contract

2. Signing of this contract

Verb (abbreviation of verb) construction period

The construction period is _ _ _ _ _ days, starting from _ _ _ _ and ending on _ _ _ _ _ _ _ _ _ _.

1 According to the construction preparation regulations, Party A can't provide the construction site (it doesn't meet the requirements of construction conditions after acceptance by Party B and relevant parties), and obstacles can't be removed, which affects the construction in the site.

2. The conditions provided by Party A cannot meet the construction needs or the defects found in the inspection need to be repaired or replaced, which will affect the progress.

3. Major design changes, design scheme changes that are not within the scope of the contract system, or factors that affect the progress due to the inability to construct. During the construction process, due to irresistible factors such as power failure and water cut-off, the normal construction was affected, and the project payment was not allocated as stipulated in the contract, which led to the postponement of the construction period.

Item quality of intransitive verbs

1, the quality of this project has reached _ _ _ _℃, and the drawing design requirements are in accordance with the research requirements of both parties.

2. Party B must carry out the construction in strict accordance with the construction drawings and documents, and accept the supervision of the engineering representative sent by Party A. ..

3. Party B must abide by the following provisions during the construction:

(1) The main raw materials, equipment, components and semi-finished products provided by Party B must be qualified according to relevant regulations before they can be used for construction;

(2) The main raw materials, equipment, components and semi-finished products provided by Party A and civil contractors must have quality certificates before they can be used in the project. The change or substitution of materials must be approved by the original design unit, and can only be used in the project after formal written notice and the visa of Party A's engineering representative.

(3) Party B shall evaluate the project quality of disciplines, divisions and units according to the quality inspection and evaluation standards, and send the evaluation results of unit projects to Party A and the quality supervisor in time. After the completion of the unit engineering structure, the intermediate acceptance shall be conducted with Party A and the quality supervisor.

(4) In case of any quality accident during construction, Party B shall report to Party A's accredited representative and supervision representative in time. The handling results of general quality accidents shall be sent to Party A and the quality supervisor for filing; The treatment scheme of major quality accidents shall be studied by the design unit, quality supervision unit, Party A and other units, and implemented after being signed by the design and construction unit;

(5) After the project is completed, Party B shall guarantee the project for one year, and the warranty period shall be counted from the date when the project is completed and accepted.

Seven, the payment and acceptance of the project.

Taking each building as a tenon joint unit, Party A shall pay _ _ _ _% of the total project cost within seven days after the materials enter the site, _ _ _% of the total project cost within seven days after the floor heating construction of the building is completed, _ _ _ _% within seven days after the acceptance, and the remaining _ _ _ _% shall be used as the quality guarantee fund, and the warranty period expires.

Eight. Rights and obligations of both parties

1, Party A

(1) Provide flat ground meeting the construction conditions, empty ground objects, provide water and power supply meeting the construction conditions, and ensure the elevation control line of indoor construction.

(2) Responsible for coordinating the relationship between the general contractor and other construction units.

(3) Provide floor heating drawings and other related documents.

(4) Provide materials storage site.

(5) Supervise the project quality and construction progress, and be responsible for material mobilization, concealed works and project completion acceptance.

(6) Coordinate relevant units to protect the completed construction part of Party B..

(7) Provide Party B with the contact information of the project supervision unit, director and professional supervision engineer, and clarify their functions and powers in writing.

(8) Party A has the right to take back the unqualified materials entered by Party B, and the expenses arising therefrom shall be borne by Party B.;

(9) When Party A finds that the project quality does not meet the requirements, it has the right to require Party B to rework, and the expenses arising therefrom shall be borne by Party B. ..

2. Party B

(1) was appointed as the site representative, responsible for coordination and communication with Party A and various construction teams.

(2) Prepare the construction organization design or construction scheme before commencement, and submit it to Party A and the supervisor for approval.

(3) The floor heating materials determined by both parties shall be used in the project and shall not be changed without authorization.

(4) Complete the project construction with good quality and quantity.

(5) Conduct safety education for construction personnel, and do not operate illegally. Party B shall bear all responsibilities and expenses for the safety accidents caused thereby.

(6) Ensure the cleanliness of the construction site, and be responsible for cleaning up the construction site after the project is completed.

Nine, the completion acceptance

1. Conduct acceptance according to Technical Specification for Radiant Floor Heating (JGJ 142-20__), drawing design and other requirements agreed by both parties.

