What does the renovation contract sample contain? Download renovation contract samples.

Renovation contract's role is self-evident. What problems should renovation contract pay attention to during the signing process? What does the renovation contract sample contain? Is the renovation contract sample useful? Today, Bian Xiao has compiled the latest renovation contract sample and the most comprehensive renovation contract sample template for your reference or download, in case you are cheated when signing the renovation contract!

Family renovation contract sample

Customer (Party A):

Organizer (Party B):

Project: After friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, this contract (including its annexes and all supplementary contracts) is hereby signed for * * * to abide by.

Article 1: Project Overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Room specifications: room floor (style), room, hall, kitchen and bathroom.

/room kloc-0/,_ _ _ _ _ _ _ square meters;

2._ _ _ _ _ _ _ Hall, which is _ _ _ _ _ _ _ square meters;

3, _ _ _ _ _ _ kitchen, meter _ _ _ _ _ _ _ square meters;

4. _ _ _ _ _ toilet, one meter _ _ _ _ _ _ _ square meters;

5._ _ _ _ _ _ balcony, which is _ _ _ _ _ _ _ square meters;

6. _ _ _ _ _ _ corridor, which is _ _ _ _ _ square meters;

7. Others (please specify the location) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total: construction area _ _ _ _ _ _ _ _ square meters;

3. Construction contents: See the attachment List of Home Decoration Construction Contents and the construction drawing for details.

4. Entrustment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Total days of the project: _ _ _ _ _ _ _ _

Article 2: Project Price

The project price (in words) is RMB. For details, please refer to the Appendix "Budget Table of Home Decoration Engineering Materials" of this contract.

1, material _ _ _ _ yuan; 2, labor costs _ _ _ _ _ _ _ yuan;

3. The design fee is _ _ _ _ _ yuan; 4, the construction freight _ _ _ _ _ _ _ yuan;

5. The handling fee is _ _ _ _ _ _ _ yuan; 6. The management fee is _ _ _ _ _ _ yuan;

7. The tax is (3.41%) _ _ _ _ _ _ _ yuan;

8. Other expenses (please specify the contents) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties. For details, please refer to the Annex List of Final Accounts of Home Decoration Engineering Materials.

2. Regarding the acceptance standard of this project, both parties agree to refer to the local municipal standard DB3 1/T30- 1999 Acceptance Standard for Residential Decoration.

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

4. Quality supervision department: Home Decoration Professional Committee of City Interior Decoration Industry Association.

5. Party A shall be responsible for the quality of all materials and equipment purchased by it; Party B shall be responsible for the quality of the project.

6. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. For details, please refer to the Appendix "Budget Table of Home Decoration Engineering Materials" of this contract. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. For details of the materials and equipment that Party A is responsible for purchasing and supplying, please refer to the Appendix "List of Decorative Materials Provided by Party A" of this contract. It should be a qualified product that meets the design requirements and be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5: Method of Payment

1. After the contract is signed, Party A shall pay 100% of the project cost and 50% of the project cost; When the progress of the construction period is over half (year, month and day), Party A will pay 40% of the project payment for the second time. The remaining 10% shall be paid to Party A after the project is completed and accepted. (Note: Construction costs include labor costs)

Party A pays off the project price, as shown in the Settlement Table of Home Decoration Project in this contract, and Party B issues a unified invoice, hands it over to Party A and issues a decoration project warranty card, as shown in the Home Decoration Project Quality Warranty Card in this contract.

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there are any additions, deletions or changes in the construction, please refer to the Home Decoration Engineering Change Order in this contract for details. Both parties sign a supplementary contract, and Party B is responsible for issuing a construction change order and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in the contract, Party A shall pay 1% of the unpaid project price to Party B for each day overdue.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party B shall pay Party A 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid 1% of the labor cost in the decoration project price as lost time.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. During the construction, the shutdown caused by engineering quality problems and disagreement between the two parties shall not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.

