Five electronic renovation contract samples.

Renovation contract is a housing renovation contract signed in accordance with the Civil Code of People's Republic of China (PRC) and other relevant laws. I'll bring you the electronic version of renovation contract's sample, and you can click "renovation contract" for more renovation contract.

Renovation contract sample electronic version 1

Party A: (hereinafter referred to as Party A)

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)

Party B is a unit or individual entrusted by the owner or user of the greenhouse property in the park for decoration. Now, Party A and Party B have entered into this agreement through equal consultation.

I. Decoration application and approval

Article 1 Party B shall apply to Party A for renovation before renovation, and fill in the renovation application form; Party B shall provide Party A with the following materials:

1. Copy of the business license and qualification certificate of the construction unit (with official seal). Entrust individuals, need to provide decoration power of attorney.

2. Party B shall provide Party A with the list of on-site construction personnel, copies of ID cards and 2 recent photos of 1 inch.

3. Certificates and photocopies of special jobs such as electricians and welders in the decoration team.

Article 2 After receiving Party B's application, Party A shall review the information provided by Party B, and if it is qualified, Party B shall issue a construction permit ... Party B shall start the renovation according to the permit time, and at the same time post the permit in a prominent position on the renovation site for Party A's inspection.

Article 4 Party B shall not change the materials audited by Party A without authorization. If it is necessary to modify or change, it shall notify Party A in writing in advance and submit the modified materials to Party A for review.

Article 5 If Party B starts construction without applying for renovation or without Party A's consent, Party A has the right to order it to stop, and all consequences arising therefrom shall be borne by Party B. ..

Second, the pass.

1. In order to ensure the smooth progress of Party B's renovation work, Party B needs to apply for site passes for the construction workers it employs. Party A has the right to prevent people from entering the community if they fail to apply for the pass, lose it or lend it to others, and all the consequences arising therefrom shall be borne by Party B. ..

2. If Party A finds that the construction workers employed by Party B have violated the law or the management regulations of the park, Party A has the right to clear the construction workers out of the community, and all the consequences arising therefrom shall be borne by Party B. ..

3. After the renovation, Party B shall return all the passes it has handled to Party A in time, and Party A shall return the temporary pass deposit after verification.

Third, the decoration deposit

1. In order to ensure the interests of the owner and the safety of the nursing room structure and supporting equipment, Party A charges Party B the management fee for each household in 500 yuan.

2. After the renovation is completed and accepted by Party A, after deducting the actual expenses, there will be no quality problems for 3 months, and the final payment will be returned according to the regulations. If the acceptance is unqualified, Party A will continue to charge Party B the relevant expenses during the rectification period.

Fourth, matters needing attention

The first greenhouse structure decoration

1. Doors and windows shall not be changed to keep the appearance of greenhouses and sanatoriums beautiful and uniform.

2. It is forbidden to dismantle and destroy the original structure, load-bearing wall and balance wall. It is not allowed to pick slots and make holes in the main structure without authorization, and it is not allowed to cut through partition boards on the ground, roof and balcony.

3. Don't destroy the waterproof layer of the original bathroom and laundry room without authorization. If there is any damage, waterproof treatment must be redone, and 24-hour closed water test should be conducted. The property engineering department can only continue the construction after passing the inspection.

4. The wooden materials used for Party B's decoration shall be treated with fire prevention, flame retardant and anti-corrosion.

5. Rooms without waterproof requirements shall not be set as bathrooms and kitchens.

Article 2 Decoration of water, heating and gas pipeline facilities

1. It is forbidden to change indoor heating pipeline facilities, install radiators or dismantle them. When installing the heating cover, be sure to leave a manhole with a length and width of not less than 400mm to facilitate future maintenance, otherwise the consequences will be at your own risk.

2. It is forbidden to change the indoor water meter, and the original design pipeline shall not be changed without authorization.

3. It is forbidden to change or block gas pipelines and instrument facilities.

4. A distance of more than 100mm should be reserved around all indoor pipe joints and interfaces, and inspection ports with a length and width of not less than 400mm must be reserved according to regulations for future maintenance and inspection.