2. The project shall have hidden acceptance visa, pressure test and water test records, and Party A shall handle the acceptance visa formalities in time;

3. Party B shall be responsible for the debugging and normal operation of the system and deliver it to Party A for use.

4. After the completion acceptance, if it needs to be changed due to Party A's reasons, Party A shall agree on the service time with Party B in advance, and the change fee shall be borne by Party A..

5. For the items that belong to the warranty scope and content, Party B shall send someone to repair them within 24 hours after receiving the maintenance notice. If Party B fails to send someone to repair it within the agreed time limit, Party A may entrust someone else to repair it, and the warranty fee shall be deducted from the quality guarantee fund; In case of emergency repair accidents (such as leakage of pipes and fittings, etc.). ), after receiving the accident notice, Party B shall immediately go to the scene of the accident for emergency repair. For accidents not caused by Party B's construction quality, the repair costs shall be borne by the responsible party, and for accidents caused by product quality defects, the costs shall be borne by the product supplier.

X. Liability for breach of contract and dispute resolution

After the signing of this contract, both parties shall not breach the contract without reason, otherwise, the breaching party shall compensate the other party for all economic losses. In case of any dispute during the execution of this contract, both parties shall settle it through consultation in time. If negotiation fails, the case may be submitted to an arbitration institution for execution in accordance with the relevant provisions of the Contract Law, or a lawsuit may be filed.

XI。 supplementary terms

1. When this contract is signed, if Party A and Party B need to propose amendments, a supplementary agreement can be signed as a supplementary contract to this contract after negotiation between both parties.

2. This contract is made in quadruplicate, one for each party, one for the supervision department and one for the record. This contract shall come into effect after being signed and sealed by both parties, and shall be submitted for inspection when the project is completed, and the balance shall be settled. The warranty period expires naturally.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5 Party A's heating pipeline construction contract:

Party B:

Article 1: Project Overview

1. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. Total contract price: 65,438+05,000.00 yuan (in words: fifteen thousand yuan only). If additional items are added, it shall be calculated separately.

4. Construction period: This project was completed from May/0/4, 20 _ _ _ _ to May 28th, 20____ _ _ _.

5. Project quality: qualified

Article 2: Party A's responsibilities

1. Be responsible for providing Party B with necessary water and electricity;

2, responsible for coordinating relevant departments to do a good job in public security, fire protection, city appearance, garbage disposal, etc.

Article 3: Party B's responsibilities

1, responsible for organizing the construction according to the contract requirements and the scheduled maintenance plan, ensuring the quality and quantity, and completing the project on schedule.

2. Strictly implement the current construction specifications, civilized construction regulations and fire safety regulations. Strictly implement safety construction regulations and implement various safety measures on site. In case of any safety accident in site construction, Party B shall bear the consequences.

3. Properly protect the buildings, equipment, water, electricity and gas facilities around the construction site from damage. If there is any damage, Party B shall be responsible for it, and do a good job in safety, garbage and fire control at the construction site.

4. Before the completion of the project is handed over to Party A, be responsible for protecting all the facilities and finished products on site.

Article 4: Agreement on Project Quality and Acceptance

1, this project should meet the national quality evaluation standards.

2. After the completion of the project, Party B shall notify Party A for acceptance, and Party A shall organize acceptance within 3 days after receiving the notice, and go through the acceptance handover procedures.

Article 5: Project Payment Settlement Agreement

1. All kinds of materials and labor costs required for this project shall be funded by Party B. ..

2. After the project is completed and accepted, all the project funds shall be paid in one lump sum.

Article 6: This contract is made in duplicate and shall come into effect as of the date of signature.

Party A (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Heating Pipeline Construction Contract 6 Party A: _ _ _ _ _ _ _

Address: _ _ _ _ _ _

Party B: _ _ _ _ _ _

Address: _ _ _ _ _ _

Due to the need of engineering construction, Party A entrusts Party B to contract _ _ _ _ _. In order to ensure the quality, progress, safety and civilized construction of the project and clarify the responsibilities, rights and obligations of both parties, this contract is signed by both parties through consultation in accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant regulations.

Article 1 General situation of the project

1. Project name: _ _ _ _ _ _ _ _ _ _ _.

2. Project location: _ _ _ _ _ _ _ _ _ _.

3. Project content: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. Project contracting mode: comprehensive unit price contracting, and Party B will contract for the work and materials.

