Security door installation project construction contract

Contractor (hereinafter referred to as Party A): _________

Contractor (hereinafter referred to as Party B): _________

Article 1 Project

　1.1 Project name: ________; Project location: _________; Contract scope: _________; Amount: _________.

1.2 Construction period:

(1) Construction start date: After the contract is signed and becomes effective, it will be determined based on the progress of Party A’s construction site.

(2) Completion date: The date when it is accepted by the relevant functional departments of the ________ Municipal Civil Air Defense Office and is normally delivered for use.

1.3 Quality level: Production and installation are strictly in accordance with the requirements of the National Civil Air Defense Office and the Ministry of Construction's standard atlas, complying with the regulations of the state and _________ city civil air defense, and reaching excellent standards.

1.4 Contract price: The total lump sum cost is RMB: ________ yuan; capital: ________ yuan (including loading, transportation, secondary handling, installation fees, special fees and taxes).

1.5 Contracting method: This project takes the form of a large contract covering the production, installation, acceptance, project cost, construction period, quality, safety, etc. and is approved by the ________ Municipal Civil Air Defense Office Acceptance and other all procedures, and bear all costs.

I highly recommend

1.6 Various taxes and other fees paid by Party B according to regulations are included in the cost of this project and shall be paid by Party B to the relevant departments and units.

Article 2: Composition and order of interpretation of contract documents

2.1 Agreement terms: _________.

2.2 Physical quantities of the project and list of equipment materials, model, quantity, unit price, and amount.

2.3 Negotiation, changes, etc., minutes and agreements that clarify the rights and obligations of both parties.

2.4 Standards, specifications and other relevant technical information and technical requirements.

2.5 National laws, regulations, departmental regulations and documents of _________ municipal government departments related to the contract.

Article 3 Drawings

All drawings required for the construction of this project shall be provided by Party B, and four sets of drawings shall be provided to Party A.

Article 4 Party A’s representative at the construction site

Party A appoints a special person to be the representative at the construction site to supervise and inspect the quality, progress and other matters of the project. If Party A’s representative changes, this must be done in advance Notify Party B that his successor must fully continue to bear the responsibilities of his predecessor.

I highly recommend

Article 5 Party B’s representative at the construction site

5.1 The general person in charge or general representative appointed by Party B at the construction site shall notify Party A and Any written instructions given by the supervision company, Party A or the supervision company will be deemed to have been effectively given to Party B. If Party B's representative changes people, Party A and the supervision company must be notified seven days in advance, and the successor must continue to bear the responsibilities of the predecessor.

5.2 Party A’s representative shall exercise the rights and perform the duties stipulated in the contract. Party B's requests and notices shall be in writing and signed by Party B's representative and submitted to the supervision company and Party A's representative. The supervision company or Party A's representative shall sign the name on the reply receipt and indicate the time of receipt.

Article 6 Rights and Obligations of Party A

6.1 Party A has the right to propose to Party B to adjust or change the quantity or quantity of products under this contract based on the opinions of the design unit and the requirements of the relevant competent authorities. model. After the change, the changes will be performed in accordance with Article 9 of this contract.

6.2 Party A must notify Party B to arrange for the production and installation of civil defense doors one month before the completion of the basement floor. Within the planned time, Party A may, according to the construction progress, require Party B to send people to the site to negotiate for construction. coordination issues.

I highly recommend

6.3 Party A has the right to supervise and manage the sanitation, quality and safety of Party B’s on-site installation and construction.

6.4 Party A must provide Party B with water and electricity for installation and construction, as well as temporary equipment support materials that can be provided on site.

6.5 Party A is responsible for on-site construction coordination.

6.6 Party A must provide Party B with a copy of the basement civil air defense approval drawing; after completion, Party B will notify the relevant units to accept the civil air defense door, and Party A will send personnel to participate.

6.7 Party A must entrust the civil construction unit to reserve the door openings required for the installation of civil air defense doors when reinforcing the shear wall according to the technical information provided by Party B.

Article 7 Party B’s Rights and Obligations

7.1 Party B must provide Party A with technical information and construction drawings related to on-site construction according to the needs of Party A’s project.

7.2 Party B shall enter the site to cooperate with the construction within the effective notice period of Party A. If the site or environmental conditions are not met, Party B must notify Party A and negotiate for settlement.

I highly recommend

7.3 If due to the requirements of the design unit and the civil air defense department, Party A proposes that the quantity and model of the contracted products must be adjusted or changed, and they comply with the civil air defense regulations, Party B shall Actively cooperate with Party A to negotiate and handle supplementary agreements based on the actual situation.

7.4 Party B is obliged to provide technical guidance services related to installation and construction cooperation to Party A’s construction site.

7.5 When Party B enters the construction site, it must abide by Party A’s on-site health, safety and civilized construction management regulations. If there is any accident involving engineering, property losses or personal injury caused by violation of regulations, all responsibilities and The expenses incurred shall be borne by Party B.

7.6 Party B must carry out construction according to the construction plan approved by Party A. Party B shall provide specific requirements and methods for the lifting rings of the civil air defense door, and Party A shall embed them in advance during the construction or entrust the civil construction party to install them.

7.7 Party B must ensure that the installation of civil air defense doors passes the acceptance inspection of the civil air defense office at one time, and assist Party A in handling the relevant acceptance work of the civil air defense project.

7.8 Party B shall carry out construction in accordance with the construction plan agreed upon with Party A and Party A’s requirements to ensure completion on schedule.

I highly recommend

7.9 Party B shall organize and manage the construction well, keep the site clean and keep the roads smooth.

7.10 In addition to Party A’s personnel’s own responsibility, Party B shall bear all the responsibilities for all safety accidents that occur during construction, and shall report them immediately to Party A and the construction authority.

