The full version of the commercial housing pre-sale contract model is simple.

Now it is a society ruled by law, and contracts are everywhere, just like the pre-sale of commercial housing, which will be used. The following is a simple model of pre-sale contract of commercial housing compiled by me for your reference only. Welcome to read this article.

The full version of the commercial housing pre-sale model contract is simple (1). The seller (hereinafter referred to as Party A) is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

The Buyer (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to the provisions of relevant laws and regulations, Party A and Party B have reached the following agreement on Party B's purchase of commercial housing from Party A on the basis of equality, voluntariness and consensus:

1. The commercial house purchased by Party B is located in _ _ _ _ _ _ _ _ _.

2. The specific building floors, building structure, design purpose and construction area of the commodity house are as follows.

________________________________。

If there is any difference in the delivery area of the Commodity House, the area measured by the property right supervision authority shall prevail.

Three. Party A shall show Party B the following documents of the house sold.

1. State-owned land use certificate, serial number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

2. The property ownership certificate with the certificate number of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

3. Commodity House Pre-sale Permit,No.: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

4. The selling price of the commodity house is: the actual construction area (interior area) _ _ _ _ _ _ _ _ Yuan/m2 (the apportioned area is converted into the unit price of the actual construction area according to the construction cost), and the house price is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

Verb (abbreviation of verb) Payment method and time shall be handled by both parties according to the following _ _ _ _.

1. Within _ _ _ _ days from the date of signing this contract, Party B shall pay off the house price in one lump sum, and Party A shall give Party B _ _ _% discount, that is, the paid house price is RMB.

2. Within _ _ _ _ _ _ days from the date of signing this contract, Party B shall pay the down payment of RMB _ _ _ _ _ _, and the balance shall be paid in _ _ _ _ _ _.

3. Party A and Party B agree on other payment methods or Party B's loan (mortgage) to purchase the house, and Party A and Party B sign a supplementary contract on this content.

6. If Party B fails to pay the house price as agreed in Article 5 of this contract, it is a breach of contract by Party B. Party A shall hold Party B liable for breach of contract according to the following agreement.

1. When this contract is terminated, Party B shall pay liquidated damages to Party A at _ _ _% of the house payment payable. If the actual economic loss of Party A exceeds the liquidated damages paid by Party B, the difference between the actual economic loss and the amount of breach of contract shall be compensated by Party B according to the facts.

2. If the contract continues to be performed, Party B shall pay liquidated damages to Party A according to _ _ _ _ _ _.

7. Party A shall deliver the commercial house that has passed the completion acceptance (including the quality acceptance of the construction project and the required comprehensive acceptance) to Party B before.

Eight, except for the special circumstances stipulated in Article 7 of this contract, Party A's failure to deliver the commodity house to Party B within the time limit stipulated in this contract is a breach of contract by Party A, and Party B shall investigate Party A's liability for breach of contract in the following way.

1. When this contract is terminated, Party A shall support Party B with _ _ _ _% of the house payment payable by Party B as liquidated damages. When the actual economic loss of Party B exceeds the liquidated damages paid by Party A, the difference between the actual economic loss and the liquidated damages shall be compensated by Party A according to the facts.

2. If the contract continues to be performed, Party A shall pay liquidated damages to Party B according to _ _ _ _ _ _.

9. If the difference between the area of the commercial house sold by Party A and the measured area of the property right supervision authority is within _ _ _ _% (inclusive), the house payment shall be settled according to the measured area; If the difference exceeds _ _ _ _ _ _% (inclusive), Party B shall handle it according to the following _ _ _ _ _ _ _ _ agreement.

1. When this contract is dissolved, Party A shall return the house payment paid by Party B to Party B within _ _ _ _ _ days from the date when Party B requests to dissolve the contract, and pay interest at the interest rate of _ _ _ _ _.

