Ceramic tile labor service construction contract

With the popularization of legal knowledge, the legal effect of contracts is increasing day by day, which is also an important measure to reduce and prevent disputes. So how is the general contracting drafted? The following is a sample of ceramic tile service construction contract (generally 5) I collected for your reference, hoping to help friends in need.

1 ceramic tile labor service construction contract Party A:

Party B: ID number:

In accordance with the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, and following the principles of equality, voluntariness, honesty and credibility, both parties have reached the following agreement on matters related to the Agreement on Bricklaying of External Walls through consultation:

1. Project name: Buildings 20 and 22, Wang Fu, Dongchuan, Jinchuan.

Two. Scope of contract: all external wall bricklaying works.

Third, the contract form: no material contract.

Four. Duration: the duration is from year month day to year month day, and the duration is calendar days. For every day of delay in the construction period, claim RMB.

Verb (abbreviation of verb) settlement method: the final settlement shall be based on the actual brick area, with 28 yuan per square meter (28 yuan/square meter, including facing, chamfering, round joint, cleaning, edge mending, and vacancy filling until acceptance). Other tools and meals shall be provided by Party B. ..

6. Quality requirements: Acceptance shall be carried out according to the current national and local acceptance specifications for construction projects, and they are qualified.

Seven. Payment terms:

1. After it is completed in a large area and accepted by Party A and the supervisor, it shall be paid according to 90% of the actual quantities; Pay 95% of the actual engineering quantity after completion acceptance, and settle 5% deposit three months after completion. If there is a settlement date for alimony, it will be postponed.

2. If fines are imposed due to violation of production safety and regulations, all fines will be deducted from progress payment.

Eight. Rights and obligations of both parties:

1. After Party B's operators or staff enter the site, they must accept the three-level education and safety technical disclosure from the project department. Operators must abide by moral behavior and must not steal, rob, fight and other uncivilized behaviors. Party B is prohibited from assisting wanted criminals to carry out the construction site; In the process of construction, Party B shall strictly abide by the rules and regulations of production safety, and must understand the safety precautions, and shall not arbitrarily destroy the on-site safety protection measures. If any safety problems occur, Party B shall bear the responsibility alone, which has nothing to do with Party A. ..

2. Party B shall not delay the construction progress without reason and must meet the requirements of Party A's construction progress. Party A has the right to lodge a claim for failing to meet Party A's schedule requirements.

3. Party B shall do a good job in protecting the products that have not been laid or are being laid; We must do a good job in product protection such as anti-collision and anti-theft; Party B shall not waste the materials provided by Party A at will when paving exterior wall tiles, and offenders will be fined twice as much as the materials.

4. In the process of construction, arrange in strict accordance with the requirements of the project department and the construction specifications of each process. If it fails to accept the just requirements of the management, Party A has the right to terminate the agreement and leave by itself, and all the adverse consequences arising therefrom shall be borne by Party B..

5. Party B shall provide a fixed substitute on site. Failing to do so within the time limit, a fine of RMB 3,000 will be imposed.

9. Force Majeure: If one party fails to perform this contract as agreed due to force majeure, it may be exempted from liability in part or in whole according to the influence of force majeure, but it shall notify the other party in time and provide proof to the other party within five days after the end of force majeure.

X dispute settlement: any dispute arising under this contract shall be settled through negotiation between both parties or mediation by the administrative department. If negotiation or mediation fails, it shall be settled in the following (2) way (only one option can be selected).

(1) Bring a lawsuit to the people's court where the contract is signed;

(2) Apply to the arbitration commission in the place where the contract is signed for an award.

XI。 Other terms:

1. This contract shall come into effect as of the date of signature and seal by both parties. This contract has * * * pages in total and is made in duplicate, with each party holding one copy.

2. The annexes to this contract and various written documents formed during the performance of this contract, after being signed and confirmed by both parties, become an integral part of this contract and have the same legal effect as this contract. Unless otherwise specified, the sequence of interpretation shall be based on the time when the document was generated. For matters not covered in this contract, both parties can sign a supplementary agreement through consultation, which has the same legal effect as this contract.

Party A (seal): Party B (seal):

Legal representative:

Authorized Agent: Authorized Agent:

Tel: Tel:

Year, month, sun, moon, sun.

Ceramic tile service construction contract 2 Owner:

Contractor:

I. Project name:

Second, the project site selection:

Three. Construction period: year month day to year month day.

4. Contracting method: construction shall be carried out according to the construction drawings and current national standards, and there is no material, no quality, no construction period and no civilized construction.

Verb (abbreviation of verb) contract content: paving and caulking of walls and tiles in public areas.

Six, project quality, time limit for a project:

1, strictly implement the current national construction acceptance standards.