6 when the bathroom and kitchen walls are changed, the construction plan should be made according to the waterproof standard, so as to be waterproof.

Article 3 Decoration of power distribution and weak current signal facilities

1. The distribution system layout must be constructed according to the approved scheme and drawings, and the construction personnel responsible for this work must hold the electrician operation certificate issued by the Labor Bureau (a copy of the certificate of special type of work is filed in the property management company).

2. It is forbidden to destroy the original indoor wiring circuit and directly bury high and low voltage lines. It must be laid in accordance with the construction specifications. Party B shall be responsible for all consequences caused by any violation.

3. It is not allowed to add or modify the original design distribution control and metering instruments without authorization, and the concealed construction parts: lighting, sockets and air conditioning sockets must be controlled in one direction according to the original design load.

Article 4 Exterior Decoration of Greenhouse

1. It is forbidden to dismantle and change external windows and fire windows, and it is forbidden to install guardrails without authorization.

2. It is strictly prohibited to illegally build or hang other items on the platform in Grandpa's * * * area at the door. The offender's property company has the right to demand its unconditional demolition at its own risk.

3. The outdoor unit of the air conditioner must be installed at the designated position, and the condensate drain pipe must be connected with the air conditioner condensate pipe or fixed on the wall at one side of the outer window.

Article 5 Layout of the construction site

1. Handling of decorative materials: arrange the handling time so as not to damage public areas. When handling building materials, it must be sealed and leak-free, and the handling route must be cleaned up in time after handling.

2. Cleaning and removal of decoration garbage: Party B must abide by Party A's regulations, transport the sealed bagged garbage to the designated place at the designated time, and clean up the debris in front of the door at any time. It is forbidden to pile up building materials and decoration garbage in public areas, and it is forbidden to dump debris and paint into sewer pipes.

3. Construction personnel: Party B's construction personnel shall wear neat clothes and traffic signs, and enter through designated passages; It is forbidden to wander in the non-working area of this community, and it is not allowed to damage the public facilities and equipment of the community and the finances of others; Strictly abide by management regulations and keep public areas clean and tidy.

4. Decoration construction time:

1) Working hours: 8: 00- 12: 00, 14: 00- 18: 00. At other times, construction workers are forbidden to enter or stay in the community, and construction workers are forbidden to spend the night in the community.

2) Operation time of mechanical equipment: 8: 00- 1 1: 30, 14: 30- 18: 00, and the rest time is silent operation time, so construction is strictly prohibited to disturb people.

5. Fire safety: Every household in the decoration construction site must be equipped with two 5 kg fire extinguishers, and smoking is prohibited in the work site.

Six, decoration completion acceptance

After the decoration is completed, Party B shall notify Party A of the appointed time in advance, and Party A shall, within 5 working days after receiving Party B's formal acceptance application, conduct acceptance together with the property department, the owner, the person in charge of the decoration company and the technical personnel related to the decoration construction. Unqualified projects shall be rectified by the construction unit within a time limit. All losses and expenses caused by rectification shall be borne by the construction party.

Seven. others

Article 1 Party B hereby guarantees that all the consequences caused by its renovation, such as the damage to the structure, layout and external decoration of the house, the damage to the house adjacent to the real estate, the loss to others' personal safety or property, and the loss to neighbors caused by the leakage of the house, will be borne by Party B. All matters arising therefrom, such as litigation and arbitration, will be handled by Party B at its own expense.

Article 2 Where Party B's renovation causes personal and property losses to others and causes others to claim compensation from Party A, Party B shall bear all the losses caused to Party A from this. ..

Article 3 Matters not covered in this Agreement shall be settled by both parties through negotiation.

Article 4 This Agreement is made in duplicate, one for each party, and shall come into effect as of the date of signature by both parties.

Article 5 During the renovation of the project, Party B must strengthen the management of production safety and equip special safety supervisors for safety supervision. During the renovation period, Party B shall be responsible for any accidents of the decoration personnel inside and outside the park, and Party A shall not be responsible.

Party A: Party B: _ _ _ _ _ _ _ _ _ _

Agent: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

date month year

Renovation contract Sample Electronic Edition 2

Client (Party A): _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _

Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate (decorate) the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.

