contract agreement

Party B: (Lessor)

According to the Contract Law of People's Republic of China (PRC) and the relevant provisions of the lease contract of the Contract Law, Party A and Party B have reached the following agreement on the lease of Party B's tower crane through friendly negotiation on the basis of equality and mutual benefit:

Article 1: Project Overview

I. Name of the project; Dahua West Coast Property Hotel Project

2. Project Location: West Coast of Haikou

3. Building height: about 44m.

Four. Duration: Commencement Time: Year Month Day Completion Time: Year Month Day.

Article 2 Lease of mechanical equipment

I. Overview of Leased Machinery and Equipment

Second, the mechanical equipment rental price:

1, tower crane rent QTZ63 yuan whole each (. Including the monthly rental fee, operator's salary, maintenance fee, daily maintenance, maintenance, accessories and all expenses required for the normal work of this project (excluding command and taxes, Party B will receive the payment with the receipt).

2. The entry and exit fee of tower crane is RMB per set, including B ..

Transportation fee, installation and debugging fee, inspection fee, etc. After the installation and debugging of the tower crane is completed, it shall be paid to Party B in one lump sum. (Party B will receive the admission fee with the receipt).

3. Tower crane commanders, Party B is responsible for arranging experienced commanders to take up their posts, and Party A is responsible for paying the commanders the salary of Wu Bai Yuan per person per month (￥ 1500.00 Yuan). Each tower crane is tentatively assigned a commander, who must obey the command of Party A's on-site dispatcher.

Third, the lease term.

1, the lease period is tentatively calculated on a monthly basis, and those exceeding the month are calculated on the basis of actual days.

2. Rent-starting time: After receiving the notice from Party A, Party B will transport the equipment to Party A's construction site, install it to a height of more than 25m, and start to calculate the rent.

3. Deadline: the date when Party A notifies Party B in writing to stop using it.

4. Transportation, disassembly and installation of leased machinery and equipment.

1. Party A shall be responsible for completing the tower crane foundation construction according to the tower crane foundation drawing provided by Party B, and Party B shall arrange professional and technical personnel to cooperate at the site, and be responsible for installing the anchor bolts and bases.

2. Party B is responsible for the on-site and off-site transportation of the leased machinery and equipment.

3. Party B shall be responsible for the installation and disassembly of the leased machinery and equipment, and the specific time shall be determined according to Party A's requirements.

Article 3 Work of Party A

1. Ensure that the access road of equipment and the operation surface required for equipment installation, jacking and dismantling are smooth, and carry out foundation construction according to the tower crane foundation drawing provided by Party B, so as to ensure the durability of the ground to meet the safety requirements of mechanical equipment (Party B shall check the slot).

2. Party A is responsible for the coordination required in the process of equipment installation, disassembly and hoisting.

3. Make the tower crane foundation according to the tower crane foundation drawings and other materials provided by Party B, and be responsible for the quality problems of the tower crane foundation. Party B sends people to guide the construction. (If it is a brand-new tower crane, Party A will also make a counterweight for Party B free of charge. )

Four, provide free power supply to meet the needs of the normal use of tower crane, responsible for the on-site power supply next to the tower crane foundation, and equipped with special electric boxes and special lines. The distribution box is not more than 10 meters away from tower crane equipment, and the voltage is guaranteed to be within 380 V 5%.

5. After the installation and debugging of Party B's tower crane is completed, Party A shall pay Party B an entry and exit fee of 20,000 yuan each. Party A shall pay Party B the rent for the first two months in one lump sum in the third month, and then pay Party B the tower crane rental fee for the current month on time when it is due. During the lease period, if the work is stopped due to Party A's reasons or natural disasters, the rent during the work stoppage shall be calculated as usual. The national statutory holiday rent is calculated according to the standard. The tower crane guarantees 24-hour cooperation with the construction site.

6. Party A provides free accommodation and overtime meals at night for tower crane drivers and commanders.

Article 4 Party B's Work

1. Party B is responsible for the installation, jacking, disassembly and transportation of the equipment.

2. Be responsible for the inspection procedures of the quality inspection department within 40 days after installation. Provide relevant information of tower crane and a copy of detailed construction drawing of tower crane foundation.