2. According to Party A's brick arrangement requirements, when paving, the flat-fell seam of brick arrangement and the surface smoothness of adjacent bricks must meet the requirements. Do a good job in the finished product protection of paving bricks and doorframes, walls and columns.

3. If the project fails to meet the requirements of specifications and standards due to Party B's reasons, economic losses such as material costs and labor costs caused by rework shall be borne by Party B, and Party A will not calculate the workload. The construction period will not be postponed. If the circumstances are serious, Party A has the right to terminate the contract.

Seven, the contract unit price:

Labor cost of indoor floor tiles and wall tiles is _ _ _ _ Yuan/㎡ (excluding materials and mosaics, special-shaped bricks are counted separately), and the quantities are calculated according to the actual site.

Eight, project payment:

After the construction is completed, the developer will make a one-time payment after the acceptance.

Nine. Work of Party A:

1, responsible for on-site coordination and technical management, guiding on-site construction, checking the engineering quality of Party B, and assisting Party B's personnel to improve the engineering quality and construction progress.

2. Be responsible for providing Party B with a set of construction drawings.

3. Be responsible for the written technical disclosure of the construction personnel of each process in which Party B participates in the construction.

4. If the field work needs to be adjusted due to the actual needs of construction, Party B shall cooperate and complete it within the time specified by Party A. ..

X. Party B's work:

1, Party B must be equipped with enough construction personnel and full-time construction team leader, and report the roster of construction personnel and the contact telephone number of the team leader to Party A. ..

2. Confirm Party A's incompetence, including the construction personnel who are responsible for the failure of part of the project schedule and construction quality to meet the contract requirements; Construction personnel who are not familiar with the professional work, etc. ; Not actively cooperating with Party A's normal work and violating Party A's on-site management regulations; Dumping construction waste at random at high altitude, stealing, drinking, fighting, urinating or defecating anywhere, will be punished according to regulations or cleared up after being approved by Party A. ..

3. Party B must unconditionally obey the management of Party A, conscientiously implement the management system formulated by Party A, and unconditionally cooperate with the inspection of higher authorities and government actions.

4. After Party B's construction is completed, all garbage will be transported to the outdoor ground, which will be handled by the developer and has nothing to do with Party B. ..

XI。 Entry into force of the contract:

Date of conclusion of the contract: year month day.

This contract is made in duplicate and will come into effect after both parties agree to sign it.

Party A (official seal): _ _ _ _ _ _

Party B (official seal): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

Legal representative (signature): _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3 Party A's (full name) ceramic tile labor service construction contract:

Party B (full name):

Through negotiation between Party A and Party B, Party A subcontracted the outdoor ground brick laying service for the construction project of Zhangye Hall 3 to Party B for construction. In order to clarify the responsibilities, rights and interests of Party A and Party B, and ensure the quality, progress, safety and civilized production of the project, this contract is specially concluded for both parties to abide by and implement.

I. Overview of the Project

Project name: Zhangye No.3 Pavilion Construction Project

Scope of work: outdoor floor cushion, flower pond and peripheral wall masonry, floor brick and kerb construction period:

Second, the way of contracting and charging standards

1. Contract settlement method: Subcontract the construction to Party B as a dry contractor, and calculate the settlement according to the actual completed area on site.

2. Contract price:

Unit price:

(3) The unit price of laying flower pond and peripheral wall is 0.05 yuan/block (standard red brick, including concrete cushion, formwork, 300-thick coping concrete, cleaning and maintenance at the grass-roots level, etc.). ); Unit price per floor/meter (including earthwork cleaning, leveling and tamping at the grass-roots level);

(5) The unit price of outdoor steps is 0.05 yuan/block (standard small red brick, including concrete cushion and formwork); (Priming, cleaning base, material transfer, painting, mortar mixing, etc.). ).

Third, the project audit and payment

1. Every time Party B applies for progress payment, Party A shall pay Party B 80% of the completed project cost according to the actual brick laying progress. ..

2. After Party B's project is completed, Party A will pay 80% of the total project cost after the initial acceptance, 95% of the total project cost after the owner's acceptance, and the remaining 5% will be warranty money.

3. There is no advance payment for this project, and the progress payment is paid according to the image progress.

Fourth, the project warranty gold and warranty period

1. Project warranty: 5% of the total settlement price of the decoration project is used as the project quality warranty, which will be returned without interest after deducting relevant expenses during the warranty period.

2. Warranty period:

3. During the warranty period, if there are any engineering quality problems that need maintenance, be sure to be present for treatment within three days after receiving the maintenance notice; Otherwise, Party A has the right to entrust others to enter the site for maintenance, and the related maintenance expenses incurred shall be deducted from the warranty fund.

