Painter's contract

In a society where people's legal awareness is increasing, there are more and more types of contracts. Signing a contract can make both parties promise and perform cooperation in a standardized way. So what should we pay attention to when concluding a contract? The following is the model painter's contract I compiled for you. Welcome to read the collection.

Principal of painter's contract 1 (hereinafter referred to as Party A):

Construction party (hereinafter referred to as Party B):

Based on the principle of equality, voluntariness and consensus, Party A and Party B have reached the following agreement on matters related to Party B's contracting of Party A's home painting and decoration project (hereinafter referred to as the project):

Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Project content:

Entrusting method: Party A provides the materials and Party B guarantees the work.

Construction period:

1. Commencement date: year, month and day (calculated from the date when Party B's workers start work).

2. Completion date: year, month and day (subject to the acceptance date specified in the acceptance standard).

5. Total project cost:100000 yuan.

Rights and obligations of party a:

Party A is responsible for purchasing building materials by itself. The purchased materials shall meet the relevant standards stipulated by the state, and the materials must be purchased in the member stores of the Association. If the paint is not purchased in the store of the association member, the contract may be invalid.

The materials purchased by Party A shall be kept by Party B. Party B shall be responsible for compensating the losses caused by improper keeping.

Party A shall go through the construction procedures (passes, etc.). ) for the use of construction personnel. Provide water, electricity and scaffolding needed for construction. If it is necessary to use the public parts temporarily during the construction period, Party A shall greet its neighbors.

During the construction process, when Party A needs to change or add construction projects, it shall promptly and truthfully inform Party B, and both parties shall sign an engineering change order and negotiate the cost.

Party A shall cooperate with Party B's construction personnel.

Seven. Rights and obligations of Party B:

Party B's construction personnel shall carry out the construction in strict accordance with the process regulations.

Party B shall take protective measures against other items purchased by Party A. ..

Supervise according to the construction procedure, and report the supervision and construction progress to Party A in time.

Party B shall complete the project on time. If the construction period is delayed due to force majeure, it shall be settled through consultation with Party A. ..

Eight, grassroots inspection:

When Party B checks the grass-roots situation at the project site, if it finds factors that may affect the painting effect, it shall put forward rectification opinions in time, and Party A shall implement them ... After rectification, Party A and Party B shall make written confirmation. If it cannot be changed with paint due to objective reasons, both parties shall make records and confirm in advance.

Nine, engineering construction and acceptance criteria:

Annex II

X. payment terms:

1. After the contract is signed, Party A shall pay the down payment 600 yuan first.

2. Five days after Party B's personnel enter the site for construction, Party A shall pay 25% of the total project cost, namely _ _ _ _ _ _.

3. After the wood paint is completed, Party A shall pay 50% of the total project cost, namely _ _ _ _ _ _ _ _.

4. After the interior wall latex is completed, both parties shall conduct acceptance according to the acceptance criteria within 3 working days. After the acceptance, Party A shall pay off the balance of the project, namely _ _ _ _ _ _ _ _ _.

When the project changes, Party A shall pay the price agreed by both parties to Party B..

XI。 Warranty commitment after renovation:

Party B shall undertake the warranty responsibility within the quality scope of the decoration project, and the warranty period shall be 2 years from the date when the project is completed and accepted.

During the warranty period, Party B shall be responsible for the coating construction expenses caused by improper construction of Party B. ..

The warranty content is in the form of maintenance. And only responsible for the quality of the coating, and do not bear other joint and several responsibilities.

During the warranty period, Party B shall confirm that it belongs to the warranty scope after receiving the notice, and send someone to repair it within 5 working days.

During the warranty period, it is caused by improper use of Party A, non-decorative external forces or irresistible factors (natural aging, structural degradation, temperature difference shrinkage, carbonization shrinkage, etc.). ) is not covered by the warranty. If Party B needs maintenance, Party A shall be responsible for the maintenance materials and labor costs.

Twelve. Liability for breach of contract:

After the contract comes into effect, the party who cancels the contract without authorization shall pay the other party 10% of the total contract amount as liquidated damages.

If Party A fails to make payment on schedule without justifiable reasons, and Party B has the right to stop the construction after being urged by Party B, and the consequences arising therefrom shall be borne by Party A.. ..