2. The Contract continues to be performed, and both parties agree on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

X. During the development and construction of pre-sold commercial housing, if Party A adjusts or modifies the original design scheme, and Party B must notify Party B in writing to cancel the house purchase within _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

XI。 When the commercial house sold by Party A is delivered to Party B, the supporting environment and facilities of the commercial house must conform to the commitments made by Party A when selling the house and the agreements of both parties. The standards, warranty responsibilities and quality requirements of the decoration, fitment and supporting facilities and equipment of the Commodity House must conform to the descriptions, regulations and commitments in the attached Manual for the Use of Commercial House and Quality Guarantee of Commercial House.

12. After the commercial house is delivered to Party B, Party A shall assist Party B to go through the ownership registration formalities with the real estate supervision department within _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

1. In case of termination of the contract, Party A shall return the house payment paid by Party B to Party B within _ _ _ _ days from the date when Party B requests to terminate the contract, and pay _ _ _% of the house payment paid by Party B as liquidated damages.

2. If the contract continues to be performed, Party A shall pay liquidated damages to Party B according to _ _ _ _ _ _.

Thirteen. When signing this contract, Party A and Party B shall sign the preliminary property management service agreement in accordance with relevant government regulations.

14. For matters not covered in this contract, Party A and Party B shall negotiate separately and sign a supplementary agreement.

15. This contract together with its annexes and supplementary agreement * * * _ _ _ _ pages shall come into effect after being signed by both parties, one for each party, and one for the record of Chengdu Housing Property Supervision Office, which has the same legal effect.

16. Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, both parties agree to settle the matter in the following _ _ _ _ _ _ _ _ _ _ _.

1. Arbitration by _ _ _ _ _ _ _ Arbitration Commission.

2. Bring a lawsuit to the people's court.

Seventeen. Other agreements: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party A: _ _ _ _ _ _ _

Party B: _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _

The complete version of the pre-sale contract model of commercial housing is simple (II) The Seller (hereinafter referred to as Party A) :_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

The Buyer (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

According to People's Republic of China (PRC) City Real Estate Management Law and related regulations, Party A has obtained _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B voluntarily purchases Party A's _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. The down payment of the house purchased by Party B is RMB Yuan only. Both parties have reached an agreement on the pre-sale and pre-purchase of the house, and entered into this contract.

Article 1 The house is detailed in Annex 1. The building area of the house is _ _ _ _ _ _ _ _ square meters (including _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _). * * * See Annex II for the parts used. The above-mentioned building area is temporarily measured by Party A, and the area measured by the surveying and mapping department shall prevail after the house is completed.

When Party A sells the house, it also transfers the land use right within the occupied area of the house to Party B. The land use area (including the apportioned interior area of * * * *) is _ _ _ _ _ _ _ square meters, which is the temporarily measured area of Party A. After the house is completed, it shall be subject to the measured area of the surveying and mapping department. The term of land use shall be from the date of property right transfer to _ _ _ _ _ _.

Article 2 Party A and Party B agree that when settling the house price, if the error between the actually measured building area and the temporarily measured building area does not exceed _ _ _% (including _ _ _%), the house price stated in Article 3 of this contract shall be settled truthfully; If the error of the construction area exceeds the above agreed range, both parties agree to deal with it in the following _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

1. Party B has the right to terminate this contract. The termination of this contract shall take effect from the date when Party B sends a written notice to Party A, and Party A shall double the deposit paid by Party B and all the house payment and interest within _ _ _ _ _ days from the date of termination of this contract. Interest is calculated at the interest rate of _ _ _ _ _ _.

2. Settle according to the unit price stipulated in Article 3 of this contract.

3.________________________________________________________

Article 3 Both parties agree that the selling price of the above-mentioned pre-sale house is RMB per square meter of the building. The total price is RMB (in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Party B agrees to pay the payment in person to Party A or remit it to the bank designated by Party A as scheduled according to the payment method agreed by both parties. The deposit paid by Party B will be converted into the purchase price when Party B makes the last payment. The supervising bank of Party A's sales payment is _ _ _ _ _ _ _ _ _ _ _ _

Article 4 If Party B fails to make payment within the time specified in Annex 3 to this contract, Party A has the right to demand Party B to pay liquidated damages ... From the second day after the expiration of the payment period agreed in this contract to the actual payment date, Party B shall pay Party A RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The termination of this contract shall come into effect as of the date when Party A's written notice reaches Party B. The deposit paid by Party B shall not be refunded by Party A. ..

