House decoration agreement

In today's social life, agreements play an increasingly important role, and signing agreements can protect their legitimate rights and interests to the greatest extent. So, have you mastered the format of the agreement? The following are three house decoration agreements I collected for you, for reference only. Welcome to read them.

House Decoration Agreement 1 Employer: (hereinafter referred to as Party A)

Contractor: (hereinafter referred to as Party B)

In strict accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction of this construction project and concluded this contract.

Article 1: General situation of the project.

1. Project name: office decoration.

2. Project location:

3. Project scope: interior decoration (see budget list)

4. Project contracting mode: This project adopts integrated contracting mode (see attached table for details).

5. Project cost:

(1) The total cost of the project budget is RMB, in words: RMB only;

(2) The calculation basis of the total cost of this project:

A, according to the engineering design and construction drawings and design changes, on-site visa;

B. During the construction period, Party A and Party B shall confirm the cost of changes or additional measures caused by construction obstacles;

C. The new project cost required by Party A during the construction.

Article 2: Project duration.

1. Through negotiation between Party A and Party B, the contract duration of this project is days (calendar), and the specific commencement and completion time shall be subject to the commencement report signed by both parties.

2. The planned commencement date of this project is YY, and the planned completion date is YY.

3. During the construction of this project, the construction period can be extended in case of the following circumstances:

(1) The normal construction cannot be carried out due to force majeure;

(2) Continuous construction is affected due to Party A's reasons;

(3) Due to design change or design uncertainty;

(4) because the relevant property rights or administrative examination and approval procedures have not been completed;

(5) Within one month, due to power failure, water and gas cut-off at the construction site (not due to Party B's reasons), the cumulative work stoppage exceeds 8 hours;

(6) The construction is affected because Party A fails to provide support in time or the supporting unit does not cooperate.

Article 3: Construction preparation and responsibilities of both parties.

1. Party A's responsibilities:

(1) Before the commencement of construction, Party A shall coordinate all aspects and complete the entry formalities;

(2) Organize design disclosure and the blue prints.the design work;

(3) Being entrusted as the representative of Party A, supervising the quality and progress of the project on behalf of Party A and handling the daily affairs of the project;

(4) Before the start of construction 1 day, Party A shall vacate the decoration site and prepare to start construction;

(5) Do a good job in the supply of materials and equipment provided by Party A, implement the construction funds, allocate the project advance payment on schedule, apply for the on-site visa, and conduct the completion acceptance.

2. Party B's responsibilities:

(1) Provide complete construction drawings and construction technical data;

(2) Organize relevant personnel to be familiar with the construction drawings and design data, prepare the construction drawing budget and construction organization plan, and formulate the construction master plan;

(3) Prepare for construction and organize mobilization, procurement, supply and management of personnel, materials and equipment;

(4) Carry out the construction in strict accordance with the construction drawings and instructions, ensure the quality of the project, complete the delivery on schedule according to the time stipulated in the contract, and undertake the relevant provisions of the maintenance agreement agreed by both parties. Man-made damage shall be repaired by the responsible party at its own expense;

(5) Being entrusted as the representative of Party B, contacting the representative of Party A on behalf of Party B. ..

Article 4: Project Price and Payment.

1. The contract budget of this project is based on the workload of the construction drawing and the construction scheme.

2. The related expenses such as management cooperation fee and decoration deposit charged by the property shall be paid by Party A. ..

3. The total contract price of this project is RMB ().

4. Pay by installments according to the progress of the project.

5. The time and corresponding amount of installment payment are:

(1) Pay 10% of the contract price when signing the contract, totaling ￥ (RMB only);

(2) After the completion of the project, pay the balance of the project ￥ (RMB only);

Payment for engineering changes shall be confirmed by both parties, and the construction of additional projects can only be carried out after payment.

Article 5: Construction quality and design changes.

1. In any case, the construction must be carried out according to the drawings, and neither party may arbitrarily change the original design. If the following circumstances cause losses to Party B, it shall be borne by the responsible party.

(1) If the design is found to be wrong or seriously unreasonable, after Party B notifies Party A, Party A shall negotiate with the design unit within three days, issue a design modification document, and start work only after both parties sign an agreement.

(2) When the design change exceeds the original design standard or scale, Party A must re-submit it for approval according to the examination and approval procedures, and construction can only start after both parties sign an agreement.

(3) If the project progress payment can't be paid in time due to Party A's insufficient investment, which leads to the stoppage or delay of the project, Party A and Party B agree to ensure the safety of the project under construction, and Party A shall bear the economic losses of Party B. ..

(4) If Party B's construction technology, quality and raw materials are not up to standard, which leads to the stoppage or delay of the project, both parties agree to put the project in place safely, and Party B shall bear the economic losses of Party A. ..

2. If Party B encounters important and complicated concealed works, it can notify Party A for acceptance. If Party A fails to be present on time, Party B can accept it by itself and Party A will approve it.

Article 6: Settlement of project completion acceptance.

1. Party B shall notify Party A of acceptance in writing or orally before the completion of the project;

2. Party A shall organize the acceptance after receiving the acceptance notice, and issue the project acceptance certificate after passing the acceptance;

3. If the project is used by Party A in advance without acceptance, it shall be deemed that Party A has confirmed that the project is qualified. If quality problems are found after use, Party A shall bear the responsibility;

4. After the completion of the project, Party B will provide free maintenance service for one year, excluding the damaged part caused by human factors.

Article 7: Safe production and civilized construction of the project.

1. Party A shall make safety disclosure for the project undertaken by Party B, make clear the safety requirements and conduct supervision and inspection, and both parties shall negotiate related safety production responsibilities and public security and fire control matters according to regulations.

2. Party B must conscientiously implement the rules and regulations on safety production and civilized construction, do a good job in safety production and civilized construction education, strictly implement safety operation procedures and civilized construction requirements, and strictly implement public security fire control regulations.

3. In the process of project construction, if Party B's personnel suffer from work-related injuries and acute diseases, Party A has the obligation to provide convenience and assistance, and the responsibilities and expenses shall be borne by the responsible party.

Article 8: Engineering Punishment and Arbitration.

1. If the construction period is delayed by one day according to the contract of this project, it will be punished according to two thousandths of the total project cost, and the construction period punishment will be settled at one time after the completion of this project. If one party breaches the contract, the breaching party shall bear the penalty of 20% of the contract price;

2. If Party A delays the settlement and payment, it shall be implemented according to the current relevant national regulations;

3. In case of any contract dispute during the execution of this contract, both parties shall settle it through negotiation in time. If negotiation fails, either party may apply to the superior competent department or the construction competent department of both parties for mediation. If mediation fails, it may be submitted to the Arbitration Commission where the project is located for arbitration or bring a lawsuit to the people's court where the project is located.

Article 9: Supplementary provisions.

1. For matters not covered in this contract, both parties shall negotiate supplementary terms in time, which have the same legal effect as this contract.

2. This contract is made in duplicate, with each party holding one copy.

3. This contract shall come into effect after being signed and sealed by both parties. The warranty period expires after the project is completed, accepted and delivered, and the project price will be automatically terminated after settlement.

4. Effective annexes to this contract.

(1) Party B shall provide the plane drawings;

(2) Project budget;

(3) Supplementary clauses;

(4) others.

Party A (seal): Party B (seal):

Agent:

Year, month, sun, moon, sun.

Chapter II of House Decoration Agreement Client (Party A):

Organizer (Party B):

Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.

Article 1: General situation of the project.

1. Project location: XXX

2. Regarding the project contracting mode, both parties agree to adopt the following (1) contracting mode:

(1) Party B contracts all materials;

(2) Party B contracts some materials and Party A provides some materials.

(3) Party B undertakes the work and Party A undertakes all the materials. house decoration contract

3. Total price: XXX

4. Start date, month and year

Article 2: Quality requirements.

1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.

2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.

3. In the process of construction, if Party A has special construction projects or special quality requirements, both parties shall sign a supplementary contract for the increased cost.

4. Party A shall be responsible for the product quality of all materials and equipment purchased by Party A, and Party B shall be responsible for the construction quality. ..

5. If Party A hires a project supervisor, it shall notify Party B before the project starts, so as to facilitate the work connection.

Article 3: Material supply.

1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.

2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall be prohibited from being used. If it has been used, all losses caused to the project shall be borne by Party B. ..

3. The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. Pay Party B 10% of the total materials provided by Party A as the management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.

Article 4: Method of payment.

1. After the contract is signed, Party A shall pay 20% of the project cost; The remaining 80% will be settled by Party A after the project is completed and accepted.

Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.

2. If there is any increase or decrease in the project or need to be changed during the construction, both parties shall sign a supplementary contract, and Party B shall be responsible for the construction change order and notify the person in charge of the construction site. Increase or decrease the project price and settle on the spot.

3. If Party A fails to prepay the project price within the time limit stipulated in this contract, Party A shall pay 1% of the unpaid project price to Party B for each day overdue.

Article 5: Liability for breach of contract.

After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.

Article 6: The Contract comes into effect.

1. This contract and its annexes shall be sealed by both parties and come into force after being signed. Matters not covered in this contract shall be settled by both parties through consultation.

2. The supplementary contract has the same legal effect as this contract.

3. This contract is made in duplicate, with each party holding one copy.

Party A (Owner): Party B:

Bank account number: Bank account number:

Date of signature: year month day.

Entrusting Party (Party A) in Article 3 of the House Decoration Agreement: Pan Yonghua and Zhang Pengxi Undertaker (Party B):

After friendly negotiation between Party A and Party B, Party A decided to entrust Party B to decorate the house and signed this agreement for both parties to abide by.

I. Project Location, Room 40 1 Building G, Huayu Community, * * County

Form and structure: single floor, three bedrooms, two halls, one kitchen and two bathrooms

Three. Duration: one and a half months (45 days) from the commencement date.

Fourth, the way of contracting:

Part of the materials are contracted by Party B, and part of the materials are provided by Party A (see Schedule 1: List of Decoration Materials Provided by Party A for details). Schedule 2: List of Decoration Materials Provided by Party B)

Verb (abbreviation for verb) item:

1. Party B is responsible for laying tiles, laying corner lines and leveling the floors of five rooms (three bedrooms, one living room and one living room); The top of a kitchen and two bathrooms are covered with porcelain, leaving room for the ceiling and polishing the corners. Tiles shall be provided by Party A, and other materials shall be provided by Party B. ..

2. Party B is responsible for the circuit waterway reconstruction;

3. Party B is responsible for the integrated ceiling: kitchen and two bathrooms.

Step 4 Pack three water pipes

5. Party B is responsible for plastering the top of the living room and the top of the living room corridor. Materials shall be provided by Party B. ..

6. The wall should be coated with double lime powder. Party A shall provide paint materials, and Party B shall be responsible for the rest.

7. Party B is responsible for installing two bathroom door, lamps and sanitary ware, and the materials are provided by Party A. ..

8. After the renovation is completed, Party B shall be responsible for cleaning up.

9. The specific decoration of kitchen cabinets shall be proposed by Party A and determined through negotiation.

For matters not covered, Party A shall propose a plan and determine it through negotiation.

Supply of intransitive verb materials and equipment

1. The materials and equipment provided by Party A shall be qualified products that meet the requirements of design and national standards, and shall be supplied to the site in time according to the construction schedule, and Party B shall be notified in advance. Both parties shall accept the quantity and appearance of the supplied materials, and Party B shall be responsible for keeping them after handling the handover procedures.

2. The materials supplied by Party A shall not be used for other purposes without Party A's consent. If Party B misappropriates the materials, it shall compensate Party A at twice the price of the misappropriated materials.

3. The materials and equipment provided by Party B must conform to the varieties, specifications, models, quality, measurement standards and quantity in the list of materials provided.

4. If the materials and equipment provided by Party B do not meet the quality requirements of national standards or have different specifications, it is prohibited to use them; If it has been used, the consequences and losses shall be borne by Party B. ..

Seven, quality standards

The construction quality shall meet the safety requirements, and the decoration quality shall not be lower than the decoration standard of the same building type, which shall be approved by both parties. After the project is completed and accepted, if there are quality problems in Party B's construction within 3 months, Party B shall be responsible for rework and maintenance for free.

Eight, the project cost

Party A * * * pays Party B *** 15600 yuan for the decoration labor and materials.

Nine, the project payment is paid in the following ways:

(1) Party A shall pay 20% of the total price (3120 yuan) 2-5 days after the signing of this contract;

(2) Within three days after 50% of the engineering quantity is completed, Party A shall pay the engineering quantity equivalent to 40% of the total price (6240);

(3) Within three days after the completion acceptance, Party A shall pay the project payment equivalent to 40% of the total price (6240).

(IV) After one year of completion acceptance or the expiration of the warranty period agreed by both parties, if there is any quality problem in the decoration, Party B will check for Party A free of charge, otherwise, the damaged amount will be refunded!

X this agreement is made in duplicate, one for each party, with the same effect. This agreement shall come into effect as of the date of signature by both parties.

Party A: Party B:

Signature (seal): Signature (seal):

Tel: Tel:

Year, month, sun, moon, sun.