Article 1: Project Overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ Room specifications

3. Entrusting method: contracting for labor and materials (excluding the expenses of security doors, lamps and flooring materials)

4. Project price (amount in words): RMB _ _ _ _ _ _ _ _ Yuan only, including the project materials listed in Article 3 of this contract, all labor costs in the decoration process, handling fees, decoration garbage cleaning fees, etc. (Remarks: All labor costs and engineering materials related to decoration shall be borne by Party B. If Party B requests to pay other expenses in the construction project, Party A has the right to refuse to pay. If Party B delays the construction on this ground, Party A has the right to terminate the contract and investigate the relevant liabilities for breach of contract. )

5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 2: Construction Contents

1. living room: one shoe cabinet, living room, plaster line, ceiling, plastic steel window, four sockets and two switches.

2. Master bedroom: a wardrobe (with shuttle door) plus a hanging cabinet, a balcony wardrobe (with shuttle door) plus a hanging cabinet, two bedside tables, plaster lines, six sockets and two switches.

3. Second bedroom: a wardrobe (with shuttle door) plus a hanging cabinet, a new wall between the master bedroom and the second bedroom, a plastic-steel bay window, a computer desk with bookcases, two bedside tables, plaster lines, four sockets and two switches.

4. Kitchen: decoration, wall tiles, integrated cabinets, smokeless stoves, exhaust fans, stone doors, suspended ceilings (aluminum gusset plates), vegetable pots, stirring valves, quartz stone chopping boards, six sockets, two switches, waterproof.

5. Toilet: decoration water, wall tiles, floor tiles, suspended ceiling (aluminum gusset), installation of cross doors, washstand, cabinet, washbasin mixing valve, faucet, washing machine interface, floor drain, toilet (including water tank), installation of two sockets and two switches, and waterproof treatment.

6. Specific requirements for the installation of strong and weak current: all lines (wires, cable TV, telephone and computer network cable) should be penetrated, and the wires should be grounded. The strong current lines should not be connected underground, but should be connected to the distribution box (socket and ceiling). The socket panel should have five eyes, the switch should have five eyes, and six groups of distribution boxes should be installed.

7. Wall construction technology: primer once, topcoat twice. Latex paint must be made in strict accordance with the proportion of water, and no more water can be added. Wall treatment should be horizontal and vertical, and the angle of yin and yang should be straightened.

8. Customized integral cabinet: Party B entrusts a professional manufacturer to customize the integral cabinet, and the standard is 750 yuan/meter. If the cost exceeds this standard, Party A will bear the excess. Special provisions: the back of the whole cabinet must be pasted with wall tiles, and the countertop material is quartz stone and the countertop is PU board.

Article 3: Material supply

1. All materials used in this contract shall be clearly marked by Party B and are qualified products produced by regular manufacturers. The materials provided by Party A shall be used in the interior decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

4. The varieties, specifications and names of the main materials used by Party B in the project shall be approved by Party A. ..

5. The project price includes the cost of materials. If Party A purchases materials by itself, the expenses will be deducted from the total payment.

Article 4: Method of Payment

Pay the commencement fee of RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 5: Other matters

1. Safety issues: Party B shall strictly observe the safety construction, and Party B shall be responsible for any safety accidents.

2. This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature.

Party A (owner): _ _ _ _ _ Party B (contractor): _ _ _ _ _ _

Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Renovation contract Sample Electronic Edition 3

Entrusting party (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.

Article 1: Project Overview

1. Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;

2. Specification of room type: the room type is a three-story brick-concrete frame with a total construction area of _ _ _ _ _ _ _ _ square meters.

3. Construction content: interior wall tiles, floor tiles and wood floors are laid, interior walls are plastered with white ash, doors and windows are brightened, bathroom accessories are installed, and kitchens and wardrobes are installed. See the construction drawing for details.

4. Entrustment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Project Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;

6. Project completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;

Total days of the project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 2: Project Price

The project price (in words) is _ _ _ _ _ _ _ _ Yuan (in words).