3. Be responsible for providing tower crane operation certificates for skilled professionals to enter Party A's site to start the machine. Tower crane operators shall obey the work arrangement of Party A and abide by Party A's on-site rules and regulations. If the operators provided by Party B do not obey Party A's work arrangement or Party A's on-site rules and regulations and cannot meet Party A's requirements, Party A has the right to ask Party B to replace or retire, and Party B shall replace them in time within 2 days after Party A's request for replacement or retirement.

Four, responsible for on-site safety management and daily safety education and task requirements for operators. During the installation, disassembly, operation and maintenance of the tower crane, it shall be carried out in strict accordance with the operating procedures stipulated by the state, and the working performance and safety of the tower crane shall be regularly checked and maintained every day to ensure the safe use of Party A. ..

Five, to ensure the normal operation of the tower crane for 24 hours, in case of failure, should promptly organize personnel for maintenance. If the equipment stops using due to failure, it shall not exceed 72 hours per month, excluding the maintenance time of the main motor. If the above time is exceeded, the normal use will be affected, and the excess will be deducted from Party B's rent every month.

Six, the operator must hold valid certificates issued by the competent department of the industry, technology must meet the requirements of industry management, have good professional ethics, and shall not eat, take, card or ask for it from Party A under any excuse. ..

7. Party B shall be responsible for safety accidents and property losses caused by improper operation and equipment failure.

Article 5 Job responsibilities of mechanical operators

A, tower crane operators must strictly abide by the site safety management system, the operator must have a formal license issued by the functional departments, and carry a deputy certificate, easy to accept the inspection.

Second, the operator must obey the production arrangement of the project, complete the task with high efficiency and high quality to improve his own quality, and it is strictly forbidden to refuse the operation for abnormal reasons to prevent the operator from asking for property from the project or subcontractors.

Three, the operator must strictly abide by the operating rules, do "four understanding", "three meetings, two sessions", not illegal operation, lifting should adhere to the "ten don't lift", it is forbidden to fatigue operation and drunk operation.

Four, the operator should strictly abide by the system of succession, clear and accurate records, must do a good job of daily maintenance before class, it is forbidden to mechanical operation in spite of illness, the operator should take the initiative to negotiate with the head of the project intends to have objections at work.

Five, tower crane mechanical failure, the operator should be ruled out in time, if it can't be solved, it should promptly notify the person in charge of Party B, immediately send professionals to carry out maintenance, and report the specific situation to the project intends to at the same time, otherwise the responsibility will be at your own risk.

Six, the operator should actively cooperate with the bell man's command to carry light, it is forbidden to barbaric construction. All losses caused to Party A and the third party on site due to barbaric construction shall be borne by Party B. Operators must be familiar with the overall situation on site, identify key parts and take safety precautions.

Article 6 Liability for breach of contract

1. If Party A fails to pay the rent to Party B on time as agreed, Party B has the right to stop work, and the rent will be calculated as usual during the period of stop work.

2. If Party A fails to use the leased equipment according to its normal performance and agreed purpose, Party B has the right to take back the leased equipment and terminate the contract, and Party A shall bear the liability for breach of contract and compensate for the equipment losses.

3. If Party A dismantles or changes the equipment without authorization, it shall be responsible for compensating the losses caused to Party B..

4. If Party B fails to provide machinery and equipment according to the quality standards stipulated in the contract, so that Party A cannot use it normally as scheduled, Party B shall be responsible for timely repair, replacement or full compensation, and compensate for the direct losses caused to Party A as a result.

Five, within the scope of the contract, both parties shall not withdraw the lease for any reason. In case of rent withdrawal, the party who proposes rent withdrawal shall compensate the other party for the direct losses caused thereby.

Article 7 Disputes

In case of any dispute during the execution of this contract, both parties shall settle it through consultation. If negotiation fails, arbitration can be conducted at the plaintiff's place. For matters not covered in this contract, both parties shall negotiate and sign a supplementary agreement in time, which has the same legal effect as this contract.