If Party A fails to make payment as stipulated in the contract, or delays the completion due to Party A's reasons, it shall pay Party B 1‰ of the contract project price for each day overdue.

If Party B fails to complete the project according to the contract period or the construction quality fails to meet the requirements, Party B must rework and repair it. If the construction period is delayed due to rework, Party B shall pay Party A 1‰ of the contract project cost for each day of delay.

Thirteen. Dispute settlement: friendly negotiation between the two parties. If negotiation fails, it may be decided by the people's court where Party B is located.

Fourteen Validity of the contract: This contract is made in duplicate, with each party holding one copy. It comes into effect after being signed and sealed by both parties, and the supplementary contract has the same legal effect.

Party A: Party B:

ID number: Representative:

Contact information: contact information:

Date of signing: Date of signing:

Second Owner of Painter's Contract (Project Department): hereinafter referred to as Party A.

Laborer (team or individual): hereinafter referred to as Party B.

In order to enliven the internal management of the project department, clarify the reasonable management responsibilities of the project department and the contracting team, further improve the contracting construction responsibilities, and complete the construction tasks of the project department with high quality and speed, after full consultation, Party A contracted the indoor wall plastering and coating construction project of the third bid section of Shanshuiwan Phase II to Party B, and both parties negotiated on the basis of equality, voluntariness, fair consultation, honesty and credibility.

I. Term and mode of labor contract:

The term of the labor service contract is to complete the project of 4-2 School, Building 35, South Basement, Third Bid Section of Shanshuiwan Phase II. And complete the business from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Second, the contract content and price:

1. Party A and Party B agree on the scope of performance of the labor service contract: indoor wall painting in the third bid section of Shanshuiwan Phase II, plastering of concrete ceiling beams and columns, and local public paint for every two layers. It is forbidden to enter other floors for construction without acceptance.

2. The construction quotation includes basic batch of putty materials, gadgets, shovels, ash buckets, rulers, etc. , horizontal and vertical transportation of materials, garbage removal, finished product protection and other expenses.

3, the construction unit price:

1), cement mortar painting surface layer batch putty grinding: unit price 7.0 yuan ㎡.

2) Batch putty (black cement provided by Party A for the first time), polish, straighten the angle of yin and yang, and rectify the concrete ceiling: unit price: 9.0 yuan ㎡.

3) Paint exterior wall latex paint (black water mud is provided by Party A for the first time), polish and straighten the angle of yin and yang, and correct the deviation of concrete ceiling: unit price 14.0 yuan ㎡. (Exterior wall latex paint shall be provided by Party A)

4) The basement batch of waterproof putty shall be painted with the bottom coating, and the surface shall be painted with latex paint at a unit price of 13 yuan ㎡. (The latex paint for primer and topcoat shall be provided by Party A, and the waterproof putty at the grass-roots level must be certified. )

5) The unit price of surface rolling emulsion paint is 2.0 yuan ㎡. (Latex paint is provided by Party A)

4. The second floor of indoor construction is an acceptance batch, and the next four floors can only be constructed after each second floor construction is completed and signed by the quality engineer and supervisor. Construction teams that do not meet the requirements of quality and time limit for a project must withdraw unconditionally.

Third, the quality requirements and grades:

1. Party B must carry out the construction according to the construction drawing and design change notice. Engineering quality grade: qualified.

2. Party B must use qualified materials (white cement, glue or finished putty powder must have a certificate of conformity), and it can only be used after the incoming materials are inspected to be qualified. Party B must use qualified gypsum putty to straighten the angle of yin and yang and correct the concrete ceiling.

3. The basement must be painted with waterproof putty, sealed with primer before painting, and the surface must be painted with mildew-proof paint. During the warranty period, Party B must rework the mildew unconditionally.

4. Party A shall be equipped with full-time quality inspectors to check the construction quality of Party B.. If the project does not meet the quality requirements, Party B must immediately and unconditionally rework, and bear the cost of reworked materials. Party A will arrange other workers (contractors) for those who refuse to rework, and Party B will bear all rework expenses, and Party A will only punish Party B for XXX yuan. If Party A repeatedly reworks for reasons attributable to Party B, it shall be deemed that Party B cannot perform this contract (that is, the construction is terminated and Party B's personnel leave automatically), and all losses shall be borne by Party B. ..

