Electric power company project contract

Contract number:

Signing date:

Project contract terms

Party A: ××± Company

Party B:

In accordance with the Contract Law of the People's Republic of China and the People's Republic of China, Party A and Party B have reached the following agreement with the contractor based on the principle of mutual benefit and based on the actual situation of this project.

Article 1 Project Overview

1.1 Project Name: 35KV Hightower Substation Project.

Project Location: Qilian County, Qinghai Province

Project content and contract scope: All construction contents within the scope of the civil construction drawings designed by the design institute (earth excavation and backfilling in the area, excavation of the 100-meter wall foundation trench, excavation of the main factory building, and grounding grid excavation and backfilling Except)

1.2 Construction completion date: October 20, 2005 ------- June 30, 2006 (installation conditions must be met on December 10, 2005)

1.3 Quality level: Excellent (excellent rate reaches 95)

1.4 Contract price: The approved design institute (approximate) budget is reduced by 23 (including changes and visa parts)

Article 2 Party B’s person in charge of the project: Xu Rukun

Article 3 Party B must strictly fulfill the quality, construction period and safety requirements of the construction contract during the construction process, and carry out construction in strict accordance with the requirements of the drawings and national construction standards. There is any behavior of cutting corners and shoddy manufacturing. If quality accidents are found, rework is found or the construction period is delayed, the economic losses caused will be borne by Party B.

Article 4 Party B must accept Party A’s regulations on construction quality operation specifications. Inspection and supervision. Party B’s construction personnel must respect the opinions of Party A and the supervisor, and shall not refuse supervision instructions related to quality.

Article 5 Within one month after the completion acceptance of this project, Party B must prepare four copies of the as-built drawings , four copies of the project final accounts and the project completion list. The remaining information should be submitted when the project is completed and accepted. Other contents include: project construction diary, project construction summary, hidden project data experimental records and various technical data.

Article 6 Party B must provide Party A with the construction progress plan for next month and the actual completion progress report for this month before the 23rd of each month, otherwise Party A will not pay the progress payment for this month.

Article 7 During the entire construction process, Party B must carefully fill in various relevant technical information, construction diaries, hidden engineering information, design changes, sub-project quality assessment records and other state-stipulated delivery information. The information must be complete at the time of delivery.

Article 8 All materials required for the project must be of high quality and have complete three certificates. Unqualified materials are never allowed to be used for construction; concrete and mortar test blocks and pressure test reports must be prepared.

Article 9 Construction must be carried out strictly in accordance with the operating procedures to ensure site safety, educate construction personnel on safe construction and civilized construction, and strengthen safety management. Personal, equipment, project quality accidents and other man-made accidents caused by Party B’s negligence shall All responsibilities shall be borne by Party B. Party A shall not bear any criminal liability or economic responsibility, nor shall it pay any fees.

Article 10 Party B must implement all construction contract terms promised to the construction unit.

p>

Article 11 During the construction process of the project, Party B must complete all external procedures. Any fees and penalties required by the competent authorities and relevant government departments shall be borne by Party B; if Party B cannot If it is handled in a timely manner, Party A will arrange personnel to handle it, and all expenses incurred will be deducted from Party B’s fees.

Article 12

Arbitration When a dispute arises between Party B and Party A, the two parties shall try their best to resolve it through negotiation. If the negotiation cannot resolve the dispute, the complaining party may apply for arbitration by the arbitration committee or file a lawsuit in court.

Article 13 Legal matters not covered in this contract , the two parties shall refer to the "Contract Law of the People's Republic of China" to negotiate and resolve.

Article 14 Supplementary Clauses

1. Party B must provide the tax stamp for the contract price in full (Including material tax stamps), the taxes shall be borne by Party B.

2. All liquidated damages incurred due to delay in construction period shall be borne by Party B.

3. If Party B is unable to perform this contract , or the contract cannot be executed due to other reasons, Party A will settle 80% of the completed work to Party B, and the remaining 20% ??will be used as entry fees for the new team.

4. Since Party B cannot follow Party A’s instructions When the required construction period is completed, Party A has the right to arrange for other teams to enter the site for construction, and the costs incurred will be deducted from Party B’s contracting costs.

5. If the civil construction project meets the delivery safety conditions, the total cost of the project will be calculated for each day of delay. A penalty of five thousandths will be imposed, and the total amount of the penalty shall not exceed 50,000 yuan.

6. Party A pays Party B’s project payment by transfer. When transferring the money, Party B will provide a tax-paid invoice and a public account. To be After the completion of the project, Party A will pay 95% of the total project cost, and the remaining 5% will be used as a quality deposit. If there are no quality problems one year after the project is completed and accepted, Party A will pay Party B without interest.

7 , This contract is made in triplicate, with Party A holding two copies and Party B holding one copy.

8. This contract will take effect after being signed and sealed by both parties, and will automatically expire after the project payment is settled.

Party A: Party B:

Representative: Representative:

Year, month and day

Project Contracting Contract

Contract number :

Signing date:

Project contract terms

Party A: Xining Zhongheng Electric Power Installation Engineering Co., Ltd.

Party B:

According to the Contract Law of the People's Republic of China and the People's Republic of China, Party A and Party B have reached the following agreement with the contractor based on the principle of mutual benefit and based on the actual situation of this project. .