4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7: Project Acceptance

1. For the quality acceptance of the project, please refer to the Quality Acceptance Form of Home Decoration Project attached to this contract. Party B shall organize Party A to carry out the completion acceptance after the project is completed, except that the concealed works need to be accepted by sections. Both parties shall handle the project settlement and handover procedures.

2. After Party B notifies Party A to carry out process acceptance and completion acceptance, Party A shall come for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.

3. If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.

Article 8: Other matters

1. Party A

1. The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided; otherwise, Party A shall provide the house plan and water, electricity and gas circuit diagram and make on-site disclosure to Party B. ..

2. The second decoration project, all or part of the empty house, remove obstacles that affect the construction. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..

3. If it is really necessary to dismantle or change the original building structure or equipment and pipelines, it shall go through the formalities with the local housing management department and bear the relevant expenses. If you need to use public parts temporarily during construction, you should say hello to the neighborhood.

2. Party B

1. Take the initiative to show business license, membership card or construction qualification; If it is a subordinate branch, it must also have a certificate issued by the superior company; The handling salesman must have a certificate of entrustment from the legal representative.

2. Assign (name) as the on-site representative of Party B, be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.

3. Be responsible for the safety, fire prevention and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

4. Strictly perform the contract and implement the credit period. If the completion is delayed, such as material stripping, slowdown or an excuse to induce Party A to pay in advance, it will be regarded as a breach of contract after investigation.

5. Be responsible for the warranty within the scope of decoration construction. The warranty period is 12 months, counting from the date when the project is completed and accepted by Party A. ..

Article 9: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 10: dispute settlement

1. In case of any dispute during the performance of this contract, both parties shall settle it through negotiation without affecting the project progress. Or bring this contract and the unified invoice issued by Party B to complain to the Home Improvement Professional Committee of the Interior Decoration Industry Association of the city and demand settlement.

2. The parties are unwilling to settle the dispute through negotiation or mediation, or if negotiation or mediation fails, they may apply to the Arbitration Commission for arbitration according to this contract; -the people's court brought a lawsuit.

Article 11: Modification and Termination of the Contract

1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.

2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.

Article 12: Contract comes into effect

1. This contract and its annexes shall be sealed by both parties and come into force after being signed.

2. The supplementary contract has the same legal effect as this contract.

3. This contract (including its annexes and supplementary contracts) is made in duplicate, one for each party and the witness department.

Party A (Owner): (Signature) Party B: (Signature)

Address of domicile: address of enterprise:

Postal code:

Work Unit: Legal Representative:

Article 8 Time limit for a project is delayed

8. 1 If the completion date is delayed due to the following reasons, the construction period will be postponed accordingly after confirmation by the Employer:

(1) engineering quantity change and design change;

(2) Force majeure;

(3) Other circumstances in which the Employer agrees to postpone the construction period.

8.2 If the time limit for a project is affected by the failure of the Employer to complete the work it should be responsible for as agreed, the time limit for a project will be postponed; If the quality of the project is affected by the unqualified materials and equipment provided by the employer, the cost of rework shall be borne by the employer, and the construction period shall be postponed.

8.3 If the Employer fails to pay the project payment on schedule, the contract period shall be postponed accordingly.

8.4 If the construction period is affected due to the contractor's failure to start construction on schedule or stop work halfway for no reason, the construction period will not be postponed; If there is any problem with the project quality due to the contractor, the cost of rework shall be borne by the contractor, and the construction period shall not be postponed.

Article 9 Quality standards

Both parties agree that the construction quality standard of this project is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

In case of any dispute between the two parties over the quality of the project during construction, the _ _ _ _ _ _ department shall certify the quality of the project. If the certified quality of the project fails to meet the standards agreed in the contract, the contractor shall bear the relevant expenses incurred in the certification process; The certified project quality meets the standards agreed in the contract, and the relevant expenses incurred in the certification process shall be borne by the employer.

Article 10 Project Acceptance and Warranty

10. 1 Both parties agree to check and accept the project quality at the following stages in the construction process:

( 1)_________________________;

(2)_________________________;

(3)_________________________。

The contractor shall notify the owner of the acceptance two days in advance, and fill in the project acceptance form after the stage acceptance is qualified (see Schedule 8: Acceptance Form for Family Room Decoration Project).

10.2 after the completion of the project, the contractor will notify the employer for acceptance, and the employer will organize acceptance within two days after receiving the acceptance notice, and fill in the project acceptance sheet (see Schedule 8: Acceptance Sheet for Family Room Decoration Project). After the project payment is settled, handle the handover procedures (see Schedule 9: Statement of Family Room Decoration Project for details).

10.3 The warranty period of this project is _ _ months from the date of acceptance and signature by both parties. After the acceptance and signature, fill in the project warranty form (see attached table 10: warranty form for family room decoration project).

Article 11 Method of payment for project funds

1 1. 1 Both parties agree to pay the project payment according to the following method:

(1) After the contract comes into effect, the employer shall directly pay the project payment to the contractor according to the following table:

-

| Payment Times | Payment Time| Payment Amount |

| - | - | - |

| Pay RMB for the first time | three days before the start of school |

| The second time | More than half of the project progress | Yuan paid | Yuan

| Third time | Acceptance by both parties | Paid yuan |

-

More than half of the project progress means: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

(2) Other payment methods: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1 1.2 After the acceptance of the project, the contractor puts forward the project settlement proposal to the employer and sends relevant information to the employer. If the employer has no objection within _ _ _ days after receiving the information, it shall be deemed as consent. Both parties shall fill in the project settlement form (see attached table: settlement form of family room decoration project) and sign it. The Employer shall settle the final payment of the project with the Contractor when signing the contract.

1 1.3 After all the project funds are settled, the contractor shall issue a formal unified invoice to the employer.

Article 12 Liability for breach of contract

12. 1 If either party fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall bear the responsibilities and compensate the other party for the economic losses.

12.2 The Employer shall be responsible for the losses caused by the Employer's use of the completed project in advance or without going through the acceptance formalities.

12.3 if the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party and go through the contract termination procedures, and the responsible party shall compensate the other party for the corresponding economic losses.

12.4 If the Employer fails to pay the second (third) project payment on schedule, it shall pay the other party RMB as penalty for each day of delay.

12.5 if the quality of the project fails to meet the quality standards agreed by both parties due to the contractor, the contractor shall be responsible for the repair, and the construction period will not be postponed.

12.6 If the construction period is delayed due to the contractor's reasons, the contractor shall pay the other party RMB as liquidated damages for each day of delay.

Article 13 Settlement of Contract Disputes

Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following way:

(a) submitted to the _ _ _ _ _ Arbitration Commission for arbitration;

(two) to bring a lawsuit to the people's court according to law.

Some specific provisions of Article 14

14. 1 The contractor is responsible for transporting the garbage out of the construction site and to the designated place, and the employer is responsible for paying the garbage removal fee (in words) _ _ _ _ _ _ _ _ _ (this fee is not included in the project price).

14.2 during the construction period, the employer will give the key of the outhouse to the contractor for safekeeping. After the project is completed and accepted, the employer is responsible for providing new locks, and the contractor is responsible for site installation and delivery.

14.3 During the construction period, the contractor's daily working hours are: from _ _ _ to _ _ _ and from _ _ _ to _ _ _ in the afternoon.

Article 15 Other agreed matters: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 16 Supplementary Provisions

16. 1 This contract shall come into effect after being signed (sealed) by both parties, and shall be terminated upon completion of the contract.

16.2 after the signing of this contract, the project shall not be subcontracted.

16.3 this contract is in duplicate, and each party holds _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

16.4 annexes to this contract are an integral part of this contract and have the same legal effect as this contract.

Employer (signature): Contractor (seal):

Legal representative:

Entrusted agent:

Year, month, year, month, year

I believe you already know something about the renovation contract sample. Please feel free to leave a message about the renovation contract sample provided by Bian Xiao. Bian Xiao will solve the problem of renovation contract sample for you at the first time!