7.11 Clean up the site after the completion of the project to ensure that the site is clean after completion.

Article 8: Project quality level

Implement the technical standards stipulated by the state and the _________ Municipal Civil Air Defense Office, and achieve excellent quality.

Article 9 Contract Price Adjustment

9.1 The contract price is the lump sum contract price and will not be subject to any adjustment due to changes in labor and material prices during the construction process. Adjustments may be made if one of the following circumstances occurs;

(1) Design changes, modifications and construction site visas confirmed by Party A’s representative.

(2) Increase or decrease in the quantity of work signed by Party A’s representative.

9.2 After the above situation occurs, Party B will prepare an adjustment estimate (settlement) and submit it to Party A for review, and then determine the increase or decrease in the contract price.

If the settlement price is listed in Clause 1.1 of this contract, it shall be settled in accordance with the clauses. If it is not specified in the clauses, the settlement price shall be settled in accordance with the documents of the ________ Provincial Civil Air Defense Office.

I highly recommend

Article 10 Project Payment

10.1 After the contract is signed, Party A shall issue a production notice to Party B two months before Party B enters the site. After signing the contract, Party A will pay 10% of the total contract amount to Party B as the material preparation payment.

10.2 Within three working days after Party B enters the site and completes the installation of the door frame, Party A pays 40% of the total contract amount to Party B as project progress payment.

10.3 Within three working days after Party B enters the site and completes the door leaf installation, Party A pays 80% of the total contract amount to Party B as project progress payment.

10.4 Within three working days after passing the inspection and acceptance by the Civil Air Defense Office, Party A shall pay _________ of the total contract amount to Party B, and Party B shall submit the acceptance certificate for the basement civil air defense door at the same time.

10.5 The remaining balance___________ shall be paid within three days after the expiration of the warranty period.

10.6 Party B shall first submit a written application for payment to Party A each time it requires payment of the contract price (Articles 10.2, 10.3, and 10.4).

Article 11 Supply of materials and equipment

All materials and equipment for this project shall be purchased by Party B and supplied to the construction site of this project.

I highly recommend

Article 12 Design Changes

12.1 Party B shall not arbitrarily propose modifications or changes to the original design. If the original design must be modified due to special circumstances, Any changes or modifications to the design must be approved by Party A.

12.2 If Party A makes changes to the original design, it must notify Party B before Party B starts construction and issue a written notice of change or modification to Party B. Party B shall make changes according to the notice.

12.3 All costs incurred in modifications or changes caused by Party B’s construction quality problems shall be borne by Party B, and the construction period will not be extended.

Article 13 Completion Acceptance

13.1 Party A and Party B shall be subject to acceptance by the _________ Municipal Civil Air Defense Office and other competent authorities. In addition to being responsible for the content within the scope of Party B's project being inspected and accepted by the relevant functional departments of the _________ Municipal Civil Air Defense Office, Party B shall also assist in handling the acceptance of relevant civil air defense projects. If the content within the scope of Party B's work fails to be inspected and needs to be rectified, all the consequences that occur The rectification costs and inspection fees shall be paid by Party B. If the content that is not within the scope of Party B's work fails to pass the acceptance and needs to be rectified, the rectification costs and inspection costs incurred are not included in the contract cost of this project, and the affected construction period will be postponed.

I highly recommend

13.2 The completion date is the date when the civil air defense door is installed and passed the completion acceptance by the _________ Municipal Civil Air Defense Office and other relevant departments.

Article 14 Completion Settlement

When submitting the completion acceptance report to Party A, Party B shall also submit to Party A three sets of complete completion materials, a completion settlement report, and a complete settlement Information, the settlement statement approved by Party A shall be the effective basis for settling the project payment.

Article 15 Warranty

15.1 Warranty period: _________ years starting from the completion and acceptance of the project.

15.2 Scope of warranty liability: Except for damage caused by man-made damage during use by Party A, natural disasters and force majeure factors, all this falls within the scope of Party B’s warranty liability.

15.3 Warranty content includes: all contents of the project included in the contract price (including supplementary contract price), design changes or modifications, on-site visas or written agreements, and meeting minutes of two or more parties.

I highly recommend

15.4 Warranty costs: Party B shall pay.

15.5 During the warranty period, Party B shall send someone to repair the problem immediately upon receiving notice from Party A.

Article 16 Breach of Contract

16.1 Treatment of Breach of Contract: Failure of either party to fully perform the terms of the contract shall constitute a breach of contract. The economic losses caused by breach of contract shall be borne by the breaching party. Responsibility for delays in the construction period caused by breach of contract shall be shared: Party A breaches the contract, and the construction period shall be postponed; Party B breaches the contract, and the construction period shall not be postponed. For every day the construction period is delayed, Party B shall pay Party A a fine of _________ yuan.

16.2 Standards for liquidated damages: If any party during the performance of a contract unilaterally proposes to terminate the contract without justifiable reasons, it is a unilateral breach of the contract. In addition to compensating all the economic losses caused by the other party, the breaching party must also Pay a liquidated damages of 10% of the project price to the other party.

16.3 Scope of compensation for economic losses:

(1) Party A’s representative fails to perform his obligations as stipulated in the contract, or engages in other behaviors that make it impossible to perform the contract, resulting in Party B’s economic losses loss.

(2) Party B fails to complete the construction within the contract time limit, the construction quality fails to meet the design and specification requirements, or other behaviors occur that make it impossible to perform the contract, resulting in Party A's economic losses.

I highly recommend