Article 8 Others

This contract is made in quadruplicate, with Party A and Party B holding two copies respectively. It shall come into effect as of the date of signature and seal by both parties, and this contract will automatically become invalid after both parties have completed the agreed work contents and settled all expenses.

Representative of Party A: Representative of Party B:

(signature and seal): (signature and seal):

Date, year and month

Article 2 of the contract Both parties to the contract:

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

In order to make full use of water resources, develop fishery production, provide more commercial fish for urban and rural people, and increase collective and individual income, according to the spirit of the central documents (83) and (84) 1, after full discussion at the general meeting of members and serious consultation between Party A and Party B, this contract is hereby concluded for both parties to abide by.

I. Place and area of the contract

Party A will contract fish ponds (rivers, reservoirs and lakes) located in _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Second, the contract period

The contract period is _ _ _ _ _ _ _ years.

Three. The method and time for Party B to pay Party A's commission.

During the contract period, Party B shall pay _ _ _ _ _ gold (or _ _ _ _ yuan) to Party A for fresh fish (or contract money). Among the fresh fish delivered to Party A, there are _ _ _ _ _ _ _ Jin (_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Four. Rights and obligations of Party A

1. Party A shall provide Party B with _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.

3. If the superior has loans, cash or materials to support fishery production, Party A shall distribute them to Party B reasonably.

3. Party A shall educate its members on the protection of fishery production. In case of theft, poisoning and fish frying, Party A shall actively assist Party B to deal with it.

4. When there is a contradiction between fish farming and agricultural water use, Party A must ensure that the minimum water level of Party B is not less than _ _ _ _ meters.

5. When Party B needs to drain or pump water, Party A shall provide Party B with a water pump in time.

Party A has the right to urge Party B to fulfill its obligations under this contract.

Verb (abbreviation of verb) Rights and obligations of Party B.

1. Except for force majeure, Party B must complete the obligations stipulated in the contract within the time stipulated in the contract and complete the national commercial fish acquisition task (if any).

3. Party B shall pay for raising fish, releasing fry and taking care of fish ponds (or rivers, reservoirs and lakes).

3. When fishing, Party B is forbidden to use dangerous methods such as electric fish, poisonous fish and fried fish.

4. Party B shall give priority to completing the contracting tasks after fishing every year.

5. After the expiration of the contract, Party B shall promptly return the house and fish tools provided by Party A to Party B for use. In case of damage or loss, Party B shall be responsible for repair or compensation.

6. After the expiration of the contract, Party B shall hand over the small fish and fry in the fish ponds (or rivers, reservoirs and lakes) to Party A (or Party A shall purchase them at the agreed price).

7. Party B has the right to manage fish farming independently, and Party A shall not interfere. After Party B completes the obligations stipulated in the contract, the excess shall be owned by Party B. ..

If Party B catches the fish thief, each person will be fined RMB for stealing fish, and the fine will be returned to Party B. ..

(9) After the expiration of the contract, if Party A contracts again, under the same conditions, Party B has the priority to contract.

Intransitive Verb Party A's Liability for Breach of Contract

1. If Party A fails to provide Party B with the house and fish tools as stipulated in the contract, it shall pay Party B RMB as penalty, and Party B may propose to terminate the contract.

3. If Party A intercepts the loans, cash or materials supported by the higher authorities for fishery production, it shall pay liquidated damages to Party B at _ _ _% of the intercepted loan amount; If cash or articles are detained, Party B shall pay liquidated damages of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

3. If Party A fails to provide the water pump to Party B in time without any reason, Party A shall be responsible for the losses caused thereby.

Seven. Party B's liability for breach of contract

1. If Party B fails to complete the contract tasks within the time stipulated in the contract, Party B shall pay _ _ _ _% of the market price (or contract amount) of commercial fish to Party A for each day overdue.

3. If Party B fishes by dangerous methods such as electricity, poison and explosion, it shall pay liquidated damages to Party A at _ _% of the total contract price (commercial fish is discounted at the market price), and Party A may propose to terminate the contract.