1, material _ _ _ _ _ _ yuan;

2. Working hours are _ _ _ _ _ _ _ _ _ yuan;

3, the construction freight _ _ _ _ _ _ _ _ yuan;

4. The handling fee is _ _ _ _ _ _ _ yuan.

Article 3: Quality Requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

4. All materials and equipment purchased by Party A shall be borne by Party A; Party B shall be responsible for the quality of the project.

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4: Supply of Materials

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B _ _ _% of the total amount of materials provided by Party A as the management fee ... After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5: Method of Payment

1. After the contract is signed, Party A shall pay _ _ _ _ _% of the engineering materials and _ _ _ _% of the engineering expenses; When the progress of the construction period is over half (_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _), Party A shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. If there is any increase or decrease in the project or need to be changed during the project construction, both parties shall sign a supplementary contract, and Party B shall be responsible for issuing the construction change form and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to pay the project price in advance within the time limit stipulated in this contract, Party A shall pay 1% of the unpaid project price to Party B for each overdue day.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 6: Construction Period

1. If the completion is delayed due to Party B's reasons, Party B shall pay liquidated damages of _ _ _% of the working expenses to Party A every day until the working expenses are deducted. If the completion of the project is delayed due to Party A's reasons, Party B shall be paid a fee of _ _ _ _ _ _ _ _ _ _.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. During the construction, the shutdown caused by engineering quality problems and disagreement between the two parties shall not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.

4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7: Project Acceptance

For project quality acceptance, except for concealed projects, Party B shall organize Party A to conduct completion acceptance after the project is completed. Both parties shall handle the project settlement and handover procedures.

Article 8: Other matters

1. Party A's responsibilities

The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, otherwise Party A shall provide the house plan and water, electricity and gas circuit diagram and make on-site disclosure to Party B. ..

2. Party B's responsibilities

Be responsible for the safety, fire prevention, certificates and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.

Article 9: Liability for breach of contract

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay _ _ _% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 10: dispute settlement

In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.

Article 11: Modification and Termination of the Contract

After this contract is signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.

Article 12: Contract comes into effect

This contract shall come into effect after being sealed and signed by both parties. In duplicate, each party holds one copy.

Party A (signature): _ _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Renovation contract Sample Electronic Edition 4

Entrusting party (Party A): _ _ _ _ _ _ _

Organizer (Party B): _ _ _ _ _ _

Project: _ _ _ _ _ _

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, this contract (including its annexes and all supplementary contracts) is hereby signed for * * * to abide by.

Article 1 General situation of the project

1. Project address: _ _ _ _ _ _ _

2. Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Room specifications: _ _ _ _ _ _ _ _ _ _ _ _ Room specifications

Article 2 Project Price

The project price (in words) is _ _ _ _ _ _ _ _ Yuan (in words).

(1) Material Clause _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;

(2) Labor cost _ _ _ _ _ _ _ yuan;

(3) The design fee is RMB _ _ _ _ _ _ _;

(4) the construction freight is _ _ _ _ _ _ _ yuan;

(5) The handling fee is _ _ _ _ _ _ yuan;

(6) The management fee is _ _ _ _ _ _ _ yuan;

(7) The tax is _ _ _ _ _ _ _ yuan;

(8) Other expenses (specify contents) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Article 3 Quality requirements

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties. See Annex (III) List of Final Accounts of Home Decoration Engineering Materials for details.

2. Regarding the acceptance standard of this project, both parties agree to refer to the Shanghai local standard DB3 1/T30- 1999 Acceptance Standard for Residential Decoration.

3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.

4. Quality inspection and supervision department: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

5. Party A shall be responsible for the quality of all materials and equipment purchased by it; Party B shall be responsible for the quality of the project.

6. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 4 Material supply

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. For details, please refer to Annex (II) Budget Table of Home Decoration Engineering Materials. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. For the materials and equipment that Party A is responsible for purchasing and supplying, see Appendix (IV) of this contract for the list of decorative materials provided by Party A. The decorative materials should be qualified products that meet the design requirements and be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 5 Payment Terms

1. After the contract is signed, Party A shall pay 100% of the project cost and 50% of the project cost; When the progress of the construction period is over half, Party A will pay 40% of the second project cost. The remaining 10% shall be paid to Party A after the project is completed and accepted. (Note: Construction costs include labor costs)

Party A shall pay off the project price, as shown in Annex VII of the Contract, and Party B shall issue a unified invoice, hand it over to Party A and issue a decoration project warranty card, as shown in Annex VIII of the Contract, Home Decoration Project Quality Warranty Card.