Verb (abbreviation for verb) The responsibilities and rights of both parties.

1. Party A is equipped with management personnel, who are responsible for the preparation of schedule and construction scheme, the supply and scheduling of materials and equipment, and the timely technical disclosure of construction safety.

2. Party A is responsible for providing Party B with the construction site and other convenient construction conditions.

3. Party B must set up a diligent and systematic management team with a sufficient number of skilled professional teams according to the construction tasks and technical requirements provided by Party A, and Party A has the right to ask Party B to dismiss or replace inappropriate workers and teams;

4. Party B's construction personnel shall meet the reasonable schedule of Party A;

5. Party B shall provide professional construction machinery and tools, including table saws, chainsaws, electric drills, hammers, wrenches, wood trowels, iron trowels and grey knives. Party B shall be responsible for the maintenance and replacement of tools.

6. Party B shall work overtime at night as required, and cooperate with various arrangements (safety, civilized construction, quality and progress) of the company's management personnel;

7. Party B has the obligation to cooperate with other teams in cross construction and provide them with working faces and other convenient construction conditions;

8. Party B shall consciously care for Party A's machinery, tools and other property at the construction site, and shall have the responsibility to protect the finished products, semi-finished products and other labor achievements of this team and other teams. In case of any damage, Party B shall be responsible for cleaning the site in time after completion;

9. Party B must obey the arrangement of Party A's management personnel in terms of safety, technology, progress, materials, labor force and civilized construction, so as to ensure that the site is cleared after the work, which meets the company's requirements for civilized production; If Party B refuses or ignores Party A's civilized construction requirements, Party A may arrange other workers to complete the work, and the expenses shall be borne by Party B.. ..

10. Party B shall use materials reasonably and economically during the construction period;

1 1. Party B shall be responsible for the expenses of illness, death or disability of Party B's workers during the construction period.

Six, time limit for a project, quality and safety in production

1. The construction period shall be issued by Party A to Party B according to the progress (to meet the requirements of Party A to speed up the work progress as required). If Party B's labor shortage, poor organization and other factors affect the construction period, Party A may impose economic penalties.

2. If Party B cannot increase the number of workers, Party A can contact other teams to enter the site for construction, and all expenses (including extra expenses) arising therefrom shall be borne by Party B. ..

3. Party B shall ensure that the project quality reaches the qualified standard. If Party B has quality problems in the construction process, Party A has the right to impose economic penalties in addition to rework and compensation for material losses without compensation. In case of major quality accidents, Party A has the right to terminate the contract and not settle the completed project quantity of Party B to compensate for the losses.

4. Party B must carry out model construction before starting any subdivisional work. If the sample construction fails to meet the quality standards (or the standards agreed in the contract), Party B shall not proceed with the next construction;

5. In the process of construction, Party B shall accept the inspection of Party A at any time, and if it finds that the construction quality does not meet the requirements, it shall be rectified in time;

6. Party B shall earnestly strengthen the management of production safety to ensure that the target requirements of Party A's responsibility for production safety are met; Otherwise, Party A has the right to punish according to relevant regulations. (For details, please refer to Safety Production Responsibility Management Objectives and Safety Production Responsibility Management Decomposition. )

Seven. additional remarks

In principle, the construction team should complete all the work within the scope of the team contract. If it is really necessary to complete the work of other teams outside the contract (instructed by Party A's on-site engineer), Party B has the obligation to remind Party A's on-site engineer to indicate which team's responsibility scope is completed when handling the workload list. If you have any questions, please consult Party A. ..

Eight. Matters not covered: Matters not covered in this contract shall be settled by both parties through consultation.

Nine. Number of copies of the contract: This contract is made in quadruplicate, one for each party, with the same legal effect. It shall come into effect after being signed by both parties, and automatically become invalid after the project is completed and the settlement money is paid.

Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _

Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Labor Contract for Tiling Bricks 4 Party A: _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)

Party B: _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

In order to clarify the rights, obligations and economic responsibilities of both sides in the construction process and promote the cooperation between the two sides. Based on the principles of equality, voluntariness, fairness, honesty and credibility, both parties have entered into this agreement through friendly negotiation for mutual compliance.

I. Project address and name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Project scope: Party B shall guarantee the construction period and quality (qualified) until the project is completed, and the engineering quantity shall be calculated according to the actual measurement.

Three. Party A is responsible for the on-site disclosure (drawings), arrangement and guidance of technicians, and providing all materials and water and electricity. Assist Party B's personnel to carry out the construction smoothly and avoid delaying the construction period. During the construction of Party B's workers, Party A shall provide accommodation for Party B's workers.