3. At the expiration of the contract, if the fish and fry caught by Party B are less than _ _ _ _ _ _ _ _

Eight. force majeure

If fish ponds (rivers, reservoirs and lakes) collapse and dry up due to irresistible natural disasters (such as floods and droughts), after confirmation, Party A shall actually reduce or exempt Party B from contracting tasks.

Nine. others

This contract shall come into effect as of the date of signing, and neither party may change or terminate the contract at will. If the representative of Party A changes, this contract shall not be changed. If there are any matters not covered in this contract, both parties shall settle them through consultation.

Supplementary provisions. Supplementary terms have the same legal effect as this contract. Upon expiration of the contract, if both parties are willing to continue to perform the contract, they shall sign a new contract.

The original of this contract is in duplicate, one for each party; A copy of this contract exists in the form of _ _ _ _ _ _ _ _ _

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Representative: _ _ _ _ _ _ _

Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

Article 3 of the Contract: Employer (Party A):

Contractor (Party B):

Party A and Party B, in accordance with the relevant provisions of the Economic Contract Law of the People's Republic of China and the Regulations on Construction Project Contract, and in combination with the actual situation of this project, have reached the following agreement through consultation on the principle of equality, mutual benefit and voluntariness:

I. Project name:

Second, the project site selection:

Three. Total project cost: RMB.

Four. Commencement date of the project: year month day;

Verb (abbreviation of verb) signing method:

1. Party B is responsible for contracting labor, materials, safety, quality, civilized construction, warranty and project cost.

2. After the project is completed and accepted, the construction unit will pay the project settlement money to Party A, and Party A will withdraw the management fee from Party B's total project payment. ..

Form of intransitive verb progress payment: seven. Party A's responsibilities:

1. Provide construction drawings.

2. Be responsible for providing water and electricity for Party B's construction.

3. Pay the project payment on time according to the contract.

4. Coordinate the relationship between Party B and the construction unit and other construction teams.

Eight. Party B's responsibilities:

1. Party B is responsible for the installation and use of temporary water pipes and wires used in Party B's site construction. The cost of water and electricity used shall be paid by Party B. ..

2, according to the construction drawings and design specifications, to ensure the engineering quality.

3. Provide Party A with product certificate and complete project completion data.

4, according to the contract construction progress, ensure the time limit for a project.

5, after the completion of the construction into the construction maintenance, to ensure that the completion inspection and acceptance before delivery to the construction unit without engineering quality accidents.

Nine, construction safety and quality:

(1) mass: 1. Party B must set up a full-time person-in-charge for key construction procedures, and do a good job in quality self-inspection and mutual inspection; All construction machinery, materials and accessories must be inspected and inspected in detail.

2. During the whole construction process, Party B must carefully keep the construction records and diaries, and fill in various parameters in the record form, which will be a part of the necessary contents of the completion data.

3. In case of quality accident, Party B shall report it in time and work out treatment measures together with Party A and designers.

4. Party B must provide the following information at any time according to the requirements of Party A: raw material factory certificate; Sampling inspection or inspection report of raw materials; Certificate and test report of substitute materials; Inspection or calibration report of construction equipment, instruments and meters; Construction records of each process.

(2) Safety:

1, all kinds of mechanical equipment operators are not allowed to work without examination.

2, the field electrical equipment and wiring should be the responsibility of the specialist and regular inspection, wire contact with the construction scaffolding must have reliable measures to ensure that the line does not leak.

3, the site materials, machines and tools, equipment piled up, must be neat and stable, the demolition of the template, wire, tools, waste, etc. Clear it in time.

4. The storage and use of flammable, explosive and toxic substances on the construction site must comply with relevant safety regulations.

5. In the process of construction, Party B must obey the supervision, inspection and quality management of Party A. If rework is caused by quality problems, all expenses shall be borne by Party B..

6. Party B shall carefully organize during the construction to ensure safety. In case of quality safety accidents, mechanical equipment safety accidents and life safety accidents, Party B shall be responsible for all the consequences.