Article 2 Project Overview

1.1 Project name: 110kV Bayin-Lianhu G1-G56 power transmission line project.

Project location: Delingha, Qinghai Province.

Project content and contract scope: All construction contents within the scope of the construction drawings designed by the design institute (including basic sand and gravel, water, slope protection stones and construction tools and equipment;

Other materials are provided by Party A provides that the amount of cement in the materials provided by Party A must be controlled within the range of the material usage table produced by the design institute).

1.2 Construction completion date: August 5, 2010------June 30, 2010.

1.3 Quality level: Passed the one-time inspection.

1.4 Contract price: 89,000 yuan/km for flat land and rocky terrain; 125,000 yuan/km for swamps. The final price is determined by the actual on-site inspection results.

Article 2: Party B’s project leader:

Article 3: Party B must strictly fulfill the quality, construction period, and safety requirements of the construction contract during the construction process, and strictly follow the requirements of the drawings The construction will be carried out in accordance with the national construction specifications and standards, and any behavior of cutting corners or shoddy work will never be allowed to occur. If quality accidents are found, rework or the construction period is delayed, the economic losses caused will be borne by Party B.

Article 4: Party B must accept Party A’s inspection and supervision of construction quality operating specifications. Party B’s construction personnel must respect the opinions of Party A and the supervisor and must not refuse supervision instructions related to quality.

Article 5: According to the standardization requirements, Party A is responsible for the production of various types of signs for Party B, and the costs shall be borne by Party B.

Article 6: According to relevant regulations, Party B is not allowed to subcontract the project to a third party, otherwise Party A has the right to terminate Party B’s contracting qualifications and bear corresponding losses.

Article 7: Party B must apply for personal accident insurance for each employee, otherwise it will not start work.

Article 8: Party A has the right to supervise and intervene in the determination and payment of wages of migrant workers to avoid serious violations of the Labor Law.

Article 15: Within one month after the completion and acceptance of the project, Party B must prepare four copies of the completion drawings: four copies of the project final account and the project completion list. The remaining information should be submitted at the time of the completion and acceptance of the project. Others Content includes: project construction diary, project construction summary, hidden project data experimental records and various technical data.

Article 16: Party B must provide Party A with next month’s construction progress plan and this month’s actual completion progress report before the 23rd of each month, otherwise Party A will not pay this month’s progress payment.

Article 17: During the entire construction process, Party B must carefully fill in various relevant technical information, construction diaries, hidden engineering information, design changes, sub-project quality assessment records and other state-stipulated delivery documents. The information must be complete when handing over the work.

Article 18: The quality of various materials required for the project must be guaranteed and the three certificates must be complete. Unqualified materials are never allowed to be used for construction. Concrete and mortar test blocks and pressure test reports must be prepared. .

Article 19: Construction must be carried out strictly in accordance with operating procedures to ensure site safety, educate construction personnel on safe construction and civilized construction, and strengthen safety management. Any personal, equipment, or project quality damage caused by Party B’s negligence All responsibilities for accidents and other man-made accidents shall be borne by Party B. Party A will not assume any criminal liability or financial responsibility, nor will it pay any fees.

Article 20: Party B must implement all construction contract terms promised to the construction unit.

Article 21:

During the construction process of the project, Party B must complete all external procedures and pay any fees required by the competent authorities and relevant government departments. Party B will be responsible for all penalties and penalties. If Party B cannot handle the matter in time, Party A will arrange personnel to handle the matter and deduct all costs incurred from Party B's fees.

Article 22: Arbitration When a dispute arises between Party B and Party A, the two parties shall try their best to resolve the dispute through negotiation. If the negotiation cannot resolve the dispute, the complaining party may apply for arbitration by the arbitration committee or file a lawsuit in court.

Article 23: Legal matters not covered in this contract shall be resolved through negotiation by both parties with reference to the Contract Law of the People's Republic of China.

Article 24: Supplementary Terms

9. Party B must provide tax stamps (including material tax stamps) for the contract price in full, and Party B shall bear the tax.

10. All liquidated damages incurred due to delay in construction period shall be borne by Party B.

11. If Party B is unable to perform this contract, or the contract cannot be executed due to other reasons, Party A will settle 80% of the completed work quantity to Party B, and the remaining 20% ??will be used as the entry fee for the new entry team.

12. Since Party B is unable to complete the construction within the time limit required by Party A, Party A has the right to arrange for other teams to enter the site for construction, and the costs incurred will be deducted from Party B's contracting costs.

13. A penalty of five thousandths of the total project cost will be imposed for each day of delay, and the total penalty shall not exceed 50,000 yuan.

14. Party A pays Party B the project payment by transfer. When transferring the money, Party B provides a tax-paid invoice and a public account. After the completion of the project, Party A pays 90% of the total project cost. , and the remaining 10 will be used as a quality deposit. If there are no quality problems one year after the project is completed and accepted, Party A will pay it to Party B without interest.

15. This contract is made in triplicate, with Party A holding two copies and Party B holding one copy.

16. This contract will come into effect upon signature and seal of both parties, and will automatically expire after the project payment is settled.

Party A: Party B:

Representative: Representative:

Year, month, day