5. Settlement principle: according to the unit price agreed in the contract and the actual situation of Party B, complete the settlement of engineering quantity. ..

6. Commencement: Party B shall enter the site for commencement within seven working days after the construction conditions are met at the construction site.

7. All building materials, building components and other equipment (hereinafter referred to as engineering materials) used in this project are purchased and used by Party B, and the engineering materials meet the relevant national standards.

Article 2 Contract Price (Project Payment) and Payment

1. Total contract price (RMB, the same below): (in words): _ _ _ _ _ _ _ _ _ (in figures): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

This contract is a comprehensive unit price contract. The unit price standard is shown in the attached project budget, and the above contract price is tentative.

2, project payment:

Article 3 Rights and obligations of both parties

1. Rights and obligations of Party A

1) Pay the project payment in time according to the contract requirements.

2) Provide a construction site with construction conditions.

3) Organize the project acceptance and settlement in time as agreed in the contract.

4) Assist relevant departments to cooperate with Party B to coordinate cross-construction on the construction site.

5) Before the project starts, provide Party B with the engineering geological survey data of the construction site, the data of underground pipelines such as gas supply, heat supply, power supply, communication, radio and television in the construction site and its adjacent areas, and the relevant data or drawings of adjacent buildings and structures and underground projects, and ensure the authenticity and effectiveness of these data.

2. Rights and obligations of Party B

1) Party B shall organize the construction within seven working days after receiving the project advance payment and the construction site has the construction conditions.

2) Carry out the construction in strict accordance with the design drawings, construction specifications and relevant technical requirements. The construction quality must conform to the current relevant national construction standards, and must pass the acceptance.

3) Be responsible for the safe production of the project and the construction safety of the construction personnel.

Article 4 the agreement of the time limit for a project

1. Duration: from the commencement date 10 working days. If the construction period is not postponed, Party B shall complete the project within the above-mentioned construction period and notify Party A for acceptance after completion.

2. When Party A requests to complete the construction period stipulated in the contract in advance, it must obtain the consent of Party B..

3. Work stoppage due to design change or increase of engineering quantity or other reasons not attributable to Party B (such as weather factors). ), the construction period will be postponed.

Article 5 Quality, Acceptance and Settlement

1. This project is based on the construction drawing, practice description and design changes; Take Code for Construction and Acceptance of Water Supply and Drainage Pipeline Engineering as the acceptance standard for construction management and quality evaluation.

2. Quality requirements of this project: qualified.

3. After the completion of the project, Party B shall notify Party A of the acceptance, and Party A shall organize the acceptance within seven days from the date of receiving the acceptance notice, and complete the acceptance and handle the acceptance handover procedures within five days after the acceptance begins. If Party A fails to organize the acceptance within the specified time due to objective reasons, it shall notify Party B in time and set another acceptance date. If Party A fails to organize the acceptance for more than fifteen days after receiving the acceptance notice, it shall be deemed as qualified, and Party A shall handle the project settlement and pay the project payment in time.

4. After the acceptance is completed, Party B shall submit the settlement data, and Party A shall complete the settlement audit within 40 days after receiving the settlement data, and pay the remaining project settlement money to Party B in one lump sum. If Party A fails to reply (or put forward opinions) within 40 days after receiving Party B's settlement data, it shall be deemed that Party A has verified and agreed to confirm Party B's settlement data, and Party A shall settle the remaining projects as required.

Article 6 exemption clause

During the construction period, due to bad weather (such as rainy days) and other reasons not caused by Party B, the construction period will be postponed accordingly, and Party B will not be responsible.

Article 7 Dispute settlement

Any dispute arising from this contract shall be settled by both parties through friendly negotiation. If negotiation fails, it shall be settled in the following ways: bring a lawsuit to the people's court of Party B's domicile.

Article 8 Signing and Entry into Force of the Contract

1. This contract shall come into effect after being sealed by both parties.

2. This contract is made in seven copies, two for Party A and five for Party B, all of which have the same legal effect.

Party A (seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Legal (authorized) representative: _ _ _ _ _ _ _ _ _ _ _ _

Agent: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (seal): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Legal (authorized) representative: _ _ _ _ _ _ _ _

Account number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Handled by: _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Date of signing this contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ \

Bank of deposit: _ _ _ _ _ _ _ _ _ _ _ _