X. liability for breach of contract:

1. If the project quality does not meet the contract requirements, Party B shall be responsible for free repair or timely rework, and the losses caused thereby shall be borne by Party B. ..

2. Party B must ensure that the construction task is completed within the construction period. Except that the project cannot be completed on schedule due to force majeure and the construction period is delayed with the consent of Party A, Party B will be fined RMB for each day of delay.

3. If Party B fails to complete the project or meet the requirements, Party A has the right to terminate the contract and may require Party B to pay RMB liquidated damages.

XI。 Other matters:

1. All expenses for Party B's living and accommodation shall be settled by Party B itself.

2. Any dispute caused by Party B shall be borne by Party B. ..

Twelve. This contract is made in duplicate, with each party holding one copy. For matters not covered in this contract, both parties may negotiate a supplementary agreement separately. The supplementary agreement has the same effect as this contract.

Thirteen. Entry into force and termination of the contract:

This contract shall come into effect as of the date of signature and seal by both parties; After completion settlement and payment by Party A, Party B will deliver the project to Party A, and this clause will be terminated after the acceptance by the construction unit.

Employer:

Person in charge:

Name of unit (seal):

Contractor: person in charge:

Article 4 of the contract 1) The purpose of the contract is to complete certain work and sort out the legal characteristics of the contract.

In the contract, the contractor shall complete the work according to the standards and requirements agreed with the ordering party, and the main purpose of the ordering party is to obtain the work results completed by the contractor.

2) the independence of the contractor to complete the work

Generally, the ordering party concludes a contract with the contractor based on the contractor's ability and conditions. Only when the contractor completes the work by himself can the requirements of the ordering party be met.

3) the particularity of customized products

Most contracts are negotiated by individuals, and crops are often specific.

4) This contract is a commitment contract.

5) This contract is a paid contract.

I. Contents of the Contract

The main right of the contractor is the right to operate and manage according to law (that is, the right to contract management); The main obligation is to complete the contracted production and operation tasks according to the provisions of the enterprise contract.

The main right of the employer is to inspect and supervise the production and business activities of the contractor; The main obligation is to safeguard the legitimate rights and interests of the contractor according to the provisions of the contract, and to help coordinate and solve the difficulties in the production and operation of the contractor according to the scope of their joint and several responsibilities.

The signing of enterprise contracts is generally carried out through public bidding according to law. The bidder may be an individual citizen, a group or an enterprise legal person, and the winning bidder is an enterprise operator generated through competition. Model contract "Arrangement of legal characteristics of contract". On this basis, the business operator signs the business contract with the employer on behalf of the contractor in accordance with the principle of equality and voluntary consultation.

The main terms of an enterprise contract include: the form and duration of the contract, the amount of profits to be paid or losses reduced, the tasks of technological transformation and the preservation and appreciation of state-owned assets, product quality and other major economic and technical indicators, the use of retained profits, the repayment of loans, the treatment of creditor's rights and debts before the contract, the rights and obligations of both parties, the rewards and punishments for enterprise operators, and the liability for breach of contract. After the enterprise contract is concluded according to law, it has legal effect, and neither party may change or terminate it at will, except as provided by law.

The reasons why the enterprise contract can be changed or dissolved by law include:

(1) the State Council has made major adjustments to taxes, tax rates, xx and product prices;

(2) The enterprise contract cannot be performed due to force majeure or external reasons that cannot be prevented by both parties;

(3) Due to the poor management of the contractor, it is impossible to complete the contracted production and operation tasks;

(4) Due to the breach of contract by the employer, the other party to the enterprise contract fails to perform its contractual obligations as required, and shall be liable for breach of contract.

For enterprise contract disputes, the parties may apply to the administrative department for industry and commerce for arbitration or bring a lawsuit to the people's court for settlement.

Contents of the contract:

1, the names of the employer and the contractor;

2, the name, address and other information of the person in charge of the employer and the person in charge of the contractor. This is a necessary clause in the contract. If the parties cannot be clearly defined, it is impossible to determine the ownership of rights and the undertaker of obligations, and it is also difficult to resolve disputes.