Article 5 When Party A delivers the house to Party B, it shall also submit the Urban Construction Project Quality Certificate issued by the construction project quality supervision department and the measured area data of the surveying and mapping department; If both parties agree to deliver the newly renovated house, they must submit the acceptance certificate of the quality supervision department of the construction project and the measured area data of the surveying and mapping department, which is in line with the gist of the Provisions on the Verification of Decoration Quality in the Initial Stage of Construction Project (Trial). After meeting the conditions specified in this clause, the date of delivery of the house by Party A is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. If the house delivered by Party A fails to pass the inspection by the construction quality supervision department, Party B has the right to terminate this contract. Party A shall return all the house payment and interest paid by Party B within _ _ _ _ days from the date of termination of the Contract, and the interest shall be calculated at _ _ _ _.

Article 6 If the decoration and equipment of the house delivered by Party A do not meet the standards specified in the annex, Party A agrees to compensate Party B according to _ _ _ _ _ _.

Article 7 Except for force majeure, if Party A fails to deliver the house to Party B on schedule, Party B has the right to demand liquidated damages from Party A. From the second day after the delivery of the house agreed in this contract to the actual delivery date, Party A shall pay Party B _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The termination of this contract shall take effect from the date when Party B sends a written notice to Party A. Party A shall, within _ _ _ _ _ days from the date of termination of this contract, return all the house payment and interest paid by Party B, and double the deposit to Party B (interest calculation is the same as Article 5).

Article 8 After the signing of this contract, if Party A changes the architectural design, which affects the interior area, plane layout and use space of the house purchased by Party B, it shall notify Party B in writing within _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The termination of this contract shall take effect from the date when Party B's written notice is delivered to Party A. Party A shall return the house purchase price and interest paid by Party B to Party B within _ _ _ _ _ _ _ days from the date of termination of this contract (interest calculation is the same as Article 5), and return it to Party B twice ... If Party A changes the architectural design without notifying Party B, Party B has the right to terminate this contract. Party A shall not only refund the house payment and interest paid by Party B (the interest calculation is the same as Article 5), but also double the deposit to Party B, and bear the liabilities for breach of contract agreed by both parties in the supplementary agreement.

Article 9 Party A agrees to guarantee the house purchased by Party B in accordance with the Measures for Quality Management of Construction Projects, Regulations on Quality of Construction Projects and relevant regulations from the date of delivery of the completed house.

Article 10 Party B agrees that Party A or the property management company designated by Party A will manage the house purchased by Party A before the residential property management committee or the owners management committee selects the property management organization.

Article 11 Both parties agree to go through the pre-sale and pre-purchase registration formalities at the municipal real estate transaction management department with this contract and relevant documents within _ _ _ _ days after the signing of this contract.

Article 12 After the signing of this contract and before the delivery of the house, Party B shall not transfer the house purchased in advance. If the transfer is necessary for special reasons, Party A must agree and sign a written agreement on pre-sale transfer, and report it to the Municipal Housing and Land Administration for approval.

Article 13 Both parties agree that when the house meets the delivery conditions, it shall go through the formalities of house sale and transfer in the real estate transaction management department as required, handle the certificate of real estate ownership, and pay relevant taxes as required.

Article 14 In case of any dispute during the performance of this contract, both parties shall settle it through negotiation. If negotiation fails, both parties agree to settle the dispute by the following _ _ _ _ _ (in words):

1. Submit to _ _ _ _ _ _ _ _ Arbitration Commission for arbitration;

2. Either party may bring a lawsuit to the people's court where the real estate is located.

Article 15 For matters not covered in this contract, both parties may sign a supplementary agreement. The annex to this contract and the supplementary agreement signed by both parties are an integral part of this contract and have the same legal effect.