5. During the construction period, Party B must take measures to protect the finished doors, windows and floors, and be responsible for cleaning the polluted finished doors, windows and floors to meet the acceptance requirements.

6. In case of quality problems during the warranty period of the project, Party A shall inform Party B that workers must be in place for maintenance within 48 hours, otherwise Party A will arrange personnel for maintenance, and the maintenance cost will be deducted from the 5% warranty cost.

7. Name of arbitration institution for quality evaluation: _ _ City Construction and Installation Engineering Quality Supervision Station.

Fourth, the time limit for a project requirements:

1. When Party B enters the site, Party A shall provide Party B with the planned construction progress, and Party B shall conduct the construction in an orderly manner and make reasonable arrangements. The construction team must have the ability to complete the second floor construction in 10 days.

2. If Party B fails to complete the time and engineering tasks specified in the weekly planned construction progress once, it must ensure that the construction progress is completed for the second time. If it is not completed for the second time, Party A will give a warning to Party B, and Party A will punish Party B for failing to complete the time and engineering tasks specified in the weekly planned construction progress issued by Party A for three consecutive times (that is, Party B's personnel will leave their jobs automatically).

Verb (short for verb) security:

1. The construction personnel entering the site shall carry out the construction in accordance with the operating rules of construction and installation safety technology, and strictly abide by all safety disciplines and rules and regulations of Party A. ..

2. During the construction process, Party B unconditionally obeys the unified command of the site management personnel, and conducts safety education and disclosure to the construction personnel before going to work every day. Party B has the right to refuse the illegal command of Party A's management or force risky operation. Fighting and gambling are strictly prohibited on the construction site. Those who violate the rules will be fined, and those who violate the rules will be sent to the public security organs for handling.

3. Party B shall educate and manage the employees in this class, and bear all responsibilities and expenses for traffic and public security accidents.

4. If Party B's personnel are injured in the construction process, Party A shall assist Party B to do a good job of coordination, and all the expenses arising therefrom, such as wages, transportation, medical expenses and lost time, shall be borne by Party B and have nothing to do with Party A. ..

5. It is strictly prohibited to use migrant workers from Lu 'an, Anqing and Jinzhai in Anhui Province (the employment agreement of migrant workers from Lu 'an, Anqing and Jinzhai in Anhui Province was found invalid and retired, and the workers were found to be in trouble and handed over to the public security organs for handling). Construction personnel must have ID cards when entering the site.

Terms of payment for intransitive verbs:

1. Party A shall pay the living expenses of 1000 yuan/person/month according to the actual number of people on site. Party B must provide the attendance record of construction workers in line with the ID card and the signing form for the payment of living expenses of construction workers last month before the end of the month, otherwise it will be implemented according to the regulations of the labor inspection agency.

2. After Party B's project is completely completed and reaches the agreed quality level, Party A shall pay Party B 70% of the total contract price, 95% at the end of the year, and the remaining 5% of the quality guarantee fund shall be paid in one lump sum within 3 months after delivery and acceptance.

Seven, civilized construction:

1, according to the provincial civilized scene management, must meet the municipal civilized scene (plum blossom cup) standard. All site construction personnel must take good care of public safety facilities.

2. Party A shall provide accommodation and dining places for Party B's personnel, which shall be arranged by Party A in a unified way. Party B shall be responsible for cleaning its living place and sanitary area. Party B shall not allow lesbians to spend the night in their own residence, and impose financial penalties on those with poor sanitary conditions.

3. Party B must clean the site after work every day, and it is forbidden to urinate and defecate in the construction site, so as to achieve civilized construction and clean the site. Party A will arrange other laborers (contractors) for the site that laborers (contractors) cannot clean up in time, and all expenses shall be borne by Party B..

Eight, logistics management:

1. Party B's construction personnel shall be responsible for their own food and purchase food in the canteen. You are not allowed to open another sushi.

2. There are no electric stoves, rice cookers, rice cookers, etc. It is not allowed to burn in the dormitory area of the construction site. Once found, 200 yuan will be fined.

Nine, matters needing attention:

1. Party B shall mainly use local people. Those under the age of 1850 and in good health must all hold ID cards or valid certificates issued by the local police station.

2. Party B's personnel should take good care of Party A's property and make the best use of it. If there is intentional waste of materials, Party A will punish Party B at 25 times of the original price, which will be deducted from Party B's contracted project salary.

3. The project price contracted by Party B has included the cost of small tools, and the large mechanical equipment is provided by Party A. ..

4. Party B must carry out the construction according to the drawings, and ensure the completion according to the date agreed in the agreement. Upon completion, the remaining materials will be neatly stacked (at the place designated by Party A).

5. In case of odd jobs, Party A shall pay Party B RMB 65,438+080 per working day; If Party B uses Party A's labor force, Party B shall pay Party A RMB 65,438+080 per working day.

X if party b is found to have subcontracted or subcontracted after the signing of this contract, party a shall immediately terminate the contract.

Party B's personnel must leave the site automatically, and all losses caused thereby shall be borne by Party B ... The person in charge of the site must be on duty for more than 6 days per week, and the monthly living expenses shall be deducted according to the days of absence in 500 yuan.

XI。 This agreement is made in quadruplicate, with each party holding two copies. This agreement shall come into force after being signed by the representatives of both parties, and shall become invalid after the project is completed and the project payment is settled. Alteration shall be invalid.

Party A:

party B

Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Painters Contract 3 Employer (Party A):

Contractor (Party B):

In accordance with the relevant provisions of the laws of People's Republic of China (PRC) and People's Republic of China (PRC), and following the principles of equality, voluntariness, fairness, honesty and credibility, this contract is signed by both parties through consultation.

I. Overview of the Project

Project Name: Paint Project

Project location:

Scope of work:

Paint brand: Nippon strength

Second, the way of contracting: contracting for labor and materials.

Third, the construction cycle

The installation of large-scale frame shall be completed within days after Party A's written notice to enter the site and meet the installation conditions, and within days after Party A's written notice, and shall not affect the progress of other projects of Party A. ..

Four. Warranty period and service commitment

1. Before the project is completed and accepted, Party B is responsible for the protection of semi-finished products and finished products.

2. The quality of the project is guaranteed for two years. Wearable parts damaged by non-human factors will be repaired and replaced free of charge within two years after the completion acceptance. After two years, maintenance only charges for materials, not for labor.

3. After Party B receives the maintenance call, the maintenance personnel shall arrive at the site within 24 hours.

Verb (abbreviation for verb) price and payment method

1. Price: per square meter 18 yuan. The total project price is calculated according to the field measured data.

2. Payment method:

(1) The wall putty coating is polished and 50% of the project price is delivered.

(2) The coating is good, and 30% of the project price will be delivered after acceptance.

(3) Pay 15% of the project price after the overall project is completed and accepted.

(4) The remaining 5% quality guarantee shall be paid in one year.

Six, safety construction

Party B shall provide safety education to employees entering the construction site, abide by the management regulations on safety production in engineering construction, organize construction in strict accordance with safety standards, and accept the supervision and inspection of safety inspectors at any time. Party B shall take out accident insurance for its employees, and Party B shall be responsible for the accidents and expenses caused by Party B's ineffective safety measures.

Seven. responsibility for breach of contract

1. After this contract comes into effect, if the contract is unilaterally dissolved or actually not performed, the breaching party shall pay a penalty of% of the square meter project cost.

2. If Party A fails to pay the project payment according to the contract, and it is overdue for more than one month, it shall pay 0.5 ‰ of the unpaid project payment per day according to the number of days overdue, and pay liquidated damages.

3. If Party B fails to complete the installation of the large frame or window sash within the time specified in Article 4, Party A shall pay liquidated damages to Party A for each day overdue according to Party A's records, and Party A has the right to deduct it from the project payment payable.

4. If the project quality is unqualified due to Party B's reasons, Party B will unconditionally rework, bear economic losses and pay equal liquidated damages.

5. If Party B fails to fulfill the warranty obligations as agreed, Party A has the right to entrust a third party for maintenance, and Party B shall pay the maintenance fee and equal liquidated damages.

Eight. For matters not covered in this contract, both parties may sign a supplementary agreement, which has the same legal effect as this contract.

IX. This contract is made in duplicate, one for Party A and one for Party B, and it will come into effect after being signed and sealed by both parties.

Party A:

Party B:

Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

;