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there are any additions, deletions or changes in the project construction, please refer to Annex V of this contract, Change Form of Home Decoration Project. Both parties sign a supplementary contract, and Party B is responsible for issuing a construction change order and notifying the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to pay the project price in advance within the time limit stipulated in this contract, Party A shall pay 1% of the unpaid project price to Party B for each overdue day.

4. If Party A mortgages the house decoration to the bank, it shall hand over the mortgage certificate and relevant documents (copies) to Party B. ..

Article 6 Construction period

1. If the completion is delayed due to Party B's reasons, Party B shall pay Party A 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid 1% of the labor cost in the decoration project price as _ _ _ _ _ _ _.

2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.

3. During the construction, the shutdown caused by engineering quality problems and disagreement between the two parties shall not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.

4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.

5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.

Article 7 Project acceptance

1. See Annex (VI) Home Decoration Engineering Quality Acceptance Form for the project quality acceptance. Party B shall organize Party A to carry out the completion acceptance after the project is completed, except that the concealed works need to be accepted by sections. Both parties handle the project settlement and handover.

Renovation contract Sample Electronic Edition 5

Entrusting party (Party A): _ _ _ _ _ _ _ _ _ _ Contact information: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Contractor (Party B): _ _ _ _ _ _ _ _ _ _ Contact information: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

After friendly negotiation, Party A decided to entrust Party B to lay floor tiles and wall tiles, and signed this agreement for both parties to abide by.

I. Project Location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Two. Formal structure: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Third, the project:

1, four rooms (two bedrooms and two living rooms) shall be paved with _ _ _ _ _ _ _ _ tiles and corner lines, which shall be smooth; The kitchen and bathroom walls are _ _ _ _ _ _ _ _ porcelain to the top, leaving room for ceiling, grinding corners and floor tiles _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

2. If no details are involved, Party A shall propose a plan and discuss it.

4. Contracting method: Party A must ensure the materials needed during the decoration period (Party B informs Party A in advance) and the lunch supply during the construction period according to Party B's requirements, and Party B shall be responsible for the construction.

Verb (abbreviation of verb) quality standard: the construction quality meets the safety requirements, and the decoration quality is not lower than the decoration standard of the same construction type, which is recognized by both parties. Within _ _ _ _ months after the project is completed and accepted, Party B shall be responsible for rework and maintenance for quality problems caused by Party B's construction.

Engineering cost of intransitive verbs: materials are provided by Party A, and Party A pays Party B the labor cost of decoration.

Seven. Payment method: in order to ensure the project quality, the deposit of RMB _ _ _ _ _ _ _ _ _ will be withheld temporarily, and will be paid from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. After the project is completed, Party A shall pay Party B the labor cost within three days if it meets the above construction project and design requirements upon acceptance.

Eight. Entry into force of the contract: this agreement is made in duplicate, each party holds one copy, which has the same effect. This agreement shall come into effect as of the date of signature by both parties.

Party A (seal): _ _ _ _ _ _ _ _ _ _ _

Party B (seal): _ _ _ _ _ _ _ _ _ _ _

20___ _ _ _ _ _ _ _ _

20___ _ _ _ _ _ _ _ _

Five related clauses in the electronic version of renovation contract sample;

★ 202 1 5 electronic versions entrusted to renovation contract.

★ Text of electronic contract for interior decoration (5 articles)

★ The latest five complete copies of renovation contract.

★ 5 simplified renovation contract samples.

★ Electronic renovation contract sample

★ The latest edition of renovation contract Model in 2022 contains 5 articles.

★ 2022 five-room renovation contract electronic template.

★ Entrust renovation contract (5 articles in total)

★ Five simple renovation contract.

★ There are five formal renovation contract protocol formats.