3, the content of the contracted project and the specific requirements of the employer. This is also a condition that a contract must have, without which a contract cannot be established;

4. Term and start and end dates of the contract. The term of the contract is directly related to the performance time of the rights and obligations of both parties and involves the interests of the parties;

5. Rights and obligations of the owner and the contractor. Both parties agree on their respective rights and obligations without violating national laws and regulations;

6, the contractor's delayed performance responsibility. Including the delay in commencement and completion caused by the contractor;

7. The contractor failed to complete the project on time due to the delay in commencement caused by the employer's factors;

8. Acceptance methods and standards and payment methods;

9. Other contents agreed by both parties that do not violate national laws and regulations.

Article 5 of the contract Party A's unit: XXXX Co., Ltd. Party B's person in charge of the contract: XX.

Workshop area: 192m2 Production personnel: 00.

Location of contracting workshop: XX workshop on the first floor Processing type: X

The date of the contract is from year to year.

In accordance with relevant laws and regulations, both parties have reached the following terms and conditions through negotiation on the basis of legality, equality and voluntariness:

1. Party B voluntarily contracts, operates independently, is responsible for its own profits and losses, independently undertakes management affairs such as production, quality, quantity and safety, and accepts the supervision and management of Party A. All rules and regulations shall be implemented in accordance with Party A's system.

2. Party A provides for Party B; 1; Plant, equipment and supporting facilities, 2 points; Hydropower.

Three. Party B must operate in strict accordance with the specifications and be responsible for the repair, maintenance and maintenance of the plant, equipment and facilities at its own expense.

Four. When Party A's factory inspection and other activities need Party B's cooperation, Party B shall fully cooperate with Party A's arrangement.

5. Party B shall not change the performance and use of the plant, equipment and facilities. If it is really changed due to production needs, it shall be reported to Party A in writing for approval before it can be modified, but the expenses shall be borne by itself.

6. Upon the expiration of the contract, the plant, equipment and facilities must be kept in their original state, and the losses or losses shall be fully compensated by Party B according to the actual value at the time of handover. (See Annex 1 for the equipment list)

7. Party B must accept Party A's weekly equipment maintenance and safety inspection.

Eight. Party B shall strengthen employee management in accordance with Party A's labor management system and China's Labor Contract Law. In addition, all accidents such as work-related injuries of Party B's workers shall be solved by Party B itself, which has nothing to do with Party A. ..

Nine. Party B shall bear all expenses required for the labor protection of employees.

X. Party B may recruit or dismiss employees on its own according to the production situation, and shall file with Party A for the record and go through relevant procedures. When recruiting employees, Party B must do a good job in factory registration and relevant knowledge training, but shall not employ employees from other departments or workshops of Party A or employees dismissed or handled by Party A. The recruitment of old employees must be approved by Party A. The dismissal of employees must be implemented in accordance with Party A's labor management system and fault (negligence) accountability system to avoid labor disputes.

Eleven, employees must abide by the factory rules, law-abiding, saving water and electricity, unity and friendship, love each other's good fashion, proficient in technology, technology, to achieve quality and quantity to complete the task, to contribute to the factory and society.

12. If any employee of Party B violates the regulations and laws of the factory, Party A can immediately expel him from the factory and send him to the administrative department for handling.

Thirteen, in the normal production of the factory, if there is any dispute or illegal behavior between Party A and Party B, both parties should coordinate to solve it. If it cannot be solved, it shall be submitted to the administrative department for solution.

14. In the production process, Party B must cooperate with the production progress made by Party A, deliver the goods on time, and never pick orders without authorization. If the goods cannot be delivered in time, Party B shall be responsible for the losses caused.

15. In the production process, if the views of Party A and Party B are inconsistent or thoughtless, both parties can settle them through consultation, and the imperfections can be solved by referring to the effective labor contract law.

16. This contract shall come into effect as of the date of signature by both parties.

Person in charge of Party A (signature):

Person in charge of Party B (signature):

Date of signing: * * Year Month Day Restaurant Contract Hotel Contract Cleaning Contract