Four. Charge standard and agreed price: RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Duration of the project: this project starts from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Intransitive verb project price and settlement method: Party A shall pay 50 yuan living expenses in advance for each worker who enters the construction site, and Party A shall pay 90% of the project funds to Party B for other work construction according to the monthly progress. The balance 10% shall be paid to Party B in one lump sum within 7 days after the completion of the project.

7. Party B is responsible for providing Party A with plans for the use of construction, labor and materials, and Party A shall cooperate and coordinate Party B's work until the completion.

Eight. The above agreement is made in duplicate, one for each party, and shall come into effect after being signed by both parties. Matters not covered shall be settled through consultation.

Party A: _ _ _ _ _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contact address: _ _ _ _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

ID number: _ _ _ _ _ _ _ _ _ _ _ _ Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A's tile 5 labor service construction contract:

Party B:

In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the construction contract signed by Party A and the owner and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, this contract is signed by both parties through consultation and earnestly performed.

First project

1. Project name: jianhu county Sun City 1# and 5# commercial and residential buildings.

2. Scope of subcontracted works: exterior wall decorative tiles (45x 145 small wall tiles and 600x600 large wall tiles).

Three. Duration of subcontracted works: 20xx starts on April 20th and is completed on May 15. Due to the delay of Party B's construction period, Party A has the right to increase the number of workers entering the site for construction, and the expenses incurred will be deducted from Party B's project payment, and 500 yuan will be fined for each day of delay.

Article 2 Contract Price and Settlement

1. The contract price of this project shall be settled according to the actual workload of veneering, and the edge of door and window frame shall be calculated according to the actual development area. The price of brick 45x 145 and 600x600 is 29 yuan and 33.50 yuan per square meter respectively.

2. Payment method: 65,438+05,000 yuan for the living expenses of each building is paid in advance after veneer, 60% of the total workload is paid after the project is withdrawn, and 95% of the total workload is paid after the main body is delivered and accepted. The remaining 5% will be paid as the quality guarantee within one year.

Article 3 Project Quality

Party A shall make technical disclosure and organize acceptance according to national quality acceptance specifications and evaluation standards, and Party B shall carefully organize construction according to construction requirements to ensure project quality. If the quality is unqualified, it must be reworked and repaired, and the materials and material losses shall be borne by Party B; If the quality of the project is poor and cannot be saved, Party B shall be responsible for compensating all the material losses.

Article 4 Safety in production

1. Party A shall make safety disclosure for the project undertaken by Party B, put forward clear safety requirements, and conduct supervision and inspection. Party B must conscientiously implement the rules and regulations for safe construction and strictly abide by the safety operation rules. The safety production facilities provided by Party A must be inspected before Party B can use them. In case of casualty accidents due to violation of the above regulations during construction, Party B shall be responsible for the losses.

2. In the process of construction, Party B shall be responsible for the fire accident caused by violation of fire laws and regulations.

Article 5 Life management

1. After Party B's workers enter the site, the accommodation problem shall be solved by Party B. Party A shall provide some underground garages for Party B's use, but Party B must ensure the hygiene and electricity safety, otherwise Party A has the right to take back the right to use the underground garages of Party B..

Article 6 Site management

1. The personnel of Party A and Party B shall strictly abide by the site management system and organize the construction under the unified leadership of the site leader of Party A.. The two sides cooperate closely in planning, progress and material supply to ensure the smooth progress of the construction.

2. Party B shall educate the construction personnel about obeying the law, safety in production and caring for property, and it is forbidden to steal materials from the site. If there is any illegal act in violation of the site management system, Party A has the right to take necessary measures, and Party B shall bear legal responsibilities and be responsible for compensating economic losses.

Article 7 Liability for breach of contract

1. The project subcontracted by Party B shall not be subcontracted again. In the process of construction, if the inspection does not meet the requirements of national acceptance standards and the quality of the project cannot be guaranteed, Party A has the right to terminate the contract and Party B shall compensate for the losses caused by rework.

Two, after the signing of the contract, without the consent of both parties, neither party shall arbitrarily change or terminate. If Party B unilaterally terminates the contract without Party A's consent, Party B shall compensate Party A for the economic losses caused by affecting the construction plan; If Party A terminates the contract midway, Party A shall compensate Party B for the economic losses caused thereby.

Article 8 Supplementary Provisions

1. In case of any dispute arising from this contract, both parties shall negotiate in time. If negotiation fails or negotiation fails, it may apply to the Economic Contract Arbitration Committee where the building is located for arbitration or bring a lawsuit to the local people's court.

2. This contract is made in duplicate, with each party holding one copy. This contract shall come into effect as of the date of signature by both parties, and shall become invalid after the project is completely completed and settled.

Signature of Party A:

Signature of Party B:

date month year