Article 16 The original of this contract is in duplicate, each party holds one copy, and the real estate transaction management department keeps one copy, _ _ _ _ _ _ _ _ _ _.

Party A (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Legal Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Phone number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Postal code: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Agent: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Phone number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Pre-sale registration authority: (seal) _ _ _ _ _ _ _ _ _ _ _ _

Agent: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Simple full version of Model Commodity House Pre-sale Contract (III) Seller (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Address: _ _ _ _ _ _ _ _ _ _ Postal Code: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Tel: _ _ _ _ _ _

Buyer (Party B): _ _ _ _ _ _ _ _ _ _ _ _

Name: _ _ _ _ _ _ _ _ _ _ _ Gender: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Date of birth: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

ID number: _ _ _ _ _ _ _

Address: _ _ _ _ _ _ _

Position: _ _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 1 After approval, Party A has obtained the land use right of _ _ _ _ _ _ square meters.

Prot. : _ _ _ _ The service life is _ _ _ years, counting from _ _ _ _ _ _ _ _. The building built by Party A on the above-mentioned land is called _ _ _ _ _ _ _ _ _ _, which shall be pre-sold by Party A. ..

Article 2 Party B orders voluntarily. _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The building area is _ _ ㎡, and the land area is/㎡ (including _ _ ㎡ shared basement part, _ _ ㎡ public part and other parts _ _ ㎡).

Article 3 Party A shall deliver the house to Party B for use on.

Delivery may be delayed for no more than _ _ _ _ _ days for any of the following special reasons:

1. Force majeure natural disasters;

2. Abnormal difficulties and major technical problems encountered in the construction cannot be solved in time;

3. Other factors beyond Party A's control.

The above reasons must be based on the certification documents of the relevant competent authorities in _ _ _ _ _ _ _ _ _ _.

Article 4 Party A and Party B agree that the selling price of the above-mentioned ordered house is RMB per square meter, and the total amount is RMB only.

Payment method: Party B pays through the bank designated by Party A:

Account name: _ _ _ _ _ _ _ _ _ _ _ _ Account number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 5 If Party B fails to make payment within the time stipulated in Article 4 of this contract, Party A has the right to demand payment of penalty interest. If the overdue period is over _ _ _ days, Party A has the right to unilaterally terminate the contract and sell the house to others.

Article 6 If Party A fails to deliver the goods to Party B on the date stipulated in Article 3 of this contract, it shall calculate the interest on the payment from the second day of the delivery date stipulated in this contract to compensate Party B for its losses.

Article 7 The house sold by Party A must pass the inspection by the municipal building quality inspection department and be guaranteed for one year. If the quality is unqualified, Party B has the right to reject the house. After the house is rejected, Party A shall return the payment and all interest to Party B within _ _ _ _ _ _.

Article 8 After the house is delivered and paid off, Party A and Party B sign a real estate transfer contract and go through the transfer registration formalities with the municipal competent department, then Party B can obtain the real estate right.

During the use period, Party B has the right to enjoy the public passages, facilities and venues related to the building, and must abide by the laws, decrees and social ethics of People's Republic of China (PRC), and safeguard public facilities and public interests.

Article 9 The house purchased by Party B is only used for _ _ _ _ _ purposes, and the structure and purpose of the house shall not be changed without authorization during the use period. If it is damaged, it should be repaired at its own expense.

The land occupied by the house purchased by Party B shall pay the land use fee according to the relevant land management regulations.

Article 10 Party B shall not transfer or mortgage the pre-sold house, otherwise it will bear the consequences.

Article 11 This contract shall come into effect as of the date of signature and seal. In case of any dispute, both parties shall settle it through friendly negotiation. If negotiation fails, it shall be settled in the following () way:

1. Arbitration by an arbitration institution;

2. The judgment of the people's court;

Article 12 The original of this contract is in quadruplicate, one for each party, one for the notary office and one for the real estate ownership registration office